HomeMy Public PortalAboutORD09550 BILL NO.
INT CMC® BY 0OUNCII,MN
ORDINANCE NO.
AN ORDINANCE OF THE CITY OF JEFFERSON, PHG`Y)URI, AUTHORIZING AND DIRECTING
THE AIAY0R AND CITY CLERK OF THE CITY TO EXEC[A'E A WRITIEN M1rR.ACr WITH WILL,ARD
S71UOIAN CCN3IWCTION CO. , FOR THE CONSTRUCTION OF PRIVATE SEWER NO. 320,
SOUIIiRID(E DRIVE SANITARY SEWER TO SERVE THE SOUrHRIDM DRIVE AREA.
BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF JEFFERSON, MISSOURI AS
FOLLOWS:
Section 1. The Mayor and Clerk of the City are hereby authorized and
directed, for and in the name of the City, to execute a written contract with
Willard Stockman Construction Co. , for the construction of Private Sewer No.
320, Southridge Drive Sanitary Sewer to serve the Southridge Drive area.
Section 2. Said contract shall read in words and figures as follows:
(SEE ATTACHED)
Section 3. This ordinance shall take effect and be in force from and
after its passage and approval.
Passed a7/ , /,'�T, Approved 9-vbv. /�� / �Z �
esiden of the Counc Mayor
ATTEST:
7
C Clerk
r •
CONTRACT FOR PIIBI TC WORK
THIS CONTRACT , made and entered into this / day of
November;,+, 19 - 80 __, by and between George Hartsfield,
Wresident of the City Council of the City of Jefferson, Missouri , a
municipal corporation of the third class of the State of Missouri ,
Party of the First Part , and who acts for and on behalf of the City of
Jefferson, Willard Stockman Construction Company ,
Party of the Second Part , IUITNESSFTH:
THAT, WHEREAS, the City Council of the City of Jefferson, Missouri ,
did on the 20th day of October, , 19 80 , award to the
Party of the Second Part , Willard Stn kman Construction Company
the contract for the *xapma a XVfx construction of
Private Sewer 320, Southridge Drive,
NOW, THEREFORE, for and in consideration of the awarding of this
contract and the work thereunder by said First Party hereto , the City of
Jefferson, Missouri , to the Second Party,
, the said Second Party does hereby
ontract and agree to do and perform said work, above specified and
referred to for the following prices and to accept in payment therefore
monies now in the treasury of the First Party, upon the acceptance of
said work by the City Council of the said City of Jefferson.
(QUANTITY CLASSIFICATION UNIT PRICE AMOUNT
1 LS Site Grading, Excavation & Earthwork 2 , 500 . 00 2 , 500 . 00
1 LS Aggregate Surface on Road 300 . 00 300 . 00
40 LF 24" CMP 20. 00 800 .00
1 LS Finish Grading, Seeding & Mulch 400 . 00 400 . 00
1 LS Concrete Work to Build Structure 14 ,000 .00 14 , 000 . 00
1 LS Painting, Manway and Misc . Finishing 300 . 00 300 . 00
Appurtenances
1 LS 2 Gorman Rupp Submersible Pumps 'With 12 , 500 . 00 12 , 500 . 00
30HP Motor Model SS4B20-X30
0 LS Emergency Pump & Hoses 1 , 550 . 00 1 , 550 . 00
LS Piping & Appurtenances 2-4" Shut Off 1 ,127 . 00 1 , 127 .00
Valves
1 LS 2-4" Check Valves 1 , 300 . 00 1 , 300 .00
1 LS 1-3" Shut Off Valves 300 .00 300 .00
1 LS 1-3" Check Valves 600. 00 600 . 00
1 LS 1-6" Shut Off Valve Located Outside 900 . 00 900 . 00
Valve Pit
1 LS Misc. Piping, Fittings , & Appurtenances 4 , 556 .00 4 , 556 .00
1 LS Electrical Service Entrance 847 . 00 847 . 00
1 LS Healy Ruff Controls 8 , 263. 00 8 , 263 .00
1 LS Alarm Telephone Dialer Adcor 2 , 915 . 00 20915 .00
1 LS Misc. Electrical Wiring 3 ,145 . 00 3, 145 .00
5020 LF 8" Sanitary Sewer Pipe (In Place) 4 . 60 239092 . 00
107 LF 8" Sanitary Sewer Pipe Ductile Iron 10.00 1 , 070 .00
r. (In Place)
1062 LF 6 PVC Force Again Pipe (In Place) 3. 50 4 ,417 . 00
3886 LF Ditching f Backfilling (0-61 ) 3. 40 13 , 212 .40
1028 LF Ditching & Backfilling (6-81 ) 3. 90 4 , 009 . 20
219 LF Ditching F Backfilling (8 -101 ) 4 .40 963 .60
Page Two -2-
Contract for Public Work
`'SoutHridge Drive Private Sewer No. 320
QUANTITY CLASSIFICATION UNIT PRICE_, AMOUNT
82 LF Ditching & Backfilling (10-121 ) 5 .40 442 .80
". 0 LF Ditching & Backfilling (12-141 ) 6 . 50 58 . 50
8. 0 LF Ditching & Backfilling (14-161 ) 10 . 00 80. 00
37 LF Ditching $ Backfilling (16-181 ) 15 . 00 555 .00
26 Each Standard Manholes (0-61 ) 475 . 00 12 ,350 . 00
1 . 0 VF Additional Depth Manhole (Over 61 ) 40 . 00 40. 00
3 Each Standard Outside Drop (0-21 ) 150 . 00 450 . 00
5 Each Standard Lampholes 150 . 00 750. 00
46 Tons Chat Backfilling (Street Crossing) 8 . 00 368 . 00
9 Each Concrete Anchors 50 . 00 450. 00
45 LF Concrete Encasement 8 . 00 360 . 00
. 320 CY Rock Excavations 45 . 00 14 ,000. 00
3050 LF Seeding & Mulching (Force Main Gravity 1 . 00 3,050 . 00
Line)
TOTAL $136 ,421 . 50
•
Upon completion of the work, readjustments in the contract price shall
be made according to actual measurements and at the price per unit specified
in the contract .
Amk
qu NOW, BY THESE PRESENTS, it is agreed and understood by the parties
hereto, that this contract is entered into subject to all existing ordinances
of the City of Jefferson pertaining to the work awarded and subject to the
plans and specifications and estimates of the costs for such work on file in
the office of the City Clerk, and which shall be considered a part and parcel of
this contract ; that all questions arising as to the proper performance of this
contract of such work in accordance with the plans and specifications therefor,
and estimates thereof, shall be decided by the Director of Public Works of
the City of Jefferson, Missouri, or by such competent person appointed by the
Mayor and the City Council of the City of Jefferson to supervise and superin-
tend said work in the place of and instead of such Director of Public Works ;
that in the case of improper construction, the City of Jefferson reserves the
right at any time to suspend, re-let or order an entire reconstruction of the ,
wor ; that Contractor agrees to commence work on or before a date to be
siNified in a written "Notice to Proceed" and to fully complete the project
within 90 consecutive working days thereafter. The City
reserves the right at any time to suspend, re-let or order an entire recon-
struction of the work awarded and to declare the contract forfeited; but that
such suspension, re-letting or reconstruction or forfeiture shall not affect
the right of the City to recover all damages and penalties accruing or due
it by reason of the Contractor 's non-compliance with this contract . Liquidated
damages of $100 per day will be assessed against the Contractor for
each day the work remains incomplete following the completion date or extension
thereof.
The Second Party agrees to pay all classes and crafts of labor used
in the performance of this contract the prevailing hourly rate of wages
as,2etermined by the Department of Labor and Industrial Relations and
Second Party acknowledges that he knows the prevailing hourly rate of
wages for all the classes and crafts of labor to be used in the performance
of this contract because he has obtained the prevailing hourly rate of
wages from the contents of Special Wage Determination No. 1-026-039 in which
the rate of wages are set forth.
