Loading...
HomeMy Public PortalAboutAgreement_2013-08-08_Alliance Environmental Group, Inc_City Clerk Officewy.:... �l k978 West Tenth Street, Azusar CA 91702rr Fx: 626-633-3599 D• 0 Pro ject: City of Temple City File Cabinet Removal Customer © F1 "Property" Address: 9701 Las Tunas Drive City: Temple City State: ca Zip:91780 Contact: Mark Persico Work No.: 6262852171x2306 Mobile No.: Home No.: Claim Number: Scheduled Start Date: Scheduled Completion Date: Proposal/Contract www.alliance-enviro. com info@alliance-enviro.com City of Temple City Address: 9701 Las Tunas Drive City: Temple City State:ca Zip: 91780 Contact: Mark Persico Phone No.: 6262852171x2306 Fax No.: Total Bid Amount: $1,150.00 Deposit: $0.00 Balance Due on Completion: $1,150.00 ' SCOPE OF WORK (Description of Project, Materials to be Used; and/or Equipment to be Installed) 1. Notify required local regulatory agency prior to jab start if applicable. 2. Isolate work areas. 3. Set up the shower decontamination system adjacent to work area(s). 4. Run negative air filtration during the abatement and monitor air in the work area(s). 5. Scope of Work Wrap, remove, transport, and dispose of 7 file cabinets. Please Note: City of Temple City may coordinate 3rd party consultant monitoring or clearance testing activities. By signing this contract, City of Temple city releases AEG of any liability of elected non clearance monitoring ortesting activty. 6. Transport, manifest and dispose of waste at an EPA landfill. 7. Remove containment and equipment upon final inspection and/or clearance. In the event that an insurance company issues a check to the owner for payment for services performed by Alliance, please endorse the check and forward it to Alliance upon the completion of the job. DEPOSIT may not exceed $1,000 or 10 percent of Contract Amount, whichever is less. Customer shall pay Alliance the Deposit prior to Alliance scheduling work. In the event of failure to pay any of the amount due in this invoice, all collection costs and/or attorney fees in the collection of any such amount will be paid by the Customer. Interest at the rate of 1.5% per month, or the maximum rate allowed by law whichever is less, will be charged on accounts past due more than 30 days. In the event of failure to pay any of the amount due, all collection costs and/or attorney fees in the collection of any such amount will be paid by the Customer. In the event that an insurance company issues a check to the owner for payment for services performed by Alliance, please endorse the check and forward it to Alliance upon the completion of the job. and all hazardous waste fees are to be paid by the Customer acknowledges and authorizes Alliance to sign the :rator, not Alliance Environmental Group, Inc. This is Hazardous Waste Manifest "on behalf of" the generator. rding but not limited to ALL generator fees from the Board of Equalization and Department of Toxic Custome'P"Initi dance Cnnfrol The State Board of Equalization will assess a fee for each generator that produces five tons or more of hazardous waste. This assessed fee is not included in this contract amount. Please be aware that if you generate more than five tons of hazardous waste, the BOB will bill you the required fee. Current fees areas follows: Generator Size: Fee: Less than 5 tons/year $0.00 5 but less than 25 tons/year $199.00 25 but less than 50 tons/year $11594.00 50 but less than 250 tons/year $3,986.00 Please Initria�5" Page 1 of 5 Contact your AEG Project Manager/Estimator (Jay Bradshaw) for assistance in approximating your Generator Fee. Notice: Recent lead laws require that any pre 1978 structure where lead paint will be disturbed must have the paint tested or it will be presumed positive. Alliance Environmental Group, Inc. strongly recommends that these painted surfaces be tested for lead content prior to performing work. If Alliance Environmental Group, Inc. has not been provided lead testing results, it will be assumed that all surfaces contain lead. Alliance Environmental Group, Inc. will profile and characterize these materials for the proper handling and disposal. Pending results of the lead profile characterization, additional disposal cost may be charged at a price to be determined by Alliance Environmental Group, Inc. Ir s CONTRACT Alliance Environmental Group, Inc. (hereinafter referred to as "Alliance"), and the undersigned homeowner or tenant (hereinafter referred to as "Customer") agree as follows: The previous page and above portion of this page are incorporated herein as part of the Contract between the parties. 