Loading...
HomeMy Public PortalAboutORD09767 1 it t; BILL NO. 4! , ! INTRODUCED BY COUNCILMAN _. A �t ! 1 ORDINANCE NO. We t� IIAN ORDINANCE AUTHORIZING THE MAYOR AND CITY CLERK TO EXECUTE A ' ;; CONTRACT WITH UNITED HRB GENERAL CONTRACTORS, INC. , FOR THE (j CONSTRUCTION OF THE JOHN G. CHRISTY MUNICIPAL BUILDING. ! i� BE IT ORDAINED BY THE CITY COUNCIL OF THE CITY OF JEFFERSON, � f! MISSOURI, AS FOLLOWS : I ' SECTION 1. The City Council of the City of Jefferson, `iMissouri hereby finds that United HRB General Contractors , Inc. i � Y � -jis the lowest responsible bidder, who meets all of the quali- i Ifications specified, in the project for the construction of a i new municipal building. SECTION 2 . The Mayor and City Clerk are authorized to ; enter into an agreement with United HRB General Contractors , Inc. I( 11for the construction of the John G. Christy Municipal Building. i The agreement is to be substantially the same in form and ii content as that document attached hereto and incorporated herein + fby reference as Exhibit "A". SECTION 3. This ordinance shall be in full force and ! effect from and after passage and approval. i '! Passed—ell,5'" rr z-- _ Approved esidqht of the 70uncil riayor i � I ATTEST : , I CtLty ClWrk i i AGREEMENT This Agreement is made and entered into by and between Environmental Sanitation Management, Inc. (hereinafter referred to as "ESM") and The City of Jefferson, Missouri, a municipal corporation (hereinafter referred to as "City") on this IR day of 1982. The parties hereby agree as follows: I. This agreement is entered into for the purpose of providing a Spring Trash Pickup for the residents of the City of Jefferson. 2. ESM shall supply all labor, material, equipment and other necessary appurtenances required to provide for a spring trash pickup for the residents of the City of Jefferson. The service shall be provided to residential facilities, including multi-family dwelling complexes. 3. Service shall be provided between the dates of April 19, through May 1, 1982, 4. Service shall be curb pickup and shall be provided on a one tinie basis to all city residents. Items shall be limited to trash to include appliances, tree limbs no longer than four feet in length and tied in bundles, furniture or other items of such nature. All trash shall be in boxes, bundles, or disposable containers. No car bodies or large parts will be allowed for collection. All items shall be of a size and weight so that they can be loaded into a truck by a two man crew.The city will take ste;,s to insure the public does not utilize this service in lieu of and for normal household garbage, but ESM shall nevertheless pickup garbage that is among the items to be removed. The city shall not be responsible for any call back service. 5. ESM will provide a notarized statement that all items to be picked up shall be disposed of legally and lawfully at a licensed landfill. The certificate shall identify the disposal site. The certifi- cate shall be provided to the city prior to beginning the pickup service. 5. ESM shall submit a proposed schedule of service to the city. Routing shaI.l be designed to allow for a maximum period of three days delay from the time a property owner is required to place trash at the curb and the time the trash is picked up. The city shall have the right to approve the scheduling. 7. The city shall bear all costs for public advertising for this service. ESM shall provide firial scheduling and routing information to the city at least ten days prior to April 19, 1982. 8. The city shall pay ESM Sixteen Thousand Five Hundred Dollars ($16,500.00) upon completion of the two week trash pickup. 9. ESM shall procure and maintain a general liability in- surance policy and an automobile policy with limits not less than $100,000 per individual and $300,000 per occurrence, and the policies shall list the city as an additional. insured party thereunder. 