HomeMy Public PortalAbout1999-98 Authorizing agreement with James A. Cummings, Inc. for construction management services associated with the construction of the Village Civic Center Master PlanRESOLUTION NO. 99-98
A RESOLUTION OF THE VILLAGE COUNCIL
OF THE VILLAGE OF KEY BISCAYNE,
FLORIDA; AUTHORIZING THE VILLAGE
MANAGER TO ENTER INTO AN
AGREEMENT WITH JAMES A. CUMMINGS,
INC. FOR CONSTRUCTION MANAGEMENT
SERVICES ASSOCIATED WITH THE
CONSTRUCTION OF THE VILLAGE CIVIC
CENTER MASTER PLAN; PROVIDING FOR
AN EFFECTIVE DATE
WHEREAS, the Village Council has retained the Florida Department of Management
Services to assist staff in the construction, management, coordination, and implementation of the
Village Civic Center Master Plan; and
WHEREAS, the Village Manager created a Construction Management Screening Committee
for purposes of assisting the Village in the selection of a Construction Manager to build the Village
Civic Center; and
WHEREAS, the Construction Management Screening Committee held meetings on
September 27, 1999, October 6, 1999, October 20, 1999, and November 1, 1999 for purposes of
reviewing and recommending construction management firms to the Village Manager; and
WHEREAS, the Construction Management Screening Committee has recommended the
following three firms in prioritized order:
1. James A. Cummings, Inc.
2. Walbridge Aldinger
3. James B. Pirdle Construction Co.
NOW, THEREFORE BE IT RESOLVED BY THE VILLAGE COUNCIL OF THE
VILLAGE OF KEY BISCAYNE, FLORIDA AS FOLLOWS:
Section 1. That the Village Manager is authorized to enter into an Agreement to employ the
firm of James A. Cummings, Inc. as the Construction Manager for Village Civic Center.
Section 2. That the Village Manager and the Village Attorney are authorized to take any and
all action necessary to implement the Agreement.
Section 4. That the Agreement, in substantially the form attached hereto, is hereby approved
and the Manager is authorized to execute the Agreement on behalf of the Village.
Section 5. This resolution shall take effect immediately upon adoption.
PASSED AND ADOPTED THIS 16th DAY OF November 1999.
MAYOR JOE I. RASCO
ATTEST:
'4f/aA5°
CONCHITA H. ALVAREZ, CMC, VILLAGE CL
APPROVED AS TO FORM AND LEGAL SUFFICI
RICHARD JAY WEISS, VILLAGE ATTORNEY
KE
•
l�:ArJ y�?'►/,
DEPERVCAICt1�1T' OF IANAGF.hiFN'f
S ES
BUILDING CONSTRUCTION
AGREEMENT BETWEEN OWNER AND CONSTRUCTION MANAGER
PROJECT NO:
STATE MV DESIGNATION:
PROJECT NAME AND LOCATION:
INSTRUCTION MANAGER:
ARCHITECT -ENGINEERS:
VKB-98069000
A
Village Community Center
Village Fire Station, Police Station,
and Administrative Office of the Village ,
Village of Key Biscayne, Florida
James A. Cummings, Inc.
A Florida Corporation
3575 Northwest 53rd Street
Fort Lauderdale, Florida 33309
(954) 733-4211, FAX (954) 485-9688
Spillis Candela & Partners, Inc
800 Douglas Entrance
Coral Gables, Florida 33134
(305) 444-4691, FAX 447-3580
Robert G. Currie and Associates, Inc.
134 Northeast First Avenue
Delray Beach, Florida 32809
(561) 276-4951, FAX (561) 243-8184
OBM Miami, Inc.
Architecture Resort Design and Dev
Town Planning Interior Design
2600 Douglas Road, Suite 510
Coral Gables, Florida 33134
(305) 445-7811
Jeb Bush
Governor
Thomas D. McGurk
Secretary
FEB 3 2000
Posioot D or
bittrickm
Dom,-VatiNng Construction
(\;
H:/gmp/cc2std-agent
TABLE OF CONTENTS
ARTICLE DESCRIPTION PAGE
1.0.0 THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT 1
1.1.0 The Construction Team 1
1.2.0 Extent of Agreement 1
1.3.0 Definitions 1
1.4.0 Owner's Construction Budget 2
2.0.0 CONSTRUCTION MANAGER'S SERVICES 2
2.1.0 Project Management Information System (PMIS) 2
2.1.1 General 2
2.1.2 Narrative Reporting Subsystem 3
2.1.3 Scheduled Control Subsystem 3
2.1.4 Cost Control Subsystem 4
2.1.5 Project Accounting Subsystem 5
2.2.0 Project Manual 5
2.3.0 Design Review And Recommendations 6
2.4.0 Construction Phase 8
3.0.0 OWNER'S RESPONSIBILITIES 13
3.1.0 Owner's Information 13
3.2.0 Owner's Representative 13
3.3.0 Architect And Engineer's Agreement 13
3.4.0 Site Survey And Reports 13
3.5.0 Approvals And Easements 13
3.6.0 Legal Services 14
3.7.0 Drawings And Specifications 14
3.8.0 Cost Of Surveys And Reports 14
3.9.0 Project Fault Defects 14
3.10.0 Funding 14
3.11.0 Lines Of Communication 14
3.12.0 Lines Of Authority 14
3.13.0 Permitting & Code Inspections 14
4.0.0 PERMITTING AND INSPECTION 14
4.1.0 Building Permits 14
4.2.0 Code Inspections 14
5.0.0 SUBCONTRACTS 15
5.1.0 Defmition 15
5.2.0 Proposals 15
5.3.0 Required Subcontractors' Qualifications And Subcontract Conditions 15
5.3.1 Subcontractual Relations 15
5.3.2 Subcontractual Requirements 15
5.4.0 Responsibilities For Acts And Omissions 16
5.5.0 Subcontracts To Be Provided 16
6.0.0 SCHEDULE, TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION 16
6.1.0 Project Substantial Completion Date, Project Final Completion Date
And Owner Occupancy Date 16
6.2.0 Owner Occupancy And Warranties 16
7.0.0 GUARANTEED MAXIMUM PRICE FOR CONSTRUCTION 16
7.1.0 Guaranteed Maximum Price (GMP) Proposal 16
7.2.0 GMP Taxes 16
7.3.0 Adjustments In Contingency Contained Within GMP 16
7.4.0 Use Of Contingency Contained Within GMP 16
i
TABLE OF CONTENTS CONTINUED
ARTICLE
DESCRIPTION PAGE
8.0.0 CONSTRUCTION MANAGER'S FEE 17
8.1.0 Fee 17
8.1.1 Preconstruction Phase Fee 17
8.1.2 Construction Phase Fee 17
8.1.3 Overhead And Profit For Construction Phase 18
9.0.0 COST OF THE PROJECT 18
9.1.0 Definition 18
9.2.0 Direct Cost Items 18
10.0.0 CHANGE IN THE PROJECT 20
10.1.0 Change Orders 20
10.1.1 Change Order Definition 20
10.1.2 Acceptable Ways Of Determining Increases Or Decrease In The GMP On Change Orders 20
10.1.3 Itemized Accounting On Change Orders 20
10.1.4 Adjustments In Unit Prices & GMP Due To Inequitable Quantity Changes 20
10.1.5 Concealed Conditions 20
10.2.0 Claims For Additional Cost Or Time 20
10.3.0 Minor Changes In The Project 21
10.4.0 Emergencies 21
11.0.0 DISCOUNTS AND PENALTIES 21
11.1.0 Discounts And Penalties 21
12.0.0 PAYMENTS TO THE CONSTRUCTION MANAGER 21
12.1.0 Monthly Payments 21
12.2.0 Final Payment 21
12.3.0 Payments To Subcontractors 21
12.4.0 Delayed Payments By Owner 21
12.5.0 Payments For Materials And Equipment 22
12.6.0 Withholding Payments To Subcontractors 22
13.0.0 INSURANCE, INDEMNITY AND WAIVER OF SUBROGATION 22
13.1.0 Indemnity 22
13.2.0 Construction Manager's Insurance 22
13.3.0 Waiver Of Subrogation 24
13.3.1 Damages Caused By Perils Covered By Insurance 24
13.3.2 Loss Or Damage To Equipment Covered By Insurance 24
13.3.3 Property And Consequential Loss Policies 24
13.3.4 Endorsement Of Policies 24
14.0.0 TERMINATION OF THE AGREEMENT AND OWNER'S RIGHT TO PERFORM
CONSTRUCTION MANAGER'S OBLIGATION 24
14.1.0 Termination By The Construction Manager 24
14.2.0 Owner's Right To Perform Construction Manager's Obligations And Termination
By Owner For Cause 24
14.3.0 Termination By Owner Without Cause 25
15.0.0 ASSIGNMENT AND GOVERNING LAW 25
15.1.0 Assignment Consent 25
15.2.0 Governing Laws 25
15.3.0 Venue for Litigation 25
16.0.0 NOTICE OF CLAIM; WAIVER OF REMEDIES; NO DAMAGES FOR DELAY 25
16.1.0 Governing Provisions 25
16.2.0 Written Determination Of Claim 26
16.3.0 Exclusive Remedy For Delays 26
ii
TABLE OF CONTENTS CONTINUED
ARTICLE
DESCRIPTION PAGE
17.0.0 MISCELLANEOUS 26
17.1.0 Harmony 26
17.2.0 Apprentices 26
17.3.0 Invoices Submitted Under Article 9 26
17.4.0 Construction Manager's Project Records 26
17.5.0 Payments 26
17.6.0 Public Entity Crime Information Statement 26
17.7.0 Unauthorized Aliens 26
17.8.0 Electronic Mail Capabilities 26
EXHIBIT
A Construction Team Assigned Representatives 29
B Owner's Construction Budget 30
C Construction Manager's Personnel 31
D Certificate of Substantial Completion 32
E Construction Manager's Affidavit of Contract Completion 33
F State Building Permit Application 35
G Construction Manager's Personnel To Be Assigned During Preconstruction Phase 36
H Construction Manager's Per Diem Staff For Time Extensions Per 8.1.2(1)(b) 37
I Construction Manager's Personnel To Be Assigned During Construction Off -Site 38
J Construction Manager's Personnel To Be Assigned During Construction On -Site 39
K Certificate of Partial Payment 40
L Items to be Submitted 42
iii
FORM OF AGREEMENT
BETWEEN OWNER AND CONSTRUCTION MANAGER
HIS AGREEMENT made this _ day of November in the year Nineteen Hundred and Ninety Nine by and between Building
.;onstruction, Department of Management Services, State of Florida, the Agent for the Owner, and
James A. Cummings, Inc., A Florida Corporation
3575 Northwest 53rd Street
Fort Lauderdale, Florida 33309
PHONE: (954) 733-4211, FAX (954) 485-9688,
hereinafter called the Construction Manager.
FEDERAL TAX I.D. NUMBER: 59-2098732
ARTICLE 1
THE CONSTRUCTION TEAM AND EXTENT OF AGREEMENT
The Construction Manager accepts the relationship of trust and confidence established between him and the Owner by this
Agreement. He covenants with the Owner to furnish his best skill and judgment and to cooperate with the Architect -Engineer in
furthering the interests of the Owner. He agrees to furnish efficient business administration and superintendence and use his best
efforts to complete the project in the best and soundest way and in the most expeditious and economical manner consistent with
the interest of the Owner.
1.1
The Construction Team The Construction Manager, the Owner and the Architect -Engineer, called the "Construction
Team", shall work jointly during design and through fmal construction completion and shall be available thereafter
should additional services be required. The Architect -Engineer will provide leadership during the Preconstruction
Phase with support from the Construction Manager and the Construction Manager shall provide leadership to the
Construction Team on all matters relating to construction.
The specific representatives of the Construction Team are shown in Exhibit A attached.
1.2 Extent of Agreement - This Agreement for "Project VKB-98069000, Village Community Center, Village Fire Station,
Police Station, and Administrative Office of the Village, Village of Key Biscayne, Florida," between the Owner and the
Construction Manager supersedes any prior negotiations, representations or agreements. When drawings,
specifications and other descriptive documents defming the work to be included under a construction authorization are
complete, they shall be identified in the construction authorization issued by the Project Director. When drawings,
specifications and other descriptive documents defining the work to be included in the guaranteed maximum price
(GMP) are sufficiently complete, an Amendment to the Agreement shall be signed by the Owner and Construction
Manager, acknowledging the GMP amount and the drawings, specifications and other descriptive documents upon
which the GMP is based. To expedite the preparation of this GMP Amendment by the Owner, the Construction
Manager shall obtain three (3) sets of signed, sealed and dated drawings, specifications and other documents upon
which the GMP is based from the Architect -Engineer, shall acknowledge on the face of each document of each set that
it is the set upon which he based his GMP and shall send one set of the documents to the Owner's Contracts
Administrator along with his GMP proposal, while keeping one set for himself and returning one set to the Architect -
Engineer. The GMP Proposal shall include the following sections:
Section One:
Section Two:
Section Three:
Section Four:
Section Five:
Section Six:
Section Seven:
Summary of Work
GMP Price Summary — To include Construction Authorization & Tax Savings
Scope Clarifications and Assumptions
Detailed Estimate
Bid Tabulations and Recommendations
Preliminary Construction Schedule
Contract Documents — Drawing List and Specification List
This Agreement shall not be superseded by any provisions of the documents for construction and may be amended only
by written instrument signed by both Owner and Construction Manager.
1.3 Definitions:
Architect -Engineers
- Spillis Candela & Partners, Inc., 800 Douglas Entrance, Coral Gables, Florida 33134, (305) 444-4691, FAX 447-3580
-Robert G. Currie and Associates, Inc., 134 Northeast First Avenue, Delray Beach, F 32809, (561) 276-4951,
FAX (561) 243-8184
1
-OBM Miami, Inc. 2600 Douglas Road, Suite 510, Coral Gables, Florida 33134, (305) 445-7811.
Construction Authorization — The term Construction Authorization shall mean a written work order based on a defmed
scope of work excluding Construction Managers fees as specified in Article 8, prepared by the Project Director an(
issued to the Construction Manager. Construction Authorizations shall be used prior to the date of the GMI
Amendment and all work performed pursuant to Construction Authorizations shall be included in the GMP
Construction Manager - James A. Cummings, Inc., A Florida Corporation, 3575 Northwest 53rd Street, Fort
Lauderdale, Florida 33309, (954) 733-4211, FAX (954) 485-9688
Estimate - The Construction Manager's latest estimate of probable project construction cost.
Agent - The State of Florida, Department of Management Services, Building Construction, acting through its Secretary
or those persons designated by the Secretary to act in his behalf, as Agent for the Village of Key Biscayne pursuant to
the Client agreement dated August 10, 1999. The entity that will occupy, use and own the project upon substantial
completion is the Village of Key Biscayne. The funds with which the compensation of the architects, engineers,
Construction Managers, etc. will be paid are under the control of the Village of Key Biscayne, based on approval of
each payment by Building Construction. All duties of Owner hereinafter shall be performed by Building Construction.
Owner - Village of Key Biscayne
Owner's Representatives - The Project Director and his superiors or designees.
