HomeMy Public PortalAbout2020.03.26 Warrington ConstructionWarrington Construction Corp, of Oregon
Letter of Transmittal
TO: City of McCall
SPF Water Engineering
Date March 25, 2020
Attention:
Project: Jasper Subdivision, Phases II Water & Drainage Improvements 2020
We are sending you:
X Attached
The following items:
Plans
Other:
Quantity
1
1
1
1
I
Under Separate Cover V
Specifications Copy of letter
Description
Signed Agreement
Copy of Award of Project
Performance Bond & Payment Bond
Certificate of Liability Insurance
W-9
WH-5 Public Works Contract Report
Bidders Proposal as attached to original email
These are transmitted as checked below:
For approval
_X For your use
Remarks:
l.tl'U(G�I�C�
Andrea Warrington
As requested
For review and Comment
Catalog Submittals
Returned for correction
P.O. Box 910 • Ontario, Oregon 97914 • 208-452-2556 • 208-452-2557 Fax
Oregon CCB 101 184 • Idaho PWC-C 1 1590-AAA-4
I. AGREEMENT BETWEEN OWNER AND CONTRACTOR
FOR CONSTRUCTION CONTRACT
THIS AGREEMENT, is being made and entered i to thi i26 da,y of '�` 2020 and between The City of
McCall (hereinafter, "OWNER") and 2lirlil L'DY 0 ereinafter, "CONTRACTOR"):
NOW THEREFORE, the parties to this Contract, in consideration of the mutual covenants and stipulations set out,
agree as follows:
ARTICLE 1. CONTRACT DOCUMENTS
The Contract Documents which comprise the entire agreement between the OWNER or City and the Contractor
concerning the work to be performed are this Contract, pages one (1) through (5) and the following:
1. Bid Documents titled, JASPER SUBDIVISION, PHASE 11 WATER & DRAINAGE IMPROVEMENTS-
2020 with Addenda # 1 and #2
2. Standard General Conditions of the Construction Contract, 2017 ISPWC (Idaho Standards for Public Works
Construction) Division 100 (not attached) (pages 1 to 52, inclusive).
3. Bid Proposal (Section III) of the Contractor, dated February 14, 2020, to be physically attached to this
Contract;
4. The Construction Plans (12 sheets);
5. General Conditions (Section V)
6. Supplementary Conditions (Section VI)
7. Technical Specifications (Section VII)
8. Performance and Payment Bonds and Insurance Certificates, to be physically attached to this Contract;
9. The following which may be delivered or issued on or after the Effective Date of the Agreement and are not
attached hereto:
a. Notice of Award
b. Notice to Proceed.
c. Written Amendments.
d. Work Change Directives.
e. Change Orders.
f. Substantial completion certification
g. Final completion certification
10. Change Orders, which may be delivered or issued after the effective date of this Agreement;
11. Addenda issued prior to opening of bids, to be physically attached to this contract;
12. WH-5 — Public Works Contract Report for Idaho State Tax Commission
13. W9
There are no Contract Documents other than those listed in Article 1. This Contract may only be amended by change
order as provided in the General Conditions.
ARTICLE 2. WORK
The Contractor shall complete the entire work as specified, indicated and required under the Contract Documents.
The Work is generally described as follows: JASPER SUBDIVISION, PHASE II WATER & DRAINAGE
IMPROVEMENTS— 2020.
ARTICLE 3. PROJECT MANAGER and PROJECT ENGINEER
1.01 The City of McCall City Engineer (Project Manager), is to act as the OWNER's representative and
assume all duties and responsibilities, and have the rights and authority assigned to "OWNER" in the
Contract Documents in connection with the completion of the "Work" in accordance with the Contract
JASPER SUBDIVISION, PHASE II WATER & DRAINAGE IMPROVEMENTS - 2020 1 3/17/2020
Documents and the General Conditions of the Idaho Standards for Public Works Construction
(ISPWC).
1.02 The project has been designed by SPF Water Engineering, LLC (Project Engineer), which is to act as
the OWNER's representative, assume all duties and responsibilities, and have the rights and authority
assigned to "Engineer" in the Contract Documents in connection with the completion of the "Work" in
accordance with the Contract Documents and the General Conditions of the Idaho Standards for Public
Works Construction (ISPWC).
ARTICLE 4. CONTRACT TIMES/LE IITATIONS
4.01 Substantial Completion
The Contractor shall begin work in conformance with the Contract Documents and shall complete the work
prior to the date of completion. The project site will be available to the Contractor for project implementation
following Notice to Proceed anticipated by April 15, 2020 or when weather conditions permit, and only after
approval of the Project Engineer. The work to be performed pursuant to this Contract shall be substantially
complete within 120 working days after Notice to Proceed and/or no later than September 30, 20
a
The project will be considered "Substantially Complete" when all the water main, all hydrants, and all service
connections within the project limits are operational.
4.02 Final Completion
The work shall be fmally complete and ready for final payment, in accordance with Paragraph 14.07 of the
ISPWC General Conditions, within 5 working days of the date of Substantial Completion Certification or
before October 7, 2019.
4.03 Working Hours
Work can be performed 5 days a week (Monday through Friday) for a period of 12 hours (7:00 am to 7:00
PM) per day. Adjustment of the contract time can be made in accordance with the provisions of the Contract
Documents as directed by the Project Engineer, Public Works Director, or the OWNER.
