HomeMy Public PortalAboutMathews Consulting Agmt 09-2016 (Merger w/Baxter & Woodman, Inc.MATHEWS
CONSULTING
{{{U������-�L''''''��TING
(%
a BAXTEx1yw000MAN company
August 2, 2016
Mr. William Thrasher, Town Manager
TOWN OF GULF STREAM
100 Sea Road
Gulf Stream, Florida 33483
Dear Mr. Thrasher.
Town of Gulf Stream
Szeneral E aineerina-Senku
Mathews Consulting, Inc. is pleased to announce the acquisition and mergerof our fine with Baxter & Woodman, Inc.
As Mathews Consulting, a Baxter & Woodman Company, we will continue to provide exceptional engineering
services to the Town as follows:
• Plan Review- to ensure compliance with the Town's ordinance requiring onsite retention of stormwater.
• Drainage Issues - evaluation of any flooding problems within the Town and recommendation of solutions.
• Water Distribution and Sanitary Sewers - design and/or reconstruction/rehabilitation services for issues
relative to the Town's water distribution and sanitary sewer system.
• Environmental Permitting/Regulatory Compliance - permitting services for new projects and the update
of existing permits as needed in accordance with permitting rules of the Florida Department of
Environmental Protection, Palm Beach County Health Department, South Florida Water Management
District, and the United Stales Environmental Protection Agency.
• Construction Management- provide shop drawing review and approval, cost estimating, project
scheduling, bidding procurement, value engineering, contract clarification, construction inspection, job site
meetings, change order negotiation, equipment testing/startup, and certification of construction.
• General Consulting- available to answer questions or review correspondence, ordinances and regulations
on an as needed basis.
We will also be able to provide the following specialty disciplines on an as -needed basis by our new in-house staff:
• Surveying
• Electrical Engineering
• Structural Engineering
• GIS
• Instrumentation & Controls
477 S Rosemary Ave. Suite 330, West Palm Beach, FL 33401 • 561.655.6175
MATHEWS
CONSULTING
a BAXTER&WOODMAN company
We are available to provide the above services on an hourly fee basis in accordance with the attached fee schedule
or on a negotiated lump sum fee basis.
Our primary goal is to provide the Town of Gulf Stream with accurate and responsive engineering services to ensure
the success of your projects. We look forward to a continued working relationship with the Town on many important
and challenging projects.
Sincerely,
BAXTE & WOODMAN, INC.
R e .. Mathews, P.E.
Vice President
ACCEPTED BY:
FOR: TOW"d STR
DATE: 7'/3-/�
Notwithstanding the above, nothing in this agreement shall preclude the Town of Gulf Stream from issuing Requests
for proposals or otherwise soliciting or contracting engineering services form other providers on an as needed basis.
Either party may terminate this agreement in its sole discretion by providing the other party thirty (30) days written
notice prior
to the effective date.
for Baxter 8 Woodman, Inc.
Initial for the Town of Gulf Stream
A copy of Section 119.0701, Florida Statutes, has been provided to contractor.
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA
STATUTES, TO THE CONTRACTOR"S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT,
CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT 561-276-5116, RTAYLOR@GULF—STREAN.ORG;
TOWN OF GULF STREAM, TOWN CLERK, 100 SEA ROAD, GULF STREAM, FLORIDA 33483.
Initial for BAxter & Woodman, Inc.
Initial for the Town of Gulf Stream
477 S. Rosemary Ave. Suite 330, West Palm Beach, FL 33401 • 561.655.6175
MATHEWS
CONSULTING
a SA%TER&WOODMAN company
2016 Billable Rate Schedule
Classification
Hourly Rate
Principal Engineer
$165.00/hr
Senior Engineer— Level 11
$150.00/hr
Engineer— LevelI
$112.00/hr
Senior Construction Inspector(RPR)
$110.00/hr
Construction Inspector
$90.00/hr
Sr. Engineering Technician
$110.00/hr
CADD Designer
$95.00/hr
Clerical
$68.00/hr
♦ Reimbursable Expenses — billed at direct costs
♦ SubconsultantCosts— billed with 10% markup
477 5 Rosemary Ave Suite 330. West Palm Beach. FL 33401 • 561.655.6175
Statutes & Constitution :View Statutes : Online Sunshine Page 1 of 2
Select Year: 2016 v Go
The 2016 Florida Statutes
Title X Chapter 119 View Entire Chapter
PUBLIC OFFICERS, EMPLOYEES, AND RECORDS PUBLIC RECORDS
119.0701 Contracts; public records; request for contractor records; civil action.—
(1) DEFINITIONS.—For purposes of this section, the term:
(a) "Contractor" means an individual, partnership, corporation, or business entity that enters into a
contract for services with a public agency and is acting on behalf of the public agency as provided under
s. 119.011(2).
(b) "Public agency" means a state, county, district, authority, or municipal officer, or department,
division, board, bureau, commission, or other separate unit of government created or established by
law.
(2) CONTRACT REQUIREMENTS.—In addition to other contract requirements provided by law, each
public agency contract for services entered into or amended on or after July 1, 2016, must include:
(a) The following statement, in substantially the following form, identifying the contact information
of the public agency's custodian of public records in at least 14 -point boldfaced type:
IF THE CONTRACTOR HAS QUESTIONS REGARDING THE APPLICATION OF CHAPTER 119, FLORIDA
STATUTES, TO THE CONTRACTOR'S DUTY TO PROVIDE PUBLIC RECORDS RELATING TO THIS CONTRACT,
CONTACT THE CUSTODIAN OF PUBLIC RECORDS AT (telephone number, e•mafl address, and mailing address) .