10. ESM agrees to indemnify and save the city harmless from Affik and against all suits and actions of every description brought against the city, and from all damage and costs, by reason or on account of any injuries or damages received or sustained by any person or persons, or their property, by ESM, its servants, or its agents, or by any negligence or carelessness in the performance of the services under this contract. IN WITNESS WHEREOF, the parties have caused this agreement to be executed the day and year first above written. ENVIRONMENTAL SANITATION MANAGE- MENT, INC. ATTE a B --- -CITY OF JEFFERSON, MISSOURI B Qayor ATTEST: Clity Clerk AGREEMENT This Agreement is made as of the day of _app _, 198'2 , between the Owner, City of Jefferson, Missouri, and the Con- tractor, United HRB General Contractors , Inc. , for the construction of the John G. Christy Municipal Building in the City of Jefferson. The Architect for the project is The Architect' s Alliance , Inc. The Owner and Contractor agree as set forth below. ARTICLE I THE CONTRACT DOCUMENTS. The Contract Documents consist of this .Agreement, the Con- ditions of the Contract (General, Supplementary and other Con- ditions) , the Drawings, the Specifications , all Addenda issued prior to and all Modifications issued after execution- of this Agreement , the Invitation to Bid, and the Instruction to Bidders. These form the Contract, and are all as fully a part of the Contract as if attached to this Agreement or repeated herein. An enumeration of the Contract Documents appears in Article 7. ARTICLE II THE WORK. The Contractor shall perfomm all the work required by the Contract Documents for the construction of the John G. Christy Municipal Building, including site preparation. ARTICLE III TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION. The work to be performed under this Contract shall be corn- menced on April 19 , 1982, and, subject to authorized adjustments , substantial completion shall be achieved not later than three hundred sixty five (355) calendar days thereafter. Liquidated damages shall be as specified in Section 7 on P-3 of Contractors Proposal Form. -1- e M ARTICLE IV CONTRACT SUM., ® The Owner shall pay the Contractor in current funds for the performance of the Work, subject to additions and deductions by Change Order as provided in the Contract Documents , the Contract Sum of One Million Five Hundred Sixty Seven Thousand Four Hundred Fifty Two Dollars ($1,567,452.00) . ARTICLE V PROGRESS PAYMENTS. Based upon Applications for Payment submitted to the Archi- tect by the Contractor and Certificates for Payment issued by the Architect , the� Owner shall make progress payments on account of the Contract Sum to the Contractor as provided in the Contract 4ODocuments for the period ending the last day of the month as follows : Not later than thirty (30) days following the end of the period covered by the Application for Payment Ninety percent (90%) of the portion of the Contract Sum properly allocable to labor, materials and equipment incorporated in the Work and Ninety per- cent (90%) of the portion of the Contract Sum properly allocable to materials and equipment suitably stored at the site or at some other location agreed upon in writing, for the period covered by the Application for Payment, less the aggregate of previous pay- ments made by the Owner; and upon Substantial Completion of the 0 entire Work, a sum sufficient to increase the total payments to one hundred percent (100%) of the Contract Sum, less such amounts as the Architect shall determine for all incomplete Work and un- settled claims as provided in the Contract Documents . ARTICLE VI FINAL PAYMENT. Final Payment, constituting the entire unpaid balance of the Contract Sum, shall be paid by the Owner to the Contractor -2- k' when the work has been completed, the Contract fully performed, and a final Certificate for Payment has been issued by the Archi- tect and approved by the Owner. ARTICLE VII MISCELLANEOUS PROVISIONS. 7. 1. Terms used in this Agreement which are defined in the Conditions of the Contract shall have the meanings designated in those Conditions. 