Permitting Authority - Village of Key Biscayne
*Project - The Project is the total work to be performed under this Agreement. The Project consists of permitting,
construction and code inspection for "Project Number VKB-98069000, Village Community Center, Village Fire
Station, Police Station, and Administrative Office of the Village, Village of Key Biscayne, Florida," necessary to build
the component parts of the project.
Project Director - The person designated by the Owner to provide direct interface with the Construction Manager with
respect to the Owner's responsibilities. (See Exhibit A)
1.4 Owner's Construction Budget: Owner's funds budgeted and requested for construction of the Project. The Owner's
Construction Budget is TBD identified in Exhibit B, including all Construction Manager fees, costs of the work and
the Owner's and Construction Manager's construction and interface contingencies as defmed in Articles 8 and 9. This
acknowledgement of the Owner's budgeted funds is not to be construed as the Construction Manager's Guaranteed
Maximum Price. A Guaranteed Maximum Price will be offered by separate documentation as outlined in Article 7.
ARTICLE 2
CONSTRUCTION MANAGER'S SERVICES
The services which the Construction Manager shall provide include, but are not limited to, those described or specified herein.
The services described or specified shall not be deemed to constitute a comprehensive specification having the effect of excluding
services not specifically mentioned.
2.1 PROJECT MANAGEMENT INFORMATION SYSTEM (PMIS)
2.1.1 General:
(1)
Commencing immediately after contract award, the Construction Manager shall implement and shall utilize
throughout the life of this Contract all subsystems of the Project Management Information System hereinafter
referred to as PMIS.
(2) The reports, documents, and data to be provided shall represent an accurate assessment of the current status of
the Project and of the work remaining to be accomplished and it shall provide a sound basis for identifying
variances and problems and for making management decisions. It shall be prepared and furnished to the Owner
and the Architect -Engineer monthly and shall accompany each pay request.
*Only Preconstruction Services are authorized at this time.
2
(3)
If requested by the Project Director, the Construction Manager shall conduct a comprehensive workshop in
Tallahassee for participants designated by the Project Director and additional seminars as required to provide
instruction. This workshop and the seminars shall facilitate each participant's and the Owner's representatives'
use and understanding of PMIS; shall support, in -part, the function of organizing in concert with the Architect -
Engineer for the design and construction of the Project; and shall establish, with the full concurrence of the
Owner and the Architect -Engineer, procedures for accomplishing the management control aspect of the Project.
(4) The PMIS shall be described in terms of the following major subsystems:
(a) Narrative Reporting, on a monthly basis,
(b) Schedule Control, on a monthly basis,
(c) Cost Control, and estimating,
(d) Project Accounting,
(e) Accounting and Payment, and
(f) Action Reports.
2.1.2 NARRATIVE REPORTING SUBSYSTEM
(1)
The Construction Manager shall prepare written reports as described hereunder. No other PMIS narrative
reports shall be required. All reports shall be in 8 1/2" X 11" format.
(2) The Narrative Reporting Subsystem shall include the following reports:
(3)
(a) A Monthly Executive Summary which provides an overview of current issues and pending decisions, future
developments and expected achievements, and any problems or delays, including code violations found by
Permitting Authority.
(b) A Monthly Cost Narrative describing the current construction cost estimate status of the Project.
(c) A Monthly Scheduling Narrative summarizing the current status of the overall project schedule. This report
shall include an analysis of the various project schedules, a description of the critical path, and other
analyses as necessary to compare planned performance with actual performance.
(d) A Monthly Accounting Narrative describing the current cost and payment status of the entire project. This
report shall relate current encumbrances and expenditures to the budget allocations.
(e) A Monthly Construction Progress Report during the construction phase summarizing the work of the various
subcontractors. This report shall include information from the weekly job site meetings as applicable such
as general conditions, long lead supplies, current deliveries, safety and labor relations programs permits,
construction problems and recommendations, and plans for the succeeding month.
(0
(g)
A Daily Construction Diary during the construction phase describing events and conditions on the site.
A monthly Local Small Business report during the construction phase summarizing the participation of
certified Local Small Business subcontractors/material suppliers for the current month, and project to date.
The report shall include the names, addresses, and dollar amount of each certified Local Small Business
participant.
(h) Construction Manager shall implement a direct tax savings purchase plan approved by the Department of
Revenue that, upon acceptance, will be part of the Construction Manager's services.
The reports outlined in subsection (2)(a) through (e) above shall be bound with applicable computer reports and
submitted monthly during design and construction phases and shall be current through the end of the preceding
month. Copies shall be transmitted to the Owner and the Architect -Engineer and others designated by the
Project Director with the monthly pay requisition.
Additional copies of the report outlined in subsection (2)(a) shall be bound separately and distributed monthly as
directed by the Project Director.
(4) The report outlined in subsection (2)(f) above shall be maintained at the site available to the Owner and
Architect -Engineer. A copy, bound, of the complete diary shall be submitted to the Owner at the conclusion of
the project.
2.1.3 Scheduled Control Subsystem
(1) Master Project Schedule - Upon award of this Contract, the Construction Tea , shall submit a master project
3
schedule covering the planning and design approvals, construction and Owner occupancy of the Project. This
schedule will serve as the framework for the subsequent development of all detailed schedules. The master
project schedule shall be produced and updated monthly throughout the project.
(2) Construction Schedule And Requirements For Overtime Work For Projects With Construction Costs In Exces.
of $5,000,000.00 Within thirty (30) days after the date of the Owner's issuance of a Notice to Proceed, the
Construction Manager shall prepare and submit to the Architect -Engineer a construction schedule in
quadruplicate graphically depicting the activities contemplated to occur as a necessary incident to performance
of the work required to complete the project, showing the sequence in which the Construction Manager proposes
for each such activity to occur and duration (dates of commencement and completion, respectively) of each such
activity. An example of an acceptable form of such a construction schedule is contained in Appendix I of the
Corps of Engineers' Regulation ER 1-1-11 entitled "Network Analysis System", a copy of which is available to
the Construction Manager from the Architect -Engineer, upon request. Another form of construction schedule
which provides the same kind of information and employs the same basic principles as illustrated in Appendix I
of the Corps of Engineers' Regulation ER 1-1-11 will be acceptable to the Owner if used by the Construction
Manager; provided, however, that the Architect -Engineer shall determine whether the construction schedule
developed and submitted by the Construction Manager meets the requirements stated above and such
determination shall be binding on the Construction Manager. Failure of the Construction Manager to develop
and submit a construction schedule as aforesaid shall be sufficient grounds for the Architect -Engineer to fmd the
Construction Manager in substantial default and certify to the Owner that sufficient cause exists to terminate the
contract or to withhold any payment.
Following development and submittal of the construction schedule as aforesaid, the Construction Manager shall,
at the end of each calendar month occurring thereafter during the period of time required to fmally complete the
subject project, or at such earlier intervals as circumstances may require, update and/or revise the construction
schedule to show the actual progress of the work performed and the occurrence of all events which have affected
the progress of performance of the work already performed or will affect the progress of the performance of the
work yet to be performed in contrast with the planned progress of performance of such work, as depicted on the
original construction schedule and all updates and/or revisions thereto as reflected in the updated and/or revised
construction schedule last submitted prior to submittal of each such monthly update and revision. Each such
update and/or revision to the construction schedule shall be submitted to the Architect -Engineer in duplicate.
Failure of the Construction Manager to update, revise, and submit the construction schedule as aforesaid shall be
sufficient grounds for the Architect -Engineer to fmd the Construction Manager in substantial default and certif
to the Owner that sufficient cause exists to terminate the Contract or to withhold payment to the Construction
Manager until a schedule or schedule update acceptable to the Architect -Engineer is submitted.
(3) The Construction Manager shall prepare and incorporate into the schedule data base, at the required intervals,
the following schedules:
(a) Pre -Bid Schedules (Subnetworks) - The Construction Manager shall prepare a construction schedule for
work encompassed in each bid package. The schedule shall be sufficiently detailed as to be suitable for
inclusion in the bid package as a framework for contract completion by the successful bidder. It shall show
the interrelationships between the work of the successful bidder and that of other subcontractors, and shall
establish milestones keyed to the overall master schedule.
Subcontractor Construction Schedules (Subnetworks) - Upon the award of each sub -contract, the
Construction Manager shall jointly with the subcontractor, develop a schedule which is more detailed than
the pre -bid schedule included in the specifications, taking into account the work schedule of the other
subcontractors. The construction schedule shall include as many activities as necessary to make the
schedule an effective tool for construction planning and for monitoring the performance of the
subcontractor. The construction schedule shall also show pertinent activities for material purchase orders,
manpower supply, shop drawing schedules and material delivery schedules.
(c) Occupancy Schedule - The Construction Manager shall jointly develop with the Architect -Engineer and
Owner a detailed plan, inclusive of punch lists, final inspections, maintenance training and turn -over
procedures, to be used for ensuring accomplishment of a smooth and phased transition from construction to
Owner occupancy. The Occupancy Schedule shall be produced and updated monthly from its inception
through final Owner occupancy.
2.1.4 Cost Control Subsystem - The operation of this subsystem shall provide sufficient timely data and detail to permit the
Construction Team to control and adjust the project requirements, needs, materials, equipmen d systems by buildi!
and site elements so that construction will be completed at a cost which, together with all a project costs, will nt..
exceed the maximum total project budget. Requirements of this subsystem include the oll• ' ing submissions at the
following phases of the project:
(b)
4
Estimates
(a) At completion of Advanced Schematic Preconstruction Phase For Each Item, Bid Package, or Building.
(b) At Completion of Design Development Phase Each Item, Bid Package, or Building.
(c) At Completion of 100% Construction Documents Phase For Each Item, Bid Package, or Building.
(d) At establishment of the Guaranteed Maximum Price for Each Building.
(e) Construction Documents Estimates - Prior to the bid of each bid package, when the working drawings and
specifications are complete, the Construction Manager shall prepare and submit a cost estimate on the basis of a
quantitative material take -off with current local cost for each bid group by subcontract package.
2.1.5 Project Accounting Subsystem - The operation of this subsystem shall enable the Construction Team to plan effectively
and to monitor and control the funds available for the project, cash flow, costs, change orders, payments, and other
major financial factors by comparison of budget, estimate, total commitment, amounts invoiced, and amounts payable.
This subsystem will be produced and updated monthly and includes the following reports which together will serve as a
basic accounting tool and an audit trail. The Construction Manager will retain all project files in a manner consistent
with proper accounting procedures that would be sufficient for an audit by the Owner for a period of 5 years after final
completion of the project. This report will also provide for accounting by building and site element.
(a) Costs Status Report presenting the budget, estimate, and base commitment (awarded contracts and purchase
orders) for any given contract or budget line item. It shall show approved change orders for each contract which
when added to the base commitment will become the total commitment. Pending change orders will also be
shown to produce the total estimated probable cost to complete the work.
(b) A Payment Status Report showing the value in place (both current and cumulative), the amount invoiced (both
current and cumulative), the retained, the amount payable (both current and cumulative), and the balance
remaining. A summary of this report shall accompany each pay request.
(c) A Detailed Status Report showing the complete activity history of each item in the project accounting structure.
It shall include the budget, estimate and base commitment figures for each contract. It shall give the change
order history including change order numbers, description, proposed and approved dates, and the proposed and
approved dollar amounts. It shall also show all pending or rejected change orders.
(d) A Cash Flow Diagram showing the projected accumulation of cash payments against the project. Cash flow
projections shall be generated for anticipated monthly payments as well as cumulative payments.
(e) A Job Ledger shall be maintained as necessary to supplement the operation of the project accounting subsystem.
The job ledger will be used to provide construction cost accountability for general conditions work, on -site
reimbursable expenses, and costs requiring accounting needs.
2.2 PROJECT MANUAL
(1) Upon award of contract the Construction Manager shall develop a draft comprehensive Project Manual
describing the services set forth in this Contract. This shall provide a plan for the control, direction,
coordination and evaluation of work performed throughout the project organization including identification of
Key personnel, responsibilities of Construction Manager, Owner and Architect -Engineer; work flow diagrams;
and strategy for bidding the work. The Project Manual shall be updated as necessary throughout the design,
construction and Owner occupancy phases. Five copies of the Project Manual and any updates shall be
submitted to the Owner and Architect -Engineer. In developing the Project Manual, the Construction Manager
shall coordinate with the Owner and the Architect -Engineer.
(2) Contents of Project Manual - The Project Manual shall describe in detail the procedures for executing the work
and the organizations participating. The Project Manual shall include as a minimum the following sections:
(a) Project Definition - The known characteristics of the project or subprojects shall be described in general
terms which will provide the participants a basic understanding of the project or sub -projects.
(b) Project Goals - The schedule, budget, physical, technical and other objectives for the project shall be
defined.
(c) Project Strategy - A narrative description of the project delivery methods shal lized to accomplish the
project goals.
5
(d) Project Work Plan - A matrix display of the program of work to be performed by the Construction Manager,
the Architect -Engineer and the Owner during each phase of the project.
(e) Project Organization - A summary organization chart showing the interrelationships between the Owner, th.
Construction Manager and the Architect -Engineer, and other supporting organizations and permitting review
agencies. Detailed charts, one each for the Construction Manager, the Architect -Engineer, the Using
Agency and Owner showing organizational elements participating in the project shall be included.
(f) Responsibility Performance Chart - A detailed matrix showing the specific responsibilities and
interrelationships of the Owner, the Architect -Engineer, and Construction Manager. The Responsibility
Performance Chart shall indicate major responsibility, and minor responsibility, for each specific task
required to deliver the project. The Construction Manager shall develop a similar chart for the personnel
within his own organization who are assigned to the project, and also for the personnel of the Owner and the
Architect -Engineer from data supplied by each.
(g) Flow Diagrams - These charts shall display the flow of information and the decision process for the review
and approval of shop drawings and submittals, progress and change orders.
(h) Written Procedures - The Construction Manager will provide written procedures for communications and
coordination required between Construction Team members throughout the project. Procedures shall cover
such items as correspondence, minutes, reports, inspections, team meetings, technical reviews, design
reviews, and other necessary communications.
2.3 DESIGN REVIEW AND RECOMMENDATIONS
(1)
Review and Recommendations and Warranty. - The Construction Manager shall familiarize himself thoroughly
with the evolving architectural, civil, mechanical, plumbing, electrical, and structural plans and specifications
and shall follow the development of design from Preliminaries through Working Drawings. He shall make
recommendations with respect to the selection of systems and materials, and cost reducing alternatives including
assistance to the Architect -Engineer, and Owner in evaluating alternative comparisons versus long term cost
effects. The evaluation shall speak to the benefits of the speed of erection and early completion of the project.
He shall furnish pertinent information as to the availability of materials and labor that will be required. He sha
submit to the Owner, Permitting Authority and Architect -Engineer such comments as may be appropriate
concerning construction feasibility and practicality. He shall call to the Project Director's and the Architect -
Engineer's attention any apparent defects in the design, drawings and specifications or other documents. He
shall prepare an estimate of the construction cost utilizing the unit quantity survey method.
