Loading...
HomeMy Public PortalAboutORD09605 BILL NO, INTRODUCED BY COUNCILMAN ORDINANCE NO, � AN ORDINANCE OF THE CITY OF JEFFERSON, MISSOURI, AUTHORIZING THE MAYOR AND CLERK OF THE CITY TO EXECUTE AN AGREEMENT WITH Horner & Shifrin, Inc. , Consulting Engineers 5200 Oakland Avenue, St, Louis , Missouri 63110 BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF JEFFERSON, MISSOURI , AS FOLLOWS : SECTION 1. The Mayor and Clerk of the City are hereby authorized and directed, for and in the name of the City, to execute a written agreement with Horner & Shifrin, Inc, Consulting Engineers for the design of the Gray's Creek facility for the sum of $143,100.00 SECTION 2. A copy of said agreement is attached hereto. SECTION 3, This ordinance shall take effect and be in force from and after its passage and approval. Passed: f� _1 / Approved: •-�-- �t Weside/t of the Co cif y r ATTEST CiyC 4 y CONTRACT FOR PROFESSIONAL ENGINEERING SERVICES FOR PREPARATION OF CONSTRUCTION PLANS AND SPECIFICATIONS AND OTHER SERVICES IN CONJUNCTION WITH COLE JUNCTION PUMP STATION AND ASSOCIATED INTERCEPTOR SEWERS FOR THE CITY OF JEFFERSON, MISSOURI AGREEMENT This Agreement, made this day of r , 1981, by and between Horner & Shifrin, Inc. , Consulting En eers, hereinafter referred to as the "Engineer," and the City of Jefferson Missouri, hereinafter referred to as the "Owner." WITNESSETH: WHEREAS, the Owner proposes to construct a pump station and a system of interceptor sewers to serve the area in the vicinity of Cole Junction, including a connection from the Grays Creek area of the Cole County Regional Sewer District, and WHEREAS, THE U.S. Environmental Protection Agency has certain requirements and regulations for engineering contracts for professional services for funded projects, and WHEREAS, the Owner has selected the Engineer to perform certain professional engineering services as hereinafter described in conjunction with the project included in thes Step II Grant, and WHEREAS, the Engineer is willing to perform services under the terms and conditions hereinafter stated. NOW, THEREFORE, for the conditions set forth hereinafter, the parties agree as follows: ARTICLE I - GENERAL CONDITIONS A. GENERAL (a) The Owner and the Engineer agree that the following provisions apply to the EPA grant eligible work to be performed under this Agreement and that such provisions supersede any conflicting provisions of this Agreement. (b) The work under this Agreement is funded in part by a grant from the U.S. Environmental Protection Agency. Neither the United States nor the U.S. Environmental Protection Agency (hereinafter "EPA") is a party to this Agreement. This Agreement which covers grant-eligible work is subject to regulations contained in 40 CFR 35.936, 35.937, and 35.939 in effect on the date of execution of this Agreement. As used in these clauses, the words "the date of execution of this Agreement" mean the date of execution of this Agreement and any subsequent modification of the terms, compensation or scope of services pertinent to unperformed work. -1- so (c) The Owner's rights and remedies provided in these clauses are in addition to any other rights and remedies provided by law or this agreement. B. RESPONSIBILITY OF THE ENGINEER (a) The Engineer shall be responsible for the professional quality, technical accuracy, timely completion, and the coordination of all designs, drawings, specifications, reports, and other services furnished by the Engineer under this agreement. The Engineer shall, without additional compensation, correct or revise any errors, omissions or other deficiencies in his designs, drawings, specifications, reports and other services. (b) The Engineer shall perform such professional services as may be necessary to accomplish the work required to be performed under this agreement, in accordance with this agreement and applicable EPA requirements in effect on the date of execution of this agreement. (c) The Owner's or EPA's approval of drawings, designs, specifications, reports, and incidental engineering work or materials furnished hereunder shall not in any way relieve the Engineer of responsibility for the technical adequacy of his work. Neither the Owner's nor EPA's review, approval or acceptance of, nor payment for, any of the services shall be construed to operate as a waiver of any rights under this agreement or of any cause of action arising out of the performance of this agreement. (d) The Engineer shall be and shall remain liable in accordance with applicable law for all damages to the Owner or EPA caused by the Engineer's negligent performance of any of the services furnished under this agreement, except for errors, omissions or other deficiencies to the extent attributable to the Owner, Owner-furnished data or any third party. The Engineer shall not be responsible for any time delays in the project caused by circumstances beyond the Engineer's control. Where innovative processes or techniques (see 40 CRF 35.908) are recommended by the Engineer and are used, the Engineer shall be liable only for gross negligence to the extent of such use. C. SCOPE OF WORK The services to be performed by the Engineer