HomeMy Public PortalAboutORD10633 BILL NO. 17
SPONSORED BY COUNCILMAN
ORDINANCE NO.
AN ORDINANCE OF THE CITY OF JEFFERSON, MISSOURI, AUTHORIZING THE MAYOR AND
CITY CLERK TO EXECUTE A CONTRACT WITH WILLARD STOCKMAN CONSTRUCTION
CORPORATION FOR THE 1986 CURB AND GUTTER PROJECTS, PHASE IV.
BE IT ENACTED BY THE CITY COUNCIL OF THE CITY OF JEFFERSON, MISSOURI, AS
FOLLOWS:
Section 1. The Mayor and Clerk are hereby authorized and directed to
execute a contract with Willard Stockman Construction Corporation, for the
1986 Curb and Gutter Projects, Phase IV for the sum of $281,003.00.
Section 2. The contract shall be substantially the same in fora and
content- as that contract attached hereto as Exhibit A.
Section 3. This Ordinance shall be in full force and effect from and
after the date of its passage and approval.
Passed IAz Approved
qP
P sid ng Offi er Mayor
ATTEST:
6 ..- . A
City Clerk
CONSTRUCTION CONTRACT
Ah
THIS CONTRACT, made and entered into this � 3 day of
April 19 86 by and between Willard Stockman
Construction Corporation - hereinafter called
"Contractor", and the City of Jefferson, Missouri, a municipal
corporation, hereinafter called "City."
WITNESSETH: That Whereas, the Contractor has become the
lowest responsible bidder for furnishing the supervision, labor,
tools, equipment, materials and supplies and for constructing the
following City i1riprovements: 1986 Curb & Gutter Project Phase IV
Swifts Highway - Flora Drive
NOW, THEREFORE, the parties to this contract agree to the
following:
1. Manner and time for Completion. The Contractor agrees
with the City to furnish a.].1 supervision, labor, tools,
equipment, materials and supplies necessary to perform, and to
perform, said work at Contractor's own expense in accordance with
the contract documents and any applicable City ordinances and
state and federal laws, within ninety (90) (calendar,)
days from the date Contractor is ordered to proceed, which order
shall be issued by the Director of Public Works within two (2)
days after the date of this contract.
2. Prevailing Wages. All labor utilized-in the construction
of the aforementioned improvements shall be paid a wage of no
less than the "prevailing hourly rate of wages" for work of a
similar character in this locality, as established by the
Department of Labor and Industrial Relations of the State of
Missouri, and as established by the Federal Employment Standards
of the Department of Labor. Contractor acknowledges that
Contractor knows the prevailing hourly rate of wages for this
project because Contractor has obtained the prevailing hourly
rate of wages from the contents of Special Wage Determination No.
6-026-108 3 } # }CX }�XXXXXX'�XXXXXXXXXX}L xxxXx
in which the rate of wages is set forth. The Contractor further
agrees that Contractor will keep an accurate record showing the
names and occupations of all workmen en ployed by Contractor in
connection with the work to be performed under the term., of this
contract. The record shall show the actual wages paid to the
workmen in connection with the work to be performed under the
terms of this contract. A copy of the record shall be delivered
to the Director of Public Works each week. In accordance with
Section 290.250 RSMo, Contractor shall forfeit to the City Ten
Dollars ($10.00) for each workman employed, for each calendar day
or portion thereof that the workman is paid less than the
stipulated rates for any work done under this contract, by the
Contractor or any subcontractor under the Contractor.
3. Insurance. Contractor shall procure and aGiiEtJ.AfsE b
own expense during the life of this contract:
MAY 071966
PUBLIC WORKS DEPT.
(a) Workmen's Compensation Insurance for all of its
employees to be engaged in work under this contract.
(b) Contractor's Public Liability Insurance in an amount
not less than $800,000 for all claims arising out of a
single occurrence and $100,000 for any one person in a
single accident or occurrence, except for those claims
governed by the provisions of the Missouri workmen's
compensation law, Chapter 287, RSMo., and Contractor's
Property Damage Insurance in an amount not less than
$800,000 for all claims arising out of a single
accident or occurrence and $100,000 for any one person
in a single accident or occurrence.
(c) Automobile Liability Insurance in an amount not less _
than $800,000 for all claims arising out of a single
accident or occurrence and $100,000 for any one person
in a single accident or occurrence.
(d) Owner's Protective Liability Insurance - The Contractor
shall also obtain at its mm expense and deliver to the
City an Owner's Protective Liability Insurance: Policy
naming the City of Jefferson as the insured, in an
amount not less than $800,000 for all claims, arising
out of a single accident or occurrence and $100,000 for
any one person in a single accident or occurrence,
except for those claims governed by the provisions of
the Missouri workny-an's compensation law, Chapter 287,
RSMo. No policy will be accepte=d which excludes
liability for damage to underground structures or by
reason of blasting, e-.Vlosion or collapse.
(e) Subcontracts. In case any or a3_1 of this work is
sublet, the Contractor shall require the Subcontractor
to procure and maintain all insurance required in Sub-
paragraphs (a), (b) and (c) hereof and in like amounts.
(f) Scope of Insurance and Special Hazard. The insurance
required under Sub-paragraphs (b) and (c) hereof sha11
provide adequate protection for the Contractor and its
subcontractors, respectively, against damage claims
which may arise from operations under this contract,
whether such operations be by the insured or by anyone
directly or indirectly employed by it, and also against
any special hazards which may be encountered in the
performance of this contract.
NOTE: Paragraph (f) is construed to require the
procurement of Contractor's protective insurance
(or contingent public liability and contingent
property damage policies) by a general contractor
whose subcontractor has employees working on the
project, unless the general public liability and
property damage policy (or rider attached thereto)
of the general contractor provides adecriat-e
protection against claims arising from operations
by anyone directly or indirectly employed by the
Contractor.
4. Contractor's Resoonsibility for Subcontractors. It is
further agreed that Contractor shall be as fully responsible to
the City for the acts and omissions of its subcontractors, and of
persons either directly or indirectly e.Tnioyed by them, as
Contractor is for the acts and omissions of persons it directly
employs. Contractor shall cause appropriate provisions to be
inserted in all subcontracts relating to this work, to bind all
subcontractors to Contractor by all the terms herein set forth,
insofar as applicable to the work of subcontractors and to give
Contractor the same power regarding termination of any
subcontract as the City may exercise over Contractor under any
provisions of this contract. Nothing contained in this contract
shall create any contractual. relations betr;een any subcontractor
and the City or between any subcontractors.
