The URL can be used to link to this page

Home My Public Portal AboutORD10782 BILL NO. 86-177 SPONSORED BY COUNCILMAN BORGMEYER ORDINANCE NO. to 2 b'„L AN ORDINANCE OF THE CITY OF JEFFERSON, MISSOURI, AUTHORIZING THE MAYOR AND CITY CLERK TO EXECUTE A CONTRACT WITH WISCH & VAUGHAN CONSTRUCTION COMPANY, 111C. , FOR THE SCHUMATE CHAPEL - ROCK BEACON PROJECT. BE IT ENACTED BY THE COUNCIL OF THE CITY OF JEFFERSON, MISSOURI, AS FOLLOWS: Section 1. The Mayor and City Clerk are hereby authorized and directed to execute a contract with Wisch & Vaughan Construction Company, Inc. , for the Schumate Chapel - Rock Beacon Project, for the sum of $290,004.54. Section 2. The contract shall be substantially the same in form and content as that contract attached hereto as Exhibit A. Section 3. This Ordinance shall be in full force and effect from and after the date of its passage and approval. Passed Approved c-;L- - `.F'7 Prer-A ding Office Mayo ATTEST: _.P' City Clerk AGREEMENT 1'l lla AGREEMENT, made this _ �Ate' Clay of 19 lar2 by and between THE CITY OF JEFFERSON, MISSOURI hereinafler called "OWNER" INV"a 0-.•..1.Ur 1.4-10,111 and .,WISCH ANn VAUGHAN CQ STRUa1Q S. INc doing business as tl�I K x 1V.4xix (a corporation) hereinafter called "CONTRACTOR". WITNESSETH: That for and in consideration'of %he payments and agreements herein- (' after mentioned: i 1. The CONTRACTOR will commence and complete the construction of THE SCHUMATLE CHAPEL '- ROCK BEACON PROJECT Z The CONTRACTOR will furnish all of the material, supplies, tools, equipment, labor and other services necessary for the construction and completion of the PROJECT described herein. f 3. The CONTRACTOR will commend llie work required by .the CONTRACT DOC- 1 UMENTS on or before the date named in the NOTICE TO' PRO- 180; CEED and will complete the same within 180 calendar days unless the period r for completion is extended otherwise by the CON'T'RACT DOCUMENTS. '4. The CONTRACTOR agrees to perform all of the WORK described in the CON- ► ' TRACT DOCUMENTS and comply with the terms therein for the sum of S 290.004.5 _» l.; or ::s shown in the BID schedule. 5.The term "CONTRACT DOCUMENTS" means and includes the following: . (A) Advertisement For BIDS (B) Information r DS f.� (C) HID - Fo... .BID . ER__.... . . . . :. . . (D, BID BOND (E) Agreement Coqulf+K1 00C...dtIM tom CONSIPUCt1004 of _ fC0f9&tL•^WS190 wA111%A-40 M Win"OJECTS QQSODol l6g•os q fryc IGO 3 (F) Gencrai Conditions (C) SUPPLGi\ ENTAL GENERAL CONDITIONS (H) Payrficnt BOND (1) Performance BOND (j) NOTICE OF AWARD (K) NOTICE TO PROCEED (L) CHANCE ORDER , (M) DRAWINGS prepared by Sa oll & Axon. Inc. e numbered one through Thirteen , and dated June 19 86 - (N) SPECIFICATIONS prepared or issued by Russell & Axon, Inc. dated October lg 86 (0) ADDENDA: No. One —. dated December 3 29 86 .� I • No. Two , dated December 8 — 19 86 ( . No. dated _, 19 o No. _ dated 19 fNo. y dated 19 No. .dated —. 19 6. The OWNER will pay to the CONTRACTOR in the manner and at such times as r" set forth in the General Conditions such amounts as required by the CONTRACT DOCUMENTS.//%INSERT ON PAGE 00500-4 WILL BE ADDED HERE/// i � I I 7. This Agreement shall be binding ypon all parties hereto and their respective Iheirs, executors, administrators, successors, and assigns. 1 IN WITNESS WHEREOF. the parties hereto have executed, or caused to be executed � 4 Triplicate �d their duly authorized officials, this Agreement in ( • 14%0"bet a cn ) each of a•va� which shall be deemed an original on the data first above written. oec%.Mam 00500-2 ` Agovemartl Page 2 of 3 CITY OF JEFFERSON, MISSOURI BY � , N1,1M_ HAYOR GEORGE HARTSFIELD (tl'rau Trpl 1 . Title MAYOR OF THE CITY OF JEFFERSON TEAL) ' 71*EST: ` , t.aine BRENDA CIRTIN (►4ase Tym( Title CITY CLERK, CITY OF JEFFERSON CONTRACTOR: WISCH AND VAUGHAN CONSTRUCTION CO., INC. BY IiI Name -Richard Vaughan r7. _ Address 1909 SOUTH COUNTRY CLUB DRIVE �FFFFRSON CITY, MISSOURI 65101 - ,".TTEST: Lj ,lame —30 jam D. Miller r . rj X11 , 00500--3 . ._. apCyntil•rN l�. 