1. SCOPE OF WORK: In consideration of the payment specified above, Alliance is hereby authorized to furnish all labor, materials, and equipment necessary to perform removal and disposal of asbestos, lead, mold, and/or other materials and/or to perform hazardous remediation of hazardous materials, all as specified in the above agreed Scope of Work, in material compliance with applicable laws and regulations. Alliance agrees to use reasonable best efforts to complete the Scope of Work. However, Customer acknowledges and agrees that this Agreement is for Alliance's effort and not for any particular results. ALLIANCE MAKES NO REPRESENTATION OR WARRANTY THAT THE WORK DESCRIBED IN THE SCOPE OF WORK WILL RESULT IN THE ELIMINATION OF ASBESTOS, LEAD, MOLD, AND/OR OTHER HAZARDOUS MATERIALS CONTAMINATION ("HAZARDS CONTAMINATION") FROM THE AREAS DESCRIBED IN THE SCOPE OF WORK OR THAT SUCH HAZARDS CONTAMINATION WILL NOT REAPPEAR IN SUCH AREAS OR OTHER AREAS OF THE PROPERTY. ALLIANCE MAKES NO REPRESENTATION OR WARRANTY REGARDING HAZARDS CONTAMINATION IN AREAS, INCLUDING ADJOINING AREAS, NOT SPECIFIED IN THE SCOPE OF WORK, NOR THAT SUCH HAZARDS CONTAMINATION WILL NOT MIGRATE TO AREAS DESCRIBED IN THE SCOPE OF WORK FOLLOWING COMPLETION OF OR DURING THE SCOPE OF WORK. Without limiting the foregoing, Customer specifically waives and releases Alliance from any claim for damages (a) arising out of connected with or related to Hazards Contamination, (b) on account of work recommended by Alliance but not accepted by Customer or Insurer, and (c) for any consequential, incidental or punitive damages, or for loss of us, property or profits of whatever kind arising out of or in connection with performance of Scope of Work. 2. START DATE AND COMPLETION DATE: California Law requires that Contractor start this project within (20) days of execution of this Contract subject to Alliance's ability to obtain permits and Customer's ability to obtain financing if Customer is buying the property in question, subject to delay caused by any processing and obtaining permits may required which may extend Start Date and correspondingly delay the Completion Date. 3. EXCLUSIONS: Any work that is not specifically included in Scope of Work shall not be any part of this Contract. Removal of inaccessible asbestos, mold, or lead -containing materials is not covered in the Contract amount and additional charges will apply if materials must be removed to uncover same. Doors, lights, ceiling fans, curtains and other items may need to be removed by Alliance to perform work and Alliance does NOT rebuild or reinstall these items. Plumbing supply lines may be faulty and may need to be replaced. This cost is not covered in the Contract Amount. Contents and appliances need to be removed from work area prior to abatement. Additional costs will be applied if contents need to be removed, unless otherwise stated in the Scope of Work. Unless otherwise stated in the Scope of Work, the cost of third party clearance testing is not part of the Contract Amount. 4. DAMAGE: Incidental damage to doors, door casings, windows, window sills, baseboards, walls, wallpaper, wood, paneling, painted surfaces, and to contents or Customer personal items left in work area may occur as a result of work performed, including but not limited to taping plastic barriers to walls and other surfaces. Every reasonable attempt will be made to minimize such occurrences. Alliance shall not pay/reimburse for, nor does it do any, repairs, repainting, rebuilding or replacement of such "incidental damages, and such is not included in the Scope of Work. Due to odors caused by chemicals used for mastic removal, the work areas will be razor scraped to remove the majority of mastic but residual mastic may be left after scraping and will be sealed with an E.P.A. approved encapsulant. 