5. Liquidated Da.-nages. The Director of Public Works may, at
his discretion, deduct $100.00 from any amount
otherwise due under this contract for every day Contractor fails
or refuses to prosecute the work, or any separable part thereof,
with such diligence as will insure the completion by the time
above specified, or any extension thereof, or fails to complete
the work by such time, as long as the City does not terminate the
right of Contractor to proceed. It is further provided that
Contractor shall not be charged with liquidated damages because
of delays in the completion of the work due to unforseeable
causes beyond Contractor's control and without fault or
negligence on Contractor's part or the part of its agents.
6. Termination. The City reserves the right to terminate
this contract by giving at least five (5) days' prior written
notice to the Contractor, without prejudice to any other rights
or remedies of the City should the Contractor be adjudged a
bankrupt, or if Contractor should make a general assignment for
the benefit of its creditors, or if a receiver should be
appointed for Contractor or for any of its property, or if
Contractor should persistently or repeatedly refuse or fail to
supply enough properly skilled workmen or proper material, or if
Contractor should refuse or fail to make prompt payment to any
person supplying labor or materials for the work under the
contract, or persistently disregard instructions of the City or
fail to observe or perform any provisions of the contract.
7. City's Right to Proceed. In the event this contract is
terminated pursuant to Paragraph 6, then the City may take over
the work and prosecute the same to completion, by contract or
otherwise, and Contractor and its sureties shall be liable to the
City for any costs over the amount of this contract thereby
occasioned by the City. In any such case the City may take
possession of, and utilize in completing the work, such
materials, applicances and structures as may be on the work site
and are necessary for completion of the work. The foregoing
provisions are in addition to, and not in limitation of, the
rights of the City under any other provisions of the contract,
city ordinances, and state and federal laws.
B. Guards and Lights. The Contractor agrees to defend,
indemnify, and save the City harmless from and against all
claims, suits and actions of every description, brought against
the City and from all damage and costs by reason or on account of
any injuries or damages received or sustained by any person or
persons, or their property, by Contractor, its servants, agents
or subcontractors, or arising out of the award of this contract
to Contractor.
9. Indemnity. The Contractor agrees to defend, indemnify,
and save the City harmless from and against all. claims, suits and
actions of every description, brought against the City and from
all damage and costs by reason or on account of any injuries or
damages received or sustained by any person or persons, or their
property, by Contractor, its servants, agents or subcontractors
in the construction of said work, or by any negligence or
carelessness in the performance of the sane, or on account of any
act or omission of Contractor, its servants, agents, or
subcontractors, or arising out of the award of this contract to
Contractor.
10. Payment for Labor. and Materials. The Contractor agrees
and binds itself to pay for all labor done, and for all the
materials used in the construction of the work to be completed
pursuant to this contract. Contractor shall :furnish to the City a
bond to insure the payment of all materials and labor used in the
performance of this contract.
11. Payment. The City hereby agrees to pay the Contractor
the work done pursuant to this contract according to the payment
schedule set forth in the Contract Documents upon acceptance of
said work by the Director of r-ublic Works and in accordance with
the rates and/or amounts stated in the bid . of Contractor
dated April 27.. . 19 86 , which are by reference made a
part hereof. No partial. payment to the Contractor shall operate
i as approval or acceptance of work done or material:; furnished
hereunder.
12. Contract Documents. The contract documents shall consist
of the following:
a. This Contract e. General. Conditions
b. Addenda f. Special Provisions
c. Notice to Contractors g. Technical Specifications
d. Signed Copy of Bid h. Draaings and/or sketches
This contract and the other ductrnants enuanrated in this
paragraph, form the Contract between the parties. These documents
are as fully a part of the contract: as if attached hereto or
repeated herein.
13. Nondiscrimination. The Contractor agrees in the
performance of this contract riot to discriminate on the ground or
ti because of race, creed, color, national origin or ancestry, sex,
religion, handicap, age, or political opinion or affiliation,
against any employee of Contractor or applicant for c-inlo-,„mnt
and shall include a sim_i.lar provision in all subcontracts let or
awarded hereunder.
14. Notices. All notices required to be in writing may be
given by first class mail address to. the City of Jefferson, 320
E. 14-Carty, Jefferson City, ti-souri 65101, and Contractor at
St,r Rt. 2 - Schott Rd_ - jeffPrson City. 1%10 • � e date of
delivery of any notice shall be the second full day after the day
of its mailing.
15. Jurisdiction. This agreement and every question arising
hereunder shall be interpreted according to the lm-:s and statutes
i
of the State of 14i.ssouri..
16. IN TESTI14DNY I-P EREOF, tl-b-- parties have hereunto set
their hands and see-Ls this 23 day of April
19 86 .
CITY OF JEFFERSON, MISSOURI
By
r.toR
ATI=:
CITY CLERK
C(7.?rRACTOR
BY
Title:
ATTEST:
SECRETARY
ISSUE DATE(MMIDONY)
04/3IZA
PRODUCER 1 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS
NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AMEND,
EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES CC-LOW.
Lockton Insurance Agency COMPANIES AFFORDING COVERAGE
P. O. Dox 8418 -------__._— ------- -_.- -_-�_
Prairie Village Ks 66 :08 COMPANY A
LETTER Hanover
COMPANY
INSURED 1 SA ��— LETTERv
COMPANY c
Willard Stockman Const. Corp. LFTTER
COMPANY D
Star Route 2, Schutt Road LETTER _.• �_
Jefferson City, MO 65101 COMPANY �
LETTER
o e
THIS IS TO CERTIFY THAT POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED.
NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY
BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS,AND CONDI-
TIONS OF SUCH POLICIES.
