HomeMy Public PortalAbout2011-06 Selecting Pollution Elimination Corporation (PELCO) for the Ocean Lane Pump Station OL-1 Valve Replacement ProjectRESOLUTION NO. 2011-6
A RESOLUTION OF THE VILLAGE COUNCIL OF THE
VILLAGE OF KEY BISCAYNE, FLORIDA, SELECTING
POLLUTION ELIMINATION CORPORATION (D/B/A
PELCO) FOR THE OCEAN LANE PUMP STATION OL-1
VALVE REPLACEMENT PROJECT; AUTHORIZING THE
VILLAGE MANAGER TO EXECUTE AN AGREEMENT
RELATED TO THE SAME; AND PROVIDING FOR AN
EFFECTIVE DATE.
WHEREAS, the Village of Key Biscayne, Florida (the "Village") recently sought proposals
for the Ocean Lane Pump Station OL-1 Valve replacement project (the "Improvements") through
a competitive bidding process; and
WHEREAS, after careful review of the competitive bids submitted, the Village wishes to
engage Pollution Elimination Corporation (d/b/a Pelco) ("Pelco") for the Improvements; and
WHEREAS, the Village Council finds that this Resolution is in the best interest and welfare
of the residents of the Village.
NOW, THEREFORE, BE IT RESOLVED BY THE VILLAGE COUNCIL OF THE
VILLAGE OF KEY BISCAYNE, FLORIDA, AS FOLLOWS:
Section 1. Recitals Adopted. Each of the above stated recitals are hereby adopted,
confirmed and incorporated herein.
Section 2. Pelco Selected. The Village Council hereby selects Pelco for the
Improvements.
Section 3. Village Manager Authorized. The Village Manager is hereby authorized
to execute an agreement with Pelco, in substantially the form attached hereto as Exhibit "A."
Section 4. Effective Date. This Resolution shall be effective immediately upon
adoption.
PASSED AND ADOPTED this 12th day of April, 2011.
MAYOR FRANKLIN H. CAPLAN
ATT
CONCHITA H. ALVAREZ, MMC, VILLAGE CLE
APPROVED AS TO FORM AND LEGAL SUFFIC Pi
r `�}';.;-
VILLAGE ATT
2
CONTRACT FOR CONSTRUCTION
THIS IS A CONTRACT, by and between the VILLAGE OF KEY BISCAYNE,
FLORIDA, a municipal corporation of the State of Florida (hereinafter referred to as "Village"),
and POLLUTION ELIMINATION CORPORATION (D/B/A PELCO), a Florida corporation,
whose mailing address is 10762 SW 188 St. Miami, Florida 33157 (hereinafter referred to as
"Contractor".)
WITNESSETH
That Contractor and Village, for the considerations hereinafter named, the receipt and
sufficiency of which is hereby acknowledged, agree as follows:
ARTICLE 1
SCOPE OF WORK
1.1
Contractor hereby agrees to furnish all of the labor, materials, equipment, services and
incidentals necessary to perform all of the work described in the Contract Documents ("the
Work") including, without limitation as described in the approved plans, drawings and
specifications for the following Project:
Ocean Lane Pump Station OL-1 Valve Replacement Project
and in accordance with the plans prepared by CORZO CASTELLA CARBALLO
THOMPSON SALMAN, P.A. ("C3TS") (the "Village's Project Consultant") dated
(the "Plans") incorporated herein by reference and made a part of this Contract.
ARTICLE 2
CONTRACT TIME
2.1 Contractor shall be instructed to commence the Work by written instructions in the form of a
Notice to Proceed providing a commencement date and issued by the Village Manager. The
Notice to Proceed will not be issued until Contractor's submission to Village of all required
documents and after execution of this Contract.
2.2 Time is of the essence throughout this Contract. The Contractor shall prosecute the Work
with faithfulness and diligence and the Work shall be substantially completed within forty-
five (45) calendar days from the date specified in the Notice to Proceed. The Work shall be
fully completed in accord with the Contract Documents within thirty (30) calendar days
from the date certified by Village's Project Consultant as the date of Substantial Completion.
Substantial Completion shall be defined for this purpose as the date on which Village
receives beneficial use of the Project.
2.3 Upon failure of Contractor to substantially complete the Contract within the specified period
of time, Contractor shall pay to Village the sum of five hundred dollars ($500.00) for each
calendar day after the time specified in Section 2.2 above for Substantial Completion. After
Substantial Completion, should Contractor fail to complete the remaining Work within the
time specified in Section 2.2 above for final completion and readiness for final payment,
Contractor shall pay to Village the sum of two hundred fifty dollars ($250.00) for each
calendar day after the time specified in Section 2.2 for final completion and readiness for
final payment. These amounts are not penalties but are liquidated damages payable by
Contractor to Village for the failure to provide full beneficial occupancy and use of the
Project as required. Liquidated damages are hereby fixed and agreed upon between the
parties who hereby acknowledge the difficulty of determining the amount of damages that
will be sustained by Village as a consequence of Contractor's delay and failure of
Contractor to complete the Contract on time. The above -stated liquidated damages shall
apply separately to each phase of the Project for which a time for completion is given.
2.4 Village is authorized to deduct the liquidated damages from monies due to Contractor for
the Work under this Contract. In case the liquidated damage amount due to Village by
Contractor exceeds monies due Contractor from Village, Contractor shall be liable and shall
immediately upon demand by Village pay to Village the amount of said excess.
ARTICLE 3
CONTRACT PRICE
3.1 Village shall pay to Contractor for the performance of the Contract, the total lump sum of
twenty six thousand six hundred eighty-three and 00/100 Dollars ($26,683.00). This sum
("Contract Price") shall be full compensation for all services, labor, materials, equipment and
costs, including overhead and profit, associated with completion of all the Work in full
conformity with the Contract Documents and adjusted only by written change orders signed
by both parties and approved as required by local law.
3.2 Village shall provide the Contract Price above pursuant to the following schedule:
Fifty per cent (50%) of the Contract Price shall be paid to Contractor upon full
execution and approval as required of this Contract and receipt by Village of all
document required hereunder.
The balance, final payment, shall be paid to Contractor upon final completion of the
Work in accordance with the Contract Documents and acceptance by the Village
and upon certification by the Village's Project Consultant that the Work is
complete and in accord with the Contract Documents.
3.3 Any payment by Village, including the final request for payment, does not constitute
approval or acceptance by Village of any item of the Work nor shall it be construed as a
waiver of any of the Village's rights hereunder or at law or in equity.
2
3.4 This Contract is subject to the condition precedents that: (i) Village funds are available and
budgeted for the Contract Price; (ii) the Village secures and obtains any necessary grants or
loans for the accomplishment of this Project pursuant to any borrowing legislation adopted
by the Village Council relative to the Project; and (iii) Village Council enacts legislation
which awards and authorizes the execution of this Contract, if such is required.
ARTICLE 4
CONTRACT DOCUMENTS
4.1 The Contract Documents, which comprise the entire agreement between the Village and the
Contractor concerning the Work, consist of this Contract for Construction (including any
change orders and amendments thereto), the drawings, plans and specifications approved by
Village (including the Plans), the bidding documents or procurement documents for the
Project, the Contractor's bid or proposal for the Project, the Bonds (defined herein),
Insurance Certificates, the Notice of Award, and the Notice to Proceed, all of which are
deemed incorporated into and made a part of this Contract by this reference and govern this
Project. In the event of any conflict among the foregoing, the documents shall govern in the
order listed herein. Contractor is reminded and hereby recognizes that all Work under this
Contract must comply with all applicable federal, state and local law. Any mandatory
clauses which are required by applicable law shall be deemed to be incorporated herein.
4.2 This Contract incorporates and includes all prior negotiations, correspondence,
conversations, agreements, or understandings applicable to the matters contained herein and
the parties agree that there are no commitments, agreements, or understandings concerning
the subject matter of these Contract Documents that are not contained herein. Accordingly
it is agreed that no deviation from the terms hereof shall be predicated upon any prior
representations or agreements, whether oral or written.
4.3 The Contract Documents shall remain the property of the Village. The Contractor shall
have the right to keep one record set of the Contract Documents upon completion of the
Project; however in no circumstances shall the Contractor use, or permit to be used, any or
all of such Contract Documents on other projects without the Village's prior written
authorization.
ARTICLE 5
INDEMNIFICATION
5.1 Contractor shall defend, indemnify, and hold harmless the Village, its officers, agents and
employees, from and against any and all demands, claims, losses, suits, liabilities, causes
of action, judgment or damages, including legal fees and costs and through appeal,
arising out of or, related to, or in any way connected with Contractor's performance or
3
non-performance of this Contract or with Contractor's obligations or the Work related to
the Contract. Contractor shall defend, indemnify, and hold the Village harmless from all
losses, injuries or damages and wages or overtime compensation due its employees in
rendering services pursuant to this Contract, including payment of reasonable attorneys'
fees and costs in the defense of any claim made under the Fair Labor Standards Act, Title
VII of the Civil Rights Act of 1964, the Age Discrimination in Employment Act, the
Americans with Disabilities Act or any employment related litigation or worker's
compensation claims under federal or state law. The provisions of this section shall
survive termination of this Contract.
ARTICLE 6
INSURANCE AND BONDS
6.1 Insurance. Contractor shall secure and maintain throughout the duration of this Contract
insurance of such types and in such amounts as specified below, naming the Village as
named insured, underwritten by a firm rated A- or better and qualified to do business in
the State of Florida. Certificates of Insurance shall be provided to the Village at the time
of execution of this Contract reflecting the Village as a named insured. Each certificate
shall include a (30) thirty -day advance notice of cancellation provision in favor of the
Village.
a. Commercial general liability coverage with limits of liability of not less than
$1,000,000.00 per occurrence combined single limit for Bodily Injury Liability
and Property Damage Liability. This liability Insurance shall also include
completed operations and product liability coverages and eliminate the exclusion
with respect to property under the care, custody and control of Contractor. General
Aggregate (except products - completed operations) in the amount of
$2,000,000.00.
b. Professional liability errors and omissions insurance coverage in an amount not
less than $1,000,000.00.
c. Workers compensation insurance as required by law.
d. Business Automobile Liability with minimum limits of $500,000.00 per person,
per occurrence, combined single limit for Bodily Injury Liability and Property
Damage Liability each. Coverage must be afforded on a form no more restrictive
than the latest edition of the Business Automobile Liability policy, without
restrictive endorsements, as filed by the Insurance Services Office, and must
include Owned Vehicles, Hired and Non -Owned Vehicles and Employers' Non -
Ownership.
6.2 Bonds. No bonds are required of Contractor for this Work.
4
ARTICLE 7
CONTRACTOR'S REPRESENTATIONS AND WARRANTIES
In order to induce the Village to enter into this Contract, the Contractor makes the
following representations and warranties:
7.1 Contractor Represents the following:
7.1.1 Contractor has examined and carefully studied the Contract Documents and the
other data identified in the bidding documents, including, without limitation, the
"technical data" and plans and specifications and the Plans.
7.1.2 Contractor has visited the Project site and become familiar with and is satisfied as
to the general and local conditions and site conditions that may affect cost,
progress, performance or furnishing of the Work.
7.1.3 Contractor is familiar with and is satisfied as to all federal, state and local laws,
regulations and permits that may affect cost, progress, performance and furnishing
of the Work. Contractor agrees that it will at all times comply with all
requirements of the foregoing laws, regulations and permits.
7.1.4 Contractor has made, or caused to be made, examinations, investigations, tests
and/or studies as necessary to determine surface and subsurface conditions at or
on the site. Contractor acknowledges that the Village does not assume
responsibility for the accuracy or completeness of information and data shown or
indicated in the Contract Documents with respect to underground or ground
facilities at, contiguous or near the site or for existing improvements at or near the
site. Contractor has obtained and carefully studied (or assumes responsibility for
having done so) all such additional supplementary examinations, investigations,
explorations, tests, studies and data concerning conditions (surface, subsurface
and underground facilities and improvements) at, contiguous or near to the site or
otherwise which may affect cost, progress, performance or furnishing of the Work
or which relate to any aspect of the means, methods, techniques, sequences and
procedures of construction to be employed by Contractor and safety precautions
and programs incident thereto. Contractor does not consider that any additional
examinations, investigations, explorations, tests, studies or data are necessary for
the performance and furnishing of the Work at the Contract Price, within the
Contract Time and in accordance with the other terms and conditions of the
Contract Documents.
7.1.5 Contractor is aware of the general nature of Work to be performed by the Village
and others at the site that relates to the Work as indicated in the Contract
Documents.
5
7.1.6 Contractor has correlated the information known to Contractor, information and
observations obtained from visits to the site, reports and drawings identified in the
Contract Documents and all additional examinations, investigations, explorations,
tests, studies and data with the Contract Documents.
7.1.7 Contractor has given Village written notice of all conflicts, errors, ambiguities or
discrepancies that Contractor has discovered in the Contract Documents and the
written resolution thereof by Village is acceptable to Contactor, and the Contract
Documents are generally sufficient to indicate and convey understanding of all
terms and conditions for performance and furnishing of the Work.
7.1.8 The Contractor agrees and represents that it possesses the requisite skills to
perform the Work and that the Work shall be executed in a good and workmanlike
manner, free from defects, and that all materials shall be new and approved by or
acceptable to Village, except as otherwise expressly provided for in the Contract
Documents. The Contractor shall cause all materials and other parts of the Work
to be readily available as and when required or needed for or in connection with
the construction, furnishing and equipping of the Project.
7.2 Contractor warrants the following:
7.2.1 Anti -Discrimination: Contractor agrees that it will not discriminate against any
employees or applicants for employment or against persons for any other benefit
or service under this Contract because of race, color, religion, sex, national origin,
or physical or mental handicap where the handicap does not affect the ability of
an individual to perform in a position of employment, and agrees to abide by all
federal and state laws regarding non-discrimination.
7.2.2 Anti -Kickback: Contractor warrants that no person has been employed or
retained to solicit or secure this Contract upon an agreement or understanding for
a commission, percentage, brokerage or contingent fee, and that no employee or
officer of the Village has any interest, financially or otherwise, in the Project. For
breach or violation of this warranty, the Village shall have the right to annul this
Contract without liability or, in its discretion, to deduct from the Contract Price or
consideration, the full amount of such commission, percentage, brokerage or
contingent fee.
7.2.3 Licensing and Permits: Contractor warrants that it shall have, prior to
commencement of Work under this Contract and at all times during said Work, all
required licenses and permits whether federal, state, County or Village.
Contractor acknowledges that it is the obligation of Contractor to obtain all
licenses and permits required for this Project. The permits are:
None required.
6
ARTICLE 8
DEFAULT AND TERMINATION
8.1 If Contractor fails to timely begin the Work, or fails to perform the Work with sufficient
workers and equipment or with sufficient materials to insure the prompt completion of the
Work, or shall perform the Work unsuitably, or cause it to be rejected as defective and
unsuitable, or shall discontinue the prosecution of the Work pursuant to the accepted
schedule or if the Contractor shall fail to perform any material term set forth in the Contract
Documents or if Contractor shall become insolvent or be declared bankrupt, or commit any
act of bankruptcy or insolvency, or shall make an assignment for the benefit of creditors, or
from any other cause whatsoever shall not carry on the Work in an acceptable manner,
Village may, upon seven (7) days written Notice of Termination, terminate the services of
Contractor, exclude Contractor from the Project site, provide for a alternate prosecution of
the Work, appropriate or use any or all materials and equipment on the Project site as may
be suitable and acceptable, and may finish the Work by whatever methods it may deem
expedient. In such case Contractor shall not be entitled to receive any further payment until
the Project is completed. All damages, costs and charges incurred by Village, together with
the costs of completing the Project, shall be deducted from any monies due or which may
become due to Contractor. In case the damages and expenses so incurred by Village shall
exceed monies due Contractor from Village, Contractor shall be liable and shall pay to
Village the amount of said excess promptly upon demand therefore by Village. In the event
it is adjudicated that Village was not entitled to terminate the Contract as described
hereunder for default, the Contract shall automatically be deemed terminated by Village for
convenience as described below.
8.2 This Contract may be terminated by the Village for convenience upon seven (7) calendar
days' written notice to the Contractor. In the event of such a termination, the Contractor
shall incur no further obligations in connection with the Project and shall, to the extent
possible, terminate any outstanding subcontractor obligations. The Contractor shall be
compensated for all services performed to the satisfaction of the Village. In such event,
the Contractor shall promptly submit to the Village its Application for Payment for final
payment which shall comply with the provisions of the Contract Documents.
ARTICLE 9
MISCELLANEOUS
9.1 No Assignment.
7
Neither party shall assign the Contract or any sub -contract in whole or in part without the
written consent of the other, nor shall Contractor assign any monies due or to become due to
it hereunder, without the previous written consent of the Village Manager.
9.2 Contractor's Responsibility for Damages and Accidents:
9.2.1 Contractor shall accept full responsibility for the Work against all loss or damage of
any nature sustained until final acceptance by Village, and shall promptly repair any
damage done from any cause.
9.2.2 Contractor shall be responsible for all materials, equipment and supplies pertaining
to the Project. In the event any such materials, equipment and supplies are lost,
stolen, damaged or destroyed prior to final acceptance by Village, Contractor shall
replace same without cost to Village.
9.3 Defective Work. Warranty and Guarantee:
9.3.1 Village shall have the authority to reject or disapprove Work which the Village finds
to be defective. If required by the Village, Contractor shall promptly either correct
all defective Work or remove such defective Work and replace it with nondefective
Work. Contractor shall bear all direct, indirect and consequential costs of such
removal or corrections including cost of testing laboratories and personnel.
9.3.2 Should Contractor fail or refuse to remove or correct any defective Work or to make
any necessary repairs in accordance with the requirements of the Contract
Documents within the time indicated in writing by Village's Project Consultant,
Village shall have the authority to cause the defective Work to be removed or
corrected, or make such repairs as may be necessary at Contractor's expense. Any
expense incurred by Village in making such removals, corrections or repairs, shall
be paid for out of any monies due or which may become due to Contractor. In the
event of failure of Contractor to make all necessary repairs promptly and fully,
Village may declare Contractor in default.
9.3.3 The Contractor shall unconditionally warrant and guarantee all materials and
equipment furnished and Work performed for a period of one (1) year from the date
of substantial completion. If, within one (1) year after the date of substantial
completion, any of the Work is found to be defective or not in accordance with the
Contract Documents, Contractor, after receipt of written notice from Village, shall
promptly correct such defective or nonconforming Work within the time specified
by Village without cost to Village. Nothing contained herein shall be construed to
establish a period of limitation with respect to any other obligation which Contractor
might have under the Contract Documents including but not limited to any claim
regarding latent defects. Contractor shall provide and assign to Village all material
and equipment warranties upon completion of the Work hereunder.
8
9.3.4 Failure to reject any defective Work or material shall not in any way prevent later
rejection when such defect is discovered.
9.4 Legal Restrictions and Hours of Work:
Contractor shall conform to and obey all applicable laws, regulations, or ordinances with
regard to labor employed, hours of Work and Contractor's general operations. Contractor
shall conduct its operations so as not to interfere with or close any thoroughfare, without the
written consent of the Village or governing jurisdiction. Work is anticipated to be
performed Monday through Friday in accordance with the requirements and limitations
of applicable law including, without limitation, Chapter 17 of the Village Code. The
Contractor shall not perform Work beyond the time and days provided above without the
prior written approval of the Village.
9.5 Examination and Retention of Contractor's Records.
9.5.1 Village or any of its duly authorized representatives shall, until three (3) years after
final payment under this Contract, have access to and the right to examine any of the
Contractor's books, ledgers, documents, papers, or other records involving
transactions related to this Contract for the purpose of making audit, examination,
excerpts, and transcriptions.
9.5.2 The Contractor agrees to include in any subcontractor contracts for this Project
corresponding provisions for the benefit of Village providing for retention and audit
of records.
9.5.3 The right to access and examination of records stated herein and in any subcontracts
shall survive termination or expiration of this Contract and continue until disposition
of any mediation, claims, litigation or appeals related to this Project.
9.6 No Damages for Delay:
No claim for damages or any claim, other than for an extension of time shall be
made or asserted against Village by reason of any delays. Contractor shall not be
entitled to an increase in the Contract Price or payment or compensation of any kind
from Village for direct, indirect, consequential, impact or other costs, expenses or
damages, including but not limited to, costs of acceleration or inefficiency, arising
because of delay, disruption, interference or hindrance from any cause whatsoever,
whether such delay, disruption, interference or hindrance be reasonable or
unreasonable, foreseeable or unforeseeable, or avoidable or unavoidable or whether
or not caused by Village. Contractor shall be entitled only to extensions of the
Contract Time as the sole and exclusive remedy for such resulting delay.
Notwithstanding the above Contractor may be granted an extension of time and
suspension of liquidated damages for any delay beyond the control of the
9
Contractor. Should any delay, disruption, interference or hindrance be intentionally
caused by the Village, for a continuous period or cumulative period of thirty (30)
days, the Contractor may terminate the Contract upon seven days written notice to
the Village.
9.7 Public Entity Crimes Affidavit
Contractor shall comply with Section 287.133, Florida Statutes, (Public Entity
Crimes Statute) notification of which is hereby incorporated herein by reference,
including execution of any required affidavit.
9.8 Capitalized Terms
Capitalized terms shall have their plain meaning as indicated herein.
9.9 Independent Contractor:
The Contractor is an independent contractor under the Contract. This Contract does
not create any partnership or joint venture. Services provided by the Contractor shall
be by employees of the Contractor and subject to supervision by the Contractor, and
not as officers, employees, or agents of the Village. Personnel policies, tax
responsibilities, social security and health insurance, employee benefits, purchasing
policies and other similar administrative procedures, applicable to services rendered
under the Contract shall be those of the Contractor.
9.10 Payment to Sub -Contractors.
Certification of Payment to Subcontractors: The term "subcontractor", as used
herein, includes persons or firms furnishing labor, materials or equipment
incorporated into or to be incorporated into the Work or Project. The Contractor is
required to pay all subcontractors for satisfactory performance of their contracts as a
condition precedent to payment to Contractor by the Village. The Contractor shall
also return all retainage withheld to the subcontractors within 30 days after the
subcontractor's work is satisfactorily complete and accepted by the Village.
9.11 Governing Law
This Contract shall be construed in accordance with and governed by the laws of
the State of Florida. Venue for any litigation arising out of this Contract shall be
proper exclusively in Miami -Dade County, Florida.
9.12 Waiver of Jury Trial.
Village and Contractor knowingly, irrevocably, voluntarily and intentionally
waive any right either may have to a trial by jury in State and or Federal
10
court proceedings in respect to any action, proceeding, lawsuit or
counterclaim based upon the Contract for Construction, arising out of,
under, or in connection with the Construction of the Work, or any course of
conduct, course of dealing, statements or actions or inactions of any party.
9.13 Notices/Authorized Representatives.
Any notices required by this Contract shall be in writing and shall be deemed to
have been properly given if transmitted by hand -delivery, by registered or certified
mail with postage prepaid return receipt requested, or by a private postal service,
addressed to the parties (or their successors) at the following addresses:
For the Village:
With a copy to:
Genaro "Chip" Iglesias
88 W. McIntyre Street
Key Biscayne, Florida 33149
Stephen Helfman, Esq.
Village Attorney
Weiss Serota Helfman
Pastoriza Cole & Boniske, P.L.
2525 Ponce de Leon Blvd.
Coral Gables, Florida 33134
For The Contractor: Pelco
10762 SW 188 St.
Miami, Fla. 33157
Attn: Ben Barlow
ARTICLE 10
SPECIAL CONDITIONS
10.1 The following provisions supersede any provisions contained in this Contract only to the
extent of any conflict with same. These provisions are particular to a given transaction
and are transaction specific:
None
IN WITNESS WHEREOF, the parties hereto have made and executed this Agreement on
the respe tive dates under each st re: ILLAGE OF EY BISCAYNE, FLORIDA, si ng by
and h. it ill. ge Manager S �e� _ e��Council action on the � day of
d signing by and through
��► , duly authorized to execute same.
11
ATTEST:
APPROVED AS TO FORM
AND LEGAL SUFFICIENCY:
VILLAGE ATTORNEY
VILLAGE
Village ►f Key Biscay •, Florida, a municipal
corpora ► n of the State of lorid
CONTRACTOR MUST EXECUTE THIS CONTRACT AS INDICATED BELOW. USE
CORPORATION FORMAT, AS APPLICABLE.
CONTRACTOR:
[Corporate Seal)]
12
Mariana Dominguez -Hardie
Subject: O.L.D. valve replacement project - April 12th agenda item
From: Sean P. Compel [mailto:scompelCa�c3ts.coml
Sent: Wednesday, April 20, 2011 1:07 PM
To: Mariana Dominguez -Hardie
Subject: RE: O.L.D. valve replacement project - April 12th agenda item
Mariana:
There was no plan completed nor is there one required for this replacement work.
Sean Compel, P.E., LEED AP
"sscc�.lt
Corzo Castella Carballo Thompson Salman, P.A. (C3TS)
U i '(-)fl ,? Cie 2ecr, F3 v+d SuEte ,00
He') 33131
voice135 245 _900 ext 2230
i tla"I tici r;loei ' c Sts
�l CTI-,�
to er:cr r.Ie%xSe not Ty a and j€ ; r '. �t Ifil' 6�l ,dl'` C31 5
s'Itrjars Clrvl or [nterference 7. th this try 113 F75
From: Mariana Dominguez-Hardie[mailto:mdominciuez(fteybiscayne.fl.gov]
Sent: Wednesday, April 20, 2011 12:28 PM
To: Sean P. Compel
subject: O.L.D. valve replacement project - April 12th agenda item
Hi Sean,
Please refer to the section in the contract that specifies a plan as an attachment and also the
date of such.
I have not been able to locate a plan in our records.
Pls help.
Thanks.
Ocean Lane Pump Station OL-1 Valve Replacement Project
and in accordance with the plans prepared by CORZO CASTELLA CARBALLO
THOMPSON SALMAN, P.A. ("C3TS") (the "Village's Project Consultant") dated
(the "Plans") incorporated herein by reference and made a part of this Contract.
Mariana Dominguez -Hardie
1