HomeMy Public PortalAboutORD09385 BILL NO.
INTRODUCED BY COUNCILMAN ,a. .
ORDINANCE NO. �. 4(�
AN ORDINANCE OF THE CITY OF JEFFERSON, MISSOURI , AUTHORIZING
THE MAYOR AND CLERK OF THE CITY TO EXECUTE A CONTRACT WITH
Willard J. Stockman Construction Co . Inc .
1402 Stadium Boulevard
Jefferson City, Missouri 65101
BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF JEFFERSON,
MISSOURI , AS FOLLOWS:
SECTION 1 . The Mayor and Clerk of the City are hereby
authorized and directed, for and in the name of the City, to
execute a written contract with
Willard J. Stockman Construction Co . Inc .
for the improvement of
Indian Hills Private Sewer 358 Phase II
for the sum of $53, 272 .90
SECTION 2 . A copy of said contract is attached hereto.
SECTION 3. This ordinance shall take effect and be in
force from and after its passage and approval .
Passed: Approved: '2
sl nt of t e ounce D4 or
Attest :
L;lay r
�y
7
f
• CONTRACT FOR PUBLIC WORK
THIS CONTRACT, made and entered into this 31 day of
19yo _, by and between George Hartsfield,
President of the ity Council of the City of Jefferson , Missouri , a
municipal corporation of the third class of the State of Missouri ,
Party of the First Part , and who acts for and on behalf of the City of
Jefferson, Willard J. Stockman Construction Co . Inc .
Party of the Second Part , IVITNESSETH:
THAT, WHEREAS, the City' Council of the City of Jefferson, Missouri ,
did on the day of 19 award to
the Party of the Second Pa t , Sto& man Construction Co . Inc. ,
the contract for the improvements of Indian Hills Private
AOL Sewer 358 Phase II
NOW, THEREFORE, for and in consideration of the awarding of this
contract and the work thereunder by said First Party hereto , the City
of Jefferson, Missouri , to the Second Party, Stockman Construction
Company, Inc. the said Second. Party does '
hereby contract and agree to do and perform said work, above specified
and referred to for the following prices and to accept in payment there-
fore monies now in the treasury of the First Party, upon the acceptance
of said work by the City Council of the said City of Jefferson.
QUANTITY CLASSIFICATION UNIT PRICE AMOUNT
3899. 29 L.F. 3 11sanitary sewer pipe(in. place) 4 . 75 18 ,521 . 63
'914 . 16 L.F. Ditching F Backfilling (0-61 ) 3.45 10,053. 85
• 817. 13 L.F. Ditching & Backfilling (6-81 ) 3 .65 2 ,982 . 52
108 . 00 L.F. Ditching & Backfilling (8-101 ) 3 . 85 415 . 80
60. 00 L.F . Ditching $ Backfilling (10-121 ) 4 . 10 . 246 . 00
18 each Standard Manholes (0-61 ) 465 . 00 8 ,370.00
4 . 68 V.F . Additional depth (over 61 ) 45 . 00 210 . 60
2 each Standard Lamphole 140 . 00 280 . 00
1 each Concrete Anchor 75 . 00 75 .00
24 Tons Chat Backfill (street crossing) 5 . 00 120 .00
83. 00 L.F. Concrete Encasement 10 . 00 830 . 00
200. 00 C.Y. Rock Excavation 45 . 00 91000 .100
2550. 00 L:F. Seeding & Mulching . 85 2,167 . 50
Total $53 ,272 . 90
Upon completion of the work, readjustments in the contract price
shall be made according to actual measurements and at the price per
unit specified in the contract.