3 �i INSERT TO BE ADDED TO PARAGRAPH 6 OF THE AGREEMENT: If the OWNER fails to make payment thirty (30) days after approval by the A/E, in addition to other remedies available to the CONTRACTOR, then shall be added to each such payment• interest at the maximum legal rate commencing on the first day after said payment is due and continuing until the payment is received by the CONTRACTOR. The legal rate of interest shall be as specified in MMS 408.020. Aft ri I 1 r t I ' i l 'J fi 1.i 00500-a :: �,�/�� Any correspondence In relation to !/ this bond should be directed to: Wausau Insurance Companies insurance Bonding Box 150 d%zomndnies Wausau,Wisconsin 54401 Bond Number 0750-29-050053-C Duplicate of A.I.A. Document A312 December 1984 Edition Performance Irlond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business): Wisch and Vaughan Construction Co. Employers Insurance of Wausau A Mutual Company 1909 South Country Club Drive 2000 Westwood Drive Jefferson City, Missouri 65101 Wausau, Wisconsin 54401 OWNER (Name and Address): City of Jefferson 320 East McCarty Street Jefferson City, Missouri 65101 CONSTRUCTION CONTRACT Date: Amount: 5290,004.54 Descript.�_)n tName and Location): Waste Water Collection Facilities Schumate Chapel-Rock Beacon Project - Contract 2A BOND Date (Not earlier than Construction Contract Date): Amount: TWO -HUNDRED NINETY THOUSAND FOUR AND 54/100 ($290,004.54) Modifications to this Bond: K None 0 See Page 3 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Wisch and Vaug onstru C n Co. Employers InZ `�e o s Waus-a-uyA Company Signature: Signature: Name and Title: Name and Title: Christine M. Flavin Attorney-in-Fact (Any additional signatures appear on page 3) (FOR INFORMATION ONLY—Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or other party): 815.4421 285 1 I The Contractor and the Surety, jointly and severally, which it may be liable to the Owner and, as bind themselves, their heirs, executors, administrators, soon as practicable after the amount is deter- successors and assigns to the Owner for the performance mined, tender payment therefor to the of the Construction Contract,which is incorporated herein Owner; or by reference. .2 Deny liability in whole or in part and notify the 2 If the Contractor performs the Construction Contract, Owner citing reasons therefor. the Surety and the Contractor shall have no obligation 5 If the Surety does not proceed as provided in Paragraph under this Bond, except to participate in conferences as 4 with reasonable promptness,the Surety shall be deemed provided in Subparagraph 3.'1. to be in default on this Bond fifteen days after receipt of an 3 If there is no Owner Default, the Surety's obligation additional written notice from the Owner to the Surety under this Bond shall arise after: demanding that the Surety perform its obligations under 3.1 The Owner has notified the Contractor and the this Bond, and the Owner shall be entitled to enforce any 3.1 a its address described a Paragraph 1Q below remedy available to the Owner. If the Surety proceeds as Surety g p provided in Subparagraph 4.4,and the Owner refuses the that the Owner is considering declaring a Contractor payment tendered or the Surety has denied liability, in Default and has requested and attempted to arrange a whole or in part,without further notice the Owner shall be conference with the Contractor and the Surety to be entitled to enforce any remedy available to the Owner. held not later than fifteen days after receipt of such notice to discuss methods of performing the Construe- 6 After the Owner has terminated the Contractor's right tion Contract. If the Owner, the Contractor and the to complete the Construction Contract, and if the Surety Surety agree, the Contractor shall be allowed a reason- elects to act under Subparagraph 4.1, 4.2, or 4.3 above, able time to perform the Construction Contract, but then the responsibilities of the Surety to the Owner shall such an agreement shall not waive the Owner's right, if not be greater than those of the Contractor under the any, subsequently to declare a Contractor Default: and Construction Contract, and the responsibilities of the Owner to the Surety shall not be greater than those of the 3.2 The Owner has declared a Contractor Default