HomeMy Public PortalAboutORD10981 BILL NO. 87-175
SPONSORED BY COUNCILMAN BARNICLE
ORDINANCE NO. ld_jF_
AN ORDINANCE OF THE CITY OF JEFFERSON, MISSOURI, AUTHORIZING THE
MAYOR AND CITY CLERK TO EXECUTE AN AGREEMENT WITH J.C.
INDUSTRIES, INC. , FOR PHASE II - DELONG'S INC. , SITE WORK, CDBG
PROJECT NO. 86-3D-04.
BE IT ENACTED BY THE COUNCIL OF THE CITY OF JEFFERSON, MISSOURI,
AS FOLLOWS:
Section 1. The Mayor and Clerk are hereby authorized and
directed to execute a contract with J.C. Industries, Inc. , for
Phase II - DeLong's Inc. , Site Work, CDBG Project No. 86-3D-04.
Section 2. The contract shall be substantially the same in
form and content as that contract attached hereto as Exhibit A.
Section 3. This Ordinance shall be in full force and effect
from and after the date of its passage and approval.
Passed Approved
P sidi fficer or
ATTEST:
City Clerk
i
CONSTRUCTION CONTRACT
THIS CONTRACT, made and entered into this day of
19_1rf, by and between J.C. INDUSTRIES, INC.
hereinafter call "Contractor, and the City of Jefferson, Missouri , a
municipal corporation, hereinafter call "City".
WITNESSETH: That Whereas, the Contractor has become the lowest
responsible bidder for furnishing the supervision, labor, tools,
equipment, materials and supplies and for construction the following City
improvements:
"PHASE II - DELONG'S INC. SITE WORK, CDBG PROJECT NO. 86-ED-04"
NOW, THEREFORE, the parties to this contract agree to the following:
1 . Manner and time for Completion. The Contractor agrees with the
City to furnish all supervision, labor, tools, equipment, materials and
supplies necessary to perform, and to perform, said work at Contractor' s
own expense in accordance with the contract documents and any applicable
City ordinances and state and federal laws, within Sixty (60) working days
from the date Contractor is ordered to proceed, which order shall be
issued by the Director of Planning and Code Enforcement within Thirty (30)
days after the date of this contract.
2. Prevailing Wages. All labor utilized in the construction of the
aforementioned improvements shall be paid a wage of no less than the
"prevailing hourly rate of wages" for work of a similar character in this
locality, as established by the Department of Labor and Industrial
Relations of the State of Missouri , and as established by the Federal
Employment Standards of the Department of Labor. Contractor acknowledges
that Contractor knows the prevailing hourly rate of wages for this project
because Contractor has obtained the prevailing hourly rate of wages from
the contents of Special Wage Determination No. 7-026-145 and Decision No.
M087-1 , including Modification No. 5 dated October 30, 1987, in which the
rate of wages is set forth. The Contractor further agrees that Contractor
will keep an accurate record showing the names and occupations of all
workmen employed in connection with the work to be performed under the
terms of this contract. The record shall show the actual wages paid to
the workmen in connection with the work to be performed under the terms of
this contract. A copy of the record shall be delivered to the Director of
Planning and Code Enforcement each week. In accordance with Section
290.250 RSMo, Contractor shall forfeit to the City Ten Dollars ($10.00)
for each workman employed, for each calendar day or portion thereof that
the workman is paid less than the stipulated rates for any work done under
this contract, by the Contractor or any subcontractor under the
Contractor.
3. Insurance. Contractor shall procure and maintain at its own
expense during the life of this contract:
(a) Workmen' s Compensation Insurance for all of its employees to he
engaged in work under this contract.
CC-1
W Contractor' s Public Liability Insurance in an amount not less
than $800,000 for all claims arising out of a single occurrence
and $100,000 for any one person in a single accident or
occurrence, except for those claims governed by the provisions of
the Missouri workmen' s compensation law, Chapter 287, RSMo., and
Contractor' s Property Damage Insurance in an amount not less than
$800,000 for all claims arising out of a single accident or
occurrence and $100,000 for any one person in a single accident
or occurrence.
(c) Automobile Liability Insurance in an amount not less than
$800,000 for all claims arising out of a single accident or
occurrence and $100,000 for any one person in a single accident
or occurrence.
(d) Owner' s Protective Liability Insurance - The Contractor shall
also obtain at its own expense and deliver to the City an Owner' s
Protective Liability Insurance Policy naming the City of
Jefferson as the insured, in an amount of not less than $800,000
for all claims arising out of a single accident or occurrence and
$100,000 for any one person in a single accident or occurrence,
except for those claims governed by the provisions of the
Missouri workmen' s compensation law, Chapter 287, RSMo. No
policy will be accepted which excludes liability for damage to
underground structures or by reason of blasting, explosion or
collapse.
(e) Subcontracts. In case any or all of this work is sublet, the
Contractor shall require the Subcontractor to procure and
maintain all insurance required in Subparagraphs (a) , ( b) and (c)
hereof and in like amounts.
(f) Scope of Insurance and Special Hazard. The insurance required
under ^Sub-paragraphs ( b) and (c) hereof shall provide adequate
protection for the Contractor and its subcontractors,
respectively, against damage claims which may arise from
operations under this contract, whether such operations be by the
insured or by anyone directly or indirectly employed by it, and
also against any special hazards which may be encountered in the
performance of this contract.
NOTE:
Paragraph (f) is construed to require the procurement of
Contractor' s protective insurance (or contingent public liability
and contingent property damage policies) by a general contractor
whose subcontractor has employees working on the project, unless
the general public liability and property damage policy (or rider
attached thereto) of the general contractor provides adequate
protection against claims arising from operations by anyone
directly or indirectly employed by the Contractor.
CC-2
4. Contractor' s Responsibility for Subcontractors. It is further
agreed that Contractor shall be as fully responsible to the City for the
acts and omissions of its subcontractors, and of persons either directly
or indirectly employed by them, as Contractor is for the acts and
omissions of persons it directly employs. Contractor shall cause
appropriate provisions to be inserted in all subcontracts relating to this
work, to bind all subcontractors to Contractor by all the terms herein set
forth, insofar as applicable to the work of subcontractors and to give
Contractor the same power regarding termination of any subcontract as the
City may exercise over Contractor under any provisions of this contract.
Nothing contained in this contract shall create any contractual relations
between any subcontractor and the City or between any subcontractors.
S. Liquidated Damages. The Director of Planning and Code Enforcement
may, at his discretion, deduct $100 per calendar day from any amount
otherwise due under this contract for every day the Contractor fails or
refuses to prosecute the work, or any separable part thereof, with such
diligence as will insure the completion by the time above specified, or
any extension therof, or fails to complete the work by such time, as long
as the Cith does not terminate the right of the Contractor to proceed. It
is further provided that the Contractor shall not be charged with
liquidated damages because of delays in the completion of the work due to
unforseeable causes beyond the Contractor' s control and without fault or
negligence on the Contractor' s part or the part of its agents.
6. Termination. The City reserves the right to terminate this contract
by giving at least five (5) days prior written notice to the Contractor,
without prejudice to any other rights or remedies of the City, should the
Contractor be adjudged as bankrupt, or if the Contractor should make a
general assignment for the benefit of its creditors, or if a receiver
should be appointed for the Contractor or for any of its property, or if
the Contractor should persistently or repeatedly refuse or fail to supply
enough skilled workmen or proper material , or if the Contractor should
refuse or fail to make prompt payment to any person supplying labor or
materials for the work under the contract, or persistently disregard
instructions of the City or fail to observe or perform any provisions of
the contract.
7. City' s Right to Proceed. In the event this contract is terminated
pursuant to Paragraph 6, then the City may take over the work and
prosecute the same to completion, by contract or otherwise, and Contractor
and its sureties shall be liable to the City for any costs over the amount
of this contract thereby occasioned by the City. In any such case the
City may take possession of, and utilize in completing the work, such
materials, applicances and structures as may be on the work site and are
necessary for completion of the work. The foregoing provisions are in
addition to, and not in limitation of, the rights of the City under any
other provisions of the contract, city ordinances, and state and federal
laws.