4.04 Liquidated Damages
A. CONTRACTOR and OWNER recognize that time is of the essence of this Agreement and that OWNER will
suffer financial loss if the Work is not completed within the times specified in paragraph 4.02 above, plus any
extensions thereof allowed in accordance with Article 12 of the ISPWC Section 100 General Conditions. The
parties also recognize the delays, expense, and difficulties involved in proving in a legal preceding the actual
loss suffered by OWNER if the Work is not completed on time. Accordingly, instead of requiring any such
proof, OWNER and CONTRACTOR agree that as liquidated damages for delay (but not as a penalty),
CONTRACTOR shall pay OWNER $750.00 for each day that expires after the time specified in paragraph 4.02
for Substantial Completion until the Work is substantially complete. After Substantial Completion, if
CONTRACTOR shall neglect, refuse, or fail to complete the remaining Work within the Contract Time or any
proper extension thereof granted by OWNER, CONTRACTOR shall pay OWNER $750.00 for each day that
expires after the time specified in paragraph 4.02 for completion and readiness for final payment until the Work
is completed and ready for final payment.
ARTICLE 5. CONTRACT PRICE
OWNER shall pay CONTRACTOR for completion of the Work in accordance with the Contract Documents the amount
of four hundred ninety-three thousand, seventeen dollars and zero cents ($493,017.00) in current funds equal to the
sum of the amounts determined pursuant to the CONTRACTOR's Bid Proposal contained in Bid Form, Article 5, Section
III.
JASPER SUBDIVISION, PHASE 11 WATER& DRAINAGE IMPROVEMENTS-2020 2 3/17/2020
ARTICLE 6 - PAYMENT PROCEDURES
6.01 Submittal and Processing of Payments
A. CONTRACTOR shall submit Applications for Payment in accordance with Article 14 of the General
Conditions. Applications for Payment will be processed by ENGINEER as provided in the General Conditions.
Contractor shall provide an example Application for Payment submittal to the Project Engineer at the start of
the project for review and approval.
6.02 Progress Payments; Retainage
A. OWNER shall make progress payments on account of the Contract Price on the basis of CONTRACTOR's
Applications for Payment on or about the 30th day of each month during performance of the Work as provided
in paragraphs 6.02.A.1 and 6.02.A.2 below. All such payments will be measured by the schedule of values
established in paragraph 2.07.A of the General Conditions (and in the case of Unit Price Work based on the
number of units completed) or, in the event there is no schedule of values, as provided in the General
Requirements:
Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage
indicated below but, in each case, less the aggregate of payments previously made and less such
amounts as ENGINEER may determine or OWNER may withhold, in accordance with paragraph
14.02 of the General Conditions:
a. 95% of Work completed (with the balance being retainage): and
b. 95% of cost of materials and equipment not incorporated in the Work (with the balance being
retainage).
2. Upon Substantial Completion, Owner shall pay an amount sufficient to increase total payments to
Contractor to 95 percent of the Work completed, less such amounts as ENGINEER shall determine in
accordance with Paragraph 14.02.B.5.
6.03 Final Payment
A. Upon final completion and acceptance of the Work in accordance with paragraph 14.07 of the General
Conditions, OWNER shall pay the remainder ofthe Contract Price as recommended by ENGINEER as provided
in said paragraph 14.07, less any sum Owner is entitled to set off against Engineer's recommendation,
including but not limited to liquidated damages.
ARTICLE 7 - INTEREST
7.01 All moneys not paid when due as provided in Article 14 of the General Conditions shall bear interest at the rate
of 5% per annum.
ARTICLE 8. INDEPENDENT CONTRACTOR
The parties warrant by their signature that no employer -employee relationship is established between the Contractor
and the OWNER by the terms of this contract. It is understood by the parties hereto that the Contractor is an
independent contractor and as such neither it nor its employees, agents, representatives or subcontractors, if any, are
employees of the OWNER for purposes of tax, retirement system, or social security (FICA) withholding.
ARTICLE 9. SCOPE OF SERVICES
The Contractor shall perform all services required by the Contract Documents. All work shall be completed in
accordance with the specifications and plans established for this project.
JASPER SUBDIVISION, PHASE WATER& DRAINAGE IMPROVEMENTS-2020 3 3/17/2020
ARTICLE 10. HOLD HARMLESS/INDEMNIFICATION
In addition to other rights granted the OWNER by the Contract Documents, the Contractor shall indemnify and save
harmless the Architect and the Owner, its officers and employees, from all suits, actions, or claims of any character
brought because of any injuries or damages received or sustained by any person, persons, or property on account of
the operations of the Contractor or his subcontractors; or on account of or in consequence of any neglect in
safeguarding the work; or through use of unacceptable materials in constructing the work; or because of any act or
omission, neglect, or misconduct of the Contractor or his subcontractors; or because of any claims or amounts
recovered from any infringements of patent, trademark or copyright; or from any claims or amounts arising or
recovered under the Workmen's Compensation Act or any other law, ordinance, order or decree.
ARTICLE 11. CONFLICT OF INTEREST
The Contractor covenants that it presently has no interest and will not acquire any interest, direct or indirect, in the
project which would conflict in any manner or degree with the performance of its services hereunder. The Contractor
further covenants that, in performing this Contract, it will employ no person who has any such interest. Should any
conflict of interest arise during the performance of this Contract, Contractor shall immediately disclose such conflict
to the Project Manager, Architect and the OWNER.
ARTICLE 12. ENTIRE AGREEMENT, MODIFICATION AND ASSIGNABILITY
This Contract and the exhibits hereto contain the entire agreement between the parties, and no statements, promises,
or inducements made by either party, or agents of either party are valid or binding unless contained herein. This
contract may not be enlarged, modified or altered except upon written agreement signed by the parties hereto. The
Contractor may not subcontract or assign its rights (including the right to compensation) or duties arising hereunder
other than as contemplated by the Contract Documents, without the prior written consent and express authorization of
the OWNER.
ARTICLE 13. ADHERENCE TO LAW REQUIRED
All applicable local, state and federal statutes and regulations are hereby made a part of this contract and shall be
adhered to at all times. Violation of any of these statutes or regulations by the Contractor shall be deemed material
and shall subject the Contractor to termination of this contract for cause. No pleas of misunderstanding or ignorance
on the part of the Contractor will in any way serve to modify the provisions of this requirement. The Contractor and
his surety shall indemnify and save harmless the OWNER and the City of McCall and its employees, agents and
representatives against any claim or liability arising from or based on the violation of any such laws, codes, ordinances,
or regulations, whether by himself, his employees, or his subcontractors.
ARTICLE 14. LEGAL FEES
In the event either party incurs legal expenses to enforce the terms and conditions of this contract, the prevailing party
is entitled to recover reasonable attorney's fees and other costs and expenses, whether the same are incurred with or
without suit.
ARTICLE 15. SPECIAL WARRANTY
The Contractor warrants that nothing of monetary value has been given, promised or implied as remuneration or
inducement to enter into this Contract. The Contractor further declares that no improper personal, political or social
activities have been used or attempted in an effort to influence the outcome of the competition, discussion, or
negotiation leading to the award of this Contract. Any such activity by the Contractor shall make this Contract null
and void.
ARTICLE 16. COMMUNICATIONS
JASPER SUBDIVISION, PHASE B WATER & DRAINAGE IMPROVEMENTS - 2020 4 3/17/2020
Such communications as are required by this contract shall be satisfied by nailing or by personal delivery to the
parties at the followingaddress:
Contractor:
i
on , ,-t I
Owner: City of McCall
216 E. park Street
McCall., Idaho 83638
1N WITNESS WHEREOF, said Contractor and the OWNER or City has caused this Contract to be executed on the
day and year first above written.
Contractor: R C)
by' Robert S. (i es Mayor
ATTEST:
Approved .s To ]Fo
William F. Nicholls, ityAtto y
JAVER SUBDIVISION, PHASE 0 WAM & DRAINAGE I&VR0VMjWTS - 2020 5 3f 1'7/2020
I
Such communications u am ttquW by this coot sWI be sadstled by mailing or by personal delivery to the
partits at the following kldnm.
r n
tot
P.P. OZ .710
vnf)wtj,4141+—
owner. City of McCall
216 E. Park Street
McCall, Idaho 83638
IN WITNESS WHEREOF, said Conusaw and ft OWNER or City has caused this Conhact to be exemftd on the
day and yea fh* above wrtum
C40butor kklgg#1470)v Co*s:r Owner.
Jtx
X=Xj kV
be Robert S. Giles, Mayor
ATIEST:
&Mieio Wagw, Cky Clark
. .... . . . .
............
Approved As To Form.
Willism, F. RkhA City Aftorney
ACKNOWLEDOMDU
On this day of h*#.4* ------------- * 2020, before me, a
Iwe at
My Q=MbSiOft CXPVft
tau."
to Mon
...............
3/1712020
(W)
SPF WATER
ENGINEERING
March 17, 2020
Brooks Warrington
Owner / Project Manager
Warrington Construction Corp of Oregon
PO Box 910
Ontario, OR 97914
brookswarrington@gmail.com
208-452-2556
Contract: Jasper Subdivision, Phase II Water & Drainage Improvements, 2020
Dear Brooks,
You are notified that your bid proposal dated February 14, 2020 for the above Contract has
been considered and approved by City Council. You are hereby notified that you are the
Successful Bidder and have been awarded a Contract for the Jasper Subdivision, Phase II
Water & Drainage Improvements, 2020 project.
The Total Contract Price of your Contract is: $493,017 (four hundred ninety-three thousand,
seventeen dollars and zero cents).
1 copy of each of the proposed Contract Documents accompany this Notice of Award.
You must comply with the following condition precedent within 10 days of the date you
receive this Notice of Award.
1. Deliver to the OWNER fully executed counterparts of the Contract Documents. [Each
of the Contract Document must bear your signature].
2. Deliver with the executed Contract Documents the Contract security (Bonds) as
specified in the General Conditions (GC-18).
3. Deliver with the executed Contract Documents Contractor's Affidavit Concerning
Taxes.
Failure to comply with these conditions within the time specified will entitle OWNER to
consider your Bid Default, to annul this Notice of Award and to declare your Bid security
forfeited.
Within thirty days after you comply with the above condition, OWNER will return to you two
fully executed counterpart of the Contract Documents.
300 E. Mallard Drive, Suite 350, Boise, Idaho 83706 Tel: 208-383-4140 Fax: 208-383-4156
City of McCall
(OWNER)
By:
(AUT RIZED IG ATURE)
Project Manager
(TITLE)
Page 2
EJCDC=
ENGINEERS JOINT CONTRACT
DOCUMENTS COMMITTEE
PERFORMANCE BOND
CONTRACTOR (name and address):
Warrington Construction Corporation of Oregon
P.O. Box 910
Ontario, OR 97914
OWNER (name and address):
City of McCall
216 E. Park Street
McCall, ID 83638
CONSTRUCTION CONTRACT
SURETY (name and address of principal place of business):
Liberty Mutual Insurance Company
175 Berkeley Street
Boston, MA 02116
Effective Date of the Agreement: 3 - Z4 - 7-0 7"U
Amount: $493,017.00 Four Hundred Ninety Three Thousand Seventeen Dollars and 00/100
Description (name and location): Jasper Subdivision, Phase II Water & Drainage Improvements, 2020
BOND
Bond Number: 023210294
Date (not earlier than the Effective Date of the Agreement of the Construction Contract): 3 - 2-!0 -� ZC7
Amount: $493,017.00 Four Hundred Ninety Three Thousand Seventeen Dollars and 00/100
Modifications to this Bond Form: ® None ❑ See Paragraph 16
Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth below, do each cause
this Performance Bond to be duly executed by an authorized officer, agent, or representative.