(2) Review Reports and Warranty - Within 45 days after receiving the Construction Documents for each phase of
the project, the Construction Manager shall perform a specific review thereof, focused upon factors of a nature
encompassed in Paragraph (1) above and on factors set out in Paragraph (5). Promptly after completion of the
review, he shall submit to the Project Director and Permitting Authority, with copies to the Architect -Engineer, a
written report covering suggestions or recommendations previously submitted, additional suggestions or
recommendations as he may deem appropriate, and all actions taken by the Architect -Engineer with respect to
same, any comments he may deem to be appropriate with respect to separating the work into separate contracts,
alternative materials, and all comments called for under Article 2.3(5).
(3)
AT COMPLETION OF THE CONSTRUCTION MANAGER'S REVIEW OF THE PLANS AND
SPECIFICATIONS, EXCEPT ONLY AS TO SPECIFIC MA'1"1 ERS AS MAY BE IDENTIFIED BY
APPROPRIATE COMMENTS PURSUANT TO THIS SECTION, THE CONSTRUCTION MANAGER
SHALL WARRANT, WITHOUT ASSUMING ANY ARCHITECTURAL OR ENGINEERING
RESPONSIBILITY, THAT THE PLANS AND SPECIFICATIONS ARE CONSISTENT, PRACTICAL,
FEASIBLE AND CONSTRUCTIBLE. CONSTRUCTION MANAGER SHALL WARRANT THAT THE
WORK DESCRIBED IN THE PLANS AND SPECIFICATIONS FOR THE VARIOUS BIDDING PACKAGES
IS CONSTRUCTIBLE WITHIN THE SCHEDULED CONSTRUCTION TIME.
DISCLAIMER OF WARRANTY: - THE OWNER DISCLAIMS ANY WARRANTY THAT THE PLANS
AND SPECIFICATIONS FOR THE PROJECT ARE ACCURATE, PRACTICAL, CONSISTENT OR
CONSTRUCTIBLE.
Long Lead Procurements - The Construction Manager shall review the design for the purpose of identifying lo;
lead procurement items (machinery, equipment, materials and supplies). When e ch item is identified,
Construction Manager shall notify the subcontractors, the Project Director and a rchitect-Engineer of the
required procurement and schedule. Such information shall be included in the b. uments and made a part of
all affected sub -contracts. As soon as the Architect -Engineer has co le d drawings and technical
6
specifications and the Construction Manager has obtained permitting approval, the Construction Manager shall
prepare invitations for bids. The Construction Manager shall keep himself informed of the progress of the
respective subcontractors or suppliers, manufacturing or fabricating such items and advise Project Director,
Owner and Architect -Engineer of any problems or prospective delay in delivery.
(4) Separate Contracts Planning - The Construction Manager shall review the design with the Architect -Engineer
and make recommendations to the Owner and to the Architect -Engineer with respect to dividing the work in
such manner as will permit the Construction Manager to take bids and award separate construction sub -contracts
on the current schedule while the design is being completed. He shall take into consideration such factors as
natural and practical lines of severability, sequencing effectiveness, access and availability constraints, total time
for completion, construction market conditions, availability of labor and materials, community relations and any
other factors pertinent to saving time and cost by overlapping design and construction that are authorized by the
Owner.
(5) Interfacing
(a) The Construction Manager shall take such measures as are appropriate to provide that all construction
requirements will be covered in the separate subcontracts for procurement of long lead items, the separate
construction subcontracts and the general conditions items performed without duplication or overlap,
sequenced to maintain completion of all work on schedule. Particular attention shall be given to provide
that each bid package clearly identifies the work included in that particular separate subcontract, its schedule
for start and completion and its relationship to other separate subcontracts.
(b) Without assuming any Design responsibilities of the Architect -Engineer, the Construction Manager shall
include in the reports required under Article 2.3(2) comments on overlap with any other separate
subcontracts, omissions, lack of correlation between drawings, and any other deficiencies noted, in order
that the Project Director and Architect -Engineer may arrange for necessary corrections.
(6) Job -Site Facilities - The Construction Manager shall arrange for all job -site facilities necessary to enable the
Construction Manager and the Owner's representatives and the Architect -Engineer to perform their respective
duties in the management, inspection, and supervision of construction.
Tangible personal property, otherwise referred to as Job -Site facilities, include but are not limited to such things
as trailers, toilets, typewriters, computers and any other equipment necessary to carry on the project. The
method of acquiring such job -site facilities which are planned to become the property of the owner at the
conclusion of the project shall be evaluated based on cost over the life of the project. Owning versus leasing
shall be considered by the Construction Manager obtaining at least two (2) proposals for leasing and at least two
(2) proposals for purchasing and then analyzing which is least expensive over the usage life of the item. The
Construction Manager shall present his evaluation with recommendation to the owner for approval.
When the Construction Manager wishes to supply Job -Site Facilities from his own equipment pool, he shall first
evaluate buy versus lease as discussed in the paragraph above. If leasing is found to be the least expensive
approach, then he may lease such Job -Site Facilities from his own equipment pool at a price not greater than the
lowest of the three (3) lease proposals obtained.
For all such facilities purchased which may become the property of the owner at the conclusion of the project,
the Construction Manager shall maintain ownership responsibilities of such facilities until the project
conclusion. Reimbursement for cost of such equipment will be made at the conclusion of the project at the
documented purchase price. At that time, the Construction Manager shall provide the owner with a complete
inventory for each unit of equipment. The inventory shall describe the equipment and identify the purchase
price, serial number, model number and condition. Where said equipment has a title, said title shall be properly
transferred to the Owner or to his designee.
The Construction Manager is responsible for proper care and maintenance of all equipment while in his control.
At the time of transfer to the owner, the owner may refuse acceptance of the equipment if the owner determines
in its sole discretion that the equipment has not been properly cared for by the Construction Manager or that
such acquisition would not otherwise be in the best interest of the Owner. In such event, the Construction
Manager will be reimbursed for such item in accordance with Article 9.2(4) hereof.
(7)
Weather Protection - The Construction Manager shall ascertain what temporary enclosures, if any, of building
areas should be provided for and may be provided as a practical matter, in order to assure orderly progress of the
work in periods when extreme weather conditions are likely to be experienced. He shall submit to the
Construction Team his recommendations as to needed requirements of this jture and as to the contract or
contracts in which they should be included.
7
(8) Market Analysis and Stimulation of Bidder Interest
(a) The Construction Manager shall monitor conditions in the construction market to identify factors that will or
may affect costs and time for completing the project; he shall make analysis as necessary to (1) determine
and report on availability of labor, material, equipment, potential bidders, and possible impact of an,
shortages or surpluses of labor or material, and (2) in light of such determinations, make recommendations
as may be appropriate with respect to long lead procurement, separation of construction into bid packages,
sequencing of work, use of alternative materials, equipment or methods, other economics in design or
construction, and other matters that will promote cost savings and completion within the scheduled time.
(b) Within 30 days after receiving Notice to Proceed, the Construction Manager shall submit a written
"Construction Market Analysis and Prospective Bidders Report" setting out recommendations and providing
information as to prospective bidders. As various bid packages are prepared for bidding, the Construction
Manager shall submit to the Project Director and the Architect -Engineer a list of potential bidders. The
Construction Manager shall be responsible to stimulate bidder interest in the local market place and identify
and encourage bidding competition.
(c) The Construction Manager shall carry out an active program of stimulating interest of qualified Construction
Managers in bidding on the work and of familiarizing those bidders with the requirements of this project.
*2.4 CONSTRUCTION PHASE
(1) Construction Manager's Staff - The Construction Manager shall maintain sufficient off -site support staff, and
competent full time staff at the Project site authorized to act on behalf of the Construction Manager to
coordinate, inspect and provide general direction of the work and progress of the subcontractors and he shall
provide no less than those personnel during the respective phases of construction that are set forth in Exhibit "C"
to this agreement. He shall not change any of those persons named in Exhibit "C" unless mutually agreed to by
the Owner and Construction Manager. In such case, the Owner shall have the right of approval of the
qualifications of replacement personnel. Such approval will not be unreasonably withheld.
(2) Lines of Authority - The Construction Manager shall establish and maintain lines of authority for this personnel,
and shall provide this defmition to the Owner and all other affected parties such as the code inspectors of the
Permitting Authority, the sub -contractors, the Architect -Engineer and the Owner's representatives, to provid
general direction of the work and progress of the various phases and subcontractors. The Owner and Architect -
Engineer may attend meetings between the Construction Manager and his Subcontractors, however, such
attendance shall not diminish either the authority or responsibility of the Construction Manager to administer the
subcontractor.
(3)
Schedule and Project Manual Provisions - The Construction Manager shall provide subcontractors and the
Owner, its representatives and the Architect -Engineer with copies of the Project Manual (total number of copies
not to exceed 10) developed and updated as required by Article 2.2 expanded for the Construction Phase
employing their respective milestones, beginning and fmishing dates, their respective responsibilities for
performance and the relationships of their work with respect to subcontractors and suppliers. He shall also
continue to provide current scheduling information and provide direction and coordination regarding milestones,
beginning and fmishing dates, responsibilities for performance and the relationships of the Construction
Manager's work to the work of his subcontractors and suppliers to enable them to perform their respective tasks
so that the development of construction progresses in a smooth and efficient manner in conformance with the
overall project schedule. The schedule shall include all phases of the construction work, material supplies, long
lead procurement, approval of shop drawings, change orders in progress, schedules for change orders, and
performance testing requirements. He shall advise the Owner, its representatives and the Architect -Engineer of
their required participation in any meeting or inspection giving each at least one week notice unless such notice
is made impossible by conditions beyond his control. He shall hold job -site meetings at least once each month
with the Construction Team and at least once each week with the subcontractors and the Architect -Engineer's
Field Representative, or more frequently as required by work progress, to review progress, discuss problems and
their solutions and coordinate future work with all subcontractors.
(4) Solicitation of Bids
(a) Without assuming responsibilities of the Architect -Engineer, and unless waived in writing by the Owner, the
Construction Manager shall prepare invitations for bids, or requests for proposal when applicable, for all
procurements of long lead items, materials and services, and for Subcontractor contracts. Such invitatioi
for bids shall be prepared in accordance with the following guidelines.
*Not Applicable at this time.
8
1. Contracts over $1,000 but not exceeding $10,000 may be entered into by the Construction Manager
with the firm which submits the lowest verbal quotation. The Construction Manager shall obtain a
minimum of two (2) verbal quotations. These quotations shall be entered on a bid tabulation sheet and
a copy of such tabulation sent to the Owner, Architect -Engineer and to each firm. The successful
quotation shall be confirmed by written contract or purchase order to the low bid firm defming the
scope and quality of work to be provided.
2. Contracts exceeding $10,000 but not exceeding $200,000 may be entered into by the Construction
Manager with the firm who is qualified and submits the lowest responsive proposal. The Construction
Manager shall request at least three (3) firms to submit sealed written proposals based on a written
drawings and/or specification. The written proposals shall all be opened publicly at the location, date
and time named by the Construction Manager in his request for proposal. A tabulation of the results
shall be furnished to the Owner, Architect -Engineer and to each firm.
3. Contracts exceeding $200,000 but not exceeding $500,000 may be entered into by the Construction
Manager with the firm who is qualified and submits the lowest responsive proposal. The Construction
Manager shall advertise these projects at least once with the last advertisement appearing at least 21
calendar days prior to the established bid opening date and at least 5 days prior to any scheduled pre -
bid conference. These proposals shall be based on approved plans and specifications. Bids shall be
received and opened publicly at the location, date and time established in the bid advertisement.
4. Contracts exceeding $500,000 shall be treated the same as described under 3 above except that the
advertisement shall be run for at least 30 days prior to the established bid opening and at least 5 days
prior to any scheduled pre -bid conference.
5. Individual purchases of materials or rentals or leases of equipment amounting to less than $1,000.00
each may be made without bids or quotes when reasonably necessary to expedite work on the project,
however, the Construction Manager shall not divide or separate a procurement in order to avoid the
requirements set forth above.
6. Site utilities may be acquired at market rates from the entity(ies) providing such in the franchise area.
(b) As part of such preparation, the Construction Manager shall review the specifications and drawings prepared
by the Architect -Engineer. Ambiguities, conflicts or lack of clarity of language, use of illegally restrictive
requirements, and any other defects in the specifications or in the drawings noted by the Construction
Manager shall be brought to the attention of the Project Director and Architect -Engineer in written form.
(c) For each separate construction contract exceeding $25,000, the Construction Manager shall, unless waived
by Owner, conduct a pre -bid conference with prospective bidders, the Architect -Engineer and Project
Director. In the event questions are raised which require an interpretation of the bidding documents or
otherwise indicate a need for clarification or correction of the invitation, the Construction Manager shall
transmit these to the Architect -Engineer and upon receiving clarification or correction in writing shall
prepare an addendum to the bidding document, and issue same to all of the prospective bidders.
(d) For all contracts exceeding $25,000, the Construction Manager shall establish a pre -qualification procedure
for applicable subcontract trades.
Bonds - In accordance with the provisions of Section 255.05, Florida Statutes, the Construction Manager shall
provide to the Owner, on forms furnished by the Owner, a 100% Performance Bond and a 100% Labor and
Material Payment Bond each in an amount not less than the total construction cost as defined in Article 9 and
inclusive of the Construction Manager's fees.
To be acceptable to the Department of Management Services as Surety for Performance Bonds and Labor and
Material Payment Bonds, a Surety Company shall comply with the following provisions:
1. The Surety Company shall have a currently valid Certificate of Authority, issued by the State of Florida,
Department of Insurance, authorizing it to write surety bonds in the State of Florida.
2. The Surety Company shall have currently valid Certificate of Authority issued by the United States
Department of Treasury under Sections 9304 to 9308 of Title 31 of the United States Code.
3. The Surety Company shall be in full compliance with the provisions of the Florida Insurance Code.
4. The Surety Company shall have at least twice the minimum surplus pital required by the Florida
Insurance Code at the time the invitation to bid is issued.
5. If the Contract Award Amount exceeds $500,000, the Surety Company shall also comply with the following
provisions:
A. The Surety Company shall have at least the following minimum ratings in the latest issue of Best's Ke.
Rating Guide.
CONTRACT AMOUNT
POLICY REQUIRED
HOLDER'S FINANCIAL
RATING RATING
$ 500,000 TO 1,000,000 A- CLASS I
1,000,000 TO 2,000,000 A- CLASS II
2,000,000 TO 5,000,000 A- CLASS III
5,000,000 TO 10,000,000 A- CLASS IV
10,000,000 TO 25,000,000 A- CLASS V
25,000,000 TO 50,000,000 A- CLASS VI
50,000,000 TO 100,000,000 A- CLASS VII
B. The Surety Company shall not expose itself to any loss on any one risk in an amount exceeding ten
(10) percent of its surplus to policyholders, provided:
(a) Any risk or portion of any risk being reinsured shall be deducted in determining the limitation of
the risk as prescribed in this section. These minimum requirements shall apply to the reinsuring
carrier providing authorization or approval by the State of Florida, Department of Insurance to do
business in this state have been met.
(b) In the case of the surety insurance company, in addition to the deduction for reinsurance, the
amount assumed by any co -surety, the value of any security deposited, pledged or held subject to
the consent of the surety and for the protection of the surety shall be deducted.