(b) A provision that requires the contractor to comply with public records laws, specifically to:
1. Keep and maintain public records required by the public agency to perform the service.
2. Upon request from the public agency's custodian of public records, provide the public agency
with a copy of the requested records or allow the records to be inspected or copied within a reasonable
time at a cost that does not exceed the cost provided in this chapter or as otherwise provided by law.
3. Ensure that public records that are exempt or confidential and exempt from public records
disclosure requirements are not disclosed except as authorized by law for the duration of the contract
term and following completion of the contract if the contractor does not transfer the records to the
public agency.
4. Upon completion of the contract, transfer, at no cost, to the public agency all public records in
possession of the contractor or keep and maintain public records required by the public agency to
perform the service. If the contractor transfers all public records to the public agency upon completion
of the contract, the contractor shall destroy any duplicate public records that are exempt or
confidential and exempt from public records disclosure requirements. If the contractor keeps and
maintains public records upon completion of the contract, the contractor shall meet all applicable
requirements for retaining public records. All records stored electronically must be provided to the
public agency, upon request from the public agency's custodian of public records, in a format that is
compatible with the information technology systems of the public agency.
http://www.leg.state.fl.us/Statutes/index.cf n?App mode=Displa... 9/13/2016
statutes & Constitution :View Statutes : Online Sunshine Page 2 of 2
(3) REQUEST FOR RECORDS; NONCOMPLIANCE.—
(a) A request to inspect or copy public records relating to a public agency's contract for services
must be made directly to the public agency. If the public agency does not possess the requested
records, the public agency shall immediately notify the contractor of the request, and the contractor
must provide the records to the public agency or allow the records to be inspected or copied within a
reasonable time.
(b) If a contractor does not comply with the public agency's request for records, the public agency
shall enforce the contract provisions in accordance with the contract.
(c) A contractor who fails to provide the public records to the public agency within a reasonable
time may be subject to penalties under s. 119.10.
(4) CIVIL ACTION.—
(a) If a civil action is filed against a contractor to compel production of public records relating to a
public agency's contract for services, the court shall assess and award against the contractor the
reasonable casts of enforcement, including reasonable attorney fees, if:
1. The court determines that the contractor unlawfully refused to comply with the public records
request within a reasonable time; and
2. At least 8 business days before filing the action, the plaintiff provided written notice of the public
records request, including a statement that the contractor has not complied with the request, to the
public agency and to the contractor.
(b) A notice complies with subparagraph (a)2. if it is sent to the public agency's custodian of public
records and to the contractor at the contractor's address listed on its contract with the public agency or
to the contractor's registered agent. Such notices must be sent by common carrier delivery service or by
registered, Global Express Guaranteed, or certified mail, with postage or shipping paid by the sender
and with evidence of delivery, which may be in an electronic format.
(c) A contractor who complies with a public records request within 8 business days after the notice
is sent is not liable for the reasonable costs of enforcement.
History.—S. 1, ch. 2013.154; s. 1, ch. 2016-20.
Copyright m 1995-2016 The Florida Legislature • Privacy Statement • Contact U
http://www.leg.state.fl.us/Statutes/index.cfm?App mode=Displa... 9/13/2016
Rita Taylor
From: Randolph, John C. <JRandolph@jonesfoster.com>
Sent: Tuesday, September 13, 2016 9:36 AM
To: Rita Taylor
Subject: Mathews Consulting Contract
Attachments: 20160913094122434.pdf, 20160913093219859.pdf
Rita,
Attached is the Mathews Consulting agreement with the language required under Florida Statute
119.0701. With this addition, the agreement is ready to be signed.
I have also attached a copy of Florida Statute 119.0701 which is required to be given to the
contractor.
JOHN C. RANDOLPH
JONES FOSTER
JOWNWO N&Stl (IPS. V%
John C. Randolph Attomey
Direct Dial: 561.650.0458 1 has: 561.650.5300 1 jrandolphRionesfoster.com
Jones, Foster, Johnston & Stubbs, P.A.
Flagler Center Tower, 505 South Flagler Drive, Suite 1100, West Palm Beach, Florida 33401
561-659-3000 1 www.jonesfoster.com
Incoming emails are filtered which may delay receipt. This email is personal to the named recipient(s) and may be privileged
and confidential. If you are not the intended recipient, you received this in error. If so, any review, dissemination, or copying
of this email is prohibited. Please immediately notify us by email and delete the original message.
TOWN OF GULF STREAM
PALM BEACH COUNTY, FLORIDA
COMMISSIONERS
SCOTT W. MORGAN, Mayor
THOMAS M. STANLEY, Vlce-Mayor
PAUL A. LYONS, JR.
JOAN K. ORTHWEIN.
DONNA S. WHITE
October 13, 2016
Mathews Consulting
a Baxter & Woodman Company
477 S. Rosemary Ave.
Suite 330
West Palm Beach, FL 33401
Dear Ms. Mathews:
Telephone
(561)276-5116
Fax
(561)737-0188
Tawe Manager
WILLIAM H. THRASHER
Tann Clerk
RITA L. TAYLOR
Please find enclosed the FINAL fully executed copy of our agreement
for you General Engineering Services. We have placed one in our
files as well.
If you have any questions, feel free to contact the undersigned.
Very truly yours,
22 u f �-
Rita L. Taylor
Town Clerk
Encl.
100 SEA ROAD, GULF STREAM, FLORIDA 33483