The Contractor further agrees, as the Second Party, that he will keep
an accurate record showing the names and occupation of all workmen employed
by them in connection with the work to be performed under the terms of this
contract, which record shall show the actual wages paid to each of said
workmen in connection with the work to be performed under the terms of this
contract, and agrees further that the aforementioned accurate record shall be
available and open at all reasonable hours for the inspection by the Director
Off lic Works or any other authorized employee of the City of Jefferson,
Mi uri. In compliance with the Prevailing Wage Law, as Amended in Sections
290. 210 to 290.340 inclusive, Revised Statutes of Missouri, 1969, effective
October 13, 1969, not less than the prevailing hourly rate of wages in the
Jefferson City area shall be paid to all workmen performing work under this
contract, Section 290.250. The Contractor shall forfeit to the City Ten
-4-
Dollars ($10. 00) for each workman employed , for each calendar day, or
portion thereof, such workman is paid less than the stipulated rates
for any work done under said contract, by him or any subcontractors
under him. Section 290, 250 .
The Second Party agrees to completely indemnify and hold harmless
the City of Jefferson for any and all damages , injuries , actions , costs ,
attorney's fees and all other expenses whatsoever, arising out of the
performance of said work whether the property or persons damaged are the
servants and employees of the Second Party, or third parties in no man-
ner connected with said work. All interlineations , corrections , dele-
tions and changes herein have been made prior to the execution of this
contract.
IN WITNESS WHEREOF, the parties have hereunto set their hands and
seals this" zZ day of- , 19
City of Jefferson, Missouri
By
By
This contract, executed in duplicate, one copy being deposited in
the office of the City Clerk of the City of Jefferson, and the other
b'eing:.returned by the party of the, ,Second Part.
�ra.
rr$r.
Fidelity and Deposit Company
NOME OFFICE OF MARYLAND BALTIMORE, MD. 21203
Performanee Bond
KNOW ALL MEN BY THESE PRESENTS:
That....Willaxd...Sto.ckman..Cans.txu cti-Qn...CQM- PanY.....Knc........gA02 Stadium.
(Here insert the name and address or legal title of the Contractor)
.....Je-ffaw scan...Cit.}r.t...Ma.........6.51 QI,...........................................................................................................I
as Principal, hereinafter called Contractor, and FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corpora-
tion of the State of Maryland, with its home office in the City of Baltimore, Maryland, U. S. A., as Surety,
hereinafter called Surety, are held and firmly bound unto........................................................................................
Cwt,�r...Qf...Jefferson.......................................................................................................................................I
(Here Insert the name and address or legal title of the Owner)
as Obligee, hereinafter called Owner,
in the amount of......One...H.undred...T.hirty.-S.�X..Thousand .Four Hundred Twenty-
c?mo...And... -....-.--------- ------ r---------------------------
Dollars (8-.�,.G-021-x,50.•...._..•..._........), for the payment whereof Contractor and Surety bind themselves,
their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents.
WHEREAS, Contractor has by written agreement dated...........November....18........................198. r
entered into a contract with Owner for..construction of Private Sewer 320 ,
Southxidye Dxi,ve� Jefferson City, Missouri,
........... . .. .. .. .. ............................
.................................•-•--•---------..............................................................---.....------...---.....----------.................-•--••--.....---•--.......
in accordance with drawings and specifications prepared by....................................................................................
.....................................................................................................................•----....--•--.......-----....................-•--•----•----•--........
(Here insert full name,title and address)
which contract is by,)reference made a part hereof, and is hereinafter referred to as the Contract.
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contractor
shall promptly and faithfully perform said contract, then this obligation shall be null and void; otherwise
it shall remain in full force and effect.
The Surety hereby waives notice of any alteration or extension of time made by the Owner.
Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the Owner
having performed Owner's obligations thereunder, the Surety may promptly remedy the default, or shall
promptly
(1) Complete the Contract in accordance with its terms and conditions, or
(2) Obtain a bid or bids for completing the Contract in accordance with its terms and condi-
tions, and upon determination by Surety of the lowest responsible bidder, or, if the Owner elects, upon
determination by the Owner and Surety jointly of the lowest responsible bidder, arrange for a contract
between such bidder and Owner, and make available as work progresses (even though there should be
a default or a succession of defaults under the contract or contracts of completion arranged under this
paragraph) sufficient funds to pay the cost of completion less the balance of the contract price; but not
exceeding, including other costs and damages for which the Surety may be liable hereunder, the amount
set forth in the first paragraph hereof. The term "balance of the contract price," as used in this para-
graph, shall mean the total amount payable by Owner to Contractor under the Contract and any
�! amendments'thereto, less the amount properly paid by Owner to Contractor.
Any suit under this bond must be instituted before the expiration of two (2) years from the date on
which final payment under the contract falls due.
No right of action shall accrue on this bond to or for the use of any person or corporation other than
the Owner named herein or the heirs, executors, administrators or successors of Owner.
Signed and sealed this.......................1$th November 80.
g day of................................................A.D. 19........
In the presence of:
i•l-lard.-.S.tockman...Cons truction.(SwID any,Inc.
J
Principal
Title
IDELI AND DEPOSIT COMPANY OF MARYLAND
....�...... /Z.......... ........ B�-. �lG. •�.... }//.-- .1VI.%,•t.......(SEAL)
Attorney in FacctT�tle
C309s.-20M,12a5 199717
Approved by The American Institute of Architects,A.I.A.Document
No.A-311 February 1970 Edition.
Fidelity and Deposit Company
NOME OFFICE OF MARYLAND BALTIMORE, MD. 21203
Labor and Material Payment bona)
Note: This bond is issued simultaneously with Performance Bond in favor
of the owner conditioned on the full and faithful performance of the contract.
KNOW ALL MEN BY THESE PRESENTS:
That....Willard Stockman Construction CompanX.,_...Inc. , 1402 Stadium,
.......................................................................... . ....................................................
(Here nee t th name and address or legal title of the Contractor)
Jefferson City. ..-MQ........ 5101 .....................
....... ......... ....... . ......... ......................................................
as Principal, hereinafter called Principal, and FIDEi.ITY AND DEPOSIT COMPANY Or MARYLAND, a corpora-
tion of the State of Maryland, with its home office in the City of Baltimore, Maryland, U. S. A., as Surety,
hereinafter called Surety, are held and firmly bound unto........................................................................................
City of Jefferson
........................................................................................................................................................
(Ilere insert the name and address or legal title of the Owner)
as Obligee, hereinafter called Owner, for the use and benefit of claimants as hereinbelow defined,
in the amount of...One Hundred Thirty-Six Thousand Four Hundred Twenty-
...........One and 50/100--------------------------- - - ----
............................................................................................................................................................................................
,
(Here insert a sum equal to at least one-half of the contract price)
Dollars (5....7.36.,.4.2 .-.-50•-----------), for the payment whereof Principal and Surety bind themselves,
their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents.
WHEREAS, Principal has by written agreement dated.................November 18, 19 80
entered into a contract with Owner for....construction...o.f...P.7riv.ate...Se-w-er...3.2.0.,.....................
Southridge Drave_,•..Jefferson..City)-..Missouri.,._..•..............................
in accordance with drawings and specifications prepared by....................................................................................
.......................................................••---............------..............------•---•-•---•----•---•-••---...................--•--.........................••••••••--•----
mere Insert full name,title and address)
which contract is by reference made a part hereof, and is hereinafter referred to as the Contract.