(6) Quality Control - The Construction Manager shall develop and maintain a program, acceptable to the Owner and
Architect -Engineer, to assure quality control of the construction. He shall supervise the work of a
subcontractors providing instructions to each when their work does not conform to the requirements of the plans
and specifications and he shall continue to exert his influence and control over each subcontractor to ensure that
corrections are made in a timely manner so as to not affect the efficient progress of the work. Should
disagreement occur between the Construction Manager and Architect -Engineer over acceptability of work and
conformance with the requirements of the specifications and plans, the Owner shall be the fmal judge of
performance and acceptability.
Subcontractor Interfacing - The Construction Manager shall be the single point of interface with all
subcontractors for the Owner and all of its agents and representatives including the Architect -Engineer. He shall
negotiate all change orders, field orders and request for proposals, with all affected subcontractors and shall
review the costs of those proposals and advise the Owner and Architect -Engineer of their validity and
reasonableness, acting in the Owner's best interest prior to requesting approval of each change order from the
Owner. Before any work is begun on any change order, a written authorization from the Owner must be issued.
However, when health and safety are threatened, the Construction Manager shall act immediately to remove the
threat to health and safety. He shall also carefully review all shop drawings and then forward the same to the
Architect -Engineer for review and actions. The Architect -Engineer will transmit them back to the Construction
Manager who will then issue the shop drawings to the affected subcontractor for fabrication or revision. The
Construction Manager shall maintain a suspense control system to promote expeditious handling. He shall
request the Architect -Engineer to make interpretations of the drawings or specifications requested of him by the
subcontractors and shall maintain a suspense control system to promote timely response. He shall advise the
Project Director and Architect -Engineer when timely response is not occurring on any of the above.
(8) Permits - The Construction Manager shall secure all necessary building permits from the Permitting Authority
and all necessary utility connection permits, the cost of which will be considered a direct cost item.
(7)
(9) Job Site Requirements
(a) The Construction Manager shall provide for each of the following activities as a part of his Constructif
Phase fee:
1. Maintain a log of daily activities, including manpower records, a)her, delays, major decisions, etc.
10
2. Maintain a roster of companies on the project with names and telephone numbers of key personnel.
3. Establish and enforce job rules governing parking, clean-up, use of facilities and worker discipline.
4. Provide labor relations management for a harmonious, productive project.
5. Provide a safety program for the project to meet OSHA requirements. Monitor for subcontractor
compliance without relieving them of responsibilities to perform work in accordance with the best
acceptable practice.
6. Provide a quality control program as developed under Article 2.4(6) hereinabove.
7. Miscellaneous office supplies that support the construction efforts which are consumed by his own
forces.
8. Travel to and from his home office to the project site and Tallahassee as the project requires.
(b) The Construction Manager shall provide personnel and equipment or shall arrange for separate
subcontracts to provide each of the following as a direct cost item:
1. Schedule the services of independent testing laboratories and provide the necessary testing of materials
to ensure conformance to contract requirements.
2. The printing and distribution of all required bidding documents and shop drawings, including the sets
required by the Permitting Authority's inspectors.
(10) Job Site Administration - The Construction Manager shall provide as part of his construction phase fee, job site
administrative functions during construction to assure proper documentation, including but not limited to such
things as the following:
(a) Job Meetings - Hold weekly progress and coordination meetings to provide for an easy flowing project.
Implement procedures and assure timely submittals, expedite processing approvals and return of shop
drawings, samples, etc. Coordinate and expedite critical ordering including direct tax saving purchases and
delivery of materials, work sequences, inspection and testing, labor allocation, etc. Review and coordinate
each subcontractor's work. Review and implement revisions to the Schedule. Monitor and promote safety
requirements. In addition, regular project status meetings will be held between the architect, owner and
Construction Manager either biweekly or monthly, whichever is designated by the Project Director.
Use the job site meeting as a tool for preplanning of work and enforcing schedules and for establishing
procedures, responsibilities, and identification of authority for all to clearly understand.
Identify party or parties responsible for follow up on any problems, delay items or questions and record
course for solution. Revisit each pending item at each subsequent meeting until resolution is achieved.
Require all present to make any problems or delaying event known to those present for appropriate attention
and resolution.
(b) Shop Drawing Submittals/Approvals - Provide staff to check shop drawings and to implement procedures
for submittal and transmittal to the Architect -Engineer of such drawings for action, and closely monitor their
submittal and approval process.
(c) Material and Equipment Expediting - Provide staff to closely monitor material and equipment deliveries,
critically important checking and follow-up procedures on supplier commitments of all subcontractors.
(d) Payments to subcontractors - Develop and implement a procedure for review, processing, and payment of
applications by subcontractors for progress and final payments.
(e) Document Interpretation - Refer all questions for interpretation of the documents prepared by the Architect -
Engineer to the Architect -Engineer.
(f) Reports and Project Site Documents - Record the progress of the project. Submit written progress reports to
the Owner and the Architect -Engineer including information on the subcontractor's work, and the
percentage of completion. Keep a daily log available to the Owner, the Architect -Engineer and the
Permitting Authority inspectors.
(g) Subcontractor's Progress - Prepare periodic punch lists for subcontra ork including unsatisfactory or
11
incomplete items and schedules for their completion.
(h) Substantial Completion - Ascertain when the work or designated portions thereof are ready for the
Architect -Engineer's substantial completion inspection. From the Architect -Engineer's list of incomplete o
unsatisfactory items, prepare a schedule for their completion indicating completion dates for the Owner',
review. If the Construction Manager wishes the Architect -Engineer to conduct a pre -substantial completion
inspection in conjunction with his own forces, the Architect -Engineer will prepare the presubstantial punch
list from which the Construction Manager will develop a completion schedule. The Architect -Engineer will
issue a certificate of substantial completion when the work on his presubstantial punch list has been
accomplished (See Exhibit D).
(i)
Final Completion - Monitor the Subcontractor's performance on the completion of the project and provide
notice to the Owner and Architect -Engineer that the work is ready for final inspection. Secure and transmit
to the Owner, through the Architect -Engineer, all required guarantees, affidavits, releases, bonds and
waivers, manuals, record drawings, and maintenance books including the Final Completion form shown in
Exhibit E.
(j) Start -Up - With the Owner's personnel, direct the checkout of utilities, operations, systems and equipment
for readiness and assist in their initial start-up and testing by the trade subcontractors.
(k) Record Drawings - During the progress of the work, the Construction Manager shall require the plumbing,
air conditioning, heating, ventilating, elevator, and electrical subcontractors to record on their field sets of
drawings the exact locations, as installed, of all conduit, pipe and duct lines whether concealed or exposed
which were not installed exactly as shown on the contract drawings. The Construction Manager shall also
record all drawing revisions that have been authorized by change order that effect wall or partition locations,
door and window locations and other template changes. The exact routing of conduit runs shall be shown
on these drawings.
Each drawing shall be noted "As Built" and shall bear the date and name of the subcontractors that
performed the work. Where the work was installed exactly as shown on the contract drawings the sheets
shall not be disturbed except as noted above.
The Construction Manager shall review the completed As -Built drawings and ascertain that all da
furnished on the drawings are accurate and truly represent the work as actually installed. When manholes,
boxes, underground conduits, plumbing, hot or chilled water lines, inverts, etc. are involved as part of the
work, the Construction Manager shall furnish true elevations and locations, all properly referenced by using
the original bench mark used for the institution or for this project
(11) Administrative Records - The Construction Manager will maintain at the job site, unless agreed to otherwise by
the Project Director, on a current basis, files and records such as, but not limited to the following:
Contracts or Purchase Orders
Shop Drawing Submittal/Approval Logs
Equipment Purchase/Delivery Logs -
Contract Drawings and Specifications with Addenda
Warranties and Guarantees
Cost Accounting Records:
Sales Tax Recovery Status Report
Labor Costs
Material Costs
Equipment Costs
Cost Proposal Requests
Payment Request Records
Meeting Minutes
Cost -Estimates
Bulletin Quotations
Lab Test Reports
Insurance Certificates and Bonds
Contract Changes
Purchase Orders
Material Purchase Delivery Logs
Technical Standards
Design Handbooks
As -Built" Marked Prints
Operating & Maintenance Instruction
12
Daily Progress Reports
Monthly Progress Reports
Correspondence Files
Transmittal Records
Inspection Reports
Bid/Award Information
Bid Analysis and Negotiations
Punch Lists
PMIS Schedule and Updates
Suspense (Tickler) Files of Outstanding Requirements
Project Manual
The project records shall be available at all times to the Owner and Architect -Engineer for reference or review.
(12) Owner Occupancy - The Construction Manager shall provide services during the design and construction phases,
which will provide a smooth and successful Owner occupancy of the project. He shall provide consultation and
project management to facilitate Owner occupancy and provide transitional services to get the work, as
completed by the Construction Managers, "on line" in such conditions as will satisfy Owner operational
requirements.
He shall conduct the Construction Manager's preliminary punch list inspection and coordinate the completion of
all punch list work to be done with Owner occupancy requirements in mind.
He shall catalog operational and maintenance requirements of equipment to be operated by maintenance
personnel and convey these to the Owner in such a manner as to promote their usability. He shall provide
operational training, in equipment use, for building operators.
He shall secure required guarantees and warranties, assemble and deliver same to the Owner in a manner that
will facilitate their maximum enforcement and assure their meaningful implementation.
He shall continuously review "As -Built" Drawings and mark up progress prints to provide as much accuracy as
possible.
The Owner will not occupy or take control of the project until the above items discussed in this paragraph have
been completed and the "Substantial Completion", "Start -Up", "Record Drawing", and "Warranty" requirements
specified in paragraphs 2.4(10)h, 2.4(10)j, 2.4(10)k, and 2.4(13) have been completed to the Owner's
satisfaction excluding the requirements for a warranty inspection nine months after Owner Occupancy.
(13) Warranty - Where any work is performed by the Construction Manager's own forces or by subcontractors under
contract with the Construction Manager, the Construction Manager shall warrant that all materials and
equipment included in such Work will be new except where indicated otherwise in Contract Documents, and
that such Work will be of good quality, free from improper workmanship and defective materials and in
conformance with the Drawings and specifications. With respect to the same Work, the Construction Manager
further agrees to correct all work found by the Owner to be defective in material and workmanship or not in
conformance with the Drawings and Specifications for a period of one year from the Date of Substantial
Completion or for such longer periods of time as may be set forth with respect to specific warranties contained
in the trade sections of the Specifications. The Construction Manager shall collect and deliver to the Owner any
specific written warranties given by others as required by the Contract Documents. Also, the Construction
Manager shall conduct, jointly with the Owner and the Architect -Engineer, a warranty inspection nine (9)
months after the date of Owner Occupancy.
ARTICLE 3
OWNER'S RESPONSIBILITIES
3.1 Owner's Information - The Owner shall provide full information regarding his requirements for the project.
3.2 Owner's Representative - The Owner shall designate a representative who shall be fully acquainted with the project and
shall define the lines of Owner authority to approve Project Construction Budgets, and changes in Project. He shall
render decisions promptly and furnish information expeditiously.
.3 Architect and Engineer's Agreement - The Owner shall retain an Architect -Engineer for design and to prepare
construction documents for the project. The Architect -Engineer's services, duties and responsibilities are described in
the Agreement between the Owner and the Architect -Engineer, a copy of which will e furnished to the Construction
Manager. The Agreement between the Owner and the Architect -Engineer sh be modified without written
notification to the Construction Manager.
13
3.4 Site Survey and Reports - The Owner shall provide for the furnishing for the site of the project all surveys describing
the physical characteristics, soil reports, and subsurface investigations, legal limitations, utility locations, and a legal
description.
3.5 Approvals and Easements - The Owner shall pay for necessary approvals, easements, assessments and charges required
for the construction, use or occupancy of permanent structures or for permanent changes in existing facilities.
3.6 Legal Services - The Owner shall furnish such legal services as may be necessary for providing the items set forth in
Article 3.5 and such auditing services as he may require.
3.7 Drawings and Specifications - The Construction Manager will be furnished a reproducible set of all copies of Drawings
and Specifications reasonably necessary and ready for printing.
3.8 Cost of Surveys & Reports - The services, information, surveys and reports required by the above paragraphs shall be
furnished with reasonable promptness in accordance with the approved schedule at the Owner's expense, and the
Construction Manager shall be entitled to rely upon the accuracy and completeness thereof.
3.9 Project Fault Defects - If the Owner becomes aware of any fault or defect in the Project or non-conformance with the
drawings and specifications, he shall give prompt written notice thereof to the Construction Manager and Architect -
Engineer.
3.10 Funding - The Owner shall furnish in accordance with the established schedule, reasonable evidence satisfactory to the
Construction Manager that sufficient funds will be available and committed for the cost of each part of the Project. The
Construction Manager shall not commence any work, unless authorized in writing by the Owner.
3.11 Lines of Communication - The Owner and Architect -Engineer shall communicate with the subcontractors or suppliers
only through the Construction Manager while such method of communication is effective in maintaining project
schedules and quality.
3.12 Lines of Authority - The Owner shall establish and maintain lines of authority for his personnel and shall provide this
definition to the Construction Manager and all other affected parties.
3.13 Permitting & Code Inspections - The Owner recognizes and coordinates with the Permitting Authority and expects the
Construction Manager to do the same.
ARTICLE 4
PERMITTING AND INSPECTION
Before Construction can begin, it is necessary by statute for the Construction Manager to obtain a Building Permit. In addition,
construction will be inspected for code compliance, compliance with drawings and specifications, and quality by inspectors
working for the Permitting Authority. The building permitting and code inspection requirements shall be as described in Articles
4.1 through 4.2 hereinafter. The Contractor will pay all permit fees of the Village of Key Biscayne.
4.1 Building Permits - The Construction Manager shall provide the following information to the Permitting Authority and
obtain approval from the Permitting Authority prior to beginning construction:
(1)
Two (2) sets of documents, signed, sealed and dated by the Architect -Engineer, with all addenda enclosed with
each set. These documents may be sent to the Permitting Authority prior to sending the Building Permit
Application addressed in 4.1(2) hereinafter.
(2) The completed Village of Key Biscayne Building Permit Application Form attached as Exhibit F.
4.2 Code Inspections - All projects require detailed code compliance inspections during construction in disciplines
determined by the Permitting Authority. These disciplines normally include, but are not necessarily limited to,
structural, mechanical, electrical, plumbing and general building.
Inspection personnel will be provided by the Permitting Authority. Names, addresses, and phone numbers of the
inspectors will be provided to the Construction Manager by the Permitting Authority.
The Construction Manager shall notify the appropriate inspector(s), no less than 24 hours in advance, that the work
ready for inspection and before the work is covered up. Work not inspected and approved prior to cover-up shall t
uncovered for inspection when directed by the Permitting Authority. All costs for uncoyd g and reconstruction shall
be borne by the Construction Manager.
14
All inspections shall be made for conformance with the applicable building codes, compliance with drawings and
specifications, and quality.
Cost for all reinspections of work found defective and subsequently repaired shall be borne by the Construction
Manager.
ARTICLE 5
SUBCONTRACTS
5.1 Definition. - A subcontractor is a person or organization who has a direct contract with the Construction Manager to
perform any of the work at the site. Nothing contained in the Contract Document shall create any contractual relation
between the Owner or Architect -Engineer and any subcontractor.
5.2 Proposals. - Subject to Article 9 and, in accordance with Article 2.4(4), the Construction Manager shall request and
receive proposals from subcontractors and suppliers and will award those contracts to the qualified low bidder after he
has reviewed each proposal and is satisfied that the subcontractor is qualified to perform the work.