CC-3
® 8. Guards and Lights. The Contractor agrees to defend, indemnify, and
save the City harmless from and against all claims, suits and actions of
every description, brought against the City and from all damage and costs
by reason or on account of any injuries or damage and costs by reason or
on account of any injuries or damages received or sustained by any person
or persons, or their property, by Contractor, its servants, agents or
subcontractors, or arising out of the award of this contract to
Contractor.
9. Indemnity. The Contractor agrees to defend, indemnify, and save
the City harmless from and against all claims, suits and actions of every
description, brought against the City and from all damage and costs by
reason or on account of any injuries or damages received or sustained by
any person or persons, or their property, by Contractor, its servants,
agents or subcontractors in the construction of said work, or by any
negligence or carelessness in the performance of the same, or on account
of any act or omission of Contractor, its servants, agents, or
subcontractors, or arising out of the award of this contract to
Contractor.
10. Payment for Labor and Materials. The Contractor agrees and binds
itself to pay for all labor done, and for all the materials used in the
construction of the work to be completed pursuant to this contract.
Contractor shall furnish to the City a bond to insure the payment of all
materials and labor used in the performance of this contract.
11 . Payment. The City hereby agrees to pay the Contractor the work
done pursuant to this contract according to the payment schedule set forth
in the Contract Documents upon acceptance of said work by the Director of
Planning and Code Enforcement in accordance with the rates and/or amounts
stated in the bid of Contractor dated December 11 , 19 87 , which are by
reference made a part hereof. No partial payment to the Contractor shall
operate as approval or acceptance of work done or materials furnished
hereunder.
12. Contract Documents. The contract documents shall consist of the
following
a. This Contract e. General Conditions
b. Addenda f. Special Provisions
c. Notice to Contractors g. Technical Specifications
d. Signed Copy of Bid h. Drawings and/or sketches
This contract and the other documents enumerated in this paragraph,
form the Contract between the parties. These documents are as fully a
part of the contract as if attached hereto or repeated herein.
13. Nondiscrimination. The Contractor agrees in the performance of
this contract not to discrimate on the ground or because of race, creed,
color, national origin or ancestry, sex, religion, handicap, age, or
political opinion or affiliation, against any employee of Contractor or
applicant for employment and shall include a similar provision in all
subcontracts let or awarded hereunder.
CC-4
14. Notices. All notices required to be in writing may be given by
first class mail address to the City of Jefferson, 320 E. McCarty,
Jefferson City, Missouri 65101 , and Contractor at J.C. INDUSTRIES, INC. ,
P.O. BOX 1264, JEFFERSON CITY, MO 65102 _ . The date of delivery of any
notice shall be the second full day after the day of its mailing.
15. Jurisdiction. This agreement and every question arising
hereunder shall be interpreted according to the laws and statutes of the
State of Missouri .
16. IN TESTIMONY WHEREOF the parties have hereunto set their hands
and seals this _�_ day of
CITY OF JEFFERSON, MISSOURI
BY
ATTEST:
CITY CLERK
CONTRACTOR
BY
Title:
ATTEST:
"• SECRE RY
CC-5
• SAFECO INSURANCE COMPANY OF AMERICA
GENERAL INSURANCE COMPANY OF AMERICA
FIRST NATIONAL INSURANCE COMPANY
OF
SA CO HOME OFF CIE: SAFECO PLAZA
SEATTLE,WASHINGTON 98185
Bond No. 5003088
PERFORMANCE BOND
Approved by The American institute of Architects
A.I.A.Document No.A-311 February, 1970 Edition
KNOW ALL BY THESE PRESENTS,That we, J. C. Industries, Inc.