CONTRACTOR AS PRINCIPAL SURETY
0%11111�%% %ST.iCo�A i, J . q p �nsu
Warrington Construction Corpor13tls�br•., :��E)yl) Liberty Mutual insurance Company
eal RpORATt�% Surety's Name and Corporate Seal
Contractors Name and Corpoo.1912
� � � � : G7 . G i j 9'rs'ACIN`'�`42
By: • 4 r� By:
Signature ;'• Signature (ottach p erof attorney)
wC •• ••'%Ax A%% Brenda J. Smith
Print Name//�������� Print Name
Title
Attest:
Signature
Title
Attorney -in -Fact
Title
Attest: /Jo��A
SignaLie Victoria D. McCurdy
Witness
Title
Notes: (1) Provide supplemental execution by any additional parties, such as joint venturers. (2) Any singular reference to
Contractor, Surety, Owner, or other party shall be considered plural where applicable.
EJCDC° C-610, Performance Bond
Copyright m 2013 National Society of Professional Engineers, American Council of Engineering Companies,
and American Society of civil Engineers. All rights reserved. 1 of 3
1. The Contractor and Surety, jointly and severally, bind
themselves, their heirs, executors, administrators, successors, and
assigns to the Owner for the performance of the Construction
Contract, which is incorporated herein by reference.
2. If the Contractor performs the Construction Contract, the Surety
and the Contractor shall have no obligation under this Bond, except
when applicable to participate in a conference as provided in
Paragraph 3.
3. If there is no Owner Default under the Construction Contract,
the Surety's obligation under this Bond shall arise after:
3.1 The Owner first provides notice to the Contractor and
the Surety that the Owner is considering declaring a Contractor
Default. Such notice shall indicate whether the Owner is
requesting a conference among the Owner, Contractor, and
Surety to discuss the Contractor's performance. if the Owner
does not request a conference, the Surety may, within five (5)
business days after receipt of the Owner's notice, request such a
conference. If the Surety timely requests a conference, the
Owner shall attend. Unless the Owner agrees otherwise, any
conference requested under this Paragraph 3.1 shall be held
within ten (10) business days of the Surety's receipt of the
Owner's notice. If the Owner, the Contractor, and the Surety
agree, the Contractor shall be allowed a reasonable time to
perform the Constmctlon Contract, but such an agreement shall
not waive the Owner's right, if any, subsequently to declare a
Contractor Default;
3.2 The Owner declares a Contractor Default, terminates
the Construction Contract and notifies the Surety; and
3.3 The Owner has agreed to pay the Balance of the
Contract Price in accordance with the terns of the Construction
Contract to the Surety or to a contractor selected to perform the
Construction Contract.
4. Failure on the part of the Owner to comply with the notice
requirement in Paragraph 3.1 shall not constitute a failure to comply
with a condition precedent to the Surety's obligations, or release the
Surety from its obligations, except to the extent the Surety
demonstrates actual prejudice.
S. When the Owner has satisfied the conditions of Paragraph 3, the
Surety shall promptly and at the Surety's expense take one of the
following actions:
5.1 Arrange for the Contractor, with the consent of the
Owner, to perform and complete the Construction Contract;
5.2 Undertake to perform and complete the Construction
Contract itself, through its agents or independent contractors;
5.3 Obtain bids or negotiated proposals from qualified
contractors acceptable to the Owner for a contract for
performance and completion of the Construction Contract,
arrange for a contract to be prepared for execution by the
Owner and a contractor selected with the Owners concurrence,
to be secured with performance and payment bonds executed
by a qualified surety equivalent to the bonds issued on the
Construction Contract, and pay to the Owner the amount of
damages as described in Paragraph 7 in excess of the Balance of
the Contract Price incurred by the Owner as a result of the
Contractor Default; or
5.4 Waive its right to perform and complete, arrange for
completion, or obtain a new contractor, and with reasonable
promptness under the circumstances:
5.4.1 After investigation, determine the amount for
which It may be liable to the Owner and, as soon as
practicable after the amount is determined, make payment
to the Owner; or
5.4.2 Deny liability in whole or in part and notify the
Owner, citing the reasons for denial.
6. if the Surety does not proceed as provided in Paragraph 5 with
reasonable promptness, the Surety shall be deemed to be in default
on this Bond seven days after receipt of an additional written notice
from the Owner to the Surety demanding that the Surety perform its
obligations under this Bond, and the Owner shall be entitled to
enforce any remedy available to the Owner. if the Surety proceeds as
provided In Paragraph 5.4, and the Owner refuses the payment or the
Surety has denied liability, in whole or in part, without further notice
the Owner shall be entitled to enforce any remedy available to the
Owner.
7. If the Surety elects to act under Paragraph 5.1, 5.2, or 5.3, then
the responsibilities of the Surety to the Owner shall not be greater
than those of the Contractor under the Construction Contract, and
the responsibilities of the Owner to the Surety shall not be greater
than those of the Owner under the Construction Contract. Subject to
the commitment by the Owner to pay the Balance of the Contract
Price, the Surety is obligated, without duplication for:
7.1 the responsibilities of the Contractor for correction of
defective work and completion of the Construction Contract;
7.2 additional legal, design professional, and delay costs
resulting from the Contractor's Default, and resulting from the
actions or failure to act of the Surety under Paragraph 5; and
7.3 liquidated damages, or if no liquidated damages are
specified In the Construction Contract, actual damages caused by
delayed performance or non-performance of the Contractor.