CO TYPE OF INSURANCE POLICY NUMBER POLICY EFFECTIVE POLICY EXPIRATION LIABILITY LIMITS IN THOUSANDS
DATE(WnONY) DATE(MWDOrM Ea M
LTR OCCURRENCE AGGREGATE
GENERAL LIABILITY BODILY
(� COMPREHENSIVE FORM 0208 6861 03/31/86 03/31/87 INJURY $ $
x
PREMISES/OPERATIONS PROPERTY
UNDERGROUND ' Gil
a ul coverage DAMAGE $ $
x EXPLOSION 8 COLLAPSE HAZARD Y -
x PRODUCTS/COMPLETED OPERATIONS
x CONTRACTUAL iCOMBINED $
x INDEPENDENT CONTRACTORS I 1. 000 1 OL710
x BROAD FORM PROPERTY DAMAGE i
x PERSONAL INJURY PFAS014AL INJURY $
1, QI00
AUTOMOBILE LIABILITY �--�-_- etGrY
A x ANY AUTO BA42 7574 03/31/66 03/31/87 f�aaEasm) $
�{ ALL OWNED AUTOS(PRIV,PASS) &'II>5
OTHER THAN PJUaY
ALL OWNED AUTOS pRIV. PASS )cEaAa+oErrn $
x HIRED AUTOS PPOPERTY
y(
NON-OWNED AUTOS DAMAGE $
GARAGE LIABILITY
BI 8 PD
COMBINED $ 1,Q00
EXCESS LIABILITY
PD
UMBRELLA FORM BI b
COMBINED $ $
OTHER THAN UMBRELLA FORM __
WORKERS'COMPENSATION STATUTORY
A AND WHK24 53687 03/31/86 03/31/87 $ 100 (EACH ACCIDENT)
EMPLOYERS' LIABILITY $ 500E (DISEASE-POLICY LIMIT)
_
$ 100 (DISEASE-EACH EMPLOYEE)
OTHER
A OCP ` B{f 4-412E ^ 4/23/86 4/23/87 800,000 BI Occurre
I100,000 PD Occurre
DESCRIPTION OF OPE RATION S/LOCATIONSNEHICLES/SPECIAL ITC LEIS —
Construction of 1986 Curb IA• Gutter Project Phase IV - Swifts Highway -- Flora
Drive. The City of Jefferson City is add' 1 insured as respects liability only
r •
18477 ESHOULD Y OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFOR E THE EX•cit of Jefferson Cit ATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO
Y y DAYS WRITTEN NOTICE Tu THE CERTIFICATE HOLDER NAMED TO THE
ILII>iF.70 MAIL SUCH NOTICE 5HALL IMPOSE NO GBLlGATIQN QR UABIUTY
D UPON THE COMPANY, ITS AENTS OR REPRESENTATIVES.
320 E. McCarthy V.FRES JTATIVk - -ity MO x,5101
I
Bond No. 30SB100 26 29 67 SCA
THE AMERICAN INSTITUTE OF ARCHITECTS
S
� M1
AfA Document A312
Payment Bond
Any singular reference to Contractor, Suraty, Owner or other party shell be considered plural where applicable.
CONTRACTOR (Name and Address): SURETY (Name: and Principal Place of Business):
Willard Stockman Construction Corp. The Aetna Casualty and Surety Company
Star Route 2 Schott Road P.O. Box 29146
Jefferson City, MO 65101 Overland Park, KS 66201-9146
OWNER (Name and Address):
City of Jefferson, Missouri
City Hall
Jefferson City, MO.
CONSTRUCTION CONTRACT
Date: April 23, 1986
Amount: Two Hundred Eighty-One Thousand Three and N01100 ($281,003.00)
Description (Name and Location): 1986 Curb & Gutter Project Phase IV-Stwrifts
Highway, Flora Drive
BOND
Date (Not earlier than Construction Contract Date): May 5, 1986
Amount: Two Hundred Eighty-One Thousand Three and N01100 ($281,003.00)
Modifications to this Bond: k] None ❑ See Page 6
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Se Company: (Corporate Seal)
Willard Stoc man Construction Corp. The Aetna Casualty and Surety "Company
Signature: zade= Signature:C4 ) �l
Name and Title: Name and isle:
Vernon L. Hemmel, Secretary/Treasurer Deborah K. Braden a Attorney--In-Fact
(Any additional signatures appear on page 6)
(FOR INFORMATION ONLY—Name, Address and Te/cphone)
AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or
® other party):
The Lockton Insurance Agency
P.O. Box 8418
Prairie Village, KS 66208
AIA DOCUMENT A313•PERFORMANCE IIOND AND PAYMINJ BONI)•Ott 1MItER 1':IW CU.•AtA•r. "�r�,�
THE AMERICAN INS117UTE OF ARCIWECTS. 1733 NEW YC)KK AVE..N.w.,WA%IiINGTON, U.C.2"1 A312.1984 4
I The Contractor and the Surety, jointly anti severally, 6 When the Claimant has satisfied the conditions of Para•
bind themselves, their heirs, executors, administrators, graph 4, the Surety shall promptly and at the Surety's ex-
successors and assigns to the Owner to pay for labor, pease take the following actions:
materials and equipment furnished for use in the perfor• 6.1 Send an answer to the Claimant,with a copy to the
mance of the Construction Contract,which is int orporated
herein by reference. Owner,within AS days after receipt of the claim,staling
the amounts that are undisputed and the basis for chal-
2 With respect to the Owner,this obligation`hall he null lenging any amounts that are disputed.
and void if the Contractor: 6,2 Pay or arrange for payment of any undisputed '
2.1 Promptly makes payment, directly or indirectly, amounts.
for all sums due Claimants, anti 7 The Suwly's total obligation shall not exceed the
2.2 Defends, indemnifies and holds harink-ss the amount of this bond,and the amount of this Bond shall be
Owner from all claims, demands, liens or arils by any c redttt:d forany payments made in good faith by the Surety.
person or entity who furnished labor, inmerials or 0 /lonounk awed by the Owner to the Contractor under
equipment for use in the performance(if Iht,C onstruc• the ConslrLICllQn Contract shall be used for the perfor•
tion Contract, provided the Owner has promptly noti• manta of tht-Construction Contract and to satisfy claims,if
find the Contractor and the Surely (at tht' , idwss de-
scribed toy, under any Construction Performance Bond. By the
or sits in Paragraph 12) of any claim~, mv,.clem liens C onlrarlor furnishing and the Owner accepting this Bond,
liens suits and tendered defense of such cla t- ,.clt-ly, and they,egret, that all funds earned by the Contractor in the
liens or suits to the Contractor and tht� tiurely, and
provided there is no Owner Default. 1wrforrrtam v of the Construction Contract are dedicated to
satisfy obligations of the Contractor and the Surety under
3 With respect to Claimants, this obligation •hall be null this Bond, subject to the Owner's priority to use the funds
and void if the Contractor promptly make~ 1mvint•nt, di- for the completion of the work.
rectly or indirectly, for all sums due.