5. SITE ACCESS: Customer agrees to ensure that prior to any work undertaken by Alliance, the site of the work, the area from which the work is controlled, and any storage area used by Alliance in connection with the work (collectively referred to hereinafter as the "Site"), shall be vacated and remain closed to all persons (other than ALLIANCE employees) for the duration of the project. In the event that any individual other than ALLIANCE employees enters the Site, Customer agrees that ALLIANCE shall not be held liable for any claims, including, without limitation, any claims relative to asbestos, lead, mold and/or hazardous remediation exposure arising there from, and including, without limitation, any claims of negligence by ALLIANCE; and that Customer will indemnify and hold harmless ALLIANCE from all such claims, including costs of defense. 6. DIFFERING SITE CONDITIONS: If ALLIANCE encounters subsurface, latent, unusual or unknown physical conditions in the work area differing materially from those indicated in its initial inspection or the Scope of Work, ALLIANCE will promptly notify Customer or Insurer. If such conditions cause an increase in the cost of, or the time required for, performance of the Scope of Work, appropriate equitable adjustments in Scope of Work, price and completion date shall be made. 7. EXTRA WORK AND CHANGE ORDERS: Customer and Alliance, or Insurer (defined below) and Alliance, may change the Scope of Work at any time and from time to time, including changes in scope, methods, scheduling or performance requirement, but no such change shall be effective unless and until an agreed written Change Order is made and executed, including appropriate adjustments to the overll_-----p Please Initial l ai S �ge2of5 price and completion date of the Scope of Work. Subject to the following, if Alliance undertakes additional or different work notwithstanding the absence of a Change Order, it will not operate as a waiver of this provision, and Alliance will nevertheless be entitled to appropriate equitable adjustments to the price and completion date terms of the Scope of Work. All phone quotes are subject to field verification. Extra work and Change Orders become part of the Contract once the order is prepared in writing and signed by the parties. The Change Order must describe the scope of the extra or change, the cost to be added or subtracted from the contract, and the effect the order will have on the schedule of progress payments, if any. Change Orders required by the building department at the jobsite shall be considered incorporated into the contract without being signed by both parties. 8. ELIMINATION OF CONDITIONS: Customer acknowledges that it, and not Alliance, is responsible for the elimination of any and all conditions from the Property that may cause or contribute to re -contamination by Mold or other Irritants, including but not limited to standing water, faulty plumbing, leaks, dampness from condensation, damaged woad, roof leaks, direct wood to soil contact, improperly protected exterior wood surfaces, landscaping above foundation grade line, and improperly installed irrigation. 9. UTILITIES; STORAGE: Customer agrees to provide to Alliance, free of charge, reasonable use of electrical power, light, water, and storage space necessary for the proper undertaking and completion of the Services at the Property. 10. FORCE MAJEURE: Alliance shall not be deemed to default nor be liable for damages for any failure or delay in performance of its work which arise out of causes beyond its reasonable control. Such causes may include, without limitation, acts of God, acts of terrorists or terrorist organizations, the public enemy, acts of government in either its sovereign or contractual capacity, fres, floods, earthquakes, epidemics, quarantine restrictions, strikes, freight embargoes, material shortages, or unusual severe weather. In the event work by Alliance Is delayed by such causes, the completion date will be extended accordingly. 