8. If the Surety elects to act under Paragraph 5.1, 53, or 5.4, the
Surety's liability is limited to the amount of this Bond.
9. The Surety shall not be liable to the Owner or others for
obligations of the Contractor that are unrelated to the Construction
Contract, and the Balance of the Contract Price shall not be reduced
or set off on account of any such unrelated obligations. No right of
action shall accrue on this Bond to any person or entity other than
the Owner or its heirs, executors, administrators, successors, and
assigns.
EJCDC• G610, Performance Bond
Copyright m 2013 National Society of Professional Engineers, American Council of Engineering Companies,
and Amedon Society of Civil Engineers. All rights reserved. 2 of 3
10. The Surety hereby waives notice of any change, including
changes of time, to the Construction Contract or to related
subcontracts, purchase orders, and other obligations.
11. Any proceeding, legal or equitable, under this Bond may be
instituted in any court of competent jurisdiction in the location in
which the work or part of the work is located and shall be instituted
within two years after a declaration of Contractor Default or within
two years after the Contractor ceased working or within two years
after the Surety refuses or fails to perform its obligations under this
Bond, whichever occurs first. If the provisions of this paragraph are
void or prohibited by law, the minimum periods of limitations
available to sureties as a defense in the jurisdiction of the suit shall be
applicable.
12. Notice to the Surety, the Owner, or the Contractor shall be
mailed or delivered to the address shown on the page on which their
signature appears.
13. When this Bond has been furnished to comply with a statutory
or other legal requirement in the location where the construction was
to be performed, any provision in this Bond conflicting with said
statutory or legal requirement shall be deemed deleted herefrom and
provisions conforming to such statutory or other legal requirement
shall be deemed incorporated herein. When so furnished, the intent
is that this Bond shall be construed as a statutory bond and not as a
common law bond.
14. Definitions
14.1 Balance of the Contract Price: The total amount
payable by the Owner to the Contractor under the Construction
Contract after all proper adjustments have been made Including
allowance for the Contractor for any amounts received or to be
received by the Owner in settlement of insurance or other claims
for damages to which the Contractor is entitled, reduced by all
valid and proper payments made to or on behalf of the
Contractor under the Construction Contract.
14.2 Construction Contract: The agreement between the
Owner and Contractor identified on the cover page, including all
Contract Documents and changes made to the agreement and
the Contract Documents.
14.3 Contractor Default: Failure of the Contractor, which
has not been remedied or waived, to perform or otherwise to
comply with a material term of the Construction Contract.
14.4 Owner Default: Failure of the Owner, which has not
been remedied or waived, to pay the Contractor as required
under the Construction Contract or to perform and complete or
comply with the other material terms of the Construction
Contract.
14.5 Contract Documents: All the documents that comprise
the agreement between the Owner and Contractor.
15. If this Bond is issued for an agreement between a contractor and
subcontractor, the term Contractor in this Bond shall be deemed to
be Subcontractor and the term Owner shall be deemed to be
Contractor.
16. Modifications to this Bond are as follows:
EJCDC° C-610, Performance Bond
Copyright ® 2013 National Society of Professional Engineers, American Council of Engineering Companies,
and American Society of Civil Engineers. All rights reserved. 3 of 3
EJCDCNN;
ENGINEERS JOINT CONTRACT
DOCUMENTS COMMITTEE
CONTRACTOR (name and address):
Warrington Construction Corporation of Oregon
P.O. Box 910
Ontario, OR 97914
OWNER (name and address):
City of McCall
216 E. Park Street
McCall, ID 83638
CONSTRUCTION CONTRACT
PAYMENT BOND
SURETY (name and address of p
Liberty Mutual Insurance Company
175 Berkeley Street
Boston, MA 02116
Effective Date of the Agreement: 3- ZL - L0 'LC.
Amount: $493,017.00 Four Hundred Ninety Three Thousand Seventeen Dollars and 00/100
Description (name and location): Jasper Subdivision, Phase II Water & Drainage Improvements, 2020
BOND
Bond Number: 023210294
Date (not earlier than the Effective Date of the Agreement of the Construction Contract): 3 -'Z C. - T-W-L r
Amount: $493,017.00 Four Hundred Ninety Three Thousand Seventeen Dollars and 00/100
Modifications to this Bond Form: ® None ❑ See Paragraph 18
Surety and Contractor, intending to be legally bound hereby, subject to the terms set forth below, do each cause
this Payment Bond to be duly executed by an authorized officer, agent, or representative.
CONTRACTOR AS PRINCIPAL
S,ONST. CpRp i��
Warrington Construction Corporatiar 1VcJregon•'''••,r�
Contractor's Name and CorporaGORpORATE
• C2,
By: li; 2
Signature �� �� • * `�
2hdrl A Karr Ul�
-i�1y EG°��`��
1111-
Print Name
Title
Attest: L
Signature
Title
SURETY
Liberty Mutual Insurance Compan
Surety's Name and Corporate Se ��y°'��'^
By:
Signature (attac power of attorney) #
Brenda J. Smith
Print Name
Attornev-in-Fact
Title
Attest:
Signs re Victoria D. McCurdy
Witness
Title
Notes: (1) Provide supplemental execution by any additional parties, such as joint venturers. (2) Any singular reference
to Contractor, Surety, Owner, or other party shall be considered plural where applicable.
EJCDC° C-61S, Payment Bond
Copyright ® 2013 National Society of Professional Engineers, American Council of Engineering Companies,
and American Society of Civil Engineers. All rights reserved. 1 of 3
1. The Contractor and Surety, jointly and severally, bind
themselves, their heirs, executors, administrators,
successors, and assigns to the Owner to pay for labor,
materials, and equipment furnished for use in the
performance of the Construction Contract, which is
incorporated herein by reference, subject to the following
terms.