NOW, THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Principal shall promptly make pay-
ment to all claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of
the Contract,then this obligation shall be void;otherwise it shall remain in full force and effect,subject,however,to the following
conditions:
1. A claimant is defined as one having a direct contract with the Principal or with a sub-contractor of the Principal for labor,
material,or both, used or reasonably required for use in the performance of the contract, labor and material being construed to
include that part of water,gas,power, light,heat,oil,gasoline, telephone service or rental of equipment directly applicable to the
Contract.
2. The above named Principal and Surety hereby jointly and severally agree with the Owner that every claimant as herein
defined,who has not been paid in full before the expiration of a period of ninety (90)days after the date on which the last of such
claimant's work or labor was done or performed,or materials were furnished by such claimant, may sue on this bond for the use
of such claimant, prosecute the suit to final judgment for such sum or sums as may be justly due claimant, and have execution
thereon. The Owner small not be liable for the payment of any costs or expenses of any such suit.
3. No suit or action shall be commenced hereunder by any claimant:
(a) Unless claimant,other than one having a direct contract with the Principal, shall have given written notice to any
two of the following:The Principal, the Owner,or the Surety above named,within ninety (90) days after such claimant did
or performed the last of the work or labor, or furnished the last of the materials for which said claim is made,stating with
substantial accuracy the amount claimed and the name of the party to whom the materials were furnished,or for whom the
work or labor was done or performed. Such notice shall be served by mailing the same by registered mail or certified mail,
postage prepaid, in an envelope addressed to the Principal, Owner or Surety,at any place where an office is regularly main-
tained for the transaction of business,or served in any manner in which legal process may be served in the state in which the
aforesaid project is located, save that such service need not be made by a public officer.
(b) After the expiration of one (1) year following the date on which Principal ceased work on said Contract, it being
understood,however,that if any limitation embodied in this bond is prohibited by any law controlling the construction hereof
such limitation shall be deemed to be amended so as to be equal to the minimum period of limitation permitted by such law.
(c) Other than in a state court of competent jurisdiction in and for the county or other political subdivision of the state
in which the project,or any part thereof,is situated,or in the United States District Court for the district in which the project,
or any part thereof, is situated,and not elsewhere.
4. The amount of this bond shall be reduced by and to the extent of any payment or payments made in good faith here-
under, inclusive of the payment by Surety of mechanics'liens which may be filed of record against said improvement,whether or
not claim for the amount of such lien be presented under and against this bond.
Signed and sealed this.................18.th................................day of........November.................A.D. 19$.0...
In the presence of: Willard..Stockman- on, txt ,oSgipany,Inc
Principal
Title
1DELITY AND DEPOSIT COMPANY OF MARYLAND
........ . .................. B 3kA 11.C.62 7>...r
Attorney in Fact Title
C30904-20M.12.73 199717
Approved by The American institute of Architects,A.I.A.Document
No.A•311 February 1970 Edition.
Power of Attorney
FIDELITY AND DEPOSIT COMPANY OF MARYLAND
HOME Offlas SWIM=MD.
KNOW ALL MEN BY THESE PRESENTS:That the FIDELITY AND DEPOSIT COMPANY OF MARYLAND, a corpora-
tion of the State of Maryland, by C. M. PECOT, JR. , Vice-President, and C. W. ROBBINS ,
Assistant Secretary, in pursuance of authority granted by Article VI,Section 2,of the By-Laws of said Com-
pany,which reads as follows:
SEc.2.The President or any Executive Vice-President,or any of the Senior Vice-Presidents or Vice-Presidents specially author-
ized so to do by the Board of Directors or by the Executive Committee,shall have power,by and with the concurrence of the Secre-
tary or any one of the Assistant Secretaries,to appoint Resident Vice-Presidents,Assistant Vice-Presidents and Attorneys-in-Fact
as the business of the Company may require or to authorize any person or persons to execute on behalf of the Company any bonds,
undertakings,recognizances,stipulations,policies,contracts,agreements,deeds,and releases and assignments of judgments,decrees,
mortgages and instruments in the nature of mortgages,and also all other instruments and documents which the business of the Com-
pany may require,and to affix the seal of the Company thereto.
does hereby nominate, constitute and appoint William A. Norman and Mary Ann Neutzler, both
of Jefferson City, Missouri, EACH.. .... . .. . . ..... .. .. .. . .... .... . ... .. .. .