and Owner under the Construction Contract.To the limit of the formally terminated the Contractor's right to complete amount of this Bond, but subject to commitment by the the contract. Such Contractor Default shall not he de- Owner of the Balance of the Contract Price to mitigation of Glared earlier than twenty days after the Contractor and costs and damages on the Construction Contract,the Sure- the Surety have received notice as provided in Sub- ty is obligated without duplication tor: paragraph 3.1; and 3.3 6.1 The responsibilities of the Contractor for correc- Co The Owner has agreed Suret to pay the ante ce h the tion of detective work and completion of the Construc- Contract Price to the Surety in accordance with the lion Contract; terms of the Construction Contract or to a contractor selected to perform the Construction Contract in actor- 6.2 Additional legal, design professional and delav dance with the terms of the contract with the Owner. costs resulting from the Contractor's Default, and re- 4 When the Owner has satisfied the conditions of Para- sulting from the actions or failure to act of the Surety graph 3, the Surety shall promptly and at the Surety': ex- under Paragraph 4; and pense take one of the following actions: 6.3 Liquidated damages, or if no liquidated damages are specified in the Construction Contract,actual dam- Owner,Arrange for the Contractor, with consent of the ages caused by delayed performance or non-perfor- Cntra ct; or to perform and complete the Construction mance of the Contractor. Contra 7 The Surety shall not be liable to the Owner or others for 4.2 Undertake to perform and complete the Construe- obligations of the Contractor that are unrelated to the Con- tion Contract itself, through its agents or through inde- struction Contract, and the Balance of the Contract Price pendent contractors; or shall not be reduced or set off on account of any such 4.3 Obtain bids or negotiated proposals from unrelated obligations. No right of action shall accrue on qualified contractors acceptable to the Owner for a this Bond to any person or entity other than the Owner or contract for performance and completion of the Con- its heirs, executors, administrators or successors. struction Contract, arrange for a contract to be pre- g The Surety hereby waives notice of any change, includ- pared for execution by the Owner and the contractor ing changes of time, to the Construction Contract or to selected with the Owner's concurrence, to be secured related subcontracts, purchase orders and other obliga- with performance and payment bonds executed by a qualified surety equivalent to the bonds issued on the lions. Construction Contract, and pay to the Owner the 9 Any proceeding, legal or equitable, under this Bond amount of damages as described in Paragraph b in ex• may be instituted in any court of competent jurisdiction in cess of the Balance of the Contract Price incurred by the the locatiun in which the work or part of the work is located Owner resulting from the Contractor's default; or and shall be instituted within two years after Contractor 4.4 Waive its right to perform and complete, arrange Default or within two years after the Contractor ceased for completion, or obtain a new contractor and with working orwithin two years after the Surety refuses or fails- reasonable promptness under the circumstances: to perform its obligations under this Bond,whichever Oc- curs first. If the provisions of this Paragraph are void or .1 After investigation, determine the amount for prohibited by law, the minimum period of limitation avail- 2 able to sureties as a defense in the jurisdiction of the suit tractor of any amounts received or to be received by shall be applicable, the Owner in settlement of Insurance or other claims 10 Notice to the Surety,the Owner or the Contractor shall for damages to which the Contractor is entitled, re- duced by all valid and proper payments made to or on be mailed or delivered to the address shown on the sig- behalf of the Contractor under the Construction Con- nature page. tract. 