6. If a notice of non-payment required by Paragraph 5.1.1 is
given by the Owner to the Contractor, that is sufficient to
satisfy a Claimants obligation to furnish a written notice of
non-payment under Paragraph 5.1.1.
7. When a Claimant has satisfied the conditions of Paragraph
5.1 or 5.2, whichever is applicable, the Surety shall
promptly and at the Surety's expense take the following
actions:
2. If the Contractor promptly makes payment of all sums due
to Claimants, and defends, indemnifies, and holds
7.1 Send an answer to the Claimant, with a copy to the
harmless the Owner from claims, demands, liens, or suits
Owner, within sixty (60) days after receipt of the
by any person or entity seeking payment for labor,
Claim, stating the amounts that are undisputed and
materials, or equipment furnished for use in the
the basis for challenging any amounts that are
performance of the Construction Contract, then the Surety
disputed; and
and the Contractor shall have no obligation under this
Bond.
7.2 Pay or arrange for payment of any undisputed
amounts.
3. If there is no Owner Default under the Construction
Contract, the Surety's obligation to the Owner under this
7.3 The Surety's failure to discharge its obligations
Bond shall arise after the Owner has promptly notified the
under Paragraph 7.1 or 7.2 shall not be deemed to
Contractor and the Surety (at the address described in
constitute a waiver of defenses the Surety or
Paragraph 13) of claims, demands, liens, or suits against
Contractor may have or acquire as to a Claim,
the Owner or the Owner's property by any person or
except as to undisputed amounts for which the
entity seeking payment for labor, materials, or equipment
Surety and Claimant have reached agreement. If,
furnished for use in the performance of the Construction
however, the Surety fails to discharge its
Contract, and tendered defense of such claims, demands,
obligations under Paragraph 7.1 or 7.2, the Surety
liens, or suits to the Contractor and the Surety,
shall indemnify the Claimant for the reasonable
attorney's fees the Claimant incurs thereafter to
4. When the Owner has satisfied the conditions in Paragraph
recover any sums found to be due and owing to
3, the Surety shall promptly and at the Surety's expense
the Claimant.
defend, indemnify, and hold harmless the Owner against a
duly tendered claim, demand, lien, or suit.
8. The Surety's total obligation shall not exceed the amount
of this Bond, plus the amount of reasonable attorney's
S. The Surety's obligations to a Claimant under this Bond
fees provided under Paragraph 7.3, and the amount of this
shall arise after the following:
Bond shall be credited for any payments made in good
faith by the Surety.
5.1 Claimants who do not have a direct contract with
the Contractor,
9. Amounts owed by the Owner to the Contractor under the
Construction Contract shall be used for the performance
5.1.1 have furnished a written notice of non-
of the Construction Contract and to satisfy claims, if any,
payment to the Contractor, stating with
under any construction performance bond. By the
substantial accuracy the amount claimed
Contractor furnishing and the Owner accepting this Bond,
and the name of the party to whom the
they agree that all funds earned by the Contractor in the
materials were, or equipment was,
performance of the Construction Contract are dedicated
furnished or supplied or for whom the
to satisfy obligations of the Contractor and Surety under
labor was done or performed, within
this Bond, subject to the Owner's priority to use the funds
ninety (90) days after having last
for the completion of the work.
performed labor or last furnished
materials or equipment included in the
10. The Surety shall not be liable to the Owner, Claimants, or
Claim; and
others for obligations of the Contractor that are unrelated
to the Construction Contract. The Owner shall not be
5.1.2 have sent a Claim to the Surety (at the
liable for the payment of any costs or expenses of any
address described in Paragraph 13).
Claimant under this Bond, and shall have under this Bond
no obligation to make payments to or give notice on
5.2 Claimants who are employed by or have a direct
behalf of Claimants, or otherwise have any obligations to
contract with the Contractor have sent a Claim to
Claimants under this Bond.
the Surety (at the address described In Paragraph
13).
11. The Surety hereby waives notice of any change, including
changes of time, to the Construction Contract or to related
subcontracts, purchase orders, and other obligations.
EJCDC' C-615, Payment Bond
Copyright 0 2013 National Society of Professional Engineers, American Council of Engineering Companies,
and American Society of Civil Engineers. All rights reserved. 2 of 3
12. No suit or action shall be commenced by a Claimant under
8. The total amount due and unpaid to the
this Bond other than In a court of competent jurisdiction in
Claimant for labor, materials, or equipment
the state In which the project that is the subject of the
furnished as of the date of the Claim.
Construction Contract is located or after the expiration of
one year from the date (1) on which the Claimant sent a
16.2 Claimant: An individual or entity having a direct
Claim to the Surety pursuant to Paragraph 5.1.2 or 5.2, or
contract with the Contractor or with a
(2) on which the last labor or service was performed by
subcontractor of the Contractor to furnish labor,
anyone or the last materials or equipment were furnished
materials, or equipment for use in the performance
by anyone under the Construction Contract, whichever of
of the Construction Contract. The term Claimant
(1) or (2) first occurs. If the provisions of this paragraph
also includes any individual or entity that has
are void or prohibited by law, the minimum period of
rightfully asserted a claim under an applicable
limitation available to sureties as a defense in the
mechanic's lien or similar statute against the real
jurisdiction of the suit shall be applicable.
property upon which the Project is located. The
intent of this Bond shall be to include without
13. Notice and Claims to the Surety, the Owner, or the
limitation in the terms of "labor, materials, or
Contractor shall be mailed or delivered to the address
equipment" that part of the water, gas, power,
shown on the page on which their signature appears.
light, heat, oil, gasoline, telephone service, or
Actual receipt of notice or Claims, however accomplished,
rental equipment used in the Construction
shall be sufficient compliance as of the date received.
