HomeMy Public PortalAbout134-2015 - Shirk's International-International Truck w roll off container bed. P I t
ORIGINAL
PURCHASE AGREEMENT
THIS AGREEMENT made and entered into this !__Q_ day of A)U,4A/wNJ)0,/ , 2015, by
and between the City of Richmond, Indiana, a municipal corporation acting by and through its Board
of Sanitary Commissioners (hereinafter referred to as the "City") and Shirk's International, 1026
North Lincoln Street, Greensburg, Indiana 47240 (hereinafter referred to as the "Contractor").
SECTION L STATEMENT AND SUBJECT OF WORK
City hereby agrees to purchase from Contractor one 2016 4300 SBA International Truck with an
installed Stellar Shuttle Loader Model 120-16-20 and related accessories, delivered.
A Request for Quotes containing Specifications sent out October 14, 2015, has been made available
for inspection by Contractor, is on file in the offices of the Richmond Sanitary District, is attached
hereto as Exhibit "A," consisting of three (3) pages, and is hereby incorporated by reference and
made a part of this Agreement. Contractor agrees to abide by the same, and shall provide said
equipment conforming to the requirements outlined in the Specifications.
Delivery of any equipment that does not meet all specifications listed on Exhibit "A" will be
considered a breach of this Agreement, except as noted in Contractor's exception listed on Exhibit
«A
The response of Contractor to said Request for Quotes and Specifications (in addition to Contractor's
response on Exhibit "A") is attached hereto as Exhibit `B," which Exhibit is dated October 27, 2015,
consisting of nine (9) pages, and is hereby incorporated by reference and made a part of this
Agreement. Contractor shall provide all equipment, services, and warranties, listed on Exhibits "A"
and `B."
Contractor shall not modify or alter any standard warranty from the manufacturer of the above
described vehicle or equipment. Nothing contained herein shall prevent Contractor from providing
any additional or supplemental warranty in addition to that provided by the Manufacturer. Further,
Contractor shall provide City with copies of its warranty upon receiving a written or verbal request to
receive such warranty.
Should any provisions, terms, or conditions contained in any of the documents attached hereto as
Exhibits, or in any of the documents incorporated by reference herein, conflict with any of the
provisions, terms, or conditions of this Agreement, this Agreement shall be controlling.
The Contractor shall furnish all labor, material, equipment, services, and warranties necessary for the
proper completion of all work specified.
No performance of services shall commence until the following has been met:
1. The City is in receipt of any required certificates of insurance and/or
warranties;
2. The City is in receipt of any required affidavit signed by Contractor in
accordance with Indiana Code 22-5-1.7-11 (a)(2); and
3. A purchase order has been issued by the Purchasing Department.
Contract No. 134-2015
Page 1 of 6
SECTION II. STATUS OF CONTRACTOR
Contractor shall be deemed to be an independent contractor and is not an employee or agent of the
City of Richmond.
SECTION III. COMPENSATION
City shall pay Contractor a total sum of Eighty -Six Thousand One Hundred Eighty -Four Dollars and
Seventeen Cents ($86, l 84.17) for the above described equipment, delivered.
SECTION N. TERM OF AGREEMENT
This Agreement shall become effective when signed by all parties and shall continue in effect until
completion of the project.
Notwithstanding the term of this Agreement, City may terminate this Agreement in whole or in part,
for cause, at any time by giving at least five (5) working days written notice specifying the effective
date and the reasons for termination which shall include but not be limited to the following:
a. failure, for any reason of the Contractor to fulfill in a timely manner
its obligations under this Agreement;
b. submission of a report, other work product, or advice, whether oral or written, by the
Contractor to the City that is incorrect, incomplete, or does not meet reasonable
professional standards in any material respect;
c. ineffective or improper use of funds provided under this Agreement;
d. suspension or termination of the grant funding to the City under which this Agreement
is made; or
e. unavailability of sufficient funds to make payment on this Agreement.
In the event of such termination, the City shall be required to make payment for all work performed
prior to the date this Agreement is terminated, but shall be relieved of any other responsibility herein.
This Agreement may also be terminated, in whole or in part, by mutual Agreement of the parties
by setting forth the reasons for such termination, the effective date, and in the case of partial
termination, the portion to be terminated.
SECTION V. INDEMNIFICATION AND INSURANCE
Contractor agrees to obtain insurance and to indemnify the City for any damage or injury to person or
property or any other claims which may arise from the Contractor's conduct or performance of this
Agreement, either intentionally or negligently; provided, however, that nothing contained in this
Agreement shall be construed as rendering the Contractor liable for acts of the City, its officers,
agents, or employees. Contractor shall as a prerequisite to this Agreement, purchase and thereafter
maintain such insurance as will protect it from the claims set forth below which may arise out of or
result from the Contractor's operations under this Agreement, whether such operations by the
Page 2 of 6
Contractor or by any sub -contractors or by anyone directly or indirectly employed by any of them, or
by anyone for whose acts the Contractor may be held responsible.