11 When this Bond has been furnished to comply with a 12,2 Construction Contract:The agreement between statutory or other legal requirement in the location where the Owner and the Contractor identified on the sig- the construction was to be performed,any provision in this nature page, including all Contract Documents and Bond conflicting with said statutory or legal requirement changes thereto. shall be deemed deleted herefrom and provisions con- forming to such statutory or other legal requirement shall 12.3 Contractor Default: Failure of the Contractor, be deemed incorporated herein. The intent is that this which has neither been remedied nor waived, to per- Bond shall be construed as a statutory bond and not as a form or otherwise to comply with the terms of the common law bond. Construction Contract. 12 DEFINITIONS 12.4 Owner Default: Failure of the Owner,which has 12.1 Balance of the Contract Price: The total amount neither been remedied nor waived, to pay the Con- l the Owner t the Contractor under the tractor as required by the Construction Contract or to payable Y perform and complete or comply with the other terms Construction Contract after all proper adjustments thereof. have been made, including allowance to the Con- MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address: Address: is �y y M'I/C�usau Any correspondence in relation to '� this bond should be directed to: Wausau Insurance Companies insurance Bonding Box 150 L.p -nmpanies Wausau,Wisconsin 54401 tl4P,` 4 Bond Number 0750-29-050053-C Duplicate of A.I.A. Document A312 December 1984 Edition Payment Bond Any singular reference to Contractor, Surety, Owner or other party shall be considered plural where applicable. CONTRACTOR (Name and Address): SURETY (Name and Principal Place of Business): Wisch and Vaughan Construction Co. Employers Insurance of Wausau A Mutual Company 1909 South Country Club Drive 2000 Westwood Drive Jefferson City, Missouri 65101 Wausau, Wisconsin 54401 OWNER (Name and Address): 46ity of Jefferson 20 East McCarty Street Jefferson City, Missouri 65101 CONSTRUCTION CONTRACT Date: Amount: $290,004.54 Description (Name and Location): Waste Water Collection Facilities Schumate Chapel-Rock Beacon Project - Contract 2A BOND Date (Not earlier than Construction Contract Date): Amount: TWO HUNDRED NINETY THOUSAND FOUR AND 54/100($290,004.54) Modifications to this Bond: i7{I None See Page 6 CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Wisch and Vau -ructCo. Employers Insur of Wausau A Mutua Company Signature: Siinature: Name and itle: Name and itle: Christine M. Flavin Attorney-in-Fact (Any additional signatures appear on page 6) (FOR INFORMATION ONLY---Name, Address and Telephone) AGENT or BROKER: OWNER'S REPRESENTATIVE (Architect, Engineer or other party): 61"21 285 4 I' The Contractor and the Surety, jointly and severally, 6 When the Claimant has satisfied the conditions of Para- bind themselves, their heirs, executors, administrators, graph 4, the Surety shall promptly and at the Surety's ex- successors and assigns to the Owner to pay for labor, pense take the following actions: materials and equipment furnished for use in the perfor- 6,1 Send an answer to the Claimant,with a copy to the mance of the Construction Contract,which is incorporated Owner,within 45 days after receipt of the claim,stating herein by reference. the amounts that are undisputed and the basis for chal- 2 With respect to the Owner, this obligation shall be null longing any amounts that are disputed, and void if the Contractor: 6,2 Pay or arrange for payment of any undisputed 2.1 Promptly makes payment, directly or indirectly, amounts. for all sums due Claimants, and 7 'The Surety's total obligation shall not exceed the 2.2 Defends, indemnifies and holds harmless the amount of this Bond,and the amount of this Bond shall be Owner from all claims, demands, liens or suits by any credited for any payments made in good faith by the Surety. person or entity who furnished labor, materials or 8 Amounts owed by the Owner to the Contractor under equipment for use in the performance of the Construe- the Construction Contract shall be used for the perfor- tion Contract, provided the Owner has promptly noti- mance