Contract, architectural and engineering services
required for performance of the work of the
14. When this Bond has been furnished to comply with a
Contractor and the Contractor's subcontractors,
statutory or other legal requirement in the location where
and all other items for which a mechanic's lien may
the construction was to be performed, any provision In
be asserted in the jurisdiction where the labor,
this Bond conflicting with said statutory or legal
materials, or equipment were furnished.
requirement shall be deemed deleted herefrom and
provisions conforming to such statutory or other legal
16.3 Construction Contract: The agreement between
requirement shall be deemed incorporated herein. When
the Owner and Contractor identified on the cover
so furnished, the intent is that this Bond shall be construed
page, including all Contract Documents and all
as a statutory bond and not as a common law bond.
changes made to the agreement and the Contract
Documents.
15. Upon requests by any person or entity appearing to be a
potential beneficiary of this Bond, the Contractor and
Owner shall promptly furnish a copy of this Bond or shall
permit a copy to be made.
16. Definitions
16.1 Claim: A written statement by the Claimant
Including at a minimum:
1. The name of the Claimant,
2. The name of the person for whom the labor
was done, or materials or equipment
furnished;
3. A copy of the agreement or purchase order
pursuant to which labor, materials, or
equipment was furnished for use in the
performance of the Construction Contract;
4. A brief description of the labor, materials, or
equipment furnished;
S. The date on which the Claimant last
performed labor or last furnished materials or
equipment for use in the performance of the
Construction Contract;
6. The total amount earned by the Claimant for
labor, materials, or equipment furnished as of
the date of the Claim;
7. The total amount of previous payments
received by the Claimant; and
16.4 Owner Default: Failure of the Owner, which has
not been remedied or waived, to pay the
Contractor as required under the Construction
Contract or to perform and complete or comply
with the other material terms of the Construction
Contract.
16.5 Contract Documents: All the documents that
comprise the agreement between the Owner and
Contractor.
17. If this Bond is issued for an agreement between a
contractor and subcontractor, the term Contractor in this
Bond shall be deemed to be Subcontractor and the term
Owner shall be deemed to be Contractor.
18. Modifications to this Bond are as follows:
EJCDC* C-615, Payment Bond
Copyright ® 2013 National Society of Professional Engineers, American Council of Engineering Companies,
and American society of Civil Engineers. All rights reserved. 3 of 3
This Power of Attorney limits the acts of those named herein, and they have no authority to bind the Company except in the manner and to the extent herein stated. Not
valid for mortgage, note, loan, letter of credit, bank deposit, currency rate, Interest rate or residual value guarantees. To confirm the validity of this Power of Attorney call
610.832.8240 between 9:00 am and 4:30 Dm EST on any business day.
Liberty
Mutual.
SURETY
Liberty Mutual Insurance Company
The Ohio Casualty Insurance Company
West American Insurance Company
POWER OF ATTORNEY
KNOWN ALL PERSONS BY THESE PRESENTS: That The Ohio Casualty Insurance Company is a corporation duly organized under the laws of the State of New Hampshire, that Liberty
Mutual Insurance Company is a corporation duly organized under the laws of the State of Massachusetts, and West American Insurance Company is a corporation duly organized under
the laws of the State of Indiana (herein collectively called the `Companies"), pursuant to and by authority herein set forth, does hereby name, constitute and appoint, Brenda J.
Smith of the city of Boise , state of ID its true and lawful attorney -in -fact, with full power and authority hereby conferred to sign,
execute and acknowledge the following surety bond:
Principal Name: Warrington Construction Corporation of Oregon
Obligee Name: City of McCall
Surety Bond Number, 023210294 Bond Amount: See Bond Form
IN WITNESS WHEREOF, this Power of Attorney has been subscribed by an authorized officer or official of the Companies and the corporate seats of the Companies have been affixed
thereto this 12h day of December, 2018.
INSU `SY INSU NWSUgq The Ohio Casualty Insurance Company
J��P o�o�lti�� Liberty Mutual Insurance Company
Wes erican Insurance Company
1912 i 1919 i N 1991 a
�n O
HAMP`rlQ, � �t'OIANP By:
J ACID' ! David .Carey, Assistant Secretary
* t
STATE OF PENNSYLVANIA ss
COUNTY OF MONTGOMERY
On this 1211 lty Coday, of December, 2018'before me personally appeared David M. Carey, who acknowledged himself to be the Assistant Secretary of Liberty Mutual Insurance Company,
The Ohio Casuampany, and West American Insurance Company, and that he, as such, being authorized so to do, execute the foregoing instrument for the purposes therein contained
by signing on behalf of the corporations by himself as a duly authorized officer.
IN WITNESS WHEREOF, I have hereunto subscribed my name and affixed my notarial seal at King of Prussia, Pennsylvania, on the day and year first above written.
gyp PASTS COMMONWEALTH OF PENNSYLVANIA
�Q o*MONwf� !� Notarial Seal
Teresa Pastella, Notary Public
OF Upper Marion Twp., Montgomery County BY -
�\P My Commission Expires March 28, 2021 Teresa Pastella, otary Public
.yAgyt,VP `G Member, Pennsylvania Association of Notaries
�qny t �
This Power of Attome is made and executed pursuant to and by authority of the following By-laws and Authorizations of Liberty Mutual Insurance Company, The Ohio Casualty Insurance
Company, and West American Insurance Company which resolutions are now in full force and effect reading as follows:
ARTICLE IV - OFFICERS - Section 12. Power of Attorney. Any officer or other official of the Corporation authorized for that purpose in writing by the Chairman or the President, and
subject to such limitation as the Chairman or the President may prescribe, shall appoint such attorneys -in -tact, as may be necessary to act in behalf of the Corporation to make, execute,
seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attomeys-in-fact, subject to the limitations set forth in their
respective powers of attorney, shall have full power to bind the Corporation by their signature and execution of any such instruments and to attach thereto the seal of the Corporation.