5.3 Required Subcontractors' Qualifications and Subcontract Conditions.
5.3.1 Subcontractual Relations - By an appropriate written agreement, the Construction Manager shall require each
subcontractor to the extent of the work to be performed by the subcontractor, to be bound to the Construction Manager
by the terms of the Contract Documents, and to assume toward the Construction Manager all the obligations and
responsibilities which the Construction Manager by these Documents, assumes toward the Owner and the Architect -
Engineer. Said agreements shall preserve and protect the rights of the Owner and Architect -Engineer under the
Contract Documents with respect to the Work to be performed by the subcontractor so that the subcontracting thereof
will not prejudice such rights. Where appropriate, the Construction Manager shall require each Subcontractor to enter
into similar agreements with his Sub -subcontractor.
The Construction Manager shall make available to each proposed Subcontractor, prior to the execution of the
Subcontract, copies of the Contract Documents to which the Subcontractor will be bound by this Article 5.3 and
identify to the Subcontractor any terms and conditions of the proposed Subcontract which may be at variance with the
Contract Documents. Each Subcontractor shall similarly make copies of such Documents available to his Sub -
subcontractors.
5.3.2 Subcontract Requirements
(1) On all subcontracts where the bid exceeds $100,000, the Construction Manager may require subcontractors to
provide a 100% performance bond and a 100% labor and material payment bond from a surety company authorized to
do business in the State of Florida by the Department of Insurance. If the Construction Manager wishes to award
subcontracts to Subcontractors unable to supply this bonding, he may request special authorization to do so. Upon
providing justifiable background information, such authorization shall not be withheld unreasonably.
(2) On all subcontracts where the bid exceeds $200,000.00, each subcontractor must submit a completed experience
questionnaire and financial statement on the form entitled "Experience Questionnaire and Construction Manager's
Financial Statement" Form #DBC-5085, incorporated herein by reference. The subcontractors financial condition must
demonstrate that adequate fixed and liquid assets and equipment are available to properly perform the subcontract.
(3) Workforce - The subcontractor must agree to perform no less than 15% of the project construction work utilizing
its own employees.
(4) Subcontractor experience - The subcontractor must have successfully completed no less than two projects of
similar size and complexity within the last five years.
(5) Supervision - The subcontractor must agree to provide field (on -site) supervision through a named superintendent
for each trade (general concrete forming and placement, masonry, mechanical, plumbing, electrical and roofing)
included in the subcontract. In addition, the subcontractor shall assign and name a qualified employee for scheduling
direction for its work. The supervisory employees of the subcontractor (including field superintendent, foreman and
schedulers at all levels) must have been employed in a supervisory (leadership) capacity of substantially equivalent
level on a similar project for at least two years within the last five years. The subcontractor shall include a resume of
experience for each employee identified by him to supervise and schedule his work.
(6) All subcontracts shall provide:
a. LIMITATION OF REMEDY - NO DAMAGES FOR DELAY
That the subcontractor's exclusive remedy for delays in the performance of t tract caused by events beyond
15
its control, including delays claimed to be caused by the Owner or Architect -Engineer or attributable to the
Owner or Architect -Engineer and including claims based on breach of contract or negligence, shall be an
extension of its contract time.
In the event of a change in the work the subcontractor's claim for adjustments in the contract sum are limited
exclusively to its actual costs for such changes plus no more than 15% for overhead and profit and bond costs.
Each subcontract shall require the subcontractor to expressly agree that the foregoing constitute the sole and
exclusive remedies for delays and changes in the work and thus eliminate any other remedies for claim for
increase in the contract price, damages, losses or additional compensation.
b. Each subcontract shall require that any claims by subcontractor for delay or additional cost must be submitted
to Construction Manager within the time and in the manner in which the Construction Manager must submit
such claims to the Owner, and that failure to comply with the conditions for giving notice and submitting claims
shall result in the waiver of such claims.
5.4 Responsibilities for Acts and Omissions - The Construction Manager shall be responsible to the Owner for the acts and
omissions of his employees and agents and his subcontractors, their agents and employees, and all other persons
performing any of the work or supplying materials under a contract to the Construction Manager.
5.5 Subcontracts to be provided. The Construction Manager shall include a copy of each subcontract, including the general
supplementary conditions, in the project manual.
ARTICLE 6
SCHEDULE, TIME OF COMMENCEMENT AND SUBSTANTIAL COMPLETION
6.1 At the time a Guaranteed Maximum Price (GMP) is established, as provided for in Article 7, a project substantial
completion date, a project fmal completion date and an Owner Occupancy date for completion of the project in
accordance with the master project schedule, shall also be established by the Construction Team. The Construction
Manager agrees to complete the construction in accordance with the agreed upon substantial completion date, fmal
completion date and Owner Occupancy date. The Construction Manager acknowledges that failure to complete the
project within the construction time set forth in the approved schedule may result in substantial damages to the Owner,
for all of which damages the Construction Manager shall be liable.
6.2 The date of Owner Occupancy shall occur as described in Article 2.4(12) hereinabove. Warranties called for by this
Agreement or by the Drawings and Specifications shall commence on the Date of Owner Occupancy of the project.
ARTICLE 7
GUARANTEED MAXIMUM PRICE FOR CONSTRUCTION
7.1 When the Design Development Documents are sufficiently complete to establish the scope of work for the project or
any portion thereof, as generally defined by a design document listing to be provided by the Architect -Engineer and
Construction Manager upon execution of this Agreement, which is to be used only as a guide in developing the
specifications and plan data necessary to establish a Guaranteed Maximum Price, or at such time thereafter designated
by the Owner, the Construction Manager will establish and submit in writing to the Owner for his approval a
Guaranteed Maximum Price, guaranteeing the maximum price to the Owner, for the construction cost of the project or
designated part thereof. If the parties fail to agree on the GMP, either party may terminate this Agreement and shall
have no further liability. Such Guaranteed Maximum Price will be subject to modification for changes in the project as
provided in Article 10. However, the actual price paid for the work by the Owner shall be the actual cost of all work
subcontracts, supply contracts, direct labor costs, direct supervision costs, and direct job costs as defined under Article
9, plus the Construction Manager's fees or the GMP, whichever is less when the work is complete.
7.2 The GMP will only include those taxes in the cost of the project which are legally enacted at the time the GMP is
established.
7.3 When the project is bid and 100% of the Trade Contracts have been executed, the contingency within the GMP shall be
decreased in proportion to the percent of the work completed. In other words, if 10% of the work has been completed
and the Owner requests that the contingency within the GMP be adjusted, then 10% of the contingency within the GMP
will be removed from the GMP by change order.
7.4 At the time of submission of a Guaranteed Maximum Price, the Construction Manager will verify the time schedule for
activities and work which were adopted by the Construction Team and used to determine the Construction Manager
cost of work. In addition to the cost of work, a GMP will include an agreed upon sum e construction contingent)
which is included for the purpose of defraying the expenses due to unforeseen circu to es relating to construction.
The Construction Manager will be required to furnish documentation evidenc g e penditures charged to this
contingency prior to the release of funds by the Owner. Documentation for use of a Co tingency shall be determined
16
by the Construction Team, included in the Project Manual and displayed monthly in the PMIS. The Architect -Engineer
shall verify the actual costs. If bids are received below the applicable line items in the GMP, the surplus will be added
to the contingency.
If bids are received above the applicable line item in the GMP the deficiency will be taken from the contingency,
however such events shall not be cause to increase the GMP.
If bids are not received for a portion of the work at or below the applicable line item amount in the GMP, the
Construction Manager reserves the right to perform that portion of the work as acknowledged by the Owner or
negotiate for its performance for the specified line item lump sum amount or less.
ARTICLE 8
CONSTRUCTION MANAGER'S FEE
8.1 In consideration of the performance of the contract, the Owner agrees to pay the Construction Manager as
compensation for his services, fees as set forth in Subparagraphs 8.1.1, 8.1.2 and 8.1.3.
8.1.1 Preconstruction Phase Fee - For the performance of the services set forth under paragraphs 2.1.3(1), 2.1.4(a)(b)(c)(d),
2.3(1) and 2.3(2) and for profit and overhead related to these services, a total fee of $113,190.00. The Preconstruction
Phase Fee shall be paid in 7 monthly payments of $14.148.00 each and a final monthly payment of $14,154.00 at
completion of Preconstruction Phase Services. The first monthly payment shall become due thirty days following the
issuance of Notice -To -Proceed with the Preconstruction Phase Services.
The Construction Manager's personnel to be assigned during this phase and their duties and responsibilities to this
project and the duration of their assignments is shown on Exhibit G.
8.1.2 Construction Phase Fee - Prior to commencement of the Construction Phase, the Owner will direct the Construction
Manager in writing to proceed into the Construction Phase. The Construction Manager's compensation for work or
services performed during the Construction Phase shall be a fee of $* . (However, the Owner retains the right to
review the need and effectiveness of any employee or employees assigned by the Construction Manager, should the
Project Director question the need for the employee or employees). The Construction Phase Fee shall be invoiced and
paid in * monthly payments of $* each and one final monthly payment of $*. The first monthly payment shall become
due thirty days following the issuance of the first Construction Authorization by the Project Director and the final
monthly payment shall be paid only when construction of the project is finally completed and occupancy of the project
accepted by the Owner. If construction is authorized only for a part of the project, the fee paid shall be proportionate to
the amount of work authorized by the Owner.
(1) Adjustments in Fee - For changes in the project as provided in Article 10, the construction phase fee shall be
adjusted as follows:
(a) The Construction Manager shall be paid an additional fee subject to negotiation if the Construction
Manager is placed in charge of reconstruction of an insured or uninsured loss excluding any condition
that may have been caused from negligent acts by the Construction Manager.
(b) Should the duration of the construction stipulated herein for Final Completion extend beyond * months
after the Notice -To -Proceed, receipt of final drawings and specifications, or receipt of all necessary
permits, whichever is later, due to no fault of the Construction Manager, the Construction Manager's
Additional Construction Phase Fee will be $* per working day, for each day or portion thereof. The
Construction Manager's staff during such time extensions shall be that shown in Exhibit H.
(c) The Construction Manager will not be due any additional Overhead and Profit on increases in the
Guaranteed Maximum Price (GMP) that do not exceed $*. Should the GMP be increased by more than
$* under the terms of Article 10 hereinafter due to no fault of the Construction Manager, the Construction
Manager's additional Overhead and Profit for the Construction Phase will be *% of that portion of the
accumulative increases in the GMP that exceed the GMP by more than $*, and will be paid by the Owner
as a one time payment for each increase.
Construction Manager's Exclusive Remedy: In the event the construction Substantial or Final Completion
date is extended, regardless of whether delay is caused by any act or neglect of the Owner or the
Architect -Engineer, or is attributable to the Owner or the Architect -Engineer, the Construction Manager's
sole and exclusive remedy is an extension of the construction completion date and payment of additional
Construction Phase fees and Overhead and Profit for Construction Phase as proud above.
*Not Applicable at this time.
17
(2) Costs and Expenses Included in Fee - The following are included in the Construction Manager's fee for services
during the Construction Phase:
(a) Salaries or other compensation of the Construction Manager's employees at his principal office anc'
branch offices.
The Construction Manager's personnel to be assigned during the construction phase, their duties and
responsibilities to this project and the duration of their assignments are shown on Exhibits I and J.
(b) General operating expenses related to this project of the Construction Manager's principal and branch
offices.
(c) The costs of all data processing staff.
(d) Salaries or other compensation of the Construction Manager's employees at the job site. The Construction
Manager's personnel to be assigned to the site during the Construction Phase under the job site
management and supervision fee, their duties and responsibilities and the duration of their assignment are
shown on Exhibit J.
(e) General operating expenses incurred in the management and supervision of the project, except as
expressly included in Article 9.
(f) Those services set forth in Article 2.4(9)(a).
(g) Job office supplies - includes paper, pencils, paper clips, file folders, staples, etc., and janitorial supplies
(photo copy or blue print paper not included).
(h) Relocation expenses for Construction Manager's personnel.
(i) Direct tax saving purchase program.
8.1.3 Overhead And Profit For Construction Phase - For overhead, profit and general expenses of any kind, except as may be
expressly included in Article 9, for services provided during and related to the construction phase, the fee shall be $
and shall be paid proportionally to the ratio of the cost of the work in place, excluding stored materials and less
retainage (see Article 12.1), as it bears on the latest estimate of the total construction cost or to the GMP or to the
Owner's Construction Budget, whichever is less. The balance of the fee shall be paid when construction of the project
is finally completed and occupancy of the project accepted by the Owner. If construction is authorized only for a part
of the project, the fee paid shall be proportionate to the amount of work authorized by the Owner. The Construction
Manager's exclusive remedy for any adjustments in the Overhead and Profit for Construction Phase fee is provided in
Article 8.1.2(1).
ARTICLE 9
COST OF THE PROJECT
9.1 Defmition - The term Cost of the Project shall mean costs necessarily incurred in the Project during the Construction
Phase for Construction services and paid by the Construction Manager which are not included in Article 8. Such costs
shall include the items set forth below in this Article.
The Owner agrees to pay the Construction Manager for the Cost of the Project as defined in Article 9. Such payment
shall be in addition to the Construction Manager's fees stipulated in Article 8.
9.2 Direct Cost Items
(1) Wages paid for labor (as opposed to wages paid to management or supervisory personnel) in the direct employ
of the Construction Manager in the performance of his work under Agreement, times a multiple of 1.45% to
cover fringe benefits.
(2) Cost of all materials, supplies and equipment incorporated in the Project, including costs of transportation and
storage thereof.
(3)
Payments due to subcontractors from the Construction Manager or made by the Construction Manager
subcontractors for their work performed pursuant to contract under this Agreement.
*Not Applicable at this time.
18
(4) Cost including transportation and maintenance of all materials, supplies, equipment, temporary facilities and
hand tools not owned by the workmen, which are employed or consumed in the performance of the work, cost
on such items used but not consumed which may be turned over to the Owner at the end of the project and cost
less salvage value on such items used but not consumed which remain the property of the Construction Manager.
For those items to be turned over to the Owner at the end of the project, Article 2.3(6) shall apply.
(5) Rental charges on all necessary machinery and equipment, exclusive of hand.tools used at the site of the Project,
whether rented from the Construction Manager or other, including installation, repairs and replacements,
dismantling, removal, costs of lubrication, transportation and delivery costs thereof, which are used in the
support of a sub -contractor or the Construction Manager's own forces in the performance of the work, at rental
charges consistent with those prevailing in the area.
(6) Cost of the premiums for all insurance and cost of premiums for all bonds which the Construction Manager is
required to procure by this Agreement specifically for the construction project. This includes any sub -contractor
bonds the Construction Manager deems appropriate.
(7) Sales, use, gross receipts or similar taxes related to allowable direct costs of the Project imposed by any
governmental authority, and for which the Construction Manager is liable.
(8) The cost of corrective work subject, however, to the GMP and except for any corrective work made necessary
because of defective workmanship or other causes contributed to by the Construction Manager or his
subcontractors or suppliers.
No costs shall be paid by the Owner to the Construction Manager for any expenses made necessary to correct
defective workmanship or to correct any work not in conformance with the Plans and Specifications or to correct
any deficiency or damage caused by negligent acts by the Construction Manager.