7.2. The Contract Documents , which constitute the entire agreement between the Owner and the Contractor, are listed in Article I and, except for Modifications issued after execution of this Agreement, are enumerated as follows : JOHN G. CHRISTY MUNICIPAL BUILDING (by The Architects Alliance, Inc.) Specifications, dated February 1, 1982 (bound complete) , including Invitation to Bid, Instruction to Bidders, and General Conditions AIA Document A201, 1976 Addition Working Drawings , Streets PP-1 dated February 1, 1982 Sheets A-1 through A-19 dated February 1, 1982 Sheets S-1 through 5-12 dated February 1, 1982 Sheet ME-1 dated February 1, 1982 Sheets M-2 through M-6 dated February 1, 1982 Sheets E-2 through E-7 dated February 1, 1982 Addendum #1 dated February 26 , 1982 Addendum #2 dated March 1, 1982 Addendum #3 dated March 4, 1982 Addendum #4 dated March 5, 1982 Proposal Form P-1 through P-4 (attached) as submitted by Contractor on March 10 , 1982. This Agreement is entered into as of the day and year first written above. OWNER: CITY OF JEFFERSON, MISSOURI ayor ATTEST : City Qerk CONTRACTOR: UNITED HRB GENERAL CONTRACTORS , INC. By ATT T: g4 Amer" panas��al�y �o�pany of Leading, Pennsylvania CNA Plaza Chicago, Illinois 60685 THE AMERICAN "INSTITUTE OF ARCHITECTS 90 . #575 46 10 AIA Document A311 + Performance Bond KNOW ALL MEN BY THESE PRESENTS: that Mere m%eri lull name and address or legal title of Contractor) United H.R.B. General Contractors, Inc., Jefferson City, Missouri as 01 cipal, hereinafter called Contractor, and, AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA, CNA Plaza, Chicago, Illinois 60685 as Surety, hereinafter called Surety, are held and firmly bound unto (Here insert full name and address or legal title of Owner) City of Jefferson, Missouri as Obligee, hereinafter called Owner, in the amount of One Million Five Hundred Sixty Seven i'housand Four Hundred Fifty Two and no/100------------- Dollars (S 1,567,452.00 � for the payment whereof Contractor and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Contractor has by written agreement dated April 9 1982 , entered into a contract with Owner for Construction of John G. Christy Municipal Building in flordance with Drawings and Specifications prepared by (liere insert full name and address or legal lisle of Architect) The Architects Alliance, Inc., 1431 Sout]Twest Blvd. , Jefferson City, Mo. which Contract is by reference made a part hereof, and is hereinafter referred to as the Contract. AIA DOCUMENT A311 • PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND • AIA O FEBRUARY,1970,ED.• THE AMERICAN INSTITUTE OF ARCHITECTS,1735 N.Y.AVE,, N.W.,WASH.,D.C. 20006 Form 8.23195•C NOW, THEREFORE, THE CONDITION Of THIS 0811GATION is such that, if Contractor sha ,roinptly and faithfully perform said Contract, then this obligation shall be null and void; ottrervfise it shall remain in full f nd effect. The Surely hereby waives notice of any alteration or defaults under the contract or contracts of completion extension of time made by the Owner. arranged under this paragraph)sufficient funds to pay the cost of completion less the balance of the contract price; Whenever Contractor shall be, and declared by Owner but not exceeding, including other costs and damages to be in default under the Contract, the Owner having for which the Surety may be liable hereunder,the amount performed Owner's obligations thereunder, the Suretv set forth in the first paragraph hereof. The term "balance may promptly remedy the default, or shall promptly of the contract price," as used in this paragraph, shall mean the total amount payable by Owner to Contractor 1 mplete the Contract in accordance with its terms under the Contract and any amendments thereto, less Amh'an conditions, or the amount properly paid by Owner to Contractor. 2) Obtain a bid or bids for completing the Contract in Any suit under this bond must be instituted before accordance with its terms and conditions, and upon de- 'the expiration of two (2) years from the date on which termination by Surety of the lowest responsible bidder, final payrnent under the Contract falls due. or, if the Owner elects, upon determination by the Owner and the Surety jointly of the lowest responsible No right of action shall accrue on this bond to or for bidder, arrange for a contract between such bidder and the use of any person or corporation other than the Owner, and make available as Work progresses (even Owner named herein or the heirs, executors, adminis- though there should be a default or a succession of trators or successors of Owner. I Signed and sealed this 13th day of April 19 82 UNITF0 H.R.B. GONERAL CONT"r CIORS, INC. (Principal) (Scab (Witness) (Title) AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA (Surely) (seal) (Witness) i (Title) Attorney-in—Fact i THIS BOND HAS BEEN REPRODUCED BY PERMISSION OF