11. MECHANICS LIEN WARNING: Anyone who helps improve your property, but who is not paid, may record what is called a mechanics' lien on your property. A mechanics' lien is a claim, like a mortgage or home equity loan, made against your property and recorded with the county recorder. Even if you pay youi cuntiactui in full, unpaid butmunhautum, supplims, and labomm v d to improve your pnope ty may record mechanics' liens and sue you in court to foreclose the lien. If a court finds the lien is valid, you could be forced to pay twice or have a court officer sell your home to pay the lien. Liens can also affect your credit. To preserve their right to record a lien, each subcontractor and material supplier must provide you with a document called a "20 -day Preliminary Notice." This notice is not a lien. The purpose of the notice is to let you know what the person who sends you the notice has the right to record a lien on your property if he or she is not paid. BE CAREFUL, The Preliminary Notice can be sent up to 20 days after the subcontractor starts work or the supplier provides material. This can be a big problem if you pay your contractor before you have received the Preliminary Notices. You will not get Preliminary Notices from your prime contractor or from laborers who work on your project. The law assumes that you already know they are improving your property. PROTECT YOURSELF FROM LIENS. You can protect yourself from liens by getting a list from your contractor of all the subcontractors and material suppliers that work on your project. Find out from your contractor when these subcontractors started work and when these suppliers delivered goods or materials. Then wait 20 days, paying attention to the Preliminary Notices you receive. PAY WITH JOINT CHECKS. One way to protect yourself is to pay with a joint check. When your contractor tells you it is time to pay for the work of a subcontractor or supplier who has provided you with a Preliminary Notice, write a joint check payable to both the contractor and the subcontractor or material supplier. For other ways to prevent liens, visit CSLB's website at www.cslb.ca.gov <httn://www.cslb.ca.gov> or call CSLB at 1-800-321-CSLB (2752). Remember, if you do nothing, you risk having a lien placed on your home. This can mean that you may have to pay twice, or face the forced sale of your home to pay what you owe. 12. COMMERCIAL GENERAL LIABILITY INSURANCE (CGL): Alliance carries CGL insurance written by Commerce & Industry Ins. Co. You may call the insurance company at (949)851-8800 to check Alliance's coverage. 13. WORKERS' COMPENSATION INSURANCE: Alliance carries workers' compensation insurance for employees. 14. INFORMATION ABOUT CONTRACTORS STATE LICENSE BOARD (CSLB): See Attached Notice . 15. INSURANCE TRANSACTION AND INSURANCE AUTHORIZATION TO RELEASE FUNDS: When Contract for Scope of Work is between Alliance and Customer's insurance company ("Insurer"), Customer shall nevertheless be jointly and severally liable with Insurer to pay Alliance all amounts due to Alliance. Customers signature on this Contract grants Alliance the Customer's power of attorney to sign/endorse Insurer checks and/or drafts payable to the Customer, including as result of Customer's claim to Insurer for property damages, concerning or intended to be in payment for Alliance's work. Customer agrees checks from Insurer will be sent directly to Alliance. Please lndiaV Page 3 of 5 Customer authorizes payment for the services rendered to be paid directly to Alliance from Insurer or its authorized agent. If the Scope of Work is not a covered loss, Customer acknowledges that payment in full will be made upon completion of work. Mark Persico Name of Insured (please print) 9701 Las Tunas Drive Address Claim Number: na Claim Number Home Number City/State/Zip Code Work/Cell Number 'YOU, THE CUSTOMER, ARE ENTITLED TO A COMPLETELY FILLED IN COPY OF THIS CONTRACT, SIGNED BY BOTH YOU AND ALLIANCE, BEFORE ANY WORK MAY BE STARTED, YOU, THE CUSTOMER, MAY CANCEL THIS TRANSACTION AT ANY TIME PRIOR TO THE THIRD BUSINESS DAY AFTER THE DATE OF THIS TRANSACTION, SEE ATTACHED NOTICE OF CANCELLATION FORM FOR EXPLANATION OF THIS RIGHT. Customer signature below is acknowledgement that Customer has received THREE-DAY RIGHT TO CANCEL form. THIS CONTRACT WILL NOT BECOME BINDING ON THE PARTIES UNTIL ACCEPTED BY AN AUTHORIZED REPRESENTATIVE Dated: USTOMER: I (Signature) u ALLIANCE ENVIRONMENTAL GROUP, INC.: BY: Corporate