(9) Minor expenses at the site, such as telegrams, long distance telephone calls, telephone service, expressage,
postage, and similar petty cash items in connection with the Project to be billed at cost.
(10) Costs for trash and debris control and removal from the site.
(11) Cost incurred due to an emergency affecting the safety of persons and property.
(12) Legal costs reasonably and properly resulting from prosecution of the Project for the Owner, including handling
claims for changes by Subcontractors and Vendors, subject to the following limitations:
(a) The Owner approved incurring such costs in advance, which approval shall not be unreasonably denied; and
(b) The legal costs were not incurred as result of the Construction Manager's own negligence or default.
This paragraph does not provide for payment of legal costs incurred in preparing or asserting claim or requests,
by Construction Manager itself, for change orders or in enforcing the obligations of this contract.
(13) All costs directly incurred in the performance of the Project for the benefit of the Project and not included in the
Construction Manager's fees as set forth in Article 8.
(14) If requested by the Owner, the Construction Manager will perform all or a portion of any item in Article 9 for
the cost of the work.
(15) If approved by the Owner, the Construction Manager, when qualified, may perform all or a portion of the work
for any item listed on the estimate or GMP breakdown where it is deemed advantageous due to schedule or
economic benefit for the direct cost of the work.
(16) Transportation greater than 100 miles from the site for those personnel employed directly for the project, not
including relocation expenses. Such transportation must be approved in advance by the Owner, and may be in
accordance with the Construction Manager's standard personnel policy but not exceeding the limits established
by Florida Statutes 112.061.
(17) Costs of all reproductions used for bidding or information purposes required by the project to directly benefit the
project.
(18) Costs for watchman and security services for the project.
(19) Costs for efficient logistical control of the site, including horizont 1 and vertic 1 transportation of materials and
19
personnel. Also, costs for adequate storage and parking space.
(20) Costs for such temporary facilities during construction, as approved by the Owner, including temporary water,
heat, power, sanitary facilities, telephones, radios and computers with software.
(21) Costs for any job site items not referenced herein, not normally provided by the subcontractors, which will be
provided by the Construction Manager as required to complete the work.
(22) Cost of utilizing a computer aided design and drafting application (CADD) for record drawings as described in
Article 2.4(10)(k). Upon completion of the work, the Construction Manager shall obtain two (2) sets of disk
files from the Architect -Engineer and record to scale all as -built conditions. The disk shall be submitted to the
Architect -Engineer when completed, together with two sets of blue line or black line prints for certification and
forwarding to the Client Agency, at the time of fmal completion.
ARTICLE 10
CHANGE IN THE PROJECT
10.1 Change Orders - The Owner, without invalidating this Agreement, may order Changes in the Project within the general
scope of this Agreement consisting of additions, deletions or other revisions, the GMP, and the Construction
Completion Date, being adjusted accordingly. All changes in the Project not covered by an authorized contingency
shall be authorized by Change Order signed by the Owner before the change is implemented.
10.1.1 A Change Order is a written order to the Construction Manager signed by the Owner issued after the execution of this
Agreement, authorizing a Change in the Project, the Construction Manager's fee, or the Construction Completion date.
Each adjustment in the GMP resulting from a change order shall clearly separate the amount attributable to the Cost of
the Project.
10.1.2 The increase or decrease in the Guaranteed Maximum Price resulting from a change in the Project shall be determined
in one or more of the following ways:
(1) by mutual acceptance of a lump sum properly itemized and supported by sufficient substantiating data to permit
evaluation by the Architect -Engineer and Owner;
(2) by unit prices stated in the Agreement or subsequently agreed upon;
(3) by cost as defined in Article 9 and a mutually acceptable fixed or percentage fee; or
(4) by the method provided in Subparagraph 10.1.3.
10.1.3 If none of the methods set forth in Clause 10.1.2 is agreed upon, the Construction Manager, provided he receives a
written order signed by the Owner, shall promptly proceed with the Work involved. The cost of such Work shall then
be determined on the basis of the reasonable expenditures and savings of those performing the Work attributed to the
change. However, in the event a Change Order is issued under these conditions, the Architect -Engineer will establish
an estimated cost of the work and the Construction Manager shall not perform any work whose cost exceeds that
estimate without prior written approval by the Owner. In such case, and also under Article 10.1.2 above, the
Construction Manager shall keep and present, in such form as the Owner may prescribe, an itemized accounting
together with appropriate supporting data of the increase in the Cost of the Project as outlined in Article 9. The amount
of decrease in the Guaranteed Maximum Price to be allowed by the Construction Manager to the Owner for any
deletion or change which results in a net decrease in cost will be the amount of the actual net decrease.
10.1.4 If unit prices are stated in the Agreement or subsequently agreed upon, and if the quantities originally contemplated are
so changed in a proposed Change Order that application of the agreed unit prices to the quantities of Work proposed
will cause substantial inequity to the Owner or the Construction Manager, the applicable unit prices and Guaranteed
Maximum Price shall be equitably adjusted.
10.1.5 Should concealed conditions encountered in the performance of the Work below the surface of the ground or should
concealed or unknown conditions in an existing structure be at variance with the conditions indicated by the Drawings,
Specifications, or Owner furnished information or should unknown physical conditions below the surface of the ground
or should concealed or unknown conditions in an existing structure of an unusual nature, differing materially from
those ordinarily encountered and generally recognized as inherent in work of the character provided for in this
Agreement, be encountered, the Guaranteed Maximum Price and the Construction Completion date shall be equitab'
adjusted by Change Order upon a request for Change Order in accordance with le 10.2.
20
10.2 Claims For Additional Cost Or Time
All claims for additional cost or time shall be made by request for a change order submitted as provided in Article 16.
If the Construction Manager is delayed at any time in the progress of the work by any act or neglect of the Owner or
the Architect or of any employee of either or by any separate Construction Manager employed by the Owner or by any
changes ordered in the work by labor disputes, fire, or unusual delay in transportation, unavoidable casualties or any
causes beyond the Construction Manager's control or by delay authorized by the owner pending resolution of disputes,
and such delay extends the completion date, the Substantial Completion shall be extended by Change Order for such
reasonable time as the Construction Team may determine.
Only delays which are determined to extend the critical path for the schedule for constructing the project will result in a
time extension. Neither the Owner nor the Construction Manager shall be considered to own the schedule float time.
10.3 Minor Changes In The Project
The Architect -Engineer will have authority to order minor changes in the Project not involving an adjustment in the
Guaranteed Maximum Price or an extension of the Construction Completion Date and not inconsistent with the intent
of the Drawings and Specifications. Such changes shall be effected by written order. Documentation of changes shall
be determined by the Construction Team, included in the Project Manual and displayed monthly in the PMIS. Changes
shall be approved by the Project Director, Architect -Engineer.
10.4 Emergencies
In any emergency affecting the safety of persons or property, the Construction Manager shall act at his discretion, to
prevent threatened damage, injury or loss. Any increase in the Guaranteed Maximum Price or extension of time
claimed by the Construction Manager on account of emergency work shall be determined as provided in Article 10.
ARTICLE 11
DISCOUNTS AND PENALTIES
' 1.1
All discounts for prompt payment shall accrue to the Owner to the extent the Cost of the project is paid directly by the
Owner or from a fund made available by the Owner to the Construction Manager for such payments. To the extent the
Cost of the Project is paid with funds of the Construction Manager, all cash discounts shall accrue to the Construction
Manager. All trade discounts, rebates and refunds, and all returns from sale of surplus materials and equipment, shall
be credited to the Cost of the Project. All penalties incurred due to fault of the Construction Manager for late payment
of cost of the project will be paid by the Construction Manager.
ARTICLE 12
PAYMENTS TO THE CONSTRUCTION MANAGER
12.1 Monthly Statements - The Construction Manager shall submit to the Owner a statement, sworn to if required, along
with the cost reports required under Article 2.1.5, showing in detail all monies paid out, cost accumulated or costs
incurred on account of the Cost of the Project during the previous period and the amount of the Construction Manager's
fees due as provided in Article 8. This data shall be attached to the Partial Pay Request form shown in Exhibit K. Ten
percent (10%) retainage shall be held on all payments until the contract is fifty percent (50%) complete, except when
approved by the Owner certain suppliers and subcontractors may be paid the entire amount due when such payment is
generally the practice of the industry. At 50% completion, the Owner may approve a reduction of the retainage from
10% to 5% at his discretion. Retainage shall not be withheld on services or fees set forth in Article 8. Payments by the
Owner to the Construction Manager shall be made as described in Article 17.5 hereinafter.
12.2 Final Payment - Final payment constituting the unpaid balance of the Cost of the Project and the Construction
Manager's fee, shall be due and payable as described in Article 17.5 after the Owner has accepted occupancy of the
project, provided that the Project be then finally completed, that the Construction Manager has verified by his signature
that he has completed all items specified on the attached Exhibit L, and that this Agreement has been finally performed.
However, if there should remain work to be completed, the Construction Manager and the Architect -Engineer shall list
those items prior to receiving final payment and the Owner may retain a sum equal to 200% of the estimated cost of
completing any unfinished work and portion of the Construction Manager's retainage, provided that said unfmished
items are listed separately and the estimated cost of completing any unfinished items are likewise listed separately.
Thereafter, Owner shall pay to Construction Manager, monthly, the amount retained for each incomplete item after
each of said items is completed.
12.3 Payments to Subcontractors - The Construction Manager shall promptly, within 15 days after receipt of payment from
the Owner, pay all the amount due subcontractors less a retainage of ten perc t (10%) until the project is fifty percent
(50%) complete, and based on Construction Manager's evaluation of the f contractor's acceptable performance, the
21
Owner may approve a reduction in retainage from 10% to 5% thereafter. If there should remain items to be completed,
the Construction Manager and Architect -Engineer shall list those items required for completion and the Construction
Manager shall require the retainage of a sum equal to 200% of the estimated cost of completing any unfinished items,
provided that said unfmished items are listed separately and the estimated cost of completing any unfmished items
likewise listed separately. Thereafter, the Construction Manager shall pay to the subcontractors, monthly, the amoun
retained for each incomplete item after each of said items is completed. Before issuance of fmal payment without any
retainage, the subcontractor shall submit satisfactory evidence that all payrolls, material bills and other indebtedness
connected with the Project have been paid or otherwise satisfied, warranty information is complete, as -built markups
have been submitted and instruction for the Owner's operating and maintenance personnel is complete.
Final payment may be made to certain select subcontractors whose work is satisfactorily completed prior to the total
completion of the Project but only upon approval of the Owner.
12.4 Delayed Payments by Owner - If the Owner should fail to pay the Construction Manager within 30 days after the
receipt of an approvable payment request from the Construction Manager, then the Construction Manager may, upon
seven (7) additional days written notice to the Owner and the Architect -Engineer stop the Project until payment of the
Amount owing has been received.
12.5 Payments for Materials and Equipment - Payments will be made for material and equipment not incorporated in the
work but delivered and suitably stored at the site or another location subject to prior approval and acceptance by the
Owner on each occasion.
12.6 Withholding Payments To Subcontractors - The Construction Manager shall not withhold payments to subcontractors
if such payments have been made to the Construction Manager. Should this occur for any reason, the Construction
Manager shall immediately return such monies to the Owners, adjusting pay requests and project bookkeeping as
required.
ARTICLE 13
INSURANCE, INDEMNITY AND WAIVER OF SUBROGATION
13.1 Indemnity
(1) The Construction Manager agrees to indemnify and hold the Owner, Agent, and Architect -Engineer harmle:
from all claims for bodily injury and property damage (other than the work itself and other property insurer
under Paragraph 13.2(3)) that may arise from the Construction Manager's operations under this Agreement.
(2) The Owner shall cause any other Construction Manager who may have a contract with the Owner to perform
construction or installation work in the area where work will be performed under this Agreement, to agree to
indemnify the Owner, Agent, and the Construction Manager and hold them harmless from all claims for bodily
injury and property damage (other than property insured under Paragraph 13.2(3)) that may arise from the other
Construction Manager's operations, if any. Such provisions shall be in a form satisfactory to the Construction
Manager.
13.2 Construction Manager's Insurance
(1) The Construction Manager shall not commence any construction work in connection with this Agreement until
he has obtained all of the following types of insurance and such insurance has been approved by the Owner, nor
shall the Construction Manager allow any subcontractor to commence work on his subcontract until all similar
insurance required of the subcontractor has been so obtained and approved. All insurance policies shall be with
insurers qualified and doing business in Florida.
(2) Worker's Compensation Insurance - The Construction Manager shall take out and maintain during the life of this
Agreement Worker's Compensation Insurance for all his employees connected with the work of this Project and,
in case any work is sublet, the Construction Manager shall require the subcontractor similarly to provide
Worker's Compensation Insurance for all of the latter's employees unless such employees are covered by the
protection afforded by the Construction Manager. Such insurance shall comply with the Florida Worker's
Compensation Law. In case any class of employees engaged in hazardous work under this contract at the site of
the Project is not protected under the Worker's Compensation statute, the Construction Manager shall provide
adequate insurance, satisfactory to the Owner, for the protection of employees not otherwise protected.
Construction Manager's Public Liability and Property Damage Insurance -The Construction Manager shall ta'
out and maintain during the life of this Agreement Comprehensive General Liability and Comprehensi\
Automobile Liability Insurance as shall protect him from claims for damage for personal injury, including
accidental death, as well as claims for property damages which may arise from operating under this Agreement
whether such operations are by himself or by anyone directly or indirectly nployed by him, and the amount of
(3)
22
such insurance shall be minimum limits as follows:
(a) Construction Manager's Comprehensive General Liability $1,000,000 Each Occurrence,
Coverages, Bodily Injury & Property Damage Combined Single Limit
(b) Automobile Liability Coverages, $200,000 Each Occurrence,
Bodily Injury & Property Damage Combined Single Limit
(c) Excess Liability, Umbrella Form $4,000,000 Each Occurrence,
Combined Single Limit
Insurance clause for both BODILY INJURY AND PROPERTY DAMAGE shall be amended to provide
coverage on an occurrence basis.
(4) Subcontractor's Public Liability and Property Damage Insurance - The Construction Manager shall require each
of his subcontractors to procure and maintain during the life of this subcontract, insurance of the type specified
above or insure the activities of his subcontractors in his policy, as specified above.
(5) Owner's and Construction Manager's Protective Liability Insurance - The Construction Manager shall procure as
a cost of the project and furnish an Owner's and Construction Manager's Protective Liability Insurance Policy
with the following minimum limits:
(a) Bodily Injury Liability & $1,000,000 Each Occurrence
Property Damage Liability Combined Single Limit
(6) "XCU" (Explosion, Collapse, Underground Damage - The Construction Manager's Liability Policy shall provide
"XCU" coverage for those classifications in which they are excluded.
(7) Broad Form Property Damage Coverage, Products & Completed Operations Coverages -The Construction
Manager's Liability Policy shall include Broad Form Property Damage Coverage, Products and Completed
Operations Coverages.
(8) Contractual Liability Work Contracts - The Construction Manager's Liability Policy shall include Contractual
Liability Coverage designed to protect the Construction Manager for contractual liabilities assumed by the
Construction Manager in the performance of this Agreement.