Its true and lawful agent and Attorney-in-Fact, to make, execute, seal and deliver, for, and on its behalf as
surety, and as its act and deed: any and all bonds and undertakings. .. .. *6*. .. . .. . .. .
And the execution of such bonds or undertakings in pursuance of these presents,shall be as binding upon said
Company,as fully and amply,to all intents and purposes,as if they had been duly executed and acknowledged
by the regularly elected officers of the Company at its office in Baltimore, Md., in their own proper persons.
This power of attorney revokes that issued on behalf of James D. Werner, etal,
dated, July 30, 1980.
The said Assistant Secretary does hereby certify that the aforegoing is a true copy of Article VI,Section 2,of the By-Laws of
said Company,and is now in force.
IN WITNESS WHEREOF, the said Vice-President and Assistant Secretary have hereunto subscribed
their names and affixed the Corporate Seal of the said FIDELITY AND DEPOSIT COMPANY OF MARYLAND, this
....••••.................13.th............•....••---....day of..........-•---•---Qctabar.........................A.D. 19....$Q.
FIDELITY AND IDEPOSIT COMPANY OF MARYLAND
ATTEST:
SEALs.00
yrri1 ................ .............................. By......................-....
Assistant Secretary Vice-President
STATE OF MARYLAND l SS:
CITY OF BALTIMORE f
On this 13th day of October , A.D. 19 80 , before the subscriber, a Notary Public of the State of
Maryland,in and for the City of Baltimore,duly commissioned and qualified,came the above-named Vice-President and Assistant
Secretary Of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND,to me personally known to be the individuals and officers described
in and who executed the preceding instrument,and they each acknowledged the execution of the same,and being by me duly sworn,
severally and each for himself deposeth and saith,that they are the said officers of the Company aforesaid,and that the seal affixed
to the preceding instrument is the Corporate Seal of said Company,and that the said Corporate Seal and their signatures as such
officers were duly affixed and subscribed to the said instrument by the authority and direction of the said Corporation.
IN TEsTIMoNY WHEREOF, I have hereunto set my hand and affixed my Official Seal,at the City of Baltimore,the day and year
first above written.
Vr/NOlA111 ..................... ........ .......... ... . ...................................
'� Notary Pu is Commi 10 xpires..J�I71.y...9.....9.9 .2
CERTIFICATE
I,the undersigned,Assistant Secretary of the FIDELITY AND DEPOSIT COMPANY OF MARYLAND,do hereby certify that the original
Power of Attorney of which the foregoing is a full,true and correct copy,is in full force and effect on the date of this certificate;and I
do further certify that the Vice-President who executed the said Power of Attorney was one of the additional Vice-Presidents spe-
ciallx authorized by the Board of Directors to appoint any Attorney-in-Fact as provided in Article VI,Section 2 of the By-Laws of
the!'1DHLITY AND DEP09IT COMPANY OF MARYLAND.
This Certificate may be signed by facsimile under and by authority of the following resolution of the Board of Directors of the
FIDELITY AND DEPOSIT COMPANY OF MARYLAND at a meeting duly called and held on the 16th day of July, 1969.
RESOLVED: "That the facsimile or mechanically reproduced signature of any Assistant Secretary of the Company, whether
made heretofore or hereafter wherever appearing upon a certified copy of any power of attorney issued by the Company,shall be
valid and binding upon the 6ompany with the same force and effect as though manually affixed.
IN TESTIMONY WHEREOF, I have hereunto subscribed my name and affixed the corporate seal of the said Company, this
18th day of.._......... If��tember....._.._.._.., 198.0.,..
......._. _............... .. ... ........._.................._.. ......................
w•:ecu.—IM 6.80 210737
Assns Secretary