THE AMERICAN INSTITUTE OF ARCHITECTS American Casualty Company of Reading, Pennsylvania IAMURA IVCZ FROM Crq , Offices/Chicago, Illinois POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men by these Presents, That AMERICAN CASUALTY COMPANY Or READING, PENNSYLVANIA, a corporation duly organized and existing under the laws of the Commonwealth of Pennsylvania, and having its principal office in the City of Chicago, and of Illinois, does hereby make, constitute and appoint 18II7CS_t1��B1L7"�_._G_lgnda A. Fri,._, Jame ehr r, Tnd!.Nddt,a?l v___ — of its true and lawful Attorney-in-Fact with full power arid authority hereby conferred to sign, seal and execute in its behalf bonds, under- takings and other obligatory instruments of similar nature as follows: Without Limitations and to bind AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA thereby^as fully and to the same extent as if such instruments were signed by the duly authorized officers of AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA and all the acts of said Attorney, pursuant to the authority hereby given are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the following By-Law duly adopted by the Board of Directors of the Company: "Article VI—Execution of Obligations and Appointment of Attorney-in-Fact Section 2. Appointment of Attorney-in-fact. The President or a Vice President may, from time to time, appoint by written certificates attorneys-in-fact to act in behalf of the Company in the execution of policies of insurance, bonds, undertakings and other obligatory instruments of like nature. Such attorneys-in-fact, subject to the limitations set forth in their respective certificates of authority shall have full power to bind the Company by their signalure and execution of any such iv,struments and to attach the seal of the Company thereto. The President or any Vice President or the Board of Directors may at any time revoke all power and authority previously given to any attorney-in-fact." This Power of Attorney is signed and sealed by facsimile under and by the authority of the following Resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 11th day of November, 1966: "Resolved, that the signature of the President or a Vice President and the seal of the Company may be affixed by facsimile on any power of attorney granted pursuant to Section 2 of Article VI of the By-Laws, and the signature of the Secretary or an Assistant S etary and the seal of the Company may be affixed by facsimile to and,certificate of any such power and any such power or cer- e bearing such facsimile signature and seal ;hall be valid and binding on the Company. Any such power so executed and s d and certified by certificate so executed and sealed shall, with respect to any bond or undertaking to which it is attached, continue to be valid and binding an the Company." In Witness Whereof, AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed this 2nd day of July 19 80 ' AMERICAN CASUAL P OF READING, PENNSYLVANIA State of Illinois xA.11 County of Cook I ss R1" Vice President. On this 2nd day of July 19 80 , before me personally came R. J. Wall to me known, who, being by me duly sworn, did depose and say: that he resides in the Village of Western Springs State of Illinois; that he is a Vice-President of AMERICAN CASUALTY COMPANY OF READING, PENN- SYLVANIA, the corporation described in and which executed the above instrument; that he knows the seal of said Corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Direc- tors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. �(/�/ nom////�� �-r-� hCrrA*y L t 1 A n �/ _ 1I 1 0 Puar.rc Edward J. Haan III Notary Public. My Commission Expires May 12, 1984 CERTIFICATE I, P.10. Granahan , Assistant Secretary of AMERICAN CASUALTY COMPANY OF READING PENNSYLVANIA, do certify that the Power of Attorney herein above set forth is still in force, and further certify that Section 2 of Article VI of the By-Laws of the Company and the Resolution of the Board of Directors, set forth in said Power of Attorney are still in force. In testimony whereof I have hereunto subscribed my name and affixed the seal of the said Company this __ 4 PCK day of Ann ri. P. F. GraLta 1Tn Assistant Secretary. aa, 8.23142-B �, rr RlIfEA/C19!U CH5V 9LTYMA NY o r R [ A O I N o . P E N N S Y L %, ,. N I A THE AMERICAN 'INSTITUTE OF ARCHITECTS AIA Document A311 Labor and Material Payment Bond THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE BOND IN FAVOR OF THE OWNER CONDITIONED ON THE FULL AND FAITHFUL PERFORMANCE OF THE CONTRACT KNOW ALL MEN BY THESE PRESENTS: that (here insert full name and address or legal title of Contractor) United H.R.B. General Contractors, Inc., Jeffersan City, I,1issouri I as Principal, hereinafter called Contractor, and, AM ICAN (CASUALTY COMPANY OF READING, PENNSYLVANIA, 310 South Michigan Ave., Chicago, III. as Surety, hereinafter called Surety, are held and firmly bound unto (Here insert full name and address or legal title of Owner) City of Jefferson, Missouri as Obligee, hereinafter called Owner, for the use and benefits of claimants as hereinbelow defined, in the One Million Five Hundred Sixty Scven Thousand Four Hundred Fifty Two and amount of no/100--------------------------------------•------Dollars ($ 1,567,452.00 ), (Here insert a sum equal to at least one-half of the contract price) for the payment whereof Principal and Surety bind themselves, their heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these presents. WHEREAS, Principal has by written agreement dated April 9 19 82, entered into a contract with Owner for Construction of John G. Christy Municipal Building in &rdance with Drawings and Specifications prepared by (Here insert full name and address or legal title of Architect) The Architects Alliance, Inc., 14311 Soutl-naest Blvd., Jefferson City, Mo. which contract is by reference made a part hereof, and is hereinafter referred to as the Contract. AIA DOCUMENT A311 - PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND - AIA FEBRUARY, 1970,ED.-THE AMERICAN INSTITUTE OF ARCHITECTS, 1735 N.Y.AVE., N.W.,WASH., D.C.20006 Form 8-23196-C NOW, THEREFORE, THE CONDITION OF 1rirS OBLIGATION is such that, if Principal shay. ,romptly make payment to all claimants as hereinafter defined, for all labor and material used or reasonably required for use in the performance of the Contract, then this obligation shall be void; otherwise it shall remain in full force and effect, subject, however, to the following conditions: 1. A claimant is defined as one having a direct con- accuracy the amount claimed and the name of the party tract with the Principal or with a Subcontractor of the to whom the materials were furnished, or for whom Principal for labor, material, or both, used or reasonably the work or labor was done or performed. Such notice required for use in the performance of the Contract, shall be served by mailing the same by registered mail labor and material being construed to include that part or certified mail, postage prepaid, in an envelope ad- of water, gas, power, light, heat, oil, gasoline, telephone dressed to the Principal, Surety or Owner, at any place sec" or rental of equipment directly applicable to the where an office is regularly maintained for the trans- C ct. action of business, or served in any manner in which legal process may be served in the state in which the 2. The above named Principal and Surety hereby aforesaid project is located, save that such service need jointly and severally agree with the Owner that every not be made by a public officer. claimant as herein defined, who has not been paid in b) After the expiration of one (1) year following the full before the expiration of a period of ninety (90) date on which Principal ceased Work on said Contract, days after the date on which the last of such claimant's it being understood, however, that if any limitation em- work or labor was done or performed, or materials were bodied in this bond is prohibited by any law controlling furnished by such claimant, may sue on this bond for the construction hereof such limitation shall be deemed the use of such claimant, prosecute the suit to final to be amended so as to be equal to the minimum period judgment for such sum or sums as may be justly due of limitation permitted by such law. claimant, and have execution thereon. The Owner shall not be liable for the payment of any costs or expenses c) Other than in a state court of competent jurisdiction of any such suit. in and for the county or other political subdivision of the state in which the Project, or any part thereof, is 3. No suit or action shall be commenced hereunder situated, or in the United States District Court for the by any claimant: district in which the Project, or any part thereof, is sit- uated, and not elsewhere. a) Unless claimant, other than one having a direct contract with the Principal, shall have given written 4. The amount of this bond shall be reduced by and notice to any two of the following: The Principal, the to the extent of any payment or payments made in good Owner, or the Surety above named, within ninety (90) faith hereunder, inclusive of the payment by Surety of days after such claimant did or performed the last of mechanics' liens which may be filed of record against the work or labor, or furnished the last of the materials said improvement, whether or not claim for the amount for ich said claim is made, stating with substantial of such lien be presented under and against this bond. Signed and sealed this 13t1i day of April 19 82 UNIT-ED H.R.B. GENERAL OD;nRACPORS, INC. (Principal) (Seal) (Witness) (Title) AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA � (Surety) (Seal) (Witness) , (Title) Attorney-in-Fact THIS BOND HAS BEEN REPRODUCED BY PERMISSION OF THE AMERICAN INSTITUTE OF ARCHITECTS American Casualty Company of Reading, Pennsylvania 1AMURAMCC FROM CN, Offices/Chicago, Illinois POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men by these Presents, That AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA, a corporation duly organized and existing under the laws of the Commonwealth of Pennsylvania, and having its principal office in the City of Chicago, and to of Illinois, does hereby make, constitute and appoint James-11— l�enG,_G1-rrnd_a__A,`Fry�_ — ' —_-- of .7PffPrsr)n__ritV, MiRSeuLL--�_ ___.- - -_--- ------. .-- its true and lawful Attorney-in-Fact with full power and authority hereby conferred to sign, seal and execute in its behalf bonds, under. takings and other obligatory instruments of similar nature as follows: Without Limitations and to bind AMERICAN CASUALTY COMPANY OF READING. PENNSYLVANIA thereby as fully and to the same extent as if such instruments were signed by the duly authorized officers of AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA and all the acts of said Attorney, pursuant to the authority hereby given are hereby ratified and confirmed. This Power of Attorney is made and executed pursuant to and by authority of the following By-Law duly adopted by the Board of Directors of the Company: "Article V1--Execution of Obligations and Appointment of Attorney-in-Fad Section 2. Appointment of Attorney-in-fact. The President or a Vice President may, from time to time, appoint by written certificates attorneys-in-fact to act in behalf of the Company in the execution of policies of insurance, bonds, undertakings and other obligatory instruments of like nature. Such attorneys.in-fact, subject to the limitations set forth ir, their respective certificates of authority shall have full power to bind the Company by their signature and execution of any such instruments and to attach the seal of the Company thereto. The President or any Vice President or the Board of Directors may at any time revoke all power and authority previously given to any attorney-in-fact." This Power of Attorney is signed and sealed by facsimile under and by the authority of the followinE Resolution adopted by the Board of Directors of the Company at a meeting duly called and held on the 11th day of November, 1966: "Resolved, that the signature of the President or a Vice President and the seal of the Company may be affixed by facsimile on any power of attorney granted pursuant to Section 2 of Article VI of the By-Laws, and the signature of the Secretary or an Assistant Secretary and the seal of the Company may be affixed by facsimile to any certificate of any such power and any such power or cer- ate bearing such facsimile signature and seal shall be valid and binding on the Company. Any such power so executed and Wed and certified by certificate 5o executed and sealed shall, with respect to any bond or undertaking to which it is attached, continue to be valid and binding on the Company." In Witness Whereof, AMERICAN CASUALTY COMPANY OF READING, PENNSYLVANIA has caused these presents to be signed by its Vice President and its corporate seal to be hereto affixed this __?2a— day of _— July 19 80 KIJr AMERICAN CASUAL P OF READING, PENNSYLVANIA State of Illinois I 3 AnY 71. County of Cook I sss szr �+- 'b,� r -� Vice President. On this_ 2nd day of _ ;Jules _ 19 80 , before me personally came R. J. Wall to me known, who, being by me duly sworn, did depose and say: that he resides in the Village of Western Springs State of Illinois; that he is a Vice-President of AMERICAN CASUALTY COMPANY OF READING, PENN- SYLVANIA, the corporation described in and which executed the above instrument; that he knows the seal of said Corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Direc- tors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation. /� � '7-�-� MOTARY � _�__1_I (.(A M6 T J C1 Puauc Edward J. Haan III Notary,Public. cc, Dun My Cotmission Expires May 12, 1984 ® • CERTIFICATE 1, F Granahan Assistant Secretary of AMERICAN CASUALTY COMPANY OF READING PENNSYLVANIA, do certify that the Power of Attorney herein above set forth is still in force, and further certify that Section 2 of Article VI of the By-Laws of the Company and the Resolution of the Board of Directors, set forth in said Power of Attorne are still in force. In testimony whereof 1 have hereunto subscribed my name and affixed the seal of the said Company this — -?J `___ day of lg .iL, - A„wJ1 ! P. F. Grans an Assistant Secretary. 8.23142-B '� ...,i✓• w 7 J.. ,at..�. 1.�r'�I. t I 7 mor hkff • r aa-1 y.i f r-r•r•�.r-"'�•i•!1?�.all f ;G a T�1�-r �•r t�•--o 1N i,,t,��, .1''!.r.•v t�I'f'.•"""�c �•' •r r 7 .. •=i}yJ: !r\ )r rr7• r s i a, ':'a f :i f~ R7t� NAM( AND ADDRESS Or AG(NCY n COMPANIES AFFORDING COVERAGES Winter-Dent & Co. --- - -- ----- -- P.O. Box 1046 1111P A" A ANV r� Jefferson City, Missouri 65102 LETTER A United States Fidelity and Guaranty COMPANY a LETTER NAME AND ADDRESS OF INSURED COMPANY Unit General.R•.B. Genel Contractors LETTER p,,o. ffff 1214 COMPANY e M Jefferson City, Missouri 65102 LETTER V COMPANY LETTER This is to certify that policies of insurance listed below have tmen issued to the insured named above and are in force at this time. Notwithstanding any requirement,term or condition of any contract or other document with respect to which this certificate may be issued or may pertain,the insurance afforded by the policies described herein is subject to all the terms,exclusions and conditions of such policies. _ COMPANY POLICY Limits of Liabilit in Thousands( 0) LETTER TYPE OF INSURANCE POLICY NUMBER EX!'IRATION DATE EACH AGGREGATE GENERAL LIABILITY — OCCURRENCE BODILY INJURY $ S '� ®COMPREHENSIVE FORM ®PRE MIS ES—OPERATIONS PROPERTY DAMAGE $ $ Tt ®EXPLOSION AND COLLAPSE HAZARD UNDERGROUND HAZARD ®P OPERATIONS SMHAZAS SMP011381843 7-1-82 BODILY INJURY AND �'r A ®CONTRACTUAL INSURANCE PROPERTY DAMAGE $ 500, s 500, ®BROAD FORM PROPERTY COMBINED c_ DAMAGE ®INDEPENDENT CONTRACTORS ® PERSONAL INJURY PERSONAL INJURY S 500, ---- r� AUTOMOBILE LIABILITY BODILY INJURY '_ 112 ;Z' (EACH PERSON) _cs'!., -:• MPREHENSIVE FORM BODILY INJURY $ ,�,1E+,;_i'� i•' � (EACH ACCIDENT) *1%NED "s^qt-T3tit :, r 544969 7-1-32 ® HIRED PROPERTY DAMAGE S ;?`•..f�r.•+tr��?k,;R�• BODILY INJURY AND ® NON-OWNED PROPERTY DAMAGE $ 500, .L`r>•;,�..�; _ COMBINED EXCESS LIABILITY BODILY INJURY AND A ® UMBRELLA FORM CE2013962432 7-1-82 PROPERTY DAMAGE $3,000, $3,000, ❑ OTHERTHANUMBRELLA COMBINED FORM WORKERS'COMPENSATION STATUTORY A EMPLOYEandLIABILITY 170390000369817 7-1-82 �w� s� S 100, iI KI+ACCInI N• OTHER Installation $100,000. on job site A Floater SMP381843 7-1-82 25,000. in transit TDESCRIPTION OF OPERATIONS/LOCATIONS/VEHICLES The Contractor is required to provide all of tl->e Insurance and shall have the owner _ and Architect as named insureds on all policies required under this contract. Can Ion: Should any of the above described policies be cancelled before the expiration date thereof, the issuing com- pany will endeavor to mail _10 days written notice to the below named certificate holder, but failure to mail such notice shall impose no obligation or liability of any kind upon the company. :r NAME AND ADDRESS OF CERTIFICATE HOLDER DATE ISSUED._A nrll 12. 1982 City of Jefferson Jefferson City, Missouri 65101 � AUTHORIZED REPRESENTATIVE ACORD 35(1.79) Binder No. 01 Y r; '� .; 1 '�, 0 1 / r / .rL l 1 •tQ,q ! �,-• / '/ {�,�r / t. + `"' ,r 13Tf►��i�1.w',` i:: Y.:i�ax:.1.cL.5e'a:.i •wN:l�r.►.t,4�.ifW:qu.e rw"Si.'rSYis: � NAME AND ADDRESS OF AGENCY COMPANY inter-Dent & Co. nited Stags Fidelity and Guaranty P.O. Box 1046 Effective 12:01 am April 9 19 82 efferscn City, Missouri 65102 Expires p 12:01 am_ C. NoonJune 9 . 19 62 ❑This binder is issued to extend coverage in the above named Company per expiring policy #1 (except as noted Ixlw+l NAME AND G ADDRESS OF INSURED Description of Operation/Vehicles/Property City of Jefferson, Owner and Seth Evans as Architects Alliance, 1431 Southwest Boulevard Jefferson City, Missouri are named as additional named insureds Type and Location of Property Coverage/Perils/Forms Amr of Insurance Ded. a` ' P Construction of Joln• G. Christy Building _ r R East McCarty Street, Jefferscn City, Mo. All Risk, Builders Risk Form 1,567,452. 100. 80 0' P E R T Y Type of Insurance Coverage/Forms Limits of Liabili L Each Occurrence Aggregate I ❑ Scheduled Form ❑ Comprehensive Form Bodily Injury $ $ A Premises/Operations Property Broducts/Completed Operations Damage $ $ L ❑Contractual Bodily Injury & I ❑Other (specify below) Property Damage T ❑ Med. Pay. $ Per $ Per Combined $ _ Y ❑Personal Injury Person Accident ❑ A ❑ B ❑ C Personal Injury $ A y Limits of Liabili U ❑Liability ❑ Non-owned U Hired Bodily Injury (Each Person) $ T ❑Comprehensive-Deductible $ Bodily Injury (Each Accident) $ 0 ❑Collision-Deductible $ 0 ❑ Medical Payments $ Property Damage $ B ❑ Uninsured Motorist $ I ❑ No Fault (specify): Bodily Injury & Property Damage L ❑Other (specify): Combined $ E ❑ WORKERS' COMPENSATION — Statutory Limits (specify states below) ❑ EMPLOYERS' LIABILITY — Limit $ SPECIAL CONDITIONS/OTHER COVERAGES The Contractor, United H.R.B. General Contractors, is required to provide all of the insurance and shall have the Owner and Architect as additional named insureds on all policies required under this Contract. NAME AND ADDRESS OF ❑ MORTGAGEE ❑ 1-OSS PAYEE ❑ADD'L INSURED LOAN NUMBER 4-12-82 Signature of Authorired Representative Date CORD 75(11.77) Diodet No. IMF ' a.1R,� i ' C. �•i ',v�..,_<' ���'• M]��!' +� w. �°..,f" tr1. '. �y 'sf.xl,' QCor >�Pr't=iyyra'n�? • N! ! !.)r L t. I .Il�r 9i� I7� :i•. 171 1j• �I t?* ��C�^,w, ^ It.l �j�;y,�,ei•'.�'�"-• r " d ''aa:vl.�.n�^•C I:dl.r,]::_a.ia:+r.:.SL u.��sra:.:..,1.f c.:i�ir:i.^+O.i.+....�.4«.:aiJu`:t+rrr 3�j" ~� x.' NAME AND ADDRESS Of AGENCY COMPANY Winter—Dent & Co. United States Ficblity and Guaranty P.O. Box 1046 Effective 12:01 a m April 9 , 1(2 Jefferson City, xpires Q 12:01 am U NoonJune 9 , 1�2 ty, Missouri 65102 ; ❑This binder is issued to extend coverage in the above named company per expiring policy tt _ (except es noted below) NAME AN ILING ADDRESS OF INSURED Description of Operation/Vehicles/Property City of Jefferson, Jefferson City, Mo. and Construction of John G. Christy Building Architects Alliance, 1431 Southwcst Boulevard Jefferson City, Missouri are named as I additional narred insureds Type and Location of Property Coverage/Perils/Forms Amt of insurance Ded. max" P ' R 0 P E R T Y Type of Insurance Coverage/Forms Limits of Liabili 1 L _ Each Occurrence Aggregate 1 ❑Scheduled Form $7 Comprehensive Form Owners and Bodily Injury $ $ A ❑ Premises/Operations 3 Contractors Property 1 Products/Com/Completed Operations Protective Damage $ $ L ©Contractual Liability Bodily Injury & 1 ❑Other(specify below) Property Damage 580 000. 500 000. T ❑ Med. Pay. $ Per $ Per Combined Y ❑Personal Injury erson Accident 0 A p B ❑ C Personal Injury 1$ 500,000. rY `—� ►Y A Limits of Liability U ❑Liability ❑ Non-owned ❑ Hired Bodily Injury (Each Person) $ T ❑Comprehensive•Deductible $ Bodily Injury (Each Accident) $ 0 ❑Collision-Deductible $ M ❑Medical Payments $ Property Damage $ 0 R ❑Uninsured Motorist $ 1 ❑No Fault (specify): - Bodily Injury & Property Damage L ❑Other (specify): Combined $ E ❑ WORKERS' COMPENSATION •- Statutory Limits (specify states below) ❑ EMPLOYERS' LIABILITY — Limit $ SPECIAL CONDITIONS/OTHER COVERAGES The Contractor, United H.R.B. General Contractors, is required to provide all of the Insurance and shall have the Owner and Architect as additional named insureds on all polic' required under this contract NAME AND ADDRESS OF ❑ MORTGAGEE ❑LOSS PAYEE ❑ADD'L INSURED LOAN NUMBER 4-12-82 Signature of Authorized Representative Date ACORD 75(11.77)