shall include all services required to complete the task or step in accordance with applicable EPA regulations (40 CFR Part 35, Subpart E in effect on the date of execution of this agreement) to the extent to the scope of work as defined and set out in the engineering services agreement to which these provisions are attached. D. CHANGES (a) The Owner may, at any time, by written order, make changes within the general scope of this agreement in the services or work to be performed. If such changes cause an increase or decrease in the Engineer's cost of, or time required for, performance of any services under this agreement, whether or not changed by any order, an equitable adjustment shall be made and this agreement shall be modified in writing accordingly. The Engineer must assert any claim -2- for adjustment under this clause in writing within 30 days from the date of receipt by the Engineer of the notification of change, unless the Owner grants a further period of time before the date of final payment under this agreement. (b) No services for which an additional compensation will be charged by the Engineer shall be furnished without the written authorization of the Owner. (c) In the event that there is a modification of EPA requirements relating to the services to be performed under this agreement after the date of execution of this agreement, the increased or decreased cost of performance of the services provided for in this agreement shall be reflected in an appropriate modification of this agreement. E. TERMINATION (a) Either party may terminate this agreement, in whole or in part, in writing, if the other party substantially fails to fulfill its obligations under this agreement through no fault of the terminating party. However, no such termination may be effected unless the other party is given (1) not less than ten (10) calendar days written notice (delivered by certified mail, return receipt requested) of intent to terminate and (2) an apportunity for consultation with the terminating party before termination. (b) The owner may terminate this agreement in whole or in part in writing for its convenience, if the termination is for good cause (such as for legal or financial reasons, major changes in the work or program requirements, initiation of a new Step) and the Engineer is given (1) not less than ten (10) calendar days written notice (delivered by certified mail, return receipt requested) of intent to terminate and (2) an opportunity for consultation with the terminating party before termination. (c) If the owner terminates for default, an equitable adjustment in the price provided for in this agreement shall be made, but (1) no amount shall be allowed for anticipated profit on unperformed services or other work, and (2) any payment due to the Engineer at the time of termination may be adjusted to the extent of any additional costs the Owner incurs because of the Engineer's default. If the Engineer terminates for default or if the Owner terminates for convenience, the equitable adjustment shall include a reasonable profit for services or other work performed. The equitable adjustment for any termination shall provide for payment to the Engineer for services rendered and expenses incurred before the termination, in addition to termination settlement costs the Engineer reasonably incurs relating to commitments which had become firm before the termination. (d) Upon receipt of a termination action under paragraphs (a) or (b) above, the Engineer shall (1) promptly discontinue all services affected (unless the notice directs otherwise), and (2) deliver or otherwise make available to the Owner all data, drawings, specifications, reports, estimates, summaries, and such other information and materials as the Engineer may have accumulated in performing this agreement, whether completed or in process. -3- (e) Upon termination under paragraphs (a) or (b) above, the Owner may take over the work and prosecute the same to completion by agreement with another party or otherwise. Any work the Owner takes over for completion will be completed at the Owner's risk, and the Owner will hold harmless the Engineer from all claims and damages arising out of improper use of the Engineer's work. (f) If, after termination for failure of the Engineer to fulfill contractual obligations, it is determined that the Engineer had not so failed, the termination shall be deemed to have been effected for the convenience of the Owner. In such event, adjustment of the price provided for in this agreement shall be made as paragraph (c) of this clause provides. F. REMEDIES Except as this agreement otherwise provides, all claims, counter-claims, disputes and other matters in question between the Owner and the Engineer arising out of or relating to this agreement or the breach of it will be decided by arbitration if the parties hereto mutually agree, or in a court of competent jurisdiction within the State in which the Owner is located. G. PAYMENT (a) Payment shall be made in accordance with the payment schedule incorported in this agreement as soon as practicable upon submission of statements requesting payment by the Engineer to the