(9) Indemnification Rider
(a) To cover to the fullest extent permitted by law, the Construction Manager shall indemnify and hold harmless
the Owner and the Architect -Engineer and their agents and employees from and against all claims, damages,
losses and expenses, including but not limited to attorney's fees, arising out of or resulting from the
performance of the Work, provided that any such claim, damage, loss or expense (1) is attributable to bodily -
injury, sickness, disease or death, or to injury to or destruction of tangible property (other than the Work
itself) including the loss of use resulting therefrom, and (2) is caused in whole or in part by any negligent act
or omission of the Construction Manager, any subcontractor, anyone directly or indirectly employed by any
of them or anyone for whose acts any of them may be liable, regardless of whether or not it is caused in part
by a party indemnified hereunder. Such obligation shall not be construed to negate, abridge, or otherwise
reduce any other right to obligation of indemnity which would otherwise exist as to any party or person
described in this Article.
(b) In any and all claims against the Owner or the Architect -Engineer or any of their agents or employees by
any employee of the Construction Manager, any subcontractor, anyone directly or indirectly employed by
any of them or anyone for whose acts any of them may be liable, the indemnification obligations under this
Paragraph shall not be limited in any way by any limitation on the amount or type of damages,
compensation or benefits payable by or for the Construction Manager or any subcontractor under workers'
or workmen's compensation acts, disability benefit acts or other employee benefit acts.
(c) The obligations of the Construction Manager under this Article 13.2(9) shall not extend to the liability of
Architect -Engineer, his agents or employees, arising out of (1) the preparation or approval of maps,
drawings, opinions, reports, surveys, change orders, designs or specifications, or (2) the giving of or the
failure to give directions or instruction by Architect -Engineer, his agents or employees providing such
giving or failure to give is the primary cause of the injury or damage.
(d) The Construction Manager hereby acknowledges receipt of ten doll s and other good and valuable
consideration from the Owner and acknowledges receipt of ten doll
and other good and valuable
23
consideration from the Architect -Engineer in exchange for giving the Owner and Architect -Engineer,
respectively, the indemnification provided above in Article 13.2(9).
(10) Builder's Risk Coverage - The Construction Manager shall take out and maintain during the life of thi'-
Agreement a "Builder's Risk Policy" completed value form as a cost of the Project, issued to provide coverage
on an "all risk" basis including theft. This coverage shall not be lapsed or cancelled because of partial
occupancy by the Owner prior to final acceptance of the Project.
(11) Certificate of Insurance - The Owner shall be furnished proof of coverage of Insurance as follows:
Certificate of Insurance form will be furnished to the Owner along with the Contract Documents. These shall be
completed and signed by the authorized Florida Resident Agent, and returned to the office of Building
Construction. This Certificate shall be dated and show:
(a) The name of the insured Construction Manager, the specific job by name and job number, the name of the
insurer, the number of the policy, its effective date, and its termination date.
(b) Statement that the Insurer will mail notice to the Owner and a copy to the Architect -Engineer at least fifteen
(15) days prior to any material changes in provisions or cancellation of the policy.
(c) Certificate of Insurance shall be in the form as approved by Insurance Standards Office (ISO) and such
Certificate shall clearly state all the coverages required in this Section commencing at 13.2 and ending with
13.3.4.
(d) Certificate of Insurance shall state that the Owner and Agent are listed as additional insured on all
appropriate policies.
13.3 Waiver of Subrogation
13.3.1 The Owner and the Construction Manager waive all rights against each other, for damages caused by perils covered by
insurance provided under Article 13.2 to the extent covered by such insurance except such rights as they may have to
the proceeds of such insurance held by the Owner and Construction Manager as trustees. The Construction Manager
shall require similar waivers from all subcontractors and their sub -subcontractors.
13.3.2 The Owner and Construction Manager waive all rights against each other for loss or damage to any equipment used in
connection with the Project and covered by any property insurance. The Construction Manager shall require similar
waivers from all subcontractors and their sub -subcontractors.
13.3.3 The Owner waives subrogation against the Construction Manager on all property and consequential loss policies
carried by the Owner on adjacent properties and under property and consequential loss policies purchased for the
Project after its completion.
13.3.4 If the policies of insurance referred to in this Article require an endorsement to provide for continued coverage where
there is a waiver of subrogation, the Owner of such policies will cause them to be so endorsed, failure to obtain proper
endorsement nullifies the waiver of subrogation.
ARTICLE 14
TERMINATION OF THE AGREEMENT AND OWNER'S RIGHT TO PERFORM CONSTRUCTION MANAGER'S
OBLIGATION
14.1 Termination by the Construction Manager - If the Project is stopped for a period of thirty (30) days under an order of
any court or other public authority having jurisdiction or as a result of an act of government, such as a declaration of a
national emergency making materials unavailable, through no act or fault of the Construction Manager, or if the Project
should be stopped for a period of sixty (60) days by the Construction Manager, for the Owner's failure to make
payments thereon, then the Construction Manager may, upon seven days written notice to the Owner, request payment
for all work executed, the Construction Manager's fees earned to date, and for any proven loss sustained upon any
materials, equipment, tools, construction equipment, and machinery including reasonable profit, damages and terminal
expenses incurred by the Construction Manager.
14.2 Owner's Right to Perform Construction Manager's Obligations and Termination by Owner for Cause.
(1)
If the Construction Manager fails to perform any of his obligations under this Agreement including an.
obligation he assumes to perform work with his own forces, the Owner may, after seven (7) days written notice
during which period the Construction Manager fails to commence correction of su • obligation, make good such
deficiencies. The GMP, or the actual cost of the Project, whichever is less, s • 1 •e reduced by the cost to the
24
Owner of making good such deficiencies and the Construction Manager's Construction Phase Fee shall be
reduced by an amount required to manage the making good of such deficiencies.
(2) If the Construction Manager is adjudged a bankrupt, or if he makes a general assignment for the benefit of his
creditors, or if a receiver is appointed on account of his insolvency, or if he persistently or repeatedly refuses or
fails, except in case for which extension of time is provided, to supply enough properly skilled workmen or
proper materials and fails to maintain an established schedule (failure to maintain schedule shall be defined as
any activity on the critical path that falls 45 days or more behind schedule) which has been adopted by the
Construction Team, or if he fails to make prompt payment to subcontractors for materials or labor, or
persistently disregards laws, rules, ordinances, regulations, or orders of any public authority having jurisdiction,
or otherwise is guilty of a substantial violation of a provision of the Agreement, then the Owner may, without
prejudice to any right or remedy and after giving the Construction Manager and his surety, if any, seven (7) days
written notice, during which period Construction Manager fails to commence correction of the violation,
terminate the employment of the Construction Manager and take possession of the site and of all materials,
equipment, tools, construction equipment and machinery thereon owned by the Construction Manager, and may
finish the Project by whatever method he may deem expedient. In such case, the Construction Manager shall not
be entitled to receive any further payment until the Project is finished nor shall he be relieved from his
obligations assumed under Article 7. Reasonable terminal expenses incurred by the Owner may be deducted
from any payments left owing the Construction Manager (excluding monies owed the Construction Manager for
subcontract work).
(3)
If the Construction Manager refuses to allow public access to all documents, papers, letters, or other material
subject to the provisions of Chapter 119, Florida Statutes, and made or received by the Construction Manager in
conjunction with this Agreement, then the Owner may, without prejudice to any right or remedy and after giving
the Construction Manager and his surety, if any, seven (7) days written notice, during which period Construction
Manager still fails to allow access, terminate the employment of the Construction Manager and take possession
of the site and of all materials, equipment, tools, construction equipment and machinery thereon, owned by the
Construction Manager, and may finish the project by whatever method he may deem expedient. In such case,
the Construction Manager shall not be entitled to receive any further payment until the Project is finished nor
shall he be relieved from his obligations assumed under Article 7. Reasonable terminal expenses incurred by the
Owner may be deducted from any payments left owing the Construction Manager (excluding monies owed the
Construction Manager for subcontract work).
14.3 Termination by Owner Without Cause
(1) If the Owner terminates this Agreement other than pursuant to Article 14.2(2) or Article 14.2(3), he shall
reimburse the Construction Manager for any unpaid Cost of the Project due him under Article 9, plus that part of
the unpaid balance of the Construction Phase Fee in an amount as will increase the payment on account of his
fee to a sum which bears the same ratio to the Construction Phase Fee as the Cost of the Project at the time of
termination bears to the Guaranteed Maximum Price, if established, otherwise to the Owner's Construction
Budget. The Owner shall also pay to the Construction Manager fair compensation, either by purchase or rental
at the election of the Owner, for any equipment retained. In case of such termination of Agreement the Owner
shall further assume and become liable for obligations, commitments and unsettled contractual claims that the
Construction Manager has previously undertaken or incurred in good faith in connection with said Project. The
Construction Manager shall, as a condition of receiving the payments referred to in this Article 14, execute and
deliver all such papers and take all such steps including the legal assignment of his contractual rights, as the
Owner may require for the purpose of fully vesting in him the rights and benefits of the Construction Manager
under such obligations or commitments.
(2) After the establishment of the Guaranteed Maximum Price or at the completion of the Preconstruction Phase, if
the final cost estimates or lack of legislative funding make the Project no longer feasible from the standpoint of
the Owner, the Owner may terminate this Agreement and pay the Construction Manager his proportionate fee
due in accordance with Article 8.1.1 plus any costs incurred pursuant to Articles 9 and 10.
ARTICLE 15
ASSIGNMENT AND GOVERNING LAW
15.1 Neither the Owner nor the Construction Manager shall assign his interest in this Agreement without the written consent
of the other except as to the assignment of proceeds.
15.2 This Agreement shall be governed by the Laws of the State of Florida.
15.3 Venue for any litigation hereunder shall be in Miami, Dade County, Florida.
25
ARTICLE 16
NOTICE OF CLAIM: WAIVER OF REMEDIES; NO DAMAGES FOR DELAY
16.1 The Owner's liability to Construction Manager for any claims arising out of or related to the subject matter of thin
contract, whether in contract or tort, including, but not limited to, claims for extension of construction time, fo,
payment by the Owner of the costs, damages or losses because of changed conditions under which the work is to be
performed, or for additional work, shall be governed by the following provisions:
(a) All claims must be submitted as a Request for Change Order in the manner as provided herein;
(b) The Construction Manager must submit a Notice of Claim to Owner and to the Architect -Engineer within 20
days of when the Construction Manager was or should have been aware of the occurrence of the event giving
rise to the claim; and
(c) Within 10 days of submitting its Notice of Claim, the Construction Manager shall submit to the Owner its
Request for Change Order, which shall include a written statement of all details of the claim, including a
description of the work affected.
The Construction Manager agrees that the Owner shall not be liable for any claim that the Construction Manager
fails to submit as a Request for Change Order as provided in this paragraph.
16.2 After receipt of a Request for Change Order, the Owner, in consultation with the Architect -Engineer, shall deliver to
the Construction Manager its written determination of the claim
16.3 For work the Construction Manager performs with its own forces, and in addition to the adjustments provided for in
Article 8, the Construction Manager's exclusive remedy for delays in performance of the construction caused by events
beyond its control, including delays claimed to be caused by or attributable to the Owner or the Architect -Engineer,
including claims based on breach of contract or negligence, shall be a claim submitted in compliance with 16.1 above,
for an extension of the scheduled construction time. In the event of a change in such work, the Construction Manager's
claim for adjustments in the contract sum are limited exclusively to its actual costs for such changes plus 4.50% for
overhead and profit. The Construction Manager expressly agrees that the foregoing constitute its sole and exclusive
remedies for delays and changes in such work, and eliminate any other remedies for claim for increase in the contract
price, delays, changes in the work, damages, losses or additional compensation.
ARTICLE 17
MISCELLANEOUS
17.1 Harmony - Construction Manager is advised and hereby agrees that he will exert every reasonable and diligent effort to
assure that all labor employed by Construction Manager and his Subcontractors for work on the project shall work in
harmony with and be compatible ,with all other labor being used by building and construction Construction Managers
now or hereafter on the site of the project.
Construction Manager further agrees that this provision will be included in all subcontracts of the Subcontractors as
well as the Construction Manager's own contract; provided, however, that this provision shall not be interpreted or
enforced so as to deny or abridge, on account of membership or non -membership in any labor union or labor
organization, the right of any person to work as guaranteed by Article 1, Section 6 of the Florida Constitution.
17.2 Apprentices - If the Construction Manager employs apprentices on the project, the behavior of the Construction
Manager and the Owner shall be governed by the provisions of Chapter 446, Florida Statutes, and by applicable
standards and policies governing apprentice programs and agreements established by the Division of Labor of the State
of Florida Department of Labor and Employment Security. The Construction Manager will include a provision similar
to the foregoing sentence in each subcontract.
17.3 Invoices - Invoices shall be submitted in detail sufficient for a proper preaudit and postaudit thereof. Invoices for any
travel expenses shall be submitted in accordance with procedures specified in Section 112.061 of the Florida Statutes
governing payments by the State for travel expenses.
17.4 Construction Manager's Project Records - The Construction Manager's Project Records shall be maintained as
prescribed hereinabove in accordance with the State of Florida General Records Schedule for State Agencies A-1 and
shall be made available to the Owner or his authorized representative at mutually convenient times.
17.5 Payments — Payments shall be mad in accordance with the Florida Prompt Payment Act..
17.6 Public Entity Crime Information Statement - "A person or affiliate who has been placed on the convicted vendor list
following a conviction for a public entity crime may not submit a bid on a contract to provide any goods or services to
26
a public entity, may not submit a bid on a contract with a public entity for the construction or repair of a public building
or public work, may not submit bids on leases of real property to a public entity, may not be awarded or perform work
as a Construction Manager, supplier, subcontractor, or consultant under a contract with any public entity, and may not
transact business with any public entity in excess of the threshold amount provided in Section 287.017, for
CATEGORY TWO for a period of 36 months from the date of being placed on the convicted vendor list."
17.7 Unauthorized Aliens - The Department shall consider the employment by any Construction Manager of unauthorized
aliens a violation of section 274A(e) of the Immigration and Nationalization Act. Such violation shall be cause for
unilateral cancellation of this contract.
17.8 Electronic Mail Capabilities - The Construction Manager must have electronic mail capabilities through the World
Wide Web. It is the intention of the Department of Management Services to use electronic communication for all
projects whenever possible. The Construction Manager shall provide their electronic mail address and the name of a
contact person responsible for their electronic communications.
•
27
Attest:
IN WITNESS WHEREOF, the parties hereto have executed this Agreement the day and year first written above.
JAMES A. CUMMINGS, INC.
APPROVED:
By ettlYv-v0 _ By
Pamela Kalis, Corporate Secretary
As Witnessed:
u ings, Corporate ' - sident
By �/ z?ij (Corporate Seal)
As Witnessed:
By
DEPARTMENT OF MANAGEMENT SERVICES
APPROVED:
By
H. ' . Hough,
Contracts Administrator,
Building Construction,
Department of Management Services
Approved As To Form And Legality:
By AV IfOffice of General l,
Department of Ma ent Services
VILLAGE OF KEY BISCAYNE
Attest: PPROVED:
illage Clerk
(SEAL)
Approved As To Form And Legality:
By
Vill Attorney
Samuel Kissin
illage Manager
29
EXHIBIT A
CONSTRUCTION TEAM ASSIGNED REPRESENTATIVES
Owner
Ralph Martinez
Tom Berley
H.R. Hough
Harold Barrand
Deborah Whitehouse
Client
C. Samuel Kissinger
Architect -Engineer — Spillis Candella
Paul Reinarman
R, Sixto
L. Klein
L. Valle
J. Bauza
J. Clark
R. Lage
Project Director
Manager, Central Florida Project Development Section
Contracts Administrator
FCO Projects Manager
Director
Village Manager
Project Principal
Project Manager
Senior Design Architect
Mechanical Engineering Inspector
Electrical Engineering Inspector
Structural Engineering Inspector
Civil Engineer
Architect -Engineer — Robert G. Currie and Associates
Robert G. Currie
Architect -Engineer — OBM Miami, Inc.
Raul Lastra
Construction Manager
James A. Cummings
William R. Derrer
Gerry Zengel
Michael F. Lanciault
Scott W. Pate
Alan Rosenblum
John Monahan
George Gwiazdowski
Jim Daniels
TBD*
TBD*
Project Principal
Project Principal
President
Vice President of Operations
Operations Manager
V.P. Estimating
Chief Estimator
Senior Estimator
Project Manager
General Superintendent
General Superintendent
Project Engineer
Project Secretary
EXHIBIT B
OWNER'S CONSTRUCTION BUDGET
ITEM DESCRIPTION CONSTRUCTION BUDGET
CONSTRUCTION MANAGER'S PRECONSTRUCTION PHASE FEE $113,190.00
CONSTRUCTION MANAGER'S CONSTRUCTION PHASE FEE *
CONSTRUCTION MANAGER'S OVERHEAD & PROFIT *
CONSTRUCTION BUDGET BALANCE *
OWNER'S TOTAL CONSTRUCTION BUDGET $113,190.00
*To Be Determined at a Later Date.
EXHIBIT C
CONSTRUCTION MANAGERS'S PERSONNEL
OFF -SITE SUPPORT STAFF
Individual
William R. Derrer
Gerry Zengel
Michael F. Lanciault
Scott W. Pate
Alan Rosenblum
Individual
John Monahan
George Gwiazdowski
Jim Daniels
TBD*
TBD*
*To Be Determined at a Later Date
Title
Vice President of Operations
Operations Manger
V.P. Estimating
Chief Estimator
Senior Estimator
ON -SITE SUPPORT STAFF
Title
Project Manager
General Superintendent
General Superintendent
Project Engineer
Project Secretary
EXHIBIT D
STATE OF FLORIDA Distribution to:
Administrator of Client Agency
Development
DEPARTMENT OF
MANAGEMENT SERVICES
Project Director
Architect/Engineer
CM
ARCHITECT/ENGINEER'S CERTIFICATE OF SUBSTANTIAL COMPLETION
PROJECT NUMBER: ARCHITECT/ENGINEER:
PROJECT:
OWNER:
Department of Management Services
Building Construction
CONSTRUCTION MANAGER
ATTN: CONTRACT FOR:
DATE OF ISSUANCE:
ROJECT OR DESIGNATED PORTION SHALL INCLUDE:
CONTRACT DATE:
The work performed under this Contract has been reviewed and found to be substantially complete. The Date of Substantial Completion of the Project or portion
thereof designated above is hereby established as which is also the date of commencement of
applicable warranties required by the Contract Documents, except as stated below.
DEFINITION OF DATE OF SUBSTANTIAL COMPLETION
The Date of Substantial Completion of the Work or designated portion thereof is the Date certified by the Architect -Engineer when construction is sufficiently
complete, in accordance with the Contract Documents, so the Owner can occupy or utilize the Work or designated portion thereof for the use for which it is
intended as expressed in the Contract Documents.
A list of items to be completed or corrected is attached hereto. The failure to include any items on such list does not alter the responsibility of the Construction
Manager to complete all Work in accordance with the Contract Documents. The date of commencement of warranties for items on the attached list will be the
date of final payment unless otherwise agreed to in writing.
ARCHITECT/ENGINEER
BY: DATE
The Owner accepts the Work or designated portion thereof as substantially complete.
Department of Management Services
Building Construction
BY: DATE
fhe Construction Manager will complete or correct the Work on the list of items attached hereto within the time prescribed in the contract from the above Date
of Substantial Completion.
CONSTRUCTION MANAGER BY:
33
DATE
EXHIBIT E
DEPARTMENT OF MANAGEMENT SERVICES
BUILDING CONSTRUCTION
CONSTRUCTION MANAGER'S AFFIDAVIT OF CONTRACT COMPLETION
AGENCY:
PROJECT: :
CONSTRUCTION MANAGER: :
CONTRACT FOR: :
CONTRACT DATE: : CONTRACT AMOUNT: :
CONSTRUCTION MANAGER'S AFFIDAVIT
I solemnly swear and affirm: That the work under the above named contract and all amendments thereto have been completed in
accordance with the requirements of said contract; that all costs incurred for equipment, materials, labor, and services against the
project have been paid; that no liens have been attached against the project; that no suits are pending by reason of work on the project
under the contract; that all Workmen's Compensation claims are covered by Workmen's Compensation insurance as required by law;
that all public liability claims are adequately covered by insurance, and that the Construction Manager shall save, protect, defend,
indemnify, and hold the Owners harmless from and against any and all claims which arise as a direct or indirect result of any
transaction, event or occurrence related to performance of the work contemplated under said contract.
CONSTRUCTION MANAGER:
(SEAL)
Title:
Date:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this (date) by (name of officer or agent, title of officer or agent) of (name
of Corporation acknowledging), a (state or place of incorporation) corporation, on behalf of the corporation. He/She is personally
known to me or has produced (type of identification) as identification.
(Signature of person taking acknowledgment)
(Name typed printed or stamped)
(Title or Vendor)
34
EXHIBIT E (CONT'D)
DEPARTMENT OF MANAGEMENT SERVICES
BUILDING CONSTRUCTION
CERTIFICATE OF CONTRACT COMPLETION
PROJECT NO
PROJECT TITLE
CONSTRUCTION MANAGER
CONTRACT DATE: DATE OF FINAL COMPLETION
CERTIFICATE OF ARCHITECT/ENGINEER
I CERTIFY: That the work under the above contract has been satisfactorily completed on the date set forth in accordance with the terms of the contract;
that the Construction Manager has submitted his sworn affidavit as evidence that he has paid all labor, materials and other charges against the project in
accordance with the terms of the contract.
A/E Firm Name: Date
By
TO BE COMPLETED BY ARCHITECT/ENGINEER
THROUGH THE SUBSTANTIAL COMPLETION PHASE
1. Notice to Proceed (N.T.P.)
2. Time Specified in Original Contract for
Substantial Completion (S.C.)
3. Extension Granted by Change Orders (Days Between
Original Contract S.C. and Final Contract S.C.)
4. Total Days Allowable to Substantial Completion
(Add Lines 2 and 3)
5. Project Substantially Completed as Certified by A/E
(Total Days from N.T.P. through Date certified by AB)
DATE DAYS
6. Substantial Completion Overrun (Subtract @$ Per Day=$
Line 4 from 5 and Enter Overrun)
THROUGH THE FINAL COMPLETION PHASE
1. Time Specified in Contract, Between Substantial
& Final Completion XXXXXX
2. Extensions Granted by Change Orders (Days
Between S.C. & Final Completion XXXXXX
3. Total Days Allowable Between Substantial & Final
Completion (Add Lines 1 & 2) XXXXXX
4. Date Actually Completed and Total Days Between Actual S.0
& Date Certified by A/E as Actually being Finally Completed.
5. Final Completion Overrun (Subtract Line 3 & 4 @$ Per Day=$
and Enter Overrun) XXXXXX
TOTAL LIQUIDATED DAMAGES $
TATE:
DATE:
Project Director
Project Development Manager
35
EXHIBIT F
BUILDING PERMIT APPLICATION
(USE VILLAGE OF KEY BISCAYNE PERMIT FORM)
L.,.,,--'-
36
EXHIBIT G
CONSTRUCTION MANAGER'S PERSONNEL TO BE
ASSIGNED DURING PRECONSTRUCTION PHASE
Individual
James A. Cummings
William R. Derrer
Gerry Zengel
Michael F. Lanciault
Scott W. Pate
Alan Rosenblum
Mark Cantrell
John Monahan
TBD*
George Gwiazdowski
Kim Soto
Pam Kalis
Chrissy Pollack
Maggie Ascanio
Title
President
Vice President of Operations
Operations Manager
V.P. Estimating
Chief Estimator
Senior Estimator
Estimator
Project Manager
Project Engineer
General Superintendent
Secretary Estimating
Chief Financial Officer
Accountant
Payroll
Duration
In Months
4
4
4
4
4
4
4
4
4
4
4
4
4
4
Percentage
of Time
Available
3%
5%
25%
20%
20%
20%
20%
20%
20%
20%
20%
10%
10%
10%
37
EXHIBIT H
CONSTRUCTION MANAGER'S PER DIEM STAFF FOR TIME
EXTENSIONS PER 8.1.2(1)(b)
Percentage
of Time
Individual Title Available
*
*To Be Determined at a Later Date
EXHIBIT I
CONSTRUCTION MANAGER'S PERSONNEL TO BE
ASSIGNED DURING CONSTRUCTION OFF -SITE
Percentage
Duration of Time
Individual Title In Months Available
*
*To Be Determined at a Later Date
e(
39
EXHIBIT J
CONSTRUCTION MANAGER'S PERSONNEL TO BE
ASSIGNED DURING CONSTRUCTION ON -SITE
Percentage
Duration of Time
Individual Title In Months Available
*
*To Be Determined at a Later Date
40
EXHIBIT K
OWNER'S CERTIFICATE OF PARTIAL PAYMENT
Cr
-lzction Manager (Name and Address):
Architect -Engineer Job No:
Contract Time (Calendar Days):
Time Elapsed to Date:
Change Orders approved
in previous months by
Owner -- TOTAL
Subsequent Change Orders
Number Approved
(Date)
ADDITIONS $ DEDUCTIONS $
TOTALS
Net change by Change Orders $ THIS CERTIFICATE
Request No:
For Period Ending:
Project Name:
State Project:
Federal Project No:
Original Contract Sum $
Change Orders (Net) $
Contract Sum To Date $
Balance To Finish $
Completed To Date $
Materials Stored $
Total Completed &
Stored $
Less Retainage % $
Add Back Retained
Amount Covered By
Securities $
TOTAL $
Less Previous Certificates $
Less Materials Purchased
Directly By Owner: $
$
SHOW INDIVIDUAL MBE PAYMENTS SEPARATELY ON
TOTAL AMOUNT PAID THIS CERTIFICATE
SCHEDULE OF VALUES AND TOTAL ON THIS LINE TO MBE SUBCONTRACTORS $
CERTIFICATION BY THE CONSTRUCTION MANAGER: According to the best of my knowledge and belief, I certify that all items and amounts shown
on thy- face of this Application are correct, that all work has been performed and material supplied in full accordance with the terms and conditions of the
C' , and that all materialmen, laborers and subcontractors, as defined in Chapter 713.01, Florida Statutes, have been paid the amounts due them out of
an, .vious payments made to the Construction Manager by the Owner. Further, I agree to promptly pay each materialmen, laborer and subcontractor, as
defined in Chapter 713.01, Florida Statutes, upon receipt of payment from the Owner, out of the amount paid to me on, account of such materialman's
laborer's or subcontractor's work, the amount to which said materialman, laborer and subcontractor is entitled, reflecting the percentage actually retained, if
any, from payments to myself on account of such materialman's, laborer's and subcontractor's work.
CONSTRUCTION MANAGER: By:
STATE OF
COUNTY OF
The foregoing instrument was acknowledged before me this (date) by (name of officer or agent , title of officer or agent) of (name of corporation
acknowledging) , a (state or place of incorporation) corporation, on behalf of the corporation. He/she is personally known to me or has produced (type
of identification) as identification.
(Signature of person taking acknowledgement)
(Name typed printed or stamped)
(Title or Vendor)
(Serial number, if any)
CERTIFICATION BY THE ARCHITECT- ENGINEER: I certify that I have checked and verified this Progress Payment Application; that to the best of my
knowledge and belief, the above application is a true statement of the value of the work performed and the materials suitable stored on the site; that all work
and materials included in this Certificate have been inspected by me or by my authorized assistants; that all work has been performed and material supplied
in full accordance with the terms of this Contract; and I approved for payment the amount noted above.
REVIEWED AND RECOMMENDED FOR PAYMENT:
Architect -Engineer
Al . )VED FOR SERVICES, PERFORMED AS STATED BY:
Dat
Owner's Project Director
41
Date:
EXHIBIT K con't
Chapter 713.01, Florida Statues, defines Laborers, Materialmen and Subcontractors as follows:
(1) "Laborer" means any person other than an architect, landscape architect, engineer, land surveyor, and
the like who, under properly authorized contract, personally performs on the site of the improvement
labor or services for improving real property and does not furnish materials or labor service of others.
(2) "Materialman" means any person who furnishes materials under contract to the owner, Construction
Manager, subcontractor, or sub -subcontractor on the site of the improvement or for specially fabricated
materials off the site of the improvement for the particular improvement, and who performs no labor in
the installation thereof.
(3) "Subcontractor" means a person other than a materialman or laborer who enters into a contract with a
Construction Manager for the performance of any part of such Construction Manager's contract.
42
EXHIBIT L
ITEMS TO BE SUBMITTED WITH GENERAL CONSTRUCTION MANAGER'S REQUEST FOR FINAL PAYMENT
1. Rush Requisition Routing Slip
2. Pay Request (4 copies with original signatures and original seals, noted as Final)
3. Final Schedule of Contract Values
4. Consent of Surety to make fmal Payment (signed and sealed)
5. Power of Attorney from Surety for Release of Final Payment (Signed and sealed and dated same as
Consent of Surety)
6. Certificate of Contract Completion
a. page one completed by the general Construction Manager (original plus three copies)
b. page two completed by Architect -Engineer (original plus three copies)
7. Satisfactory Conclusion or Release of Lien from all subcontractors or laborers who have filed Intent
to Liens or have indicated non-payment from the general Construction Manager (especially if
attorneys are involved)
8. Construction Manager's Guarantee of Construction for one year from the date of substantial
completion
9. Copy of the approval by the Architect -Engineer and the transmittal to the using agency of manuals,
shop drawings, as-builts (one set of sepias, two sets of prints), brochures, warranties, and List of
Subcontractors, with telephone numbers and addresses
10. Verification that Using Agency personnel have been trained in the operation of their new equipment
(per system: HVAC, controls, fire alarm, etc.), attendance lists and preferred
11. Fully executed Roof Warranty (if applicable) in the name of the Using Agency
12. Other special warranties as required by specifications, in the name of the Using Agency
13. Architect's Certificate of Specification of Asbestos Containing Materials
14. Construction Manager's Certificate of Asbestos Use
15. Copy of Certificate of Occupancy
NOTE: The Project Director shall verify the math of all Pay Requests prior to signing Final Pay Request to assure
correct payment.
Project Number:
Project Name and Location:
Project Director Signature:
43