of the Construction Contract and to satisfy claims,if fied the Contractor and the Surety (at the address de- any, under any Construction Performance Bond. By the scribed in Paragraph 12)of any claims, demands, liens Contractor furnishing and the Owner accepting this Bond, liens suits and tendered defense of such claims,demands, they agree that all funds earned by the Contractor in the lens or suits to the Contractor and the Surety, and performance of the Construction Contract are dedicated to provided there is no Owner Default. satisfy obligations of the Contractor and the Surety under 3 With respect to Claimants, this obligation shall be null this Bond, subject to the Owner's priority to use the funds and void if the Contractor promptly makes payment, di- for the completion of the work. redly or indirectly, for all sums due. g The Surety Nhall not be liable to the Owner, Claimants 4 The Surety shall have no obligation to Claimants under or others for obligations of the Contractor that are unrelat- this Bond until: ed to the Construction Contract. The Owner>hall not be 4.1 Claimants who are employed by liable for payment of anv costs or expenses cot any Claimant or have a direct liable this PBond,arc! ;hall have under this Bond no ohliga- contract with the Contractor have giyr n notice to the tions to make payments to, give notices on behalf of, or Surety (at the address described in Paragraph 12) and otherwise have obligations to Claimants under this Bond. sent a copy.or notice thereof,to the(owner,stating that AM a claim is being made under this Bond and, with orb- to i'he Surety hereby waives notice of anv change,incluci- stantial accuracy, the amount of the claim. ing changes of time, to the Construction Con't'ract or to 4.2 Claimants who clo not have a direct contract with related suLcontracts. purchase orders and other obliga- the Contractor; bons. 11 No suit or action shall be commenced by a Claimant ,1 Have furnished written notice to the Con- under this Bond other than in a court of competent jurisdic- tractor and sent a copy, or notice thereof, to tion in the location in which the work or part of the work is the Owner, within 90 days after having last located or after the expiration of one year from the date(1) performed labor or last furnished materials or on which the Claimant gave the notice required by Sub- equipment included in the claim stating,with paragraph 4.1 or Clause 4.2 (iii), or (2) on which the last substantial accuracy, the amount of the claim labor or service was performed by anyone or the last mate- and the name of the party to whom the mate- rials or equipment were furnished by anyone under the rials were furnished or supplied or for whom Construction Contract,whichever of(1)or(2) first occurs. the labor was done or performed; and If the provisions of this Paragraph are void or prohibited by .2 Have either received a rejection in whole or in law,the minimum period of limitation available to sureties part from the Contractor,or not received with- as a defense in the jurisdiction of the suit shall be applica- in .30 days of furnishing the above notice any ble. communication from the Contractor by which 12 Notice to the Surety,the Owner or the Contractor shall the Contractor has indicated the claim will be be mailed or delivered to the address shown on the sig- nature page.Actual receipt of notice by Surely, the Owner .3 Not havingbeenpaidwithin the above.30days, or the Contractor, however accomplished, shall be suffi- have sent a written notice to the Surety tat the cient compliance as of the date received at the address address described in Paragraph'12)and sent a shown on the signature page, copy,or notice thereof, to the Owner, stating 13 When this Bond has been furnished to comply with a that a claim is being made under this Bond and statutory or other legal requirement in the location where enclosing a copyof they previous written notice the contitruction was to be performed,any provision in this furnished to the Contractor. Bond conflicting with said statutory or legal requirement 5 If a notice required by Paragraph 4 is givan by the(owner shall be deemed deleted