• NOW, BY THESE PRESENTS, it is agreed and understood by the parties
5: hereto , that this contract is entered into subject to all existing
Z . -
ordinances of the City of Jefferson pertaining to the work awarded
r
and subject to the plans and specifications and estimates of the costs
.for work on file in the office of the City Clerk, and which shall be
JOWL considered a part and parcel of this contract ; that all questions
arising as to the proper performance of this contract of such work
in accordance with the plans and specifications therefore , and
estimates thereof, shall be decided by the Director of Public Works
of the City of Jefferson, Missouri, or by such competent person
appointed by the Mayor and the City Council of the City of Jefferson
to supervise and superintend said work in the place of and instead of
such Director of Public Works ; that in the case -of improper construction,
the City of Jefferson reserves the right at any time to suspend, re-let,
or order an entire reconstruction of the work; that contractor agrees
to commence. work on or before a date to be specified in a written
"Notice t.o Proceed" and to fully complete the project within 120
consecutive working days thereafter. The City reserves the
right at any time to suspend, re-let or order an- entire reconstruction
of the work awarded and to declare the contract forfeited, but that
such suspension, re-letting or reconstruction or forfeiture shall not
affect the right of the City to recover all damages and penalties
accruing or due it by reason of the Contractor ' s non-compliance with
this contract. Liquidated damages of $100 . 00 per day will be assessed
against the contractor for each day the work remains incomplete
following the completion date or extension thereof.
The Second Party agrees to pay all classes and crafts of labor
used in the performance of this contract the prevailing hourly rate of
wages as determined by the Department of Labor and Industrial -Relations
and Second Party acknowledges that he knows the prevailing hourly rate
of wages for all the classes and crafts of labor to -be used in the
performance of this contract because he has obtained the prevailing
hourly rate of wages from the contents of Special Wage Determination
No. 026-065 in which the rate of wages are setforth.
The Contractor further agrees , as the Second Party, that he will
keep an accurate record showing the names and occupation of al-1 work-
man employed by them in connection with the work -to be performed under
We terms of this contract , which record shall show the actual wages
paid to each said workman in connection with the work to be performed
u.
Y under the terms of this contract , and agrees further that the afore- . . .
:; mentioned accurate record shall ,be available and open at all reasoxwable .::: :
hours for the inspection by the Director of Public Works or any other
authorized employee of the City of Jefferson, Missouri . In compliance
with the Prevailing Wage Law, as amended in Sections 290 . 210 to
90. 340 inclusive, Revised Statutes of Missouri , 1969 , effective
October 13, 1969, not less than the prevailing hourly rate of wages
in the Jefferson City area shall be paid to all workmen performing
work under this contract , Section 290 . 250 . The Contractor shall
forfeit to the City, Ten Dollars ($10) for each workman employed,
for each calendar day, or portion thereof, such workman is paid less
that the stipulated rates for any work done under said contract , by
him or any subcontractor under him, Section 290. 250 .
The Second Party agrees to completely indemnify and hold harmless
the City of Jefferson for any and all damages , injuries , actions ,
costs , attorney' s fees and all other expenses whatsoever , arising out
of the performance of said work whether the property or persons damaged
are the servants and employees of the Second Party, or third parties ,
in no manner connected with said work. All interlinations , corrections ,
deletions and changes herein have been prior to the execution of this
contract.
IN WITNESS WHEREOF, the parties have hereunto set their hands and
seals this day of , 19 .
WILLARD J. STOCKMAN CITY OF JE1 ERSON, MISSOURI
CONSTRUCTION CO. , INC.
w3r, Mayor
l
(BY)
City Clerk
This contract, executed in duplicate, one copy being deposited in the
office of the City Clerk of the City of Jefferson, and the other being
returned by the party of the Second Part .
Fidelity d Deposit Company an
NOME OFFICE OF MARYLAND BALTIMORE, MD. 21203
Performance Bond
KNOW ALL MEN BY THESE PRESENTS:
That...W�,.�. .ax. ...5kA .km i�...�.azi x.uG a.on..Cs�A.+...1nc..t...14A2...Stadium..........................
(Here Insert the name and address or legal title of the Contractor)
Je.. .1P,r.$QI1...cl tY4...x1asourl....... ...................................................................................................
as Principal, hereinafter Called Contractor, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corpora-
tion of the State of Maryland, with its home office in the City of Baltimore, Maryland, U. S. A., as Surety,
hereinafter called Surety, are held and firmly bound unto.......Ca.ty...Q;�...►7eff.e rwxi..-•.-•.................................
........................................................ .......... ..... .. ..................................................... .,
(Here insert the name and address or legal title of the Owner)
as Obligee, hereinafter called Owner,
in the amount of....—Fifty—Three Thousand Two Hundred..Seventy_-Two_ a_nd_.....__._
Dollars (S...53.,•2�2.�.gIIrr..�.-�.�nrr�.�, for the payment whereof Contractor and Surety bind themselves,
their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents.