Office: 990 W Tenth Street Azusa CA 91702 Los Angeles: 978 W. Tenth Street, Azusa, CA 91702 Orange County: 760 E. Debra Lane, Anaheim, CA 92805 San Diego: 8390 Juniper Creek Lane, San Diego, CA 92126 Ventura/Santa Barbara: 680 Flinn Avenue, Unit 32 Moorpark, CA 93021 Bay Area: 3545 Victor Street, Santa Clara CA 95054 Monterey/Santa Cruz: 161 St. Andrews Drive, Aptos, CA 95003 (Signature) Ph. 626.633.3500 Fax: 626.633.3599 Ph. 626.633.3500 Fax: 626.969.2793 Ph. 714.507.4080 Fax: 714.817.9379 Ph. 619.229.6135 Fax: 619.229.6143 Ph. 805.378.6590 Fax: 805.378.6594 Ph. 408.830.9700 Fax: 408.980.9746 Ph. 831.661.0329 Fax: 267.613.0329 Please In' i Page 4 of 5 NOTICE OF RIGHT TO CANCEL �y 3 Project: City of Temple City File Cabinet Removal Enter Date of Transaction: 4 You, the Buyer, have the right to cancel this contract within three (3) business days. You may cancel by e -mailing, mailing, faxing, or delivering a written notice to the contractor at the contractors place of business by midnight of the third business day after you received a signed and dated copy of the contract that includes this notice. Include your name, your address, and the date you received the signed copy of the contract and this notice. If you cancel, the contractor must return to you anything paid within 10 days of receiving the notice of cancellation For your part, you must make available to the contractor at your residence, in substantially as good condition as you received it, any goods delivered to you under the contract or sale. Or, you may, if you wish, comply with the contractor's instructions on how to return the goods at the contractor's expense and risk. If you do make the goods available to the contractor and the contractor does not pick them up within 20 days of the date of your notice and cancellation, you may keep them without any further obligation. If you fail to make the goods available to the contractor, or if you agree to return the goods to the contractor and fail to do so, then you remain liable for performance of all obligations under the contract. To cancel this transaction, mail or deliver a signed and dated copy of this cancellation notice, or any other written notice, or send a fax, to Alliance, 990 W. Tenth Street, Azusa, California 91702, fax 626-633-3599 or e-mail to info@alliance-enviro.com, not later than midnight, It ii s� cl&y� ft ut i t Oclaq. IfYou do decide to cancel via a mail, please 2dd'CA NCF1 I ATION' fn fhp.�i h1cwt line I herby cancel this transaction. (Date). NOTICE OF INFORMATION ABOUT CONTRACTORS STATE LICENSE BOARD CSLB is the state consumer protection agency that licenses and regulates construction contractors. You may contact CSLB for information about the licensed contractor you are considering, including information about disclosable complaints, disciplinary actions and civil judgments that are reported to CSLB. Use only licensed contractors. If you file a complaint against a licensed contractor within the legal deadline (usually four years), CSLB has authority to investigate the complaint. If you use an unlicensed contractor, CSLB may not be able to help you resolve your complaint. Your only remedy may be in civil court, and you may be liable for damages arising out of any injuries to the unlicensed contractor or the unlicensed contractor's employees. For more information: VISIT: CSLB's website at www.cslb.ca.gov. CALL: CSLB at 1-800-3321-CSLB (2752). WRITE: CSLB at P.O. Box 26000, Sacramento, CA 95826. Page 5 of 5 Content release Form I, hereby authorize Alliance Environmental Group, Inc. to remove and dispose of personal property (including, but not limited to, contents paperwork, files, etc) from the affected areas with the understanding that Alliance Environmental Group, Inc. is not responsible for loss or damage to said personal property. T,isal It is also agreed that all personal property not to be moved or discarded by Alliance Environmental Group, Inc. It is to be removed by 0\/Vllcf/ LCHUHUC.011tractor prior to decontamination, and cartage, uiival If owner elects to leave personal property on premises it is done with the understanding that Alliance Environmental Group, Inc. is not responsible for loss, disposal, or damage to said personal property. Intim If AEG is to clean and return items, although state of the art methods will be utilized to clean items, AEG assumes no liability associated with potential ASB contamination that may still exist on such items. 