9 The Surety shall not be liable to the Owner, Claimants
4 The Surely shall have no obligation to Claimant'. under or others for obligations of the Contractor that arc unrelat-
this Bond until: ed it) the Construction Contract. The Owner shall not be
liable;for payinent of any Costs or expenses of any Claimant
4.1 Claimants who are employed by or have it direct under this Bond, and shall have under this Bond no obliga-
contract with the Contractor have given notice to the lions to make payments to, give notices on behalf of, or
Surety (at the address described in Paragraph 12) and otherwise have obligations to Claimants under this Bond.
sent a copy,or notice thereof,to the Owner,slating that
a claim is being made under this Bond and, with sub- 10 The Surely hereby waives notice of any change,includ-
stantial accuracy, the amount of the claim. ing changes of time, to the Construction Contract or to
4.2 Claimants who do not have a direct contract with related :subcontracts, purchase orders and other obliga-
the Contractor: lions.
1 Have furnished written notice to I11tt Con- 11 No suit or action shall be commenced by a Claimant
tractor and sent a copy, or notice thereof, to under this Band other than in a court of competent jurisclic-
tra Owner, within t!() days after having last lion in the location in which the work or part of the work is
located or after the expiration of one year from the dale(1)
performed labor or last furnished materials or on which the Claimant have the notice required by Sub-
equipment included in the claim staling,with paragraph 4.1 or Clause 4.2 (iii), or (2) on which the last
substantial accuracy, the amount of the claim labor or service was performed by anyone or the last mate-
and the name of the party to whom the male- rials or equipment were furnished by anyone under the
vials were furnished or supplied or for whom Construction Contract,whichever of(1)or(2) first occurs.
the labor was done or performed; and If the provisions of this Paragraph are void or prohibited by
.2 Have either received a rejection in whole or in law,the minimum period of limitation available to sureties
part from the Contractor,or not received with- as a defense in the jurisdiction of the suit shall be applica-
in 30 days of furnishing the above notice any hle.
communication from the Contractor by which 12 Notice to the Surely,the Owner or the Contractor shall
the Contractor has indicated the claim will be be mailed or delivered to the address shown on the sig-
paid directly or indirectly; and oature page.Actual receipt of notice by Surely,the Owner
.3 Not having been paid withinIlwahove Ill day%. or the Contractor, however accomplished, shall be suffi-
have sent a written notice to the Surely(.1t the t ient compliance as of the date received at the address
address described in Paragraph 12)and sent a shown on the signature page.
copy,or notice thereof, to the Owner, staling 13 When this Bond has been furnished to comply with a
that a claim is being made under this Bond and statutory or other legal requirement in the location where
enclosing a copyof the previou%written notice the construction was to be performed,any provision in this
furnished to the Contractor. Mond conflicting with said statutory or legal requirvinetll
5 If a notice required by Paragraph 4 is given by thv Owner shall be deemed deleted herefrom and provisions con-
to the Contractor or to the Surely,that is sufficient Loinpli. forming to such statutory or other legal requirement shall
ante. be deemed incorporated herein. The intent is that this
AIA DOCUMENT A312- PERrORMANCE DOND AND 1'AYAIENr ItoNf1-Di(IMIIEK I,NH ED. -AIA a
THE AMERICAN INSTITUTE OF ARCHITECTS, 170 NEW YORK AVE.,N.W.,WASHINGTON.D.C. lums A312.1984 5
r
Bond shall be construed as a statutory bond and not as a Construction Contract, architectural and engineering
common law bond. services required for performance of the work of the
- 14 Upon request by any person or entity appearing Io be a Contractor and the Contractor's subcontractors, and
all other items for which a mechanic's lien may he
potential beneficiary of This Bond, the Contractor shall asserted in the jurisdiction where the labor,materials
promptly furnish a copy of this Bond or shall permit a copy or equipment were furnished.
to be made.
15 DEFINITIONS 1S.2 Construction Contract:The agreement between
the Owner and the Contractor identified on the sig-
15.1 Claimant:An individual or entity having a direct nature page, including all Contract Documents and
contract with the Contractor or with a sulu ontractor of changus thereto.
the Contractor to furnish labor, materiah or equip- 15.9 Owner Default: Failure of the Owner,which has
merit for use in the performance of the Contract. The neither been remedied nor waived, to pay the Con-
intent of this Bond shall be to include without limita- tractor as required by the Construction Contract or to
lion in the terms"labor,materials or equipment that perform and complete or comply with the other terms
part of water, gas, power, light, heat, oil, gasoline, thereof.
telephone service or rental equipment used in the
MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
(Space is provided below for additional signatures of added parties, other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporate Seal)
Signature: Signature:
Name and Title: Name and Title:
Address: Address,:
;IA DOCUMENT ATI!•PERFORMANCE BOND AND 11AYMINI UOND 1 UICEM"tR 1101 I.D. -AIA a
THE AMERICAN INSTITUTE OF ARCHITECTS.1735 NEW YORK AVE.,N.W..WASHIN60N,D.C.3tMpM+ A312.1984 6
Ton gym CMUM.TY AND SUAM COMPANY
•
Hanford.Connecticu108ttB
unsCAOwnY
POWER OF ATTORNEY AND CERTIFICATE OF AUTHORITY OF ATTORNEYISHN-FACT
KNOW All MEN W TNSN PMNNTS,YM'r YHE ATNACASVALTY AND SURETY COWANY,a corporation duly orgenlrod under the laws of the
Slate of Com»ti and MAa/fill Principal aids-M the City of Hanford.County of Hartford.State of Connecticut,hath made.Constituted and
eppolntad,end dace by tl is fNSeatts"We.cormotm and appoint J hn T. Lo kto JJr. o n T. Lo kton IIIII r
�Thh ea E Jq getttopa Ni Sion Hills Ka as or g s C. is dl �1 a col C. oat, Mie�i:el D.
Wh pe, Cl i e d.IJ. �oung Brian Cooper or�egorah R 1raden, erland 6ark,Kinaea or
or Cars F. Haabrli[ht Dav;d M. Loc�Cttaa or W111iam M. Frick, Kansas City Missouri or
Merlin D. Redfield, �enexa,Kansas or Don C. Osborne, Leawood,Kansas or William L. Frick,
Shawnee Misslon,Kansas - -
of XX ,Its We N4 kr^101AttomaytaWmFact,withtillpowerandeuthorityherebyconferred
ss sign,asavte and solatOrviled1,at any place wdddn eN Unhad Starve,or,0 tits following One be filled in,within die area there desig•
sW ed .fhe VOpotnring khawmarutal:
by hWhat aria MpnaWe ffnd e,A,airy and all bonds,ressgzAnnose owira fs of Indemnity,and other writings obligatory in tho nsture of a bond.