WHEREAS, Contractor has by written agreement dated...........February 4-t..........................19..8.x.,
entered into a contract with Owner for......:Lmprovementa..,of...Ind i an..Ri 21S•J?xiv. -at:e.............
Sewer...358...Phase.. I.�...�e- fexson...q, tY...... ......................
.....................................................•--•--••--•----........................---........---....--••--•-•--•--...........-•-•--•--•--............................---..........
in accordance with drawings and specifications prepared by....................................................................................
............................................•--..............---............--••----.........-----.....-•--•-•---...........................------....----------•----............•---•......
(Here insert full name,title and address)
which contract is by.xeference made a part hereof, and is hereinafter referred to as the Contract.
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contractor
shall promptly and faithfully perform said contract, then this obligation shall be null and void; otherwise
it shall remain in full force and effect.
The Surety hereby waives notice of any alteration or extension of time made by the Owner.
Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the Owner
having performed Owner's obligations thereunder, the Surety may promptly remedy the default, or shall
promptly
(1) Complete the Contract in accordance with its terms and conditions, or
(2) Obtain a bid or bids for completing the Contract in accordance with its terms and condi-
tions, and upon determination by Surety of the lowest responsible bidder, or, if the Owner elects, upon
determination by the Owner and Surety jointly of the lowest responsible bidder, arrange for a contract
between such bidder and Owner, and make available as work progresses (even though there should be
a default or a succession of defaults under the contract or contracts of completion arranged under this
paragraph) sufficient funds to pay the cost of completion less the balance of the contract price; but not
exceeding,including other costs and damages for which the Surety may be liable hereunder, the amount
set forth in the first paragraph hereof. The term "balance of the contract price," as used in this para-
graph, shall mean the total amount payable by Owner to Contractor under the Contract and any
amendments thereto, less the amount properly paid by Owner to Contractor.
Any suit under this bond must be instituted before the expiration of two (2) years from the date on
which final payment under the contract falls due.
No right of action shall accrue on this bond to or for the use of any person or corporation other than
the Owner named herein or the heirs, executors, administrators or successors of Owner.
February 13 Q
ti ,.
Signedand sealed this.......................th...............................day of...................................::.,..•......A.D. 19..,....E
In the presence of:
Willa d...5.tockman_.Construction
.1'ri>i c7 pal
..........:................... `'.....
Title
FIDELITY AND DEPOSIT COA PANY OF MARYLAND
............................... By....... .:. .. .....'.... ....... .....(SEAL)
• t o ney in Fact : e
C309e--20M,12.73 199717
Approved by The American Institute of Architects,A.I.A.Document
No.A-311 February 1970 Edition.
i
y '�w
i
D.
w ;
r
W x
ley h
Fidelity and Deposit Company
110.1f!s OFFICE OF MARYLAND BALTIMORE, MD. 21203
Labor and Material Payment Bond
Note: This bond is issued simultaneously with Performance Bond In favor
of the owner conditioned on the full and faithful performance of the contract,
KNOW ALL MEN BY THESE PRESENTS:
Co Inc. 1402 Stadium
That.....�nTi:llal,rd...Slrockman...Cax�st�xu.C��;on.........�..,...............�I..............................................................
(Here Insert the name and address or lepvl title of the Contractor)
Jef Sex son...Ci trXiBaoux-i.........6.5.x.01................. . ................................................
.................
as'Principal, hereina ter called
Principal, and F1DrLITY AND Dr-.POSIT COMPANY OF MARYLAND, a corpora-
tion of the State of Maryland, with its home_ office in the City of Baltimore, Maryland, U. S. A., as Surety,
hereinafter called Surety, are held and firmly bound unto.......city...af-.-J.effe]C Sori.................................
........................................................ ... ..-....... ..... .. ....-................................................,
....... ..... ..... .......... ......................... ..... .
(Here Insert the mane and address or leRal title of the Owner)
as Obligee, hereinafter called Owner, for the use and benefit of claimants as hereinbelow defined,
in the amount of....rnr..--,Fifty--Thxee.... u-send--•Two••-Hundred Seyenty-Two• and ---
90�100 Do11 ?.s--__--_-----------------------------------------------
(here Insert a sum equal to at least one-half of the contract price)
Dollars ($..53. 272-x•9.0- ), for the payment whereof Principal and Surety bind themselves,
their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents,
WHEREAS, Principal has by written agreement dated....----.-_February...4................................19--80,
entered into a contract with Owner for......improvements of Indian Hills Private
® Sewer 358 phase II, lTefferson City,
.................................................................................••------•.........-......._....•••--.....--.-.......--.........--•--......_.....-.....----•.....--•.-....._
in accordance with drawings and specifications prepared by....................................................................................
........................................................................................................................................................................•••-....-••._...----
(Here insert full name,title and address)
which contract is by reference made a part hereof, and is hereinafter referred to as the Contract.
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Principal shall promptly make pay-
ment to all claimants as hereinafter defined, for all labor and material Used or reasonably required for use in the performance of
the Contract,then this obligation shall be void;otherwise it shall remain in full force and effect,subject,however,to the following
conditions:
1. A claimant is defined as one having a direct contract with the Principal or with a sub-contractor of the Principal for labor,
material, or both, used or reasonably required for use in the performance of the contract, labor and material being construed to
include that part of water,gas, power, light,heat,oil,gasoline, telephone service or rental of equipment directly applicable to the
Contract.
2. The above named Principal and Surety hereby jointly and severally agree with the Owner that every claimant as herein
defined,who has not been paid in full before the expiration of a period of ninety (90)days after the date on which the last of such
claimant's work or labor was done or performed,or materials were furnished by such claimant, may sue on this bond for the use
of such claimant, prosecute the suit to final judgment for such sum or sums as may be justly due claimant, and have cxectttian
thereon.The Owner shall not be liable for the payment of any costs or expenses of any such suit.
3. No suit or action shall be commenced hereunder by any claimant:
(a) Unless claimant,other than one having a direct contract with the Principal, shall have given written notice to any
two of the following:The Principal,the Owner,or the Surety above named,within ninety (90) days after such claimant did
or performed the last of the work or labor, or furnished the last of the materials for which said claim is made, stating with
substantial accuracy the amount claimed and the name of the party to whom the materials were furnished,or for whom the
work or labor was done or performed. Such notice shall be served by mailing the same by registered mail or certified mail,
postage prepaid,in an envelope addressed to the Principal,Owner or Surety,at any place where an office is regularly main-
tained for the transaction of business,or served in any manner in which legal process may be served in the state in which the
aforesaid project is located,save that such service need not be made by a public officer.
(b) After the expiration of one (1) year following the date on which Principal ceased work on said Contract, it being
understood,however,that if any limitation embodied in this bond is prohibited by any law controlling the construction hereof
such limitation shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by such law.
(c) Other than in a state court of competent jurisdiction in and for the county or other puiitical subdivision of the state
in which the project,or any part thereof,is situated,or in the United States District Court for the district in which the project,
or any part thereof,is situated,and not elsewhere.
4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith here-
under,inclusive of the payment by Surety of mechanics' liens which may be filed of record against said improvement,whether or
not claim for the amount of such lien be presented under and against this bond.
Signed and sealed this....................4th•--•--••••-•-••-••••--•-----•••day of......_.......February A.D. 19.. 80;
In the presence of: Willa d Stockman Construction Co. ne.
..............................................................................Co. , rAL)
Principal
...................................................................................... y.,........-.............._-.......-................ . ............................
Title
FIDELITY AND DEPOSIT COI ANY OF MARYLAND
.N � ................................. a B)'.... /.........(SEAL
-
or ey i e Title
C30904-20M,12-75 199717
Approved by The American institute of Architects,A.I.A,Document
No.A-311 February 1970 Edition,
Power of Attorney
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
HOME OFFICES BALTIMORE,MD.