Owner. If no such payment schedule is incorporated in this agreement, the payment provisions of paragraph (b) of this clause shall apply. (b) The Engineer may request monthly progress payments and the Owner shall make them as soon as practicable upon submission of statements requesting payment by the Engineer to the Owner. When such progress payments are made, the Owner may withhold up to ten (10) percent of the vouchered amount until satisfactory completion by the Engineer of work and services within a step called for under this agreement. When the Owner determines that the work under this agreement or any specified task hereunder is substantially complete and that the amount of retained percentages is in excess of the amount considered by him to be adequate for his protection, he shall release to the Engineer such excess amount. (c) No payment request made under paragraph (a) or (b) of this clause shall exceed the estimated amount and value of the work and services performed by the Engineer under this agreement. The Engineer shall prepare the estimates of work performed and shall supplement them with such supporting data as the Owner may require. (d) Upon satisfactory completion of the work performed under this agreement, as a condition precedent to final payment under this agreement or to settlement upon termination of the agreement, the Engineer shall execute and deliver to the Owner a release of all claims against the Owner arising under or by virtue of this agreement, other than such claims, if any, as may be -4- specifically exempted by the Engineer from the operation of the release in stated amounts to be set forth therein. H. PROJECT DESIGN (a) In the performance of this agreement, the Engineer shall, to the extent practicable, provide for maximum use of structures, machines, products, materials, construction methods, and equipment which are readily available through competitive procurement, or through standard or proven production techniques, methods, and processes, consistent with 40 CFR 35.936-3 and 35.936-13 in effect on the date of execution of this agreement, except to the extent to which innovative technology may be used under 40 CFR 35.908 in effect on the date of execution of this agreement. (b) The Engineer shall not, in the performance of the work under this agreement, produce a design or specification which would require the use of structures, machines, products, materials, construction methods, equipment, or processes which the Engineer knows to be available only from a sole source, unless the Engineer has adequately justified the use of a sole source in writing. (c) The Engineer shall not, in the performance of the work under this agreement, produce a design or specification which would be restrictive in violation of Sec. 204 (a) (6) of the Clean Water Act. This statute requires that no specification for bids or statement of work shall be written in such a manner as to contain proprietary, exclusionary, or discriminatory requirements other than those based upon performance, unless such requirements are necessary to test or demonstrate a specific thing, or to provide for necessary interchangeability of parts and equipment, or at least two brand names or trade names of comparable quality or utility are listed and are followed by the words "or equal". With regard to materials, if a single material is specified, the Engineer must be prepared to substantiate the basis for the selection of the material. (d) The Engineer shall report to the Owner any sole-source or restrictive design or specification giving the reason or reasons why it is necessary to restrict the design or specification. (e) The Engineer shall not knowingly specify or approve the performance of work at a facility which is in violation of Clean Air or Water Standards and which is listed by the Director of the EPA office of Federal Activities under 40 CFR Part 15. I. AUDIT: ACCESS TO RECORDS (a) The Engineer shall maintain books, records, documents and other evidence directly pertinent to performance on EPA grant work under this agreement in accordance with generally accepted accounting principles and practices consistently applied, and 40 CFR 30.605, 30.805, and 35.935-7 in effect on the date of execution of this agreement. The Engineer shall also maintain the financial information and data used by the Engineer in the preparation or support of the cost submission required under 40 CFR 35.937-6(b) -5- in effect on the date of execution of this agreement and a copy of the cost summary submitted to the Owner. The United States Environmental Protection Agency, the Comptroller General of the United States, the United States Department of labor, Owner and Missouri Department of Natural Resources or any of their duly authorized representatives shall have access to such books, records, documents and other evidence of inspection, audit and copying. The Engineer will provide proper facilities for such access and inspection. (b) The Engineer agrees to include paragraphs (a) through (e) of this clause in all his contracts and all tier subcontracts directly related to project performance that are in excess of $10,000. (c) Audits