raoognlrmwet,or pond ilorr0 urANWdng,and any end aR owre its InWwft thereto
and to bMd THE AIM CASUALTY AND SURETY COMPANY,thereby as fully end to the some orient as If the earn*wore signed by thu duly
sutlioAssdallegeof Tin AM ACASUALTYANDWJMTVCOMPANY,andall theaMofsaidAttomerriol-In•Fact,pursuant to the authority herein
lilwn,we hwow rallied and tonsrmeA
T1ds appointment Is is under end by auoWky of dta Mavis np Etsrii&V Res lludo hs of"Id Company which Resolutions are now in full force
end mReel:
VOTED:Thal sech of bite lellowMtp ofRoen:CAaMmsr4VbO Chat~,PrsidirK Any Esemd"Vko Presldenl,Any Senior Vice President.Any Vice
Prink%nL Any Assl dMttV{asPis"riot,ArrySmorotartf,Any Asfkul`58Zseretrsry,My frcmtm9to time appolM Resident VkisPresidents.Roefdent
Assistant Secratmitd,AtWrnay0ri fteL mW ASerReto act lips end on b~olths Company snd may give sny moth appoint"such authority as his
certiRaq of suMt rhy may preedbe In 9W with ble Corrpeny's name aid ssai wiO,the Cnmpwry's"at bonds.rertognizences.eontraca of
Mdamnky.and other writings oW&Wy M bite n t n of a bond,MoDankefft or oantstiotral tnxkrgktng,and any of sold offiESrs or the Dowd of
Directors may at any tiros tiltzme a my etealh IMO,cue wW rw� W ft power mid outraMr eyon him.
VOTED:That any bmA rsvopdzW',ca,Contract of bdomnfly,orwtidttpobliga vyIn tai ratan aft band,moognizsnce.orxnditional undenaUng
ship be valid and Inkldng apart the Carrpatry when(a)signed bir ft Cholrman.Ste Vice C hoktnen,the ft4ident.an Ezearhw Via President.e
Senior Vim Pneld*t,a Via Pies+BdwiL an Assistant Via PreekliM at by a Resident Vis President,pute02r111 to the power prescribed in the
cenif em ofauthorityofsuchftAdtatViePreakl ire,a!ddWyettateed&WenaladwftttheCompany'se aaibraSrcrataryorAssistantSecretary
orbyaResk9eMAaaistseNSaerm5teY,parr:uOMhetMtcePMRtiseettlRcaeeoleutMxltyofetsdiReakkrntAseiMantSactetery;orlb)duty
exerted lundot sssl.H ragtdv O W arts at front AVArrgysanfsu pument to the power prescribed in We tr their canifitote or certificates of
authority.
This Power of AWAM at,d taatlfksts of k1dWIir Ill tligrmd and[salad by fecolmile under and by authority of the fN!mving Standing Resolution
® voted by the Board of Ok•astors of Till(ETNA CASUALTY AND SURETY COMPANY which Resolution is now in full fora and effect:
VOTED: That die alignnhws of sad,of fhs k%evky oAttare:Chakmam Vim Chelrmm,Pitta.Went.Any Exaatthra Vke President,Any Senior Via
President.AnyVimProskk An yAs*kvgti wPr*Odent,APYC*awz;y.AnyAsetatantSecretary,andthetesloftheCompanymaybeaffixedby
facsimile to arty Passau ul rAietney or to a try•sar"Mu WS*V dotrseti appobvft Ratlido st Via Presl fonts.Retklant Assistant Seci staries or
Arwnw"i-FoatwpArAmeovefoxwAkwoid CMSbonhear Aundmital&epsandotherwritingso b9oM*rrinthenaturethereof,andany
such power of sttortwy orastdf)ats bw*V suds fscaeHgo sire at f axilr Nle seal shop be valid said binding upon the Company and any such
power to examied and mosd by ouch WoaWk islowi0tirs and faasMdi"M,shall be wild and binding upon the Company in the future with
rasped to wry bond or undwrlaDrfnd to,sash it is atts0ied.
IN WITNESS WHERCOF,THE AMIA CASUALTY AND SURETY COWANY has caused this Inwu mint to be tigged by Its Assistant
Vice President ,mid he corporate teai to be hereto affixed We 27th
day of September .10 84 .,�v.
YifE A�. St1F1ETil_, COMPANY
State of Conneakart J eph . Kiernan
fnunry,)1 HMlad
a.Hanford Assistant Vice Preirident
Onbide 27th dayot September .1984 , sic mepersonehyems JOSEPH Pe KltiitNAN
to me knom%who,b*m br me i,$*awom,ctd depmo aid say:drat hahhe ls p;s tank vice Fie.fiw�a�ta ktnoy.a thi
THE ETNA rAMIJALTYAWO WJRM CDkfx`ANY,tips owpwadon ds wgwd M and which wascutsd iM eaevs kwtnurtant:mat
"slot saidaxporeNmrth We rerel Abed lof SlsuWkw kwtmKki Mich corporate sea t;endthathe/sha executed the cold intVrumorttonb @W
of tie corporation by suftft of h1ar W ofRoe taxlaf the Standng Resohrtiart thereof.
iiesimt exedse Muds a1,1989 Notary Public
CERTIFICATE johymm H. Dasnan
1.the imdatwe"j. Secretary of TM ATM CASUALTY AND SURETY COMPANY,a stock corporation of the
State o fCovM80wLOOl1VUYCEIRT1PYOWftltn SW4andWA hadPpAWofAaornsya aillC4 ancaleofAutsoriryrisa ainaMfwlformand
has riot been W A*iK-and fiNlhatm67a.shot iM EtanLyng Re0ol owns of fhe Sosrdof DkeAa7e.W OUkdh In ilia Couft tenf Authority,are now
M force.
.��t „M Noma uiwee a lit.C +w,kt ace car of iirtford sons ma day of
tom_ l�
{bfM4n task ill `� Vifrewnt A. Walsh, Secrntatry PrWND IN U.a.A
Bond No. 30SS100 26 29 67 BCA
THE AMERICAN INSTITUTE OF ARCHITECTS
Aft
AIA Document A312
Performance Woad
Any singular reference to Contractor, Surviv, Owner or other party shall be considered plural where applicable.
CONTRACTOR (Name and Address): SURETY (Name arid Principai Place of Business):
Willard Stockman Construction Corp. The Aetna Casualty and Surety Company
Star Route 2 Schott Road P.O. Box 29146
Jefferson City, MO. 65101 Overland Park, KS. 66201-9146
OWNER (Name and Address):
City of Jefferson, Missouri
City Hall
Jefferson City, MO.