KNOW ALL MEN BY THESE PRESENTS:That the FIDELITY AND DEPOSIT COMPANY Or MARYLAND, a corpora-
tion of the State of Maryland,by C. M. PECOT, JR. ,Vice-President,and C. W. ROBBINS ,
Assistant Secretary, in pursuance of authority granted by Article VI, Section 2, of the By-Laws of said Com-
pany, which reads as follows:
"The President,or any one of the Executive Vice-Presidents or any one of the additional Vice-Presidents specially authorized
so to do by the Board of Directors or by the Executive Committee , shall have power, by and with the concurrence of the Sec-
retary or any one of the Assistant Secretaries, to a point Resident Vice-Presidents, Assistant Vice-Presidents, Resident Assistant
Secretaries and Attorneys-in-Fact as the business of�the Company may require,or to authorize any person or persons to execute on
behalf of the Company any bonds,undertakings,recognizances,stipulations,policies,contracts,agreements,deeds,and releases and
assignments of judgments,decrees, mortgages and instruments in the nature of mortgages,and also all other instruments and docu-
ments which the business of the Company may require, and to affix the seal of the Company thereto."
does hereby nominate, constitute and appoint Joy L. Mealy of Jefferson City, Missouri�a.....
I s true and lawful agent and Attorney-in-Fact, to make, execute, seal and deliver, for, and on its behalf as
surety, and as its act and deed:any and all bonds and undertakings, each in a penalty not
to exceed the sum of ONE HUNDRED THOUSAND DOLLARS ($1009000)...................
A-0 e execution of such bonds or undertakings in pursuance of these presents, shall be as binding upon said
Company,as fully and amply, to all intents and purposes,as if they had been duly executed and acknowledged
by the regularly elected officers of the Company at its office in Baltimore, Md., in their own proper persons.
The said Assistant Secretary does hereby certify that the aforegoing is a true copy of Article VI,Section 2,of the By-Laws of
said Company,and is now in force.
IN WITNESS WHEREOF, the said Vice-President and Assistant Secretary have hereunto subscribed
their names and affixed the Corporate Seal Of the said FIDELITY AND DEPOSIT COMPANY or MARYLAND, this,
.......................,4.tb.............................day of...................NO.V-eMber....................... A.D. 19..78....
)'�O oEPaS c4 FIDELITY AND DEPOSIT COMPANY OF MARYLAND
37`' nom. ATTEST:
s �.
~W o B ,u,�....
' rr� 't3 . y----•••••---••-•........................ .........�..............
Assistant Secretary Vice-President
STATE OF MARYLAND 1 ss:
CITY OF BALTIMORE f
On this 14th day of November A.D. 19 7$ , before the subscriber, a Notary Public of the State of
Maryland,in and for the City of Baltimore,duly commissioned and qualified,came the above-named Vice-President and Assistant.
Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND,to me personally known to be the individuals and officers described
in and who executed the preceding instrument,and they each acknowledged the execution of the same,and being by me duly sworn,
severally and each for himself deposeth and saith,that they are the said officers of the Company aforesaid,and that the seal affixed
to the preceding instrument is the Corporat:Seal of said Company, and that the said Corporate Seal and their signatures as such
officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation.
IN TESTIMONY WHEREOF,I have hereunto set my hand and affixed my Official Seal,at the City of Baltimore,the day and year
first above written. „01-1110,,
OTAgy N
_ ..........................................................._v.
........
•-• Lfl....
'�',p c,,•'��` Notary Public Commission Expires._J3?.7..js....j982
• -y� ueu
41 sy' CERTIFICATE
I,the undersigned.Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND,do hereby certify that the original
Power of Attorney of which the foregoing is a full,true and correct copy,is in full force and effect on the date of this certificate;and I
do further certify that the Vice-President who executed the said Power of Attorney was one of the additional Vice-Presidents spe-
cial){�.I authorized by V�I the Board of Directors to appoint any Attorney-in-Fact as provided in Article VI,Section 2 of the By-Laws of
the FIDELITY AND EPOSIT COMPANY OF MARYLAND.
This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the
FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 16th day of July, 1969.
RESOLVED: "That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company, whether
made heretofore or hereafter,wherever appearing upon a certified copy of any power of attorney issued by the Company, shall be
valid and binding upon the Company with the same force and effect as though manually affixed.
IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the said Company, this
.......»...».........4th..»...»».......».......day of......._.._February'.............._...1 19---8 0.
L1419—Ctt. T05711 ............... ................ .... .. .................................. .......
Assislant ecretary»
•. • • V ,r 1. 44
Y
1
Q I°° v
o Q
o. J w a.
� H w
o n Ill Z Z
LU
0 ~
� a ® I W
a a o �■ b- Um —
,rte
�w
nr