(Here insert the name and address or legal title of Contractor)
P. 0. Box 1264, Jefferson City, Missouri 65102
as Principal, hereinafter called Contractor,and SAFECO INSURANCE COMPANY OF AMERICA,a Washington Corpora-
tion of Seattle,Washington,as Surety,hereinafter called Surety,are held and firmly bound unto
City of Jefferson, 320 E. McCarty, Jefferson City, Missouri 65101
(Here insert the name and address or legal title of Owner)
as Obligee,hereinafter called Owner,in the amount of One Hundred Seventy One Thousand Three Hundred
Twenty Five and 50/100---------------------------------Dollars($ 1710325.50 )
for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators,successors and
assigns jointly and severally,firmly by these presents.
WHEREAS, Contractor has by written agreement dated_ January 5 , 19-8—entered into a Contract
with Owner fcr Phase II - DeLong's Inc. Site Work, CDBG Project No. 86-ED-04
in accordance with Drawings and Specifications prepared by Central MO. Professional Service, Inc.
2500 E. McCarty, Jefferson City, Missouri 65101
(Here insert full name and address or legal title of Architect)
which Contract is by reference made a part hereof,and is hereinafter referred to as the Contract.
NOW THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, That, if Contractor shall promptly and
faithfully perform said Contract, then this obligation shall be null and void; otherwise it shall remain in full force and
effect.
The Surety hereby waives notice of any alteration or extension of time made by the Owner.
(continued on reverse side)
5.1219 R1 9/77 PRINTED IN U.S.A.
Whenever Contractor shall be,and declared by Owner to be in default under the Contract, the Owner having performed
Owner's obligations thereunder,the Surety may promptly remedy the default,or shall promptly
1. Complete the Contract in accordance with its terms and conditions,or
2. Obtain a bid or bids for submission to Owner for completing the Contract in accordance with its terms and conditions,
and upon determination by Surety of the lowest responsible bidder, or, if the Owner elects, upon determination by
Owner and the Surety jointly of the lowest responsible bidder,arrange for a contract between such bidder and Owner,
and make available as Work progresses (even though there should be a default or a succession of defaults under the
contract or contracts of completion arranged under this paragraph)sufficient funds to pay the cost of completion less
the balance of the contract price; but not exceeding, including other costs and damages for which the Surety may be
liable hereunder, the amount set forth in the first paragraph hereof.The term"balance of the contract price,"as used
in this paragraph, shall mean the total amount payable by Owner to Contractor under the Contract and any amend-
ments thereto,less the amount properly paid by Owner to Contractor.
Any suit under this bond must be instituted before the expiration of two(2)years from the date on which final payment
under the contract falls due.
No right of action shall accrue on this bond to or for the use of any person or corporation other than the Owner named
herein or the heirs,executors,administrators or successors of Owner.
Signed and sealed this lat day of February ,19 88
J. C. Industries, Inc. a
rincipal
(Witness)
Title
SAFECO INSURANCE COMPANY ERICA
(Witness)
By �, _
Carl E. Re o d s Atto y-in- act
SAFECO INSURANCE COMPANY OF AMERICA
POWER
OF ATTORNEY HOME OFFICE: PLAZA
SEATTLE,WASHINGTON 9 8185
SEC®
No. 5462
KNOW ALL BY THESE PRESENTS:
That SAFECO INSURANCE COMPANY OF AMERICA,a Washington corporation,does hereby appoint
-----JAMES J. LANDWEHR; WILLIAM R. TWEEDIE; CARL E. REYNOLDS; BETTY KAY CHRISTIAN,
Jefferson City, Missouri---------------_–__ —_ _-------_– --__�_
its true and lawful attorneys►-in-fact,with full authority to execute on behalf of the company fidelity and surety bonds or
undertakings and other documents of a similar character issued by the company in the course of its business,and to bind
SAFECO INSURANCE COMPANY OF AMERICA thereby as fully as if such instruments had been duly executed by its
regularly elected officers at its home office.