CONSTRUCTION CONTRACT
Date: April 23, 1986
Amount: Two Hundred Eighty-One Thousand Three and N01100 ($281,003.00)
Description (Name and Location): 1986 Curb & Gutter Project Phase IV-Swifts
Highway, Flora Drive
BOND
Date (Not earlier than Construction Contract Date): May 5, 1986
Amount: Two Hundred Eighty-One Thousand Three and N01100 ($281,003.00)
Modifications to this Bond: (N None O See Page 3
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate S l) Company: (Corporate Seal)
Willard StogWan Construct4iop Corp. The Aetna Casualty and Surety Company
Signature: Signature: a �= 1���1"t"_'
Name and-Title: Name and itl
Vernon L. Hemmel, Secretary/Treasurer Deborah K. Braden Attorney-In-Fact
(Any additional signatures appear on page 3)
(FOR INFORMATION ONLY—Name, Address and Telephone)
AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or
The Lockton Insurance Agency other party):
P.O. Box 8418
Prairie Village, KS 66208
ALA DOCUMENT A312•PERFORMANCE BOND AND PAYMENT BOND•UECLMBER 144 ED. •AIA A
THE AMERICAN INSTITUTE OF ARCHITECTS,4735 NEW YORK AVE.,N.W.,WASUINGTON.D.C.20006 A312-19M I
l
,.
1 The Contractor and the Surety, jointly and severally, which it may be liable to the Owner and, as
bind themselves, their heirs, executors, administrators, soon as practicable after the amount is dett-r•
successors and assigns to the Owner for the performance mined, tender payment therefor to the
of the Construction Contract,which is incorporated herein Owner; or
by reference. .2 Deny liability in whole or in part and notify the
2 If the Contractor performs the Construction Contract, Owner citing reasons therefor.
the Surety and the Contractor shall have no obligation S If cite Surety does not proceed as provided in Paragraph
under this Bond, except to participate in conferences as 4 with reasonable promptness,the Surely shall be deemed
provided in Subparagraph 3.1. ter be in cdefaull on this bond fifteen days after receipt of an
3 If there is no Owner Default, the Surety's obligation additional written notice from the Owner to the Surely
under this Bond shall arise after: demanding that the Surety perform its obligations under
this Boned, and the Owner shall be entitled to enforce any
3.1 The Owner has notified the Contracicrr and the remedy available to the Owner. If the Surety proceeds as
Surety at its address described in Paragraph IU below provided in Subparagraph 4.4, and the Owner refuses the
that the Owner is considering; declaring; a C'ontraclor payment tendered or the Surety has denied liability, in
Default and has requested and attempted to arrange a whole or in part,without further notice the Owner shall be
conference with the Contractor and the Surely to be entitled to enforcer any remedy available to the Owner.
held not later than fifteen days after receipt of such
notice to discuss methods of performing tilt-Construe- 6 After lilt- (honer has terminated the Contractor's right
lion Contract. If the Owner, the Contractor and the to complete• the Construction Contract, and if the Surety
Surety agree, the Contractor shall be allowed a reason- elects to act under Subparagraph 4.1, 4.2, or 4.3 above,
able time to perform the Construction Contract, but then the responsibilities of the Surety to the Owner shall
such an agreement shall not waive the Ownt-r's right,if not be greater than those of the Contractor under the
any, subsequently to declare a Contractor Default; and Construction Contract, and the responsibilities of the
Owner io the Surety shall not be greater than those of the
3.2 The Owner has declared a Contractor Uefaull and Owner under the Construction Contract.To the limit of the
formally terminated the Contractor's right to complete demount of this Bond, but subiccl to commitment by the
the contract. Such Contractor Default shall not he de- (Owner of the Balance of the Contract Price to mitigation of
clared earlier than twenty days after the Conlrac•tor and costs and damages on the Construction Contract,the Sure-
the Surety have received notice as provided in Sub- ty is obligated without duplication for:
paragraph 3.1; and
Alk 6.1 The responsibilities of the Contractor for correc-
3.3 The Owner has agreed to pay the Bal.nce of the lion of defective work and completion of the Construc-
Contract Price to the Surety in accordance with the lion Contract;
terms of the Construction Contract or to a contractor
selected to perform the Construction Contract in accor- 6.2 Additional legal, design professional and delay
dance with the terms of the contract with iliv Owner. co its resulting from the Contractor's Default, and re-
4 When the Owner has satisfied the conditions of Para- sulting from the actions or failure to act of the Surely
graph 3, the Surety shall promptly and at the Surety's ex-
under Paragraph 4; and
pense take one of the following actions: 6.3 Liquidated damages, or if no liquidated damages
4.1 Arrange for the Contractor, with consent of the are specified in the Construction Contract,actual dam-
Owner, to erform and complete the Construction ages caused by delayed performance or non-perfor-
Contract; or p p mance of the Contractor.
4.2 Undertake to perform and complete tfieConstrue- 7 The Surety shall not be liable to the Owner or others for
obligations of the Contractor that are unrelated to the Con-
don Contract itself, through its agents or through inde- struction Contract, and the Balance of the Contract Price
pendent contractors; or shall not be reduced or set off on account of any such
4.3 Obtain bids or negotiated proposals from unrelated obligations. No right of action shall accrue on
qualified contractors acceptable to the Owner for a this Bond to any person or entity other than the Owner or
contract for performance and completion of the Con- its heirs, executors, administrators or successors.
struction Contract, arrange for a contract to be pre- g The Surety hereby waives notice of any change,includ.
pared for execution by the Owner and the contractor
selected with the Owner's concurrence, to he secured ing changes of time, to the Construction Contract or to
with performance and payment bonds executed by a related subcontracts, purchase orders and other obliga-
qualified surety equivalent to the bonds issued on the Lions.
Construction Contract, and pay to they Owner the 9 Any proceeding, legal or equitable, under this Bond
amount of damages as described in Paragraph 6 in ex- may be instituted in any court of competent jurisdiction in
cess of the Balance of the Contract Price incurred by the the location in which the work orpart of thework is located
Owner resulting from the Contractor's default; or and shall be instituted within two years after Contractor
4.4 Waive its right to perform and complete, arrange Default or within two years after the Contractor eoast-d
for completion, or obtain a new contraclor and with working or within two years after the Surety refuses or fails
reasonable promptness under the circunrst,n (cs: to perform its obligations under this Bond,whichever oc-
curs first. If the provisions of this Paragraph are void or
.1 After investigation,determine(ht-,entount for prohibited by law, the minimum period of limitation avail-
AIA DOCUMENT A312 -P(RfORMANCE HOND AND PAYMINI HUNT)-L)r(:[mill R 1984 I.D. -AIA +
THE AMERICAN INSTITUTE OF ARCHIT(CTY, 1735 NEW NORK AVE.,N.W„WA1NINr;EON,U.C. 200X9, A312-1984 2
able to sureties as a defense in the jurisdiction of the suit tractor of any amounts received or to be received by
shall be applicable. the Owner in settlement of insurance or other claims
1t7 Notice to the Surely, Owner or the Cvntractcar shall for damages to which the Contractor Is entitled, re•
y duced by all valid and proper payments made to or on
be mailed or delivered to the address shown on the sigl- behalf of the Contractor under the Construction Con-
nature page. tract.