When so executed, such instruments shalt be as binding as if signed by the President and attested to by the Secretary. Any power or authority granted to any representative or attorney -
in -fact under the provisions of this article may be revoked at any time by the Board, the Chairman, the President or by the officer or officers granting such power or authority.
ARTICLE XIII - Execution of Contracts - SECTION 5. Surety Bonds and Undertakings. Any officer of the Company authorized for that purpose in writing by the chairman or the president,
and subject to such limitations as the chairman or the president may prescribe, shall appoint such attomeys-in-fact, as may be necessary to act in behalf of the Company to make, execute,
seal, acknowledge and deliver as surety any and all undertakings, bonds, recognizances and other surety obligations. Such attomeys-in-fact subject to the limitations set forth in their
respective powers of attorney, shall have full power to bind the Company by their signature and execution of any such instruments and to attach thereto the seal of the Company. When
so executed such instruments shall be as binding as if signed by the president and attested by the secretary.
Certificate of Designation - The President of the Company, acting pursuant to the Bylaws of the Company, authorizes David M. Carey, Assistant Secretary to appoint such attomeys-in-
fact as may be necessary to act on behalf of the Company to make, execute, seal, acknowledge and deliver as surety any and at I undertakings, bonds, reoognizances and other surety
obligations.
Authorization - By unanimous consent of the Company's Board of Directors, the Company consents that facsimile or mechanically reproduced signature of any assistant secretary of the
Company, wherever appearing upon a certified copy of any power of attorney issued by the Company in connection with surety bonds, shall be valid and binding upon the Company with
the same force and effect as though manually affixed.
1, Renee C. Llewellyn, the undersigned, Assistant Secretary, of Liberty Mutual Insurance Company, The Ohio Casualty Insurance Company, and West American Insurance Company
do hereby certify that this power of attomey executed by said Companies is in full force and effect and has not beef revoked. rn
IN TESTIMONY WHEREOF, I have hereunto set my hand and affixed the seals of said Companies this 24 day of ' ' /� Gw zU
LINSUq P�ZY INSU �%%Msu
rvo �m �e`J °avo¢�rotirCP n Z��.1 o� o
r+ o o c 3 By: Zg
1912 v o ti 19i9 ab W 1991 a e ee C. Lle ell Assistant Secretary
2
*
��1 W A R R I - 2
, 4 ��o R O C E R T I F I C A T E O F L I A B I L I T Y I N S U R A N C E
O P I D : T J
D A 3 / 2 3 / D / Y Y
3 / 2 3 / 2 0 2 0
0 0
T H I S C E R T I F I C A T E I S I S S U E D A S A M A T T E R O F I N F O R M A T I O N O N L Y A N D C O N F E R S N O R I G H T S U P O N T H E C E R T I F I C A T E H O L D E R . T H I S
C E R T I F I C A T E D O E S N O T A F F I R M A T I V E L Y O R N E G A T I V E L Y A M E N D , E X T E N D O R A L T E R T H E C O V E R A G E A F F O R D E D B Y T H E P O L I C I E S
B E L O W . T H I S C E R T I F I C A T E O F I N S U R A N C E D O E S N O T C O N S T I T U T E A C O N T R A C T B E T W E E N T H E I S S U I N G I N S U R E R ( S ) , A U T H O R I Z E D
R E P R E S E N T A T I V E O R P R O D U C E R , A N D T H E C E R T I F I C A T E H O L D E R .
I M P O R T A N T : I f t h e c e r t i f i c a t e h o l d e r i s a n A D D I T I O N A L I N S U R E D , t h e p o l i c y ( i e s ) m u s t h a v e A D D I T I O N A L I N S U R E D p r o v i s i o n s o r b e e n d o r s e d .
I f S U B R O G A T I O N I S W A I V E D , s u b j e c t t o t h e t e r n s a n d c o n d i t i o n s o f t h e p o l i c y , c e r t a i n p o l i c i e s m a y r e q u i r e a n e n d o r s e m e n t . A s t a t e m e n t o n
t h i s c e r t i f i c a t e d o e s n o t c o n f e r r i g h t s t o t h e c e r t i f i c a t e h o l d e r i n l i e u o f s u c h e n d o r s e m e n t s .
P R O D U C E R 5 4 1 - 8 8 9 - 8 2 1 9
T h e I n s u r a n c e G r o u p , I n c .
P . O . B o x 7 1 8
O n t a r i o , O R 9 7 9 1 4 - 0 7 1 8
G r e g o r y K . T u t t l e
N Q N T A C T M i c h a e l C . M i l l e r
P H O N E 5 4 1 - 8 8 9 - 8 2 1 9 F A X 5 4 1 - 8 8 9 - 7 4 1 5
( A / C , N o , E x t ) : ( A / C , N o ) :
E - M A I L
A D D R E S S :
I N S U R E R S A F F O R D I N G C O V E R A G E
N A I C 9
I N S U R E R A : E M C I n s u r a n c e C o m p a n i e s
2 1 4 1 5
R E D
% S U r i n g t o n C o n s t r u c t i o n C o r p
p O B O d n O
O n t a r i o , O 9 7 9 1 4
I N S U R E R B : S t a t e I n s u r a n c e F u n d
3 6 1 2 9
I N S U R E R C :
I N S U R E R D
I N S U R E R E :
I N S U R E R F :
C O V F R A G F A r F R T I F I ( '