IN WITNESS WHEREOF,SAFECO INSURANCE COMPANY OF AMERICA has executed.and attested these presents
this 20th day of August
CERTIFICATE
Extract from the By-Laws of SAFECO INSURANCE COMPANY OF AMERICA:
"Article V, Section 13. —FIDELITY AND SURETY BONDS . . . the President, any Vice President, the Secretary, and any
Assistant Vice President appointed for that purpose by the officer in charge of surety operations,shall each have authority
to appoint individuals as attorneys-in-fact or under other appropriate titles with authority to execute on behalf of the
company fidelity and surety bonds and other documents of similar character issued by the company in the course of its
business...On any instrument making or evidencing such appointment,the signatures may be affixed by facsimile.On any
instrument conferring such authority or on any bond or undertaking of the company,the seal,or a facsimile thereof,may be
impressed or affixed or in any other manner reproduced; provided, however, that the seal shall not be necessary to the
validity of any such instrument or undertaking."
Extract from a Resolution of the Board of Directors of
SAFECO INSURANCE COMPANY OF AMERICA adopted July 28, 1970.
"On any certificate executed by the Secretary or an assistant secretary of the Company setting out,
(i) The provisions of Article V,Section 13 of the By-Laws,and
(ii) A copy of the power-of-attorney appointment,executed pursuant thereto,and
(iii) Certifying that said power-of-attorney appointment is in full force and effect,
the signature of the certifying officer may be by facsimile,and the seal of the Company may be a facsimile thereof."
1, Boh A. Dickey, Secretary of SAFECO INSURANCE COMPANY OF AMERICA, do hereby certify that the foregoing
extracts of the By-Laws and of a Resolution of the Board of Directors of this corporation,and of a Power of Attorney issued
pursuant thereto,are true and correct,and that both the By-Laws,the Resolution and the Power of Attorney are still in full
force and effect.
IN WITNESS WHEREOF,I have hereunto set my hand and affixed the facsimile seal of said corporation
this 1st day of February . 19 88
5.1300 R6 3/00 PRINTED IN U.S.A.
LABOR AND MATERIAL SAFECO INSURANCE COMPANY OF AMERICA
PAYMENT BOND GENERAL INSURANCE COMPANY OF AMERICA
FIRST NATIONAL INSURANCE COMPANY
�� OF AMERICA
HOME OFFICE:SAFECO PLAZA
SEATTLE,WASHINGTON 98185
Bond No. 5003088
Approved by The American Institute of Architects
A.I.A. Document No. A-311 February, 1970 Edition
Note: This bond is issued simultaneously with a Performance Bond in favor of the Owner conditioned for the full and
faithful performance of the Contract.
KNOWALLBYTHESL•'PRF.SIN TS, Tlrat we,
J. C. Industries, Inc.
(Here insert the name and address or legal title of Contractor)
P. 0. Box 1264, Jefferson City, Missouri 65102
as Principal,hereinafter called Principal, and SAFECO INSURANCE COMPANY OF AMERICA, a Vashingfon Corppra-
tion of Seattle,Washington,as Surety,hereinafter called Surety,are held and firmly bound unto
City of Jefferson, 320 E. McCarty, Jefferson City, Missouri 65101
(Here insert the name and address or legal title of Owner)
as Obligee, hereinafter called Owner, for the use and benefit of Claimants as hereinbelow defined, in the amount of
One Hundred Seventy One Thousand Three Hundred Twenty Five and 586 ,,90(S 171,325.50 )
(Here insert a sum equal to at least one-half of the contract price)
for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators, successors and
assigns,jointly and severally, firmly by these presents.
WHEREAS,Principal has by written agreement dated January 5 1988 entered into a contract with Owner for
Phase II — DeLona's Inc. Site Work, CDBG Project No. 86—ED-04
in accordance with Drawings and Specifications prepared by Central MO Professional Service, Inc.
2500 E. McCarty, Jefferson City, Missouri 65101
(Here insert full name and address or legal title of rc itect
which contract is by reference made a part hereof,and is hereinafter referred to as the Contract.
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION IS SUCH, That if the Principal shall promptly make
payment to all Claimants as hereinafter defined, for all labor and material used or reasonably required for use in the
performance of the Contract, then this obligation shall be void; otherwise it shall remain in full force and effect,subject,
however, to the following conditions:
1. A Claimant is defined as one having a direct Contract with the Principal or with a Subcontractor of the Principal for
labor, material, or both, used or reasonably required for use in the performance of the Contract,labor and material being
construed to include that part of water, gas, power, light, heat, oil,gasoline, telephone service or rental of equipment
directly applicable to the Contract.