conducted under this provision shall be in accordance with generally accepted auditing standards and established procedures and guidelines of the reviewing or audit agency(ies). (d) The Engineer agrees to the disclosure of all information and reports resulting from access to records under paragraphs (a) and (b), of this clause to any of the agencies referred to in paragraph (a) provided that the Engineer is afforded the opportunity for an audit exit conference and an opportunity to comment and submit any supporting documentation on the pertinent portions of the draft audit report and that the final audit report will include written comments of reasonable length, if any, of the Engineer. (e) The Engineer shall maintain and make available records under paragraphs (a) and (b) of this clause during performance on EPA grant work under this agreement and until three years from date of final EPA grant payment for the project. In addition, those records which relate to any "dispute" appeal under an EPA grant agreement, to litigation, to the settlement of claims arising out of such performance, or to costs or items to which an audit exception has been taken, shall be maintained and made available until three years after the date of resolution of such appeal, litigation, claim or exception. J. PRICE REDUCTION FOR DEFECTIVE COST OR PRICING DATA (This clause is applicable if the amount of this agreement exceeds $100,000. ) (a) If the Owner or EPA determines that any price, including profit, negotiated in connection with this agreement or any cost reimbursable under this agreement was increased by any significant sums because the Engineer or any subcontractor furnished incomplete or inaccurate costs or pricing data or data not current as certified in his certification of current cost or pricing data (EPA Form 5700-41), then such price, cost, or profit shall be reduced accordingly and the agreement shall be modified in writing to reflect such reduction. (b) Failure to agree on a reduction shall be subject to the Remedies clause of this agreement. -6- K. SUBCONTRACTS (a) Any subcontractors and outside associates or consultants required by the Engineer in connection with the services under this agreement will be limited to such individuals or firms as were specifically identified and agreed to during negotiations, or as the Owner specifically authorizes during the performance of this agreement. The Owner must give price approval for any substitutions in or additions to such subcontractors, associates, or consultants. (b) The Engineer may not subcontract services in excess of thirty (30) percent of the contract price to subcontractors or consultants without the Owner's prior written approval. L. LABOR STANDARDS To the extent that this agreement involves "construction" (as defined by the Secretary of Labor), the Engineer agrees that such construction work shall be subject to the following labor standards provisions, to the extent applicable: (a) Davis-Bacon Act (40 U.S.C. 276a-276a-7) ; (b) Contract Work Hours and Safety Standards Act (40 U.S.C. 327-333); (c) Copeland Anti-Kickback Act (18 U.S.C. 874) ; and (d) Executive Order 11246 (Equal Employment Opportunity) ; and implementing rules, regulations, and relevant orders of the Secretary of Labor or EPA. The Engineer further agrees that this agreement shall include and be subject to the "Labor Standards Provisions for Federally Assisted Construction Contracts" (EPA Form 5720-4) in effect at the time of execution of this agreement. M. EQUAL EMPLOYMENT OPPORTUNITY In accordance with EPA policy as expressed in 40 CFR 30.420-5, the Engineer agrees that he will not discriminate against any employee or applicant for employment because of race, religion, color, sex, age or national origin. N. UTILIZATION OF SMALL AND MINORITY BUSINESSES In accordance with EPA policy as expressed in 40 CFR 35.936-7, the Engineer agrees that qualified small business and minority business enterprises shall have the maximum practicable opportunity to participate in the performance of EPA grant-assisted contracts and subcontracts. -7- 0. COVENANT AGAINST CONTINGENT FEES The Engineer warrants that no person or selling agency has been employed or retained to solicit or secure this contract upon an agreement or understanding for a commission, percentage, brokerage, or contingent fee, excepting bona fide employees. For breach or violation of this warranty the Owner shall have the right to annul this agreement without liability or in its discretion to deduct from the contract price or consideration, or otherwise recover, the full amount of such commission, percentage, brokerage, or contingent fee. P. GRATUITIES (a) If it is found, after notice and hearing, by the Owner that the Engineer, or any of the Engineer's Agents or Representatives, offered or gave gratuities (in the form of entertainment, gifts, or otherwise) to any official, employee, or agent of the Owner, of the State, or of EPA in an attempt to secure contract or favorable treatment in awarding, amending, or making any determinations related to the performance of this agreement, the Owner may, by written notice to the Engineer, terminate the right