111iaal A signature below indicates a clear understanding of the above and below statements. Please write io you own handwrifing the following statement "I understand that Alliance Environmental Groin is not responsible for contents damage or missing items as stated above." Signature: PTmt Tenant or Owner of said Property (Carole one) Please print or lupe. (Form designed for use on elite`T12-Pitch) typewriter.) Form Approved. OMB No. - EPA Form 8700-22 (Rev. 3-05) Previous editions are obsolete. DESIGNATED FACILITY TO DESTINATION UNIFORM HAZARDOUS 1. Generator ID NtherC002725425 A z. P�ge 1 of 3. �rAp,[ppgcy�spopgePhAne 4. Manifest �6W11 ff--tt55::##OO Tracking Number 22 4 2 3 WASTE MANIFEST .'.TILL ..'TILL JJK 5. Generptp s Na nd Mail' ss Ge tar's comes if di�y[Ent� ddres LI'�F empie y try o�"5,, I t;Ily P'llea�e(ilne Removal 9701 Las Tunas Drive, Temple City, CA 91780 9701 Las Tunas Drive Generator's Phone: Mark Persioo (626) 2285=2171 ex. 2306 Temple City, CA 91780 6. Trans oder 1 Company Name U.S. Epy I�f�uLn¢e� 60111 CA U(Jf} ,�IlianceEnvironmental Group 7. Tranffec2 Company Name U.S.E®l0. 9064 S. Designated Facility Name and Site Address U.S. EPA ID Number La Paz County Landfill, 26999 Highway 95, Mile Post 128, Parker, AZ 85344 AZC950823111 (928) 669-2559 Facility's Phone: ga 9b. U.S. DOT Description (including Proper Shipping Name, Hazard Class, ID Number, 10. Containers 11. Total 12. Unit 13. Waste Codes HM and Packing Group (if any)) No. Type Quantity wt./Vol. 1. 151 p RQ NA2212, ASBESTOS, 9, PGIII BA Y Z 2. w 3. 1 i 4. 14. Special Handling Instructions and Additional Information T1: 990W 10th Street, Azusa CA 91702 - (626)-633-3500 SCAQMD, 21865 Copley Drive, Diamond Bar, CA 91765 - (909) 396-2000 T2:953 Reece Street, San Bemadmo, CA 92411 - (909) 884-7424 - Profile No, 5124Y96316 Friable asbestos containing waste- Asbestos removal RegA0CFR&1 (bagged, sealed and labeled),. ERG#171/A -2 -- (� 1 1 ^7 15. GENERATOR'SIOFFEROR'S CERTIFICATION: I hereby declare that the contents of this consignment are fully and accurately described above by the proper shipping name, and are classified, packaged, marked and labeled/placarded, and are in all respects in proper condition for transport according to applicable international and national governmental regulations. If export shipment and I am the Primary Exporter, I certify that the contents of this consignment conform to the terms of the attached EPAAcknowledgment of Consent. I certify that the waste minimization statemen irdifel in 40 CFR 262.27(a) (if I am a tape quai generator) or (b) Of a smaj quantity generator) is tru Generator'slOReror's P'teTllTyped Name /i✓� 5 Signature z'✓C �- Month Day Year ✓ / C� z e2 ( 1 ( F 16. International Shipme is ❑Impor U.S. ❑ Export from U.S. Pod of entrylexit: Transporter signature (for exports only): Date leaving U.S.: wIT Transporter Acknowledgment of Receipt of Materials Transporter I ed/T ped Name Signature Mo Day Year 0 - ✓' Z \� Z Transporter 2 PrimedlTyped Name SignatureMonth Day Year � C �r �r� �- / Z6 113 18. Discrepancy 18a. Discrepancy Indication Space ❑ Quantity ❑Type ❑ 1 ❑ jec ion ❑ Residue Partial Rejection Full Re t e Manifest Reference Number: 18b.Alternate Facility(or Generator) U.S. EPA ID Number J U u Facility's Phone: 1So. Signature ofAltemate Facility(or Generator) Month Day Year d Z y19. Hazardous Waste Report Management Method Codes (i.e., codes for hazardous waste treatment, disposal, and recycling systems) 1. 2. 3. 4. 