(continued on reverse side)
S-1220 R1 10/72 PRINTED IN U.S.A.
2. The above named Principal and Surety hereby jointly and severally agree with the Owner that every Claimant as herein
defined, who has not been paid in full before the expiration of a period of ninety (90) days after the date on which the
last of such Claimant's work or labor was done or performed,or materials were furnished by such Claimant,may sue on
this bond for the use of such Claimant, prosecute the suit to final judgment for such sum or sums as may be justly due
Claimant, and have execution thereon.The Owner shall not be liable for the payment of any costs or expenses of any such
suit.
3.No suit or action shall be commenced hereunder by any Claimant,
a) Unless Claimant, other than one having a direct Contract with the Principal, shall have given written notice to any
two of(lie following: The Principal, the Owner, or the Surety above named,within ninety(90)days after such Claimant
did or performed the last of the work or labor, or furnished the last of the materials for which said claim is made,stating
with substantial accuracy the amount claimed and the name of the party to whom the materials were furnished, or for
whom the work or labor was done or performed. Such notice shall be served by mailing the same by registered mail or
certified mail, postage prepaid, in an envelope addressed to the Principal,Owner or Surety,at any place where an office is
regularly maintained for the transaction of business, or served in any manner in which legal process may be served in the
state in which the aforesaid project is located,save that such service need not be made by a public officer.
b)After ttte expiration of one (1) year following the date on which Principal ceased work on said Contract, it being
understood, however, that if any limitation embodied in this bond is prohibited by any law controlling the construction
hereof such limitation shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by
such law.
c) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state
in which the Project, or any part thereof, is situated, or in the United States District Court for the district in which the
Project,or any part thereof,is situated,and not elsewhere.
4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith
hereunder, inclusive of the payment by Surety of mechanics' liens which may be filed of record against said improve-
ment, whether or not claim for the amount of such lien be presented under and against this bond.
Signed and sealed this 1st day of February , 19 88
J. C. Industries, Inc. (Seal)
Principal
v
Witness
T"
Title
/ SAFECO INSURANCE COMPANY OF AMERICA
Witness
By
Carl E. olds At ey-in-Fact
POWER SAFECO INSURANCE COMPANY OF AMERICA
OF ATTORNEY HOML•OFFICE:SAFECO PLAZA
SEATTLE,WASHINGTON 98185
SAFECO
No. 5462
KNOW ALL BY THESE PRESENTS:
That SAFECO INSURANCE COMPANY OF AMERICA,a Washington corporation,does hereby appoint
----JAMES J. LANDWEHR; WILLIAM R. TWEEDIE; CARL E. REYNOLDS; BETTY KAY CHRISTIAN,
Jefferson City, Missouri------- ------------ ---its true and lawful attorney(s)-in-fact,with full authority to execute on behalf of the company fidelity and surety bonds or
undertakings and other documents of a similar character issued by the company in the course of its business,and to bind
SAFECO INSURANCE COMPANY OF AMERICA thereby as fully as if such instruments had been duly executed by its
regularly elected officers at its home office.
V
IN WITNESS WHEREOF,SAFECO INSURANCE COMPANY OF AMERICA has executed and attested these presents
this 20th day of August , 1987
w�i'.-ac. ',�<,..C-^`'�:.-.. � 'iii ,�.� -'.. .•ti.;t:. ..._
Roll A Dv:t,..,,,',.,..,t ` C: i r •ici..,
CERTIFICATE
Extract from the By-Laws of SAFECO INSURANCE COMPANY OF AMERICA:
"Article V,Section 13. — FIDELITY AND SURETY BONDS . . . the President, any Vice President, the Secretary, and any
® Assistant Vice President appointed for that purpose by the officer in charge of surety operations,shall each have authority
to appoint individuals as attorneys-in-fact or under other appropriate titles with authority to execute on behalf of the
company fidelity and surety bonds and other documents of similar character issued by the company in the course of its
business...On any instrument making or evidencing such appointment,the signatures may be affixed by facsimile.On any
instrument conferring such authority or on any bond or undertaking of the company,the seal,or a facsimile thereof,may be
impressed or affixed or in any other manner reproduced; provided, however,that the seal shall not be necessary to the
validity of any such instrument or undertaking."