of the Engineer to proceed under this agreement. The Owner may also pursue other rights and remedies that the law or this agreement provides. However, the existence of the facts upon which the Owner bases such findings shall be in issue and may be reviewed in proceedings under the Remedies clause of this agreement. (b) In the event this agreement is terminated as provided in paragraph (a) hereof, the Owner shall be entitled (1) to pursue the same remedies against the Engineer as it could pursue in the event of a breach of the contract by the Engineer, and (2) as a penalty in addition to any other damages to which it may be entitled by law, to exemplary damages in an amount (as determined by the Owner) which shall be not less than three nor more than ten times the costs the Engineer incurs in providing any such gratuities to any such officer or employee. Q. PATENTS If this agreement involves research, developmental, experimental, or demonstration work and any discovery or invention arises or is developed in the course of or under this agreement, such invention or discovery shall be subject to the reporting and rights provisions of Subpart D of 40 CFR Part 30, in effect on the date of execution of this agreement, including Appendix B of Part 30. In such case, the Engineer shall report the discovery or invention to EPA directly or through the Owner, and shall otherwise comply with the Owner's responsibilities in accordance with Subpart D of 40 CFR Part 30. The Engineer agrees that the disposition of rights to inventions made under this agreement shall be in accordance with the terms and conditions of Appendix B. The Engineer shall include appropriate patent provisions to achieve the purpose of this condition in all subcontracts involving research, developmental, experimental, or demonstration work. -8- R. COPYRIGHTS AND RIGHTS IN DATA ® (a) The Engineer agrees that any plans, drawings, designs, specifications, computer programs (which are substantially paid for with EPA grant funds), technical reports, operating manuals, and other work submitted with a Step 1 Facilities Plan or with a Step 2 or Step 3 grant application or which are specified to be delivered under this agreement or which are developed or produced and paid for under this agreement (referred to in this clause as "Subject Data") are subject to the rights in the United States, as set forth in Subpart D of 40 CFR Part 30 and in Appendix C to 40 CFR Part 30, in effect on the date of execution of this agreement, these rights include the right to use, duplicate and disclose, such Subject Data, in whole or in part, in any manner for any purpose whatsoever, and to have others do so. For purpose of this clause "grantee" as used in Appendix C refers to the Engineer. If the material is copyrightable, the Engineer may copyright it, as Appendix C permits, subject to the rights in the Government in Appendix C, but the Owner and the Federal Government reserve a royalty free, nonexclusive, and irrevocable license to reproduce, publish and use such materials, in whole or in part, and to authorize others to do so. The Engineer shall include appropriate provisions to achieve the purpose of this condition in all subcontracts expected to produce copyrightable Subject Data. (b) All such Subject Data furnished by the Engineer pursuant to this agreement are instruments of this services in respect of the project. It is understood that the Engineer does not represent such Subject Data to be suitable for reuse on any other project or for any other purpose. If the Owner reuses the Subject Data without the Engineer's specific written verification or adaptation, such reuse will be at the risk of the Owner, without liability to the Engineer. Any such verification or adaptation will entitle the Engineer to further compensation at rates agreed upon by the Owner and the Engineer. ARTICLE II - SCOPE OF SERVICES A. PREPARATION OF CONSTRUCTION PLANS AND SPECIFICATIONS After written authorization from the Owner to proceed, construction plans and specifications will be prepared for the Project which consists of the following facilities: A 5.55 MGD Cole Junction Pumping Station near Highway 179 and Grays Creek. A 12-inch interceptor sewer from existing Belair Pump Station to Cole Junction Pumping Station. Cole Junction Pumping Station Force Main. Gravity Sewer from discharge of Cole Junction Pumping Station Force Main to existing North Wears Creek Interceptor. Interceptor Sewers in Lower Grays Creek area. -9- These facilities will be planned in general accordance with the Cole County 201 Facilities Plan dated April 1977, as revised by the final supplement dated April 17, 1978, prepared for Cole County, Missouri, by Russell & Axon, Inc., and as shown on Plate No. 7A, Rev. April 1978, of the final supplement. This phase of services will include: 1. Review of the configuration of interceptor sewers for the Lower Grays Creek Drainage Area as proposed in the Study of Interceptor System for Lower Grays Creek Drainage Area prepared by Horner & Shifrin, Inc., and dated July 1976. The original configuration will be reviewed and revised as appropriate to utilize the interceptor sewer facilities