11 When this Bond has been furnished to comply with a 12,2 Construction Contract:The ag;reemenI between
statutory or other legal requirement in the location where the Owner and the Contractor identified on the sig-
the construction was to be performed,any provision in this nature page, including all Contract Documents and
Bond conflicting with said statutory or legal mquirement t hang vs thereto.
shall be deemed deleted herefrom and pnwi%ions con-
forming to such statutory or other legal rerguirt-ment shall 12.3 Contractor Default: Failure of the Contractor,
be deemed incorporated herein. The intesit is Thal this whit it has neither been remedied nor waived, to per-
Bond shall he construed as a statutory bond and not as a form or otherwise to comply with the terms of the
common law bond. Contaruction Contract.
12 DEFINITIONS 12.4 Owner Default: Failure of the Owner,which has
12.1 Balance of the Contract Price: The Iwal amount neither been remedied nor waived, to pay the Con-
payable by the Owner to the Contractcir under the tractor as required by the Construction Contract or to
Construction Contract after all proper adju%tmenis thercrm and complete or comply with the other terms
have been made, including; allowance, Io the Con-
MODIFICATIONS rt:rst.
MODIFICATIONS TO THIS BOND ARE AS FOLLOWS:
(Space is provided below for additional signatures of added parties, other than those appearing on the cover page.)
CONTRACTOR AS PRINCIPAL SURETY
Company: (Corporate Seal) Company: (Corporate Seal)
is Signature: Signature:
Name and Title: Name and Title:
Address: Address
AIA DOCUMENT A312-PERfORMANCI BOND AND PAYMINT (POND•Dlt IMIIIK 1141 tO. -AIA �THE AMERICAN INSTITUTE Of ARCIIITfCTS,173S Nt1V VORK AVE.,N.W.,wA511INGTON, U.C.21xxk A312.1984 3
M TM ArM CAWALTY AND SWETY COMPANY
Harflord,Connecticut 06115
' LIPE fi CASUALTY
POWER OF ATTORNEY AND CERTIRCATE OF AUTliORRY OF ATTORNEVISHN-FACT
KNOW ALL MEN SY THESE PRE'SINU,TNAT THE,4TNACASUALTY AND SURETY COMPANY,s oorporation duly oMan:ted undor the laws of the
State of Connaef"vA Itf,Mne No prMrolpel Owl"In the CRY of Hartford,County of Hartford,Sung of Connecticut,hash made.constituted and
appointed,and does by these pie",to make,conerihrx and opitol A J hn T„ Lo ktu Jr. JJnhn T. Lo k ton IlIii r
R?0Th as S J note yyiseion H lls Kapp�sas or'. a Ce told Aic},Hell C. Dots Mic�iaeI D.
or l1 Q1S� or 11h Ytldtng Bran fr. L:ooper or e6oxah AraAens Overload Perk jKan3aa or
ath► F. Hambrigght David Me Lockton or William Me Prick, Kansas City Missouri.or
Merlin D. Redtiald9 tonexaeKansas or Don C. Os *rue, LeawoodsKansas or 4illiam L. Frick,
Shawnee MissioneKantlas - -
of Xx kadueandbv/fulAttorrNy(eNn-Fact.with full power and nuthorlty hereby contorted
to DISH,atncua end�N any ghee wNfdrt 1 United Ststaa,1- N the foilowing line be filled In,within the area there desig•
Hated ,kha kSowirig InstrumorMs):
by his/her sole alp auma am act,any and ON Lrorldo,reoogrk"N m,COnarasee of Indemnity,and other writings obilgalory In the nature of a bond.
reoopnMnos,or oonlMortN undertaking,end any and eN oetsoar4a i WdaMS thereto
and to bind THE ATNA CASUALTY AND SURETY COMPANY,thersby es fully and to the same agent at if the some were signed by the duly
audwrleadolffoam of THa AV ACASU/LLTY ANDSURETY COMPANY,and ON the acts of said Attamaya)•tn-Fan,pursuant to the authority herein
glvsn,we hereby miiflad and contim"t
This appointment Io made under and by outhotMtr of the knowing Standing Roaolutlons of said Company which Resolutions are now in full force
and oRat:t:
VOTED:That each of Noe kttOwkng ofefoere:C2kti+mDn.Via CRNnnert,President,Any Executive Vice Prooldent,Any Senior Vice President,Any Vice
IDraelde t,AnyA1/6NaMVloaPra"K Any GWAw,Arw sinkitard may ftm time to time appoint ROW(16411 VICII Presidents,Resident
AosW&nlSscrotarlet,Aat9rtgyo* fMendAgeft IOcctOaGildonbahsnafamCompartyandmaygiveanysuchappdm eesuchauthority ashis
r»rit kats of authwfty nW protsor"to sW vft the Cwnparry'a name&-A tail with the Ctmtpanya seal bonds,r"n@ances,contracts of
tndomnky,and outer writings obmgowY In the Wore of if Corr!,rsoagrif for",a Conditional undertaking,and aw of ssld officers or the Board of
Directors may at any tine remove arty,tsar-h a.Ppnd Me ant revoke rite pmsur and authority giver.him.
VOTED:ThNsuY bond,reoOgMtents,COMtaatdkndsmftktr,tntavfl4ngOftaxy kt the natttmota bored,moogn'itsna,or conditional undertaking
shell be valid and Wad1e8 upon de Company*Wwn(al WWA by the CatWw.tie Vke Chairman,tie President,on F,xecutwe Vice President.a
Sonlor Via Prae{dwit.a Vice PrtvW00.on Asdafisne Vks Praident of ay t R02MOM b4CS Preens IL pursuant to the power prescribed in the
canifkNS of sulhafly of K%h Rosin&"VW0 Prealdw,and duly Ntaated rd so"with the Coax&*s seal by a Secretary of Aadstsnt Secretary
Of by 4 I10e1141eMA0`*WA341"DWY,0unt %10 dues&*-~bad In theooatNfkateOfouitwrityofsuchResidentAssistantSecMary:or(b)duly
executed futdor aced.It rw.V rs&by one or bare ASOMWO-Irs-44 purmem to the power proscribed in his or thdr certificate or CarVfiCates of
authority.