Extrac!from a Resolution of the Board of Directors of
SAFECO INSURANCE COMPANY OF AMERICA adopted July 28, 1970.
"On any certificate executed by the Secretary or an assistant secretary of the Company setting out,
(i) The provisions of Article V,Section 13 of the By-Laws,and
(ii) A copy of the power-of-attorney appointment,executed pursuant thereto,and
(iii) Certifying that said power-of-attorney appointment is in full force and effect,
the signature of the certifying officer may be by facsimile,and the seal of the Company may be a facsimile thereof."
1, Boh A. Dickey, Secretary of SAFECO INSURANCE COMPANY OF AMERICA, do hereby certify that the foregoing
extracts of the By-Laws and of a Resolution of the Board of Directors of this corporation,and of a Power of Attorney issued
pursuant thereto,are true and correct,and that both the By-Laws,the Resolution and the Power of Attorney are still in full
force and effect.
IN WITNESS WHEREOF, I have hereunto set my hand and affixed the facsimile seal of said corporation
'
cow'-, 1st da of February 88
y , 19
S-13W R5 3/BS PRINTED IN U.S.A.
s • Jul •
orcISSUE DATE(MMIDD/YY)
2-1-88
PRODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS
NO RIGHTS UPON THE CERTIFICATE HOLDER.THIS CERTIFICATE DOES NOT AMEND,
EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
Winter-Dent & Co.
P.O. Box 1046 COMPANIES AFFORDING COVERAGE
Jefferson City, M. 65102
c NY_iTTE R A United States Fidelity & Guaranty
COMPANY B
INSURED LETTER
J.C. Industries, Inc. COMPANY c•
P.O. Box 1264 LETTER
Jefferson City, Mo. 65102 COMPANY
LETTER
COMPAIJV E
ONE 11:11
LETTER
•
THIS IS TO CERTIFY THAT POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED.
NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY
BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS,AND CONDI.
TIONS OF SUCH POLICIES.
CO POLICY EFFECTIVE POLICY EXPIRATIDI) LIABILITY LIMITS IN THOUSANDS
LTR TYPE OF INSURANCE POLICY NUMBER DATE(M%VDDNY) DATE(MMlDDNYI EACH AGGREGATE
OCCURRENCE
GENERAL LIABILITY
BODILY
X COMPREHENSIVE FORM INJURY $ 500, $ 500
A X PREMISES/OPERATIONS MP085740380 7-1-87 7-1-88
PROPERTY
X UNDERGROUND (DAMAGE $ $
EXPLOSION&COLLAPSE HAZARD
X PRODUCTSICOMPLETED OPERATIONS
X CONTRACTUAL BI A PD
COMBINED $ $
X INDEPENDENT CONTRACTORS
X BROAD FORM PROPERTY(DAMAGE
X PERSONAL INJURY PERSONAL INJURY $ 500,
AUTOMOBILE LIABILITY BODILY
N1URY
ANY AUTO 1.-87 7-1-88 :PER PERSON) $500,
A X ALL OWNED AUTOS(PRIV. PASS.) BAP086777439 7- K.Y
OTHER THAN NJURY
• ALL OWNED AUTOS PRIV. PASS. WR AMDENT) $
• HIRED AUTOS
PROPERTY
X NON-OWNED AUTOS DAMAGE $
GARAGE LIABILITY
eIaPO
I
COMBINED $
EXCESS LIABILITY
A X UMBRELLA FORM CEP094357934 7-1-87 7-1-88 COMB NED $ $
5,000, 5,000,
OTHER THAN UMBRELLA FORM
STATUTORY
WORKERS' COMPENSATION
A AND 7000369876 7-1-87 '7-1-88 $ (EACH ACCIDENT)
EMPLOYERS'LIABILITY $ 00 (DISEASE-POLICY LIMIT)
_ $ (DISEASE-EACH EMPLOYEE)
OTHER
DESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES/SPECIAL ITEMS
JOB: Phase II - DeLong's Inc. Site Work, CDBG Project No 86-ED-04
City of Jefferson SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EX.
Y PIRATION DATE THEREOF, THE ISSUING COMPANY WILL ENDEAVOR TO
320 East McCarty MAIL 10 DAYS WRITTEN NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE
Jefferson City, MO. 65101 LEFT,BUT FAILURE TO MAIL SUCH NOTICE SHALL IMPOSE NO OBLIGATION OR UABILITY
Y OF ANY KIND UPON THE CO PANY ITS AGENTS OR REPRESENTATIVES.
AUTHO TEED RE ESENTATI
C
ISSUE DATE(MM/DD/YY)
THIS BINDER IS A TEMPORARY INSURANCE CONTRACT,SUBJECT TO THE CONDITIONS SHOWN ON THE REVERSE SIDE OF THIS FORM.
PRODUCER _ COMPANY _ BINDER NO.
United States Fidelity Guar
Winter-Dent & Co. DATE EFFECTIVE TIME DATE EXPIRATION TIME
P.O. Box 1046 12:01 AM X 12:01 AM
Jefferson City, Mo. 65102 2-1-88 PM 2-1-89 NOON
THIS BINDER 15 ISSUED TO EXTEND COVERAGE IN THE ABOVE NAMED
COMPANY PER EXPIRING POLICY NO:
CODE SUB-CODE DESCRIPTION OF OPERATIONSNEHICLES/PROPERTY(INCLUDING LOCATION)
INSURED
City of Jefferson and Central Missouri
Professional Service, Inc. Owners' Protective Liability
320 East McCarty
Jefferson City, Mo. 65101
s
TYPE OF INSURANCE COVERAGES/FORMS AMOUNT DEDUCTIBLE COINSURANCE
PROPERTY
CAUSES OF LOSS
BASIC=BROAD SPECIAL
GENERAL LIABILITY GENERAL AGGREGATE $
COMMERCIAL GENERAL LIABILITY PRODUCTS-COMPIOPS AGGREGATE $
CWµSMAPA ❑Dxupp.D F PERSONAL&ADVERTISING INJURY S
X OWNER'S&PROTECTIVE CONTRACTORS * 100 000 $800 000 /$$oo 000 EACH OCCURRENCE $
FIRE DAMAGE(ANY ONE FIRE) j$
RETRO DATE FOR CLAIMS MADE:_ MEDICAL EXPENSE(ANY ONE PERSON) 5
AUTOMOBILE ALL VEHICLES SCHEDULED VEHICLES CSL $
LIABILITYY'
81 PERSIACCID $
NON/OWNED PD $ ,1fY
HIRED MED.PAY $
GARAGE PIP $ Yt:.air
UM $ �:Ju
AUTO PHYSICAL DAMAGE ALL VEHICLES SCHEDULED VEHICLES JACV COLLISION DED: TED AMOUNT $
OTC DED: ER
EXCESS LIABILITY EACH AGGREGATE SELF-INSURED
OCCURRENCE RETENTION
UMBRELLA FORM
OTHER THAN UMBRELLA FORM RETRO DATE FOR CLAIMS.MADE:
STATUTORY r3uw'r:sr''5':%}ty7r y ''�c';'i
R
WORKER'S COMPENSATION Rjr: $ (EACH ACCIDENT)
AND
EMPLOYERS'LIABILITY rs $ (DISEASE-POLICY LIMIT)
r .
$ (DISEASE-EACH EMPLOYEE)
SPECIAL CONDITIONS/RESTRICTIONS/OTHER COVERAGES
JOB: Phase II -. De Long's Inc. Site Work, CDBG Project No 86-ED-04
J.C. Industries, Inc., P.O. Box 1264, Jefferson City, Mo. 65102 is responsible for premium
and audit.
MORTGAGEE ADDITIONAL INSURED
LOSS PAYEE
LOAN#
AUTHORIZED REPRESENTA