herefrom and provisions con- to the Contractor or to the Surety,that is sufficient comps- forming to such statutory or other legal requirement shall ante. be deemed incorporated herein. The intent is that this 5 'Bond shall be construed as a statutory bond and not as a Construction Contract, architectural and engineering common law bond. services required for performance of the work of the AM 14 Upon request by any person or entity appearing to be a Contractor and the Contractor's subcontractors, and all other items for which a potential beneficiary of this Bond, the Contractor shall mechanic's lien may be asserted in the Jurisdiction where the labor, materials promptly furnish a copy of this Bond or shall permit a copy to be made. or equipment were furnished. IS DEFINITIONS 1S.2 Construction Contract:The agreement between the Owner and the Contractor identified on the sig- 15.1 Claimant: An individual or entity having a direct nature page, including all Contract Documents and contract with the Contractor orwith a subcontractor of changes thereto. the Contractor to furnish labor, materials or equip- 15.3 Owner Default: Failure of the Owner,which has ment for use in the performance of the Contract.The neither been remedied nor waived, to pay the Con- intent of this Bond shall be to include without "that a tractor as required by the Construction Contract or to lion in the terms"labor,materials or equipment"th perform and complete or comply with the other terms part of water, gas, power, light, heat, oil, gasoline, thereof. 'telephone service or rental equipment used in the MODIFICATIONS TO THIS BOND ARE AS FOLLOWS: (Space is provided below for additional signatures of added parties, other than those appearing on the cover page.) CONTRACTOR AS PRINCIPAL SURETY Company: (Corporate Seal) Company: (Corporate Seal) Signature: Signature: Name and Title: Name and Title: Address: Address: 6 Isofdo ISS r 2-9-87 _ PRODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERB ATE DOES NOT NO RIGHTS THE CERTIFICATE HOLDER.Winter-Dent & Co. EXTEND ORUALOTER THE COVERAGE AFFO D DHBYCTHEIPOLIC ED BELOW.AMEND, P.O. Box 1046 Jefferson City, Mo. 65102 COMPANIES AFFORDING COVERAGE COMPANY A Travelers Indemnity Company COMPANY INSURED LETTER Wisch & Vaughan Construction LETTER COMPANY C 1909 South Country Club Drive Jefferson City, Mo. 65101 LETTER COMPANY LETTER s THIS IS TO CERTIFY THAT POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHIC14 THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS,AND CONDI- TIONS OF SUCH POLICIES. CO POLICY EFFECTIVE POLICY EXPIRATION LIABILITY LIMITS IN THOUSANDS LTR TYPE OF INSURANCE POLICY NUMBER DATE(MM/DDNY) DATE(MWDDlYI'1 EACH OCCURRENCE AGGREGATE GENERAL LIABILITY BODILY COMPREHENSIVE FORM INJURY $ $ A PREMISES/OPERAT)ONS 650208G78571ND86 12-31-86 12-31-87 PROPERTY UNDERGROUND DAMAGE $ $ EXPLOSION 6 COLLAPSE HA7ARD PRODUCTS/COMPLETED OPERATIONS CONTRACTUAL COMB NED $ $ 500, 500, INDEPENDENT CONTRACTORS BROAD FORM PROPERTY DAMAGE PERSONAL INJURY PERSONAL INJURY $ 500, AUTOMOBILE LIABILITY OWLY ANY AUTO 9R PER" $ A 650208G7857IND86 12-31-86 12-31-87 ALL OWNED AUTOS(PRIV.PASS.) BODILY OTHER THAN INJURY ALL OWNED AUTOS PRIV. PASS. IRA AmDENr) $ HIRED AUTOS NON-OWNED AUTOS DAMAGE D E DAMAGE R GARAGE LIABILITY BI&PD COMBINED $ 500 EXCESS LIABILITY A UMBRELLA FORM CUP208G787086 12-31-86 12-31-87 COMBINED ,2,000, $ 2,000' OTHER THAN UMBRELLA FORM STATUTORY A WORKERS'COMPENSATION KUB715G965086 12-31-86 12-31-87 $-l� (EACH ACCIDENT) AND EMPLOYERS'LIABILITY $ (DISEASE-POLICY LIMIT) $ i no (DISEASE-EACH EMPLOYEE) OTHER Installation Floater 650208G7857IND86 12-31-86 12-31-87 $290,005. DESCRIPTION OF OPERATIONSILOCATIONSNEHICLES/SPECIAL ITEMS JOB: Schumate Chapel-Rock Beacon Project Wastewater Collection Facilities Contract 2A City of Jefferson SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EX. 320 East McCarty PIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO MAIL 15 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO TFIE Jefferson City, Mo. 65101 LEFT,BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE COMPANY,ITS AGENTS OR REPRESENTATIVES. ALI=ZED ESENTATI tr