20. Desg afed acily Owner or Operator: Cedlfcation of receipt of hazardous materials covered by the manifest except as noted in item 18a Phrited(Typed Name Signature STATE (IF REC7lJiFiE®) LA Testing Cu Testing Order: 32ANDE84 520 Mission Street, South Pasadena, CA 91030 CUstomerP 32ANDE85 Phone/Fax: (323) 254-9960 / (323) 254-9982 CustomerPO: TESTINGhtto://�.latestina.com nasadenalaMblatestino.com ProjectlD: Attn: Cheryl Stewart Phone: (310) 854-6300 Andersen Environmental Fax: 5261 West Imperial Highway Received: 03/22/132:40 PM Los Angeles, CA 90045 Analysis Date: 3/25/2013 Collected: 3/22/2013 Project: 7303-464 Temple City -City Clerk's Office Test Report: Asbestos Analysis via Transmission Electron Microscopy ASTM Method D5755-03 AREA SAMPLED ASBESTOS ASBESTOS Sensitivity CONCENTRATION SAMPLE ID (cm2) TYPE STRUCTURES (str/cm') (sir/cm') COMMENTS 032213-01 MV- 100 None Detected <3 807 <2420 CS 321305104-0001 - NoneDetected <3 6ut <242U CS 321305104-0002 032213-03MV- 100 None Detected <3 807 <2420 CS 321305104-0003 032213-04MV- 100 None Detected <3 807 <2420 CS 3213051010004 032213-05MV- 100 None Detected <3 807 <2420 CS 3213051040005 032213-06MV- 100 None Detected <3 807 <2420 CS 3213051010006 032213-07MV- 100 None Detected <3 807 <2420 CS 321305104-0007 032213-08MV- 100 None Detected <3 807 <2420 CS 321305104-0608 Analysts) Sherrie Ahmad (i0) Jerry Drapala Ph.D. Laboratory Manager or other approved signatory The above report relates only to the Items tested. This report may not be reproduced, emept in full, without written approval by EMSL Analytical, Inc. Samples received In good condition unless otherwise notetl. Samples analyzed by LA Testing South Paszdena, CA Initial report from 03/25/2013 12:55:00 Test ReportTEMMicro-7.21.0 Printed: 3/25/2013 12:55:00 PM ��LA Testing 520 Mission Street; South Pasadena, CA 911730 Phone/Fax (323) 254-9960 / (323) 254-9982 YESTINrzhfto//www.latesfna.com oasadenalabOdatesOrw.com Attn: Cheryl Stewart Phone: (310)854-6300 Andersen Environmental Fax 5261 West Imperial Highway Received: 03/22/13 2:40 PM Los Angeles, CA 90045 Analysis Date: 3/25/2013 Collected: 3/22/2013 Project: 1303-464 Temple City -City Clerk's Office LA Testing Order: 321305104 CustomerlD: 32ANDE85 CUstomerPO: ProjectlD: Test Report: Asbestos Analysis via Transmission Electron Microscopy ASTM Method D5755-03 - - None Detected <3 CS 3213051010010 Analysts) Sherrie Ahmad (10) Jerry Drapala Ph.D, Laboratory Manager or other approved signatory The above report relates only to the items l sietl. This report m ay not be reproduceq except in full, without written approval by EMSL Analytical, Inc. samples received in good conditlpn s othelv'ise noted Samples analyzetl by LA Testlng South Pasadena, CA Initial report from 03/25/2013 12:55:00 Test ReportTEMMicre-721.0 Printed: 3/25/2013 12:55:00 PM THIS 1S THE LAST PAGE OF THE REPORT AREA SAMPLED ASBESTOS ASBESTOS Sensitivity CONCENTRATION SAMPLE ID (cm') TYPE STRUCTURES (str/Chi (str/cmc) COMMENTS 032213-09MV- 100 None Detected <3 807 <2420 CS 321305704-0009 - - None Detected <3 CS 3213051010010 Analysts) Sherrie Ahmad (10) Jerry Drapala Ph.D, Laboratory Manager or other approved signatory The above report relates only to the items l sietl. This report m ay not be reproduceq except in full, without written approval by EMSL Analytical, Inc. samples received in good conditlpn s othelv'ise noted Samples analyzetl by LA Testlng South Pasadena, CA Initial report from 03/25/2013 12:55:00 Test ReportTEMMicre-721.0 Printed: 3/25/2013 12:55:00 PM THIS 1S THE LAST PAGE OF THE REPORT 1 'L,'_ANDERSEN NVII20NMENTAL www.AndersenEnviro.Com (888)705-6300 JOBNAME: �Tern��le Ccl-� - C;dv C%r1�`�, Ci 6F:c JOB NUMBER: �4'vO"�J- �-II¢LI J1 CREATED BV; C��1 SiCWG.c'r DATE: 31aa"I ciCA'J SHEET NO.: 1 OF: L'-tcct�n�1 �lrx'ir Cot,�ot-.� ,.,. _,. _ , ,.��,.._. i Meng' _.:_ lNome�i� ��?slYctim j?��bly c%rTn`� ' � � i _. ' (-�c�tn�� C4ecks (��et j �_ .., ' _.. � p EF;ce ', Ulcl ode r_ab;�e�s .t�t�l� �F}re- � oCf �.e �. �rooi-�nc� ,nbc�la�-1`ocl whe.CC locukee� 1�e�e... ,LII ,\n. �f� - - � �� � � - Seec�l�' �� Si Sec�eiun,` - is _ ,. -- _ _ , � � O, _ i �, ' Gly j C.�� -UerY,'s ('1�?3C3 �T4Fl -�-� ice nti�.nn5e,- laxly _- . _; 0���►3�eln�-is l --- 1 _. �i:�a�\3-c'anw-rte. -;_le 'S1�,Se d 3 V3a1\9'i'+s rnU-es � � oc3tr � 4 ae-f;�� 1\ x`11 073av3 -i7vmV -�� 33a\� mak' ..�zCCCifir(� 3 : C44�rel.'� G�COA 13 1�;. 'F�i}. _ . _-__i :.S •IeS �rtrM 011\ hub\��.�5 t ' �� _ - 'GcC ick C1EW C[b��e%S ile[t-. I '� - _ .SOrc\e W,11•i2 - L45i 11`e Std UC L`�ge.vQ-� � I IV 11eS • Cot,�ot-.� ,.,. _,. _ , ,.��,.._. l ANDERSEN _ NVIRONMENTAL www.AndersenEnviro.Com (888)705-6300 JOB NAME: JOB NUMBER: � 2J 2z3- Ui QtA OgEATEO BY:_ �DATE: la -3"L 3G�,3 SHEET NO.: a OF: (�o sem end'