to be constructed by the Cole County R.S.D. in accordance with the Revised Final 201 Facilities Plan. 2. Preparation of a written report to be submitted to the Owner of the results of the review of the Lower Grays Creek Drainage Area described in 1 above: The results of this review also will be incorporated in the preliminary submittal data required by the Missouri DNR for review and comment. This report will serve as a means to coordinate the interceptor design being prepared for the Cole County RSD and the design of the interceptor sewers for the Lower Grays Creek area to be designed under this contract. The review will include updating the location of existing sewer systems and treatment facilities included in the original 1976 Study and sizing the revised interceptor sewers based on the population projections in the 1976 Report. 3. Preparation of documents to solicit bids for, determination of the location, and surveillance of subsurface investigations, which investigations may include borings, soil tests and analyses of soil strength and characteristics. 4. Preparation of construction plans and specifications for the Project facilities described above. Such plans and specifications will be in accordance with normally accepted professional engineering practices and standards, and will be executed under the supervision of professional engineers registered to practice in the State of Missouri. Surveys to establish location and topography of the facilities will be included except that no property surveys or outbound survey will be furnished as a part of this work. 5. Subject to review by the Owner's attorneys, preparation of those z documents required to solicit bids, receive bids and let contracts for the construction. 6. Advise the Owner of the Engineer's opinion of any adjustment of probable Project Cost caused by changes in scope, design requirements or construction costs, and furnish a revised opinion of the Project Cost based on the drawings and specifications. -10- 7. Assist the Owner to obtain approvals and permits from all governmental authorities having jurisdiction over the Project and such approvals and consents from others as may be necessary for completion of the Project plans except for land acquisitions and easements. 8. Provision of all full size prints of the construction plans and plans reduced to 11 x 17-inch size, together with required sets of specifi- cations and bidding documents. B. ADDITIONAL PROFESSIONAL SERVICES If authorized in writing by the Owner, the Engineer will provide additional professional services in connection with the Project as set forth below: 1. Preparation of application and supporting documents for government grants, loans or advances. 2. Services due to changes in the scope of the Project or its design, including but not limited to, changes in size, complexity, schedule or character of construction. 3. Revising studies, reports, design documents, drawings or specifications when such revisions are due to causes beyond the control of the Engineer. 4. Preparation of rate studies, reports and studies relating to financing, and other similar type studies for the Project. 5. Providing computation for Industrial Cost Recovery factors for facilities included in this Project in accordance with the EPA Grant conditions. 6. Providing design services relating to future facilities, systems and equipment which are not intended to be constructed or operated as a part of the Project. 7. Providing Plan of Operation as required by EPA as a part of the Grant conditions. 8. Providing special analysis of the Owners need such as; operating analysis, staffing and training, special operating drawings or charts, and any other similar analyses. Investigations involving detailed consideration of operations, maintenance and overhead expenses; earnings and expense statements, feasibility studies, appraisals and valuations; detailed quantity surveys of material and labor; and material audits or inventories required by the Owner. 9. Providing services in conjunction with public meetings, hearings, or other activities involving public participation in the Project. -11- 10. Preparation of easement plats and/or easement descriptions based on property surveys provided by the Owner. Alk 11. Services in conjunction with prequalification of equipment in accordance with EPA regulations if required by EPA or the Owner. 12. Providing other services not otherwise specifically provided for in this Agreement, including services normally furnished by the Owner as described in Article III "OWNERS RESPONSIBILITY". ARTICLE III - OWNER'S RESPONSIBILITY The Owner shall: 1. Provide full information as to the Owner's requirements for the Project. 2. Assist the Engineer by placing at his disposal all available information pertinent to the Project including previous reports and any other data relative to the Project. 3. Examine all studies, reports, sketches, drawings, specifications, proposals and other documents presented by the Engineer, obtain advice of an attorney, insurance counselor and other consultants as the Owner deems appropriate for such examination and render in writing decisions pertaining thereto within a reasonable time so as not to delay the services of the Engineer. 