Coverage
A. Worker's Compensation &
Disability Requirements
B. Employer's Liability
C. Comprehensive General Liability
Section 1. Bodily Injury
Section 2. Property Damage
D. Comprehensive Auto Liability
Section 1. Bodily Injury
Section 2. Property Damage
Limits
Statutory
$100,000
$1,000,000 each occurrence
$2,000,000 aggregate
$1,000,000 each occurrence
$1,000,000 each person
$1,000,000 each occurrence
$1,000,000 each occurrence
E. Comprehensive Umbrella Liability $1,000,000 each occurrence
$2,000,000 each aggregate
SECTION VI. COMPLIANCE WITH WORKER'S COMPENSATION LAW
Contractor shall comply with all provisions of the Indiana Worker's Compensation law, and shall,
before commencing work under this Agreement, provide the City a certificate of insurance, or a
certificate from the industrial board showing that the Contractor has complied with Indiana Code
Sections 22-3-2-5, 22-3-5-1 and 22-3-5-2. If Contractor is an out of state employer and therefore
subject to another state's worker's compensation law, Contractor may choose to comply with all
provisions of its home state's worker's compensation law and provide the City proof of such
compliance in lieu of complying with the provisions of the Indiana Worker's Compensation Law.
SECTION VII. COMPLIANCE WITH INDIANA E-VERIFY PROGRAM REQUIREMENTS
Pursuant to Indiana Code 22-5-1.7, Contractor is required to enroll in and verify the work
eligibility status of all newly hired employees of the contractor through the Indiana E-Verify
program. Contractor is not required to verify the work eligibility status of all newly hired
employees of the contractor through the Indiana E-Verify program if the Indiana E-Verify
program no longer exists. Prior to the performance of this Agreement, Contractor shall provide
to the City its signed Affidavit affirming that Contractor does not knowingly employ an
unauthorized alien in accordance with IC 22-5-1.7-11 (a) (2). In the event Contractor violates IC
22-5-1.7 the Contractor shall be required to remedy the violation not later than thirty (30) days
Page 3 of 6
after the City notifies the Contractor of the violation. If Contractor fails to remedy the violation
within the thirty (30) day period provided above, the City shall consider the Contractor to be in
breach of this Agreement and this Agreement will be terminated. If the City determines that
terminating this Agreement would be detrimental to the public interest or public property, the
City may allow this Agreement to remain in effect until the City procures a new contractor. If
this Agreement is terminated under this section, then pursuant to IC 22-5-1.7-13 (c) the
Contractor will remain liable to the City for actual damages.
SECTION VIII. IRAN INVESTMENT ACTIVITIES
Pursuant to Indiana Code (IC) 5-22-16.5, Contractor certifies that Contractor is not engaged in
investment activities in Iran. In the event City determines during the course of this Agreement
that this certification is no longer valid, City shall notify Contractor in writing of said
determination and shall give contractor ninety (90) days within which to respond to the written
notice. In the event Contractor fails to demonstrate to the City that the Contractor has ceased
investment activities in Iran within ninety (90) days after the written notice is given to the
Contractor, the City may proceed with any remedies it may have pursuant to IC 5-22-16.5. In the
event the City determines during the course of this Agreement that this certification is no longer
valid and said determination is not refuted by Contractor in the manner set forth in IC 5-22-16.5,
the City reserves the right to consider the Contractor to be in breach of this Agreement and
terminate the agreement upon the expiration of the ninety (90) day period set forth above.
SECTION IX. PROHIBITION AGAINST DISCRIMINATION
Pursuant to Indiana Code 22-9-1-10, Contractor, any sub -contractor, or any person acting on behalf of
Contractor or any sub -contractor shall not discriminate against any employee or applicant for
employment to be employed in the performance of this Agreement, with respect to hire, tenure, terms,
conditions or privileges of employment or any matter directly or indirectly related to employment,
because of race, religion, color, sex, disability, national origin, or ancestry.
B. Pursuant to Indiana Code 5-16-6-1, the Contractor agrees:
That in the hiring of employees for the performance of work under this Agreement of
any subcontract hereunder, Contractor, any subcontractor, or any person acting on
behalf of Contractor or any sub -contractor, shall not discriminate by reason of race,
religion, color, sex, national origin or ancestry against any citizen of the State of
Indiana who is qualified and available to perform the work to which the employment
relates;
2. That Contractor, any sub -contractor, or any person action on behalf of Contractor or
any sub -contractor shall in no manner discriminate against or intimidate any
employee hired for the performance of work under this Agreement on account of
race, religion, color, sex, national origin or ancestry;
3. That there may be deducted from the amount payable to Contractor by the City under
this Agreement, a penalty of five dollars ($5.00) for each person for each calendar
day during which such person was discriminated against or intimidated in violation
of the provisions of the Agreement; and
Page 4 of 6
4. That this Agreement may be canceled or terminated by the City and all money due or
to become due hereunder may be forfeited, for a second or any subsequent violation
of the terms or conditions of this section of the Agreement.
C. Violation of the terms or conditions of this Agreement relating to discrimination or
intimidation shall be considered a material breach of this Agreement.
SECTION X. RELEASE OF LIABILITY
Contractor hereby agrees to release and hold harmless the City and all officers, employees, or agents
of the same from all liability which may arise in the course of Contractor's performance of its
obligations pursuant to this Agreement.
SECTION XI. MISCELLANEOUS
This Agreement is personal to the parties hereto and neither party may assign or delegate any of its
rights or obligations hereunder without the prior written consent of the other party. Any such
assignment or delegation without the prior written consent of the other party shall be null and void.
This Agreement shall be controlled by and interpreted according to Indiana law and shall be binding
upon the parties, their successors and assigns. This document constitutes the entire Agreement
between the parties, although it may be altered or amended in whole or in part at any time by filing
with the Agreement a written instrument setting forth such changes signed by both parties. Both
parties expressly agree that this document supersedes all previous negotiations, discussions, or
conversations relating to the subject matter herein.
This Agreement may be simultaneously executed in several counterparts, each of which shall be an
original and all of which shall constitute but one and the same instrument.
The parties hereto submit to jurisdiction of the courts of Wayne County, Indiana, and any suit arising
under this Contract, must be filed in said courts. By signing this agreement, both parties are estopped
from bringing any action in alternative courts or venues. The parties specifically agree that no
arbitration or mediation shall be required prior to the commencement of legal proceedings in Wayne
County Circuit or Superior Court.
Any person executing this Contract in a representative capacity hereby warrants that he has been duly
authorized by his or her principal to execute this Contract.
In the event of any breach of this Agreement by Contractor, and in addition to any other damages or
remedies, Contractor shall be liable for all costs incurred by City due to the enforcement of this
Agreement, including but not limited to City's reasonable attorney's fees.
In the event that an ambiguity or question of intent or a need for interpretation of this Agreement
arises, this Agreement shall be construed as if drafted jointly by the parties, and no presumption or
burden of proof shall arise favoring or disfavoring any party by virtue of the authorship of any of the
provisions of this Agreement.
If any portion of this agreement is declared unenforceable by a court or tribunal, all other portions
shall remain in full force and effect.
Page 5 of 6
IN WITNESS WHEREOF, the parties have executed this Agreement at Richmond, Indiana, as of the
day and year first written above, although signatures may be affixed on different dates.
"CITY"
THE CITY OF RICHMOND,
INDIANA by and through its
Board of Sanitary Commissioners
By:
ue iller, President
—B
Gil Klose, Vice'�President—
Ni, Member
Date: / a
APPROVED:
Sarah L. Hutton, Mayor
Date:
"CONTRACTOR"
SHIRK' S INTERNATIONAL
By: /i 9,
Printed name: ( 6 n R
Title: le rO fI4& d
Date: Z
k 311
Page 6 of 6
City of Richmond -- Sanitary District
The Richmond Sanitary District wishes to receive bids for the purchase of a single axle cab and
chassis with a hook lift unit.
Bidders must check YES or NO. Failure to complete the list below will render your bid non-
responsive, causing bid to be rejected..
The unit must meet all specification except you may submit a proposal on equipment not
conforming to specs. Only if such difference is pointed out in writing within the bid.
Consideration will be given to such deviations based on their relative merit and compatibility.
MINIMUM SPECIFICATIONS
Cab and Chassis must be a cunent model International 4300 SBA 2016 4x2 with G WR: 33000
and a Calc. 33000. YES LNO
Cab is to be painted White
YES �No
Detailed Specs for Cab and Chassis are included with this Bid Paelcaee.
MINIMUM SPECIFICATION FOR HOOK LIFT UNIT
1. Minimum lift and dump capacity must be 20,000 pounds with a Maximum operating
pressure of 4,200 PSI YES NO
2. Maximum Dump angle must be 48 degrees.
YES NO
3. Hook height must be a minimum of 58 inches and a maximum of 62 inches from skid
rails to the bottom of hook bar. YES NO
4
i
4. Loader must have a pivoting front tilt section to provide a low degree for
loading/unloading angle. YES NO
5. An automatic mechanical safety latch which disengages only when container/body is
in proper position to be picked up or set off. YES NO
6. Hot Shift PTO with Direct -coupled high pressure piston pump. YES NO
k
I
{
EXHIBIT RA
City of.Richmond chmtond -- Sanitary Di's
The Richmond Sanitary District wishes to receive bids for the purchase of a single axle cab and
chassis with a hook lift unit
Bidders must check YBs or NO. Failure to complete the list below will render your bid non-
responsive, causing, bid to be rejected.
The unit must meet all specification except you may submit a,pmposal on equipment not
conforming to specs. Only if such difference is pointed out in writing within the bid.
Consideration will be given to such deviations base on their relative merit and compatibility.
MNIl4= MCIFICATIONS
Cab and Chassis must be a current model International 4300 SBA 2016 4x2 with OVVVR: 33000
and a Calc. 33000. YES NO
Cab is to be painted White YES NO
Detailed S ers for Cab and Chassis are included with thin Bid P_ ackaffe
I_VIIWIMM SPEC—M- CATIQN FOR HQfiK LTFi' UNIT
I . Minimum lift and dump capacity mint be 20,000 pounds with a Maximum operating
pressure of 4,200 PSI YES, NO
I Maximum Damp angle roust be 48 d%rees. YES NO
3. Hook height must be a minimum of 58 inches and a maximum of 62 ,inches f om skid
rails to the bottom of hook bar. YB k NO
4. Loader must have a pivoting front tilt •section to provide a low degree for
IoadingAinloading angle. 'YES < NO
5 An automatic mechanical safety latch which disengages only when container/body is
in proper position to be picked up or s ft off. 'YES NO
6. Hot Shift PTO with I3imet-coupled hi4h prepare piston pump. YES No
J.W. DEVEFS & SON INC.
5 North Broadway
Trotwood, Ohio 45426-3s99
('037) 854.3040
EXHIBIT PAGE
7. Frame ,Mounted hydraulic tank with Stack -type valve mounted on top; ball valve, on
suction line, spin -on return line Ter. YES .� NO
8. Hydraulic cylinders: All cylinders must be double acting and include pilot operated
counterbalance valves to prevent cylinder collapse in case of hose £allure.
YES .,X NO
9. Unit must have a hydraulic lock out devise to prevent operation of the tilt section
while in the dumping mode. YES - NO
10. Dump/Tilt Interlock: Tilt and Lift sections must lords into a rigid frame to provide
Support for the container while in the dump mode. Sections form #his frame without
the use of mechanical latches whicli rely on gravity, springs or container/body
mounted latches. YES X NO
I I . Rear Body hold Clowns. Must have dual fixed hold downs to secure the body of the
loader. Hold downs must secure ocutainer through all ranges of dump mode. This
must be accomplished without the Use of springs and/or hydraulic devises. Must be
compatible with existing City owned containers, YES No
12. All Pins must be 17-44 stainless steel bnd all bushing to be permanently lubricated..
YES � NO
13. Unit must be capable of picking up, hauling And dumping contaners 13 feet to 17
feet long. YESr><NQ
14. Hydraulic Controls: Must be mounted in cab near the right side of dd seat.
�S ND
15. Hydraulic controls must be dual manual levers with sealed cable actuators to allow
full feathering of all loader Amotions. YES No
16. l pair poly ma fenders with short flaps YES NO
17. ICC bumper tubing cons ruction with Red Clearance lights on ends.
YES < No
J.W. DEVERS & SON INC.
5 North zBroadway
Trotwood, Ohio 45426-3599
(937) 854-3040
EXHIBIT -.A— PAGE .3 OFa-
PRICE REQUEST
T
CITY OF MCI3MOM
WMMM4rvi? *Wa* OM I?4 'THIS IS NOT AN ORDER 23itf T.tDGlt7YAVENUGRiC[1Nt0A�, lNDIANA 47374
Pt MF (769i 983 7450 AX (765) M2W
INSTRUC77ONS
This to a request for a price for the services of materials
descrh)ed below, Any additional specifications may he
attached hereto This is 140T an order and tie City reserves
the tight to ampt,all'or part, a decline the snore proposal.
Please canplete your fell name and phone number below
vv th signature; itemize all prices and charges where
requested:and .attach any explanation for any sulfon to
speclkatioms alleted. Return in a seMed envelope, in care of
Richmond sanitary District Board of Commissioners to
the admrdStrofloti bull tirtq at the address above ' by the
enacFW datA and finis to ha rnmWpmd
PAYMENT TERMS: DELIVERY REQUIRED:
Octolter 114.205 100 AM. on October 27, 201b UPON RECEIPT OF INVOICE DELIVERED
DESCRIPTION
This is a request for quotes to purchase a single axle cab and chassis with a hook lift °unit. Please see attached
specifications. Please include,ali warranty Information with quote.
E-Verify requirements and Indiana Local Preference Claims will apply to this quote, Information enclosed,
i tetarn this sheet and the proposal sheet In a sealed gnvelppe addressed to:
Rkh mond Sanitary Wetrict
Denise Johnson,, Customer Service Mgr
2380 Liberty Avenue
Richmond IN 47374
Re, Hook Truck
Quote Valid IJntit _,jR C Is r 2 o i r
Questions? Cali Tim Ungar at 766-983-7478.
STATE TAX EXEMPTION # OW121ti09-001
Richmond Sanitary District
cost=$ f3 61 Sq ,1
-7.'
DATE
TIM
,64?Z
PHONE NUMBER
EXHIBIT ,Z PAGE __1-_OFj---I
PROPOSAL SHEET
One (1) Hook -Lift Loader Price Per Unit $"2 r,',
Make and Model Number:
Cab and Chassis %Bnb A , ,-Al b►+a i S Gi
Hook -Lift Loader =�� A Q /2o •- I (. — 26
Warranty:
Cab and Chassis 5 e,.j 4 -a - 7uJa Sjg - ICAAJ/ l o ZI v- �StOQd M,
Hook -Lift Loader S412 1 W A
Awarding dealer will be responsible for warranty work during the duration of the
warranty period including transportation or other expenses incurred if warranty work is
done at any other location than that of the awarding dealer
Delivery Time once PO has been issued. U N D t P q o J-2Ay 5
Bid firm for how long.
Bid to include all shipping and handling charges. Hook -Lift Loader to be delivered to the
Richmond Sanitary District 2380 Liberty Avenue, Richmond, IN 47374.
Awarding Dealer will instruct Sanitary personnel on operation of the unit at the time of delivery.
S � it- ti 0
Company
.Ql._.?. 6 6 3.7/I l
Phone Number
2-12 -. J (-
Date
uthorized Signa re
14AQK J=z>we
Contact Person
rEXMIBIT $ PAGE _�___OF_
MITE
43-Ou", �wo%2
Sales Proposal For:
CITY OF RICHMOND
Presented By:
SHIRK'S INTERNATIONAL
IEXHIBIT_b PAGEJ-0E-j-
INTERNATIONAL°
October 27, 2016
Prepared For:
Presented By:
CITY OF RICHMOND
SHIRKS INTERNATIONAL
VICKI ROBINSON
Mark Lowe
50 N 5th St.
1026 N. LINCOLN ST
Richmond, IN 47374-4247
GREENSBURG IN 41240 -
(765)983 - 7200
(812)663-7111
Reference ID: NIA
Thank you for the opportunity to provide you with the following quotation on a new International truck. I am sure the following detailed
specification will meet your operational requirements, and I look forward to serving your business needs.
Model Profile
2016 4300 SBA 02 (MA025)
APPLICATION:
Flat Dump
MISSION:
Requested GVWR: 33000. Calc. GVWR: 32900
Calm Start / Grade Ability: 20.20% / 1.40% @ 55 MPH
Calc Geared Speed: 79.8 MPH
DIMENSION:
Wheelbase: 207.00, CA:139.90, Usable CA: 9.90, Axle to Frame: 63.00
ENGINE, DIESEL:
(Cummins ISB 240) EPA 2010, 240 HP @ 2400 RPM, 560 lb-ft Torque @ 1600 RPM, 2600 RPM
Governed Speed, 240 Peak HP (Max)
TRANSMISSION, AUTOMATIC:
(Allison 2500 RDE P) 5th Generation Controls; Wide Ratio, &Speed, With Overdrive; On/Off
Hwy; 33,000 lb GVW & GCW Max„ With PTO Provision, Less Retarder
CLUTCH:
Omit Item (Clutch & Control)
AXLE, FRONT NOWDRIVING:
(Dana Spicer E-1202Q 1-Beam Type, 12,000-lb Capacity
AXLE, REAR, SINGLE:
(Navistar Select) Single Reduction, 23,000-lb Capacity, 200 Wheel Ends Metric, Gear Ratio: 5.38
CAB:
Conventional
TIRE, FRONT:
(2)11 R22.5 ECO PLUS HS3 (CONTINENTAL) 495 rev/mile, bad range G, 14 ply
TIRE, REAR:
(4)11R22.5 HDR2 (CONTINENTAL) 491 rev/mile, load range G, 14 ply
SUSPENSION, RR, SPRING, SINGLE:Vad-Rate; 23,500-lb Capacity, With 4500 lb Auxiliary Rubber Spring
PAINT:
Cab schematic 100GA
Location 1: 9219, Winter White (Std)
Chassis schematic N/A
2 Proposal: 2066-01
EXHIBIT PAGE _q_OF
INTERNATIONAL° Vehicle Specifications October 27, 2015
20% 4300 SBA 4X2 (MA025)
Code
Description
FIR Wt
Tot Wt
(lbs)
(lbs)
MA02500
Base Chassis, Model 4300 SBA 4X2 with 207.00 Wheelbase, 139.90 CA, 9.90
5567/2901
8468
Usable CA, and 63.00 Axle to Frame.
1CAD
FRAME RAILS High Strength Low Alloy Steel (80,000 PSI Yield); 10.250" x 3.092"
1651315
480
x 0.375" (260.4mm x 78.5mm x 9.5mm); 427.0" (10846mm) Maximum DAL
1LLD
BUMPER, FRONT Full Width, Aerodynamic, Steel; 0.142" Material Thickness
0/0
0
1WEJ
WHEELBASE RANGE 199" (505cm) Through and Including 254" (645cm)
0/0
0
2AGB
AXLE, FRONT NON -DRIVING (Dana Spicer E-1202Q I -Beam Type, 12,000-lb
-1610
-16
Capacity
3ADC
SUSPENSION, FRONT, SPRING Parabolic, Taper Leaf, 12,000-lb Capacity; With
69/0
69
Shock Absorbers
4091
BRAKE SYSTEM, AIR Dual System for Straight Truck Applications
100/30
130
4196
BRAKES, FRONT, AIR CAM 16.5" x 5", Includes 24 Sgln Long Stroke Brake
15010
150
Chambers
4AZA
AIR BRAKE ABS (Bendix AntiLock Brake System) Full Vehicle Wheel Control
9/21
30
System (4-Channel)
4EBS
AIR DRYER (Bendix AD-9) With Heater
23/4
27
4EVH
BRAKE CHAMBERS, REAR AXLE (MGM TR3030LP3TSHD) 30/30 Spring Brake
0/0
0
4EXV
BRAKE CHAMBERS, FRONT AXLE (Bendix) 24 Sgln
010
0
4LAA
SLACK ADJUSTERS, FRONT (Haldex) Automatic
SO
6
4LGA
SLACK ADJUSTERS, REAR (Haldex) Automatic
0/0
0
4NDB
BRAKES, REAR, AIR CAM S-Cam;16.5" x 7.0' ; Includes 30130 Sq.1n. Long Stroke
0/211
211
Brake Chamber and Spring Actuated Parking Brake
4SPA
AIR COMPRESSOR (Cummins)18.7 CFM Capacity
36/0
36
5AAA
STEERING COLUMN Stationary
0/0
0
5CAL
STEERING WHEEL 2-Spoke, 18" Diam., Black
'0/0
0
5PSA
STEERING GEAR (Sheppard M-100) Power
25/0
25
7BJY
EXHAUST SYSTEM Inline, Horizontal Aftertreatment Device Frame Mounted Right
0/0
0
Side, Includes Short Horizontal Tail Pipe
7WCW
TAIL PIPE Horizontal, Exits Right Side, 90 Degree Turnout
0116
16
8000
ELECTRICAL SYSTEM 12-Vo[t, Standard Equipment
010
0
8GXD
ALTERNATOR (Leese -Neville AV1160P2013) Brush Type;12 Volt 160 Amp.
0/0
0
Capacity, Pad Mount, With Remote Sense
8HAB
BODY BUILDER WIRING Back of Standard Cab at Left Frame or Under Extended
2/0
2
or Crew Cab at Left Frame; Includes Sealed Connectors for Tail/Amber Turn/
Marker/ Backup/Accessory Power/Ground and Sealed Connector for Stop/Turn
8MEP
BATTERY SYSTEM (International) Maintenance -Free (2)12-Volt 130OCCA Total
0/0
0
8VAY
HORN, ELECTRIC Disc Style
0/0
0
8WTK
STARTING MOTOR (Delco Remy 38MT Type 300)12 Volt; less Thermal Over-
0/0
0
Crank Protection
3
Proposal: 2066.01
EXHIBIT _a_ PAGE S 0F_j_
INTERNATIONAL•
Vehicle Specifications
October 27, 2015
2016 4300 SBA 02 (MA025)
Code
Description
FIR Wt
Tot Wt
(Ibs)
(ibs)
8WWJ
INDICATOR, LOW COOLANT LEVEL With Audible Alarm
0/0
0
8WZK
HEADLIGHTS Halogen; Composite Aero Design for Two Light System
0/0
0
9HAD
GRILLE Chrome
0/0
0
9WAY
FRONT END Tilting, Fiberglass, With Three Piece Construction
0/0
0
10D60
PAINT SCHEMATIC, PT-1 Single Color, Design 100
0/0
0
10761
PAINT TYPE Base Coat/Clear Coat, 1-2 Tone
0/0
0
10985
FRAME, SPECIAL RATING Limited to 32,900-lb GVWR;12,000-lb Front Axle Will
0/0
0
Be De -rated to 11,00D-ib Capacity; When Applicable
11001
CLUTCH Omit Item (Clutch & Control)
-651-10
-75
12EES
ENGINE, DIESEL (Cummins ISB 240) EPA 2010, 240 HP Q 2400 RPM, 5W lb-ft
010
0
Torque @ 1600 RPM, 2600 RPM Governed Speed, 240 Peak HP (Max)
12TSY
FAN DRIVE (Borg-Warner SA85) Viscous Type, Screw On
0/0
0
12UYE
RADIATOR Aluminum; 2-Row, Cross Flow, Over Under System, 717 Sqln
35/4
31
Louvered, With 313 Sqln Charge Air Cooler. Wdh In -Tank Transmission Cooler
12VBR
AIR CLEANER With Service Protection Element
010
0
12VXT
THROTTLE, HAND CONTROL Engine Speed Control; Electronic, Stationary,
0/0
0
Variable Speed; Mounted on Steering Wheel
12VYP
ENGINE CONTROL, REMOTE MOUNTED - No Provision Furnished for Remote
0/0
0
Mounted Engine Control
12WPV
OIL PAN 15 Quart Capacity, For Cummins ISB Engines
0/0
0
12WZE
EMISSION COMPLIANCE Federal, Does Not Comply With California Clean Air Idle
0/0
0
Regulations
12X86
FEDERAL EMISSIONS EPA, OBD and GHG Certified for Calendar Year 2015; ISB
0/0
0
Engines
13ASP
TRANSMISSION, AUTOMATIC (Allison 25M RDS P) 5th Generation Controls;
0/0
0
Wide Ratio, 5-Speed, With Overdrive; OrdOff Hwy; 33,000 lb GVW & GCW Max.,
With PTO Provislon, Less Retarder
13WLN
TRANSMISSION OIL Synthetic; 20 thru 28 Pints
0/0
0
13WYY
SHIFT CONTROL PARAMETERS Allison 1000 or 2000 Series Transmissions, 5th
0/0
0
Generation Controls, Performance Programming
14AJW
AXLE, REAR, SINGLE (Navistar Select) Single Reduction, 23,0004b Capacity, 200
0/229
229
Wheel Ends Metric, . Gear Ratio: 5.38
14VAH
SUSPENSION, RR, SPRING, SINGLE Vad-Rate; 23,500-lb Capacity, With 4500
0166
66
lb Auxiliary Rubber Spring
14WMG
AXLE, REAR, LUBE (EmGard FE-75W-90) Synthetic Oil; 30 thru 39.99 Pints
010
0
15SWU
FUEL TANK Top Draw; D-Style, Non -Polished Aluminum, 16'Tank Depth, 40 U.S.
0/0
0
Gal., 151 L Capacity, with Quick Connect Outlet, Mounted Left Side, Under Cab
15WDG
DEF TANK 7 U.S. Gal. 26.5L Capacity, Frame Mounted Outside Left Rail, Under
0/0
0
Cab
16030
CAB Conventional
0/0
0
4 Proposal: 2066-01
EXHIBIT PAGE (o OF
INTERNATIONAL` Vehicle Specifications October 27, 2016
2016 4300 SBA 4X2 (MA025)
Coe
Description
FIR Wt
Tot Wt
(lbs)
pbs)
16HBA
GAUGE CLUSTER English With English Electronic Speedometer
0/0
0
16HKT
IP CLUSTER DISPLAY On Board Diagnostics Display of Fault Codes in Gauge
0/0
0
Cluster
16HLJ
GAUGE, DEF FLUID LEVEL
0/0
0
16JNT
SEAT, DRIVER (National 2000) Air Suspension, High Back With Integral Headrest,
210
2
Vinyl, Isolator, 1 Chamber Lumbar, With 2 Position Front Cushion Adjust, -3 to +14
Degree Angle Back Adjust
16SMN
SEAT, PASSENGER (National) Non Suspension, High Back, Fixed Back, Integral
17/6
23
Headrest, Vinyl
16SNA
MIRRORS (2) (Lang Mekra) Rectangular, Black Heads, Brackets and Arms,
-3/0
-3
Breakaway Type, 7.55" x 14.1" Integral Convex Both Sides,102" Inside Spacing
16WCT
AIR CONDITIONER {Blend -Air) With Integral Heater & Defroster
66/5
71
16WJS
INSTRUMENT PANEL Center Section, Flat Panel
0/0
0
16WRX
CAB INTERIOR TRIM Deluxe
0/0
0
27DTJ
WHEELS, FRONT (Maxion 905411 DISC; 22.V' Painted Steel, 2-Hand Hole, 10•
1/0
1
Stud (285.75MM BC) Hub Piloted, Flanged Nut, Metric Mount, 8.25 DC Rims; With
Steel Hubs
28DTJ
WHEELS, REAR (Maxion 90541) DUAL DISC; 22.5" Painted Steel, 2 Hand Hole,
W69
769
10 Stud (285.75MM BC) Hub Piloted, Flanged Nut, Metric Mount, 8.25 DC Rims;
With Steel Hubs
29PAR
PAINT IDENTITY, FRONT WHEELS Disc Front Wheels; With Vendor Applied
010
0
White Powder Coat Paint
29PAS
PAINT IDENTITY, REAR WHEELS Disc Rear Wheels; With Vendor Applied White
0/0
0
Powder Coat Paint
7372135423
(4) TIRE, REAR 11 R22.5 HDR2 (CONTINENTAL) 491 revlmile, load range G, 14
0/184
184
ply
7372135429
(2) TIRE, FRONT 11R22.5 ECO PLUS HS3 (CONTINENTAL) 495 revlmile, load
7410
74
range G,14 ply
Services Section:
40116
WARRANTY Standard for Durastar 1000/4000 Series, Effective with Vehicles Built
0/0
0
January 2, 2015 or Later, CTS-2475P
Total Component Weight:
6263/4743
11006
1
stellar shuttle loader
0/0
0
Total Body Allied:
0/0
0
The weight calculations included in this proposal are an estimate of future vehicle weight. The actual weight as manufactured may be
different from the estimated weight Navistar, Inc. shall not be liable for any consequences resulting from any differences between the
estimated weight of a vehicle and the actual weight.
5
Proposal: 2066.01
EXHIBIT 8 PAGE -7OF------------
9
J.W. DEVERS & SON, INC.
Truck Body Manufaewrem Since 1806
COMPLETE LINES OF TRUCK EQUIPMENT QUOTATION
5 NORTH BROADWAY F-1 ORDER
TROTWOODj OHIO 46426-3599
PHONE (937) SS44M FAX (937) 85"017
QUOTE NUMBER 4600
QUOTATION DATE: October 20,2015
ATTENTION- mark Lam
Model 120-1620 20,000 lb capacity for dumping and loading
48 &,Vw maximum dump angle for 12-51 to 15, containers and up to 17" flatbeds
114" to 13 0" C/A chaWs required
Custom Stellar Engagement Hook and hold downs for book rods 59" to 62"
Counter-balarice valves on all cylinders
All pivot pins 17A stainless
Hot Shift PTO will duect mount pump for automatic transmission
Frame mounted hydraulic tank withcontrol valve mounted on top
(2) Section control valve, for loader operation only
Stainlesssteel bonnatted controls
,Spin -on return line filter
All hoses and fittings included
(1) pair,poly rear fen4m
Tubing ICC bumper with clearance lights on ends
Chasse lights remounted
Loader fiame painted h1wk
Installed complete Total
_Add Yed0n4F AL* TNX
-----
1
THIS
S PRICE IS FIRM FOR _,g:�4p DAYS x- doliocutificaft OrExa1
npaw Given
manufacturing conditions, smokes, fires, secIdents, delays of can
. -
to rewive material or any other causes beyond our reasonable cont'nI
A Iota tharge will be added on past due bailances at on Intereal customer
"",44ML psr month {An annual nercentede rate of 18%).
BY
$25,950.00
EXHIBIT _B PAGE
v
INTERNATIONAL'
Description
Factory List Prices:
Product Items
Service Items
Total Factory List Price Including Options:
P&D
Total Preparation And Delivery:
Freight
Total Freight:
Total Factory List Price Including Freight:
Less Customer Allowance:
Total Vehicle Price:
Total Body/Mlied Equipment:
Total Sale Price:
Total Per Vehicle Sales Price:
Net Sales Price:
Financial Summary
2016 4300 SBA 4X2 (MA025)
(US DOLLAR)
$91,938.00
$0.00
$250.00
$2,200,00
Price
$91,938.00
$250.00
$2,200.00
$94,388.00
($34,053.83)
$60,334.17
$26.850.00
$86,184.17
$86,164.17
$86,184A7
October 27, 2016
Please feel free to contact me regarding these specifications should your interests or needs change. I am confident you will be
pleased with the quality and service of an International vehicle.
Approved by Seller:
Official Title and Date
Authorized Signature
This proposal Is not binding upon the seller without
Seller's Authorized Signature
Accepted by Purchaser:
Firm or Business Name
Authorized Signature and Date
Official Title and Date
The TOPS FET calculation is an estimate for reference purposes only. The seller or retailer is responsible for calculating
and reportinglpaying appropriate FET to the IRS.
6
Proposal: 2066-01
EXHIBIT B_ PAGE _t_OF