Thin Power of Attonay std Cord9kate of Authority b dgstad Ong o¢alad by face)mile under end by audwrity of the following Standing Resolution
voted by the Ifloord of Directm a+THQ/ETNA CASUALTY AM SURETY COMPANY while Resolution is now in full force and affect:
VOTED: That the olgnatuiv of otch of tlna toifawing of loin:Ceu rust,Vki Chairman.Ptwldent,Any EznWV@Vko Preeklont,Any Senior Vice
President,Any Vloofteldati,Any Au WWA Via f4esfdant Any SousPSty,Any:'inskttant Soc a Cry,and the 1651 of the cornparry maybe affixed by
fwjlwA t to any porn of swornoy or to arty owdNoaka ndadng tlesr eppokefng Rsaidem Vke PreeMenw,Resident Asaistant Soeretarleo or
Afton rayalrt-FagFar pxpaeaa0*ofAMMUing Wild eggbordaandurxl rialdnpa Mid MhaarrtsrtgaobNgMOry lit the nature thereof,and any
such power of NtomtY xeardfiat9a boating auoh 4losknNetlNgrettare ov faeakrdle seal ball bo vald std binding upon this Company and any such
power to executed and txrdkd by such fsoalrMs tlgnature atind foaalmra goal"be valid aeM binding upon the Company in the future with
respect to any bond or undoesal keg to%+"k Is art*Ad.
IN WITNESS W HEREOF,THE AM CASUALTY AND SURETY COMPANY has mood this Inctrumevtt to be signed by IM Assistant
Vice President and Its Corw"W tool to be hereto ofNred this 27th
day of September '19 84 .�.
T13E 'D aURETY COMPANY
State of Connecticut �. J ii eph . Kiernan
County of Han/and me.Hartford Assistant Vica President
On" 27th day of September ,1984 ,boom me,poneon.ny come JOSEPH P. K119INAN
to ma kram%who,being by rte duly atom,cow dtpoae and say:*a hsMts is s;asap Vice Pao Man sus the
THE,ETNA CASUALTYAND BURETS COMPANY.the oorpomSon deaaibod In and which rrr tor»aoove et nvshe of
esal of sent Corporation:Net rite Deaf efNxed 10 Yw sand knstrun M N air*oagw"M 5141:and ttlat White executed the a"Instrument on behalf
of the ewporedgt by pAhaxky of hWhw oflloo under the SMndhn Hoseludae thereof.
tavkm Martin loav Notary Public
CERTICATE Joh M. Derinan
1.de a idenigntd, Secretary of 71111 AIM CASUALTY AND EUROY COMPANY,a stodt oorporxlon of da
Store of COMMON&DO HERESY CtRM OW OW feragoYtg and stMdhd Pawor of Attomay and C@rtlQMe of Authority remake in KM fore and
has not bean revoked:and hNCvsrronore,rinses tle StarW tg kht akWons of Cps BoerdOf Dlrecbro,as aNfoM In the Cardliema N Autho dty,we now
M tams.
�S1iiggned and Soaked N Else Hone Of ft of dw Comp",in tale City of Hsrtlbrd,Stale this day of
v r� Vincent A. Walaha Secretary
*1104)M LA � MtINTED IN U GA
DEPARTMENT OF PUBLIC WORKS
ENGINEERING DIVISION
220 E. McCAMY STREET
JEFFERSON CITY: MO 6S101
Change Order No. ONE Job No. Date July 8, 1986
Job & Location 1986 Curb & Gutter Project Phase IV - Flora Drive
Contractor Willard Stockman Construction Corp.
It is hereby mutually agreed that when this change order has been signed
by the contracting parties , the following described changes in the
work required by the contract shall be executed by the contractor with-
out changing the terms of the contract except as herein stipulated and
agreed.
Description of Changes : See Attached Sheet
CONTRACTORS PROPOSAL FOR THE ABOVE DESCRIBED CHANGES:
I/We hereby agree to the modifications of the contract as described
above and agree to furnish all materials and labor and perform all
work in connection therewith in accordance with the requirements for
similar work in existing contract except as otherwise stipulated herein, ,
for the following considerations :
Contract Amount - Add to - or•Deduct from - the -Con-tract -Amount the sum of:
Four thousand three hundred thirty-eight and 62/1f1U---_--- -- DOLLARS ($ 4,338.62
CONTRACTOR Willard Stockman Construction Corp.
SIGNATUREp July 8, 1986
Recommended by: Project Supervisor
Signature: -9 DATE J (p
Accepted by:
Owner DATE q
Afilft
Signature
STATEMENT OF CONTRACT AMOUNT:
ORIGINAL CONTRACT AMOUNT. . . . . . . . . . . 57 516.50
PREVIOUS ADDITIONS. . . . . . . . . . . . . . -x. 3:3.32
TOTAL. . . . . . . . . . . . . . . . . . . 58,749.82,,
PREVIOUS DEDUCTIONS . . . . . . . . . . . . . .
NET PRIOR TO THIS CHANGE. . . . . . . . . . . 3, 87.0?.
AMOUNT OF THIS CHANGE Xx Add Deduct . . . . 4,338.62
CONTRACT AMOUNT TO DATE . . . . . . . . . . . 58,125.64
RE, CEI ED
/ - JUL 481966
PUBLIC WORKS DEPT.
FRANCIS STOCKMAN _ VERNON HEMMEL
6354625 ���- 635-9361
MARVIN TALKEN =r. STANLEY KOLB
39s.4464 STRUCTiON CORP. 635-2466
CONCRETE PAV140 SPECLAUSTS
Star Route 2,Schott Road
JEFFERSON CITY, MO. 65101
314.635.1316
July 8, 1986
City Of .Jefferson
320 East McCarty St.Jefferson City, MO 65101
REQUEST FOR CHANGE ORDER 140. 1
1986 CURB & GUTTER PROJECT PHASE IV
Shot Rock for subgrade stabilization - 177.1 n/t @ $9.40 per n/t $1,664.74
Rolled Stone base rock for stabilization _. 15.2 n/t @ $9.40
per n/t 142.88
(1) 4' X 11' manhole 1,200.00
Installation of 15" Corrugated Steel Pipe @ $11.00 per l.f. 1 331.00
TOTAL CHANGE ORDER NO. 1 $4,338.62
RECIE vEr
JUL 081986
PUBLIC WORKS DEPT