4. Provide such legal, accounting, independent cost estimating and insurance counseling services as may be required for the Project, and such auditing servicve as the Owner may require to ascertain how or for what purpose any contractor has used the payments made by the Owner. 5. Furnish all labor, equipment and materials necessary to expose underground utilities and obstructions to permit measurements to be taken by the Engineer, where it is required, in the judgment of the Engineer, to determine the precise location of underground utilities and obstructions. 6. Furnish all borings, investigations, analyses and tests where, in the judgment of the Engineer, subsurface information is required as to soil characteristics and strength and as to location and quality of rock. However, the specifications for, the determination of the locations of the borings, and the supervision of the boring ® operations shall be the responsibility of the Engineer as set forth under Article I, Section B, paragraph 3. 7. Bear the expense of all testing required to be done by testing laboratories. 8. Provide property surveys and/or outbound surveys of sites and/or easements to be utilized for the facilities to be designated under this contract including locating property corners to utilize as data to assist the Engineer in selecting location for facilities. -12- 9. Provide necessary additional services or other services as required. ARTICLE IV - TIME OF PERFORMANCE 1. The provisions of this Article and the various rates of compensation for the Engineer's services provided for in this Agreement have been agreed to in anticipation of the orderly and continuous progress of the Project and that the authorization to proceed with the services included in Article II Section A will be issued within 30 days of the date of this contract. The Engineer's obligation to render services hereunder will extend for a period which may reasonably be required to provide the services. 2. If the Engineer's services for the Project are delayed or suspended in whole or in part by the Owner or governmental authorities for more than two months for reasons beyond the Engineer's control, the Engineer shall on written demand of the Owner (but without termination of this Agreement) be paid for work accomplished as provided in Article V. If such delay or suspension extends for more than three months for reasons beyond the Engineer's control, the payments and various rates of compensation provided for in Article V shall be subject to renegotiation. 3. Services will be provided by the Engineer in accordance with the following schedule: Services included in Article II, Section A, Paragraphs 1 through 8, will be completed in 180 calendar days after authorization to proceed. Services included in Article II, Section B, will be completed 270 consecutive calendar days following the authorization to proceed with preparation of plans and specifications. Services to be provided under this agreement will be provided and completed as indicated above except that no services will be provided after a date 15 months from the date of this contract without the written consent of both parties. ARTICLE V - FEES AND PAYMENT The Owner will pay the Engineer in accordance with the provisions of this Article. The Engineer will submit periodic statements not more frequently than once a month requesting payment. Such statements shall be based upon the amount and value of services provided and expenses incurred by the Engineer to the date of the statement and shall be supplemented or accompanied by such supporting data as may be required by the Owner. Upon the Owner's approval of each statement, the Owner shall, make payment to the Engineer as soon as practicable. After 30 days unpaid statements shall be considered to be delinquent. -13- If the Owner fails to make payments due to the Engineer for services and expenses within one hundred twenty days after receipt of the Engineer's ® statement, the amounts due the Engineer shall include a charge at the rate of 0.75% per month from the thirtieth day after the billing date and in addition, the Engineer may, after giving seven days' written notice to the Owner, suspend services under this Agreement until he has been paid in full all amounts due him for services and expenses. Payment for the professional services as defined in Article II - Section A, Preparation of Construction Plans and Specifications, shall be made to the Engineer by the Owner on the basis of a lump sum of $143,100.00. Payment for the professional services as defined in Article II - Section B, Additional Professional Services, shall be paid for on the basis of an agreed lump sum or other basis mutually accepted in writing at the time the additional work is authorized. IN WITNESS WHERE , the arties hereto have affixed their hand and seals this , 1981. ATTEST: (SEAL) AML City of Jefferson, Missouri By By rr e T i ATTEST: „ (SEAL) Horner hifrin, Inc., Consul i g E ineers By lu/- 4,.e B Zssistant Secretary ice President Title Title F.E. I.N. 43-0861661 Federal Employer's Identification Number -14-