HomeMy Public PortalAboutConstruction & Field Observation Svcs Agreement.pdfri THOMAS & HUTTON
50 PARK OF COMMERCE WAY
SAVANNAH, G4 31405 1 912.234.5300
W W W.TH 0 MASAN DH UTTO N . COM
August 25, 2017
Mr. Shawn Gillen
City Manager
City of Tybee Island
403 Butler Avenue
Tybee Island, GA 31328
Re: Construction and Field Observation Services
North Beach Post - Matthew Dune
Remediation Project - Tybee Island, Georgia
Letter Agreement for Services
Dear Mr. Gillen:
Thank you for requesting our construction observation services to provide our assistance
during the proposed dune restoration work on North Beach.
The following is a brief description of our understanding of the project description and our
proposed Scope of Services to be provided:
DUNE RESTORATION
This project will consist of the placement of beach quality sands along the eroded
escarpment of North Beach at Tybee per Olsen Associates' design plans titled "North Beach
Post -Matthew Dune Remediation Project City of Tybee Island, GA" and dated April 1, 2017.
The following are our Scope of Services for the Project:
• Conduct Pre -construction Meeting with Contractor, City and Design Engineer
• Review Material Data & Shop Drawings provided by the Contractor
• Provide on-site construction monitoring. This will include:
o Monitor the material placement for the Dune Restoration work and record
quantities and quality of material placed
o Provide Endangered Species Monitoring Services. We will utilize the
services of Mr. Steve Calver who is a qualified and approved consultant in
this field. His responsibilities will consist of the visual monitoring and
documenting the presence of endangered birds during the construction
duration.
o Review and recommend Contractor's payment application and provide
recommendations for payment by the City of Tybee Island
o Document the work being performed and site conditions
o Attend final field inspections by regulatory agencies for the project
o Review any potential change orders and provide recommendations to
the Owner
� • Coordinate with Engineer of Record during construction
*IiOwner's Initials
Consultant's Initials
Mr. Shawn Gillen
City of Tybee Island
Letter Agreement for Services
August 25, 2017
Page 2
Clarifications
It is our understanding we will be provided with all available project documents including
permit conditions, design plans and any other applicable data necessary to monitor the work
being performed by the Contractor.
Our fees are based on the understanding the project duration is approximately 90
working days, commencing on or about September 15, 2017, and will be tide dependent. Per
the direction of the engineer of record, Olsen Associates, Inc., it is anticipated the work will
require an average of 7 hours per working day, 3 days per week and may require off hours
including weekends. If during construction it is identified that Thomas & Hutton staff will be
required to be onsite for more than the above specified time frame, Thomas & Hutton will
contact the City prior to the depletion of the budget to allocate additional monies to cover the
necessary time for the additional scope should it be necessary.
The following tasks are not included but can be provided if requested for additional fees:
• Pre- and post -construction surveying or As -Built plans
• Geotechnical investigations
• Legal assistance or performing as an expert witness in any legal activities
• Coastal Engineering or Design
• Observation of the revegetation of the dunes
We propose that payment for our services will be as follows:
Fee or Time &
Phase Fee Structure Expense Budget
Dune Restoration Phase: Time & Expense @ $120.00/hour $ 60,000.00
Endangered Species
Monitoring Phase: Time & Expense @ $50.00/hour $ 31,500.00
As previously indicated, during the duration of the project, should the budget become
depleted due to additional work required by the actions of others or unforeseen conditions,
Thomas & Hutton will notify the City that budget will need to be increased through an
amendment to this contract.
The above fee arrangements are on the basis of prompt payment of our invoices and
the orderly and continuous progress of the Project through construction.
We anticipate commencement of our work immediately upon receipt of your
authorization to proceed.
This proposal between the City of Tybee Island, GA (Owner), and Thomas & Hutton
Engineering Co. ("Consultant" or "Thomas & Hutton"), consisting of the Scope of Services,
General Provisions, Engineering Services Rate Sheet, and this letter with authorized signatures,
represents the entire understanding between you and us with respect to the Project. This
agreement may only be modified in writing if signed by both of us.
Owner's Initials
4 onsuBant's Initials
Mr. Shawn Gillen
City of Tybee Island
Letter Agreement for Services
August 25, 2017
Page 3
It is our understanding that no work will commence until written authorization is provided
to us by you for the Project.
If the arrangements set forth in these documents are acceptable to you, please sign and
initial the enclosed documents in the spaces provided below and return to us. This proposal will
be open for acceptance until December 31, 2017, unless changed by us in writing.
We appreciate the opportunity to prepare this proposal and look forward to working with
you on the project.
The parties agree and acknowledge that any of the parties hereto may execute this
agreement by electronic signature, and the other party may rely upon such electronic signature
as an original record of signature.
Very truly yours,
THOMAS & HUTTON ENGINEERING CO.
By
B nny K Jones, Jr, PE
Senior Vice President / Chief Operating Officer
JVG/kts
Enclosures: General Provisions
Consulting Services Rate Sheet
ACCEPT :
By
M, 19-&612
TITLE
, 2017
o n V. Giordano, PE
Project Manager
cc. Mr. Jason Buelterman, City of Tybee Island Mayor
'Owner's Initials
7-C�onsultant's Initials
GENERAL PROVISIONS TO LETTER AGREEMENT FOR SERVICES BETWEEN
THOMAS & HUTTON ENGINEERING Co. (CONSULTANT) AND THE CITY OF TYBEE ISLAND, GA (OWNER)
CONSTRUCTION AND FIELD OBSERVATION SERVICES FOR NORTH BEACH POST -MATTHEW DUNE REMEDIATION PROJECT
AUGUST 25, 2017
PAYMENT FOR SERVICES
For services rendered, OWNER shall pay CONSULTANT as outlined in
the Letter Agreement for Services.
Payment for services on the basis of "Time & Expense' shall be paid
in accordance with the schedule of charges attached hereto.
Project related costs for printing. reproductions, materials, and
travel will be billed as reimbursable expenses.
Projects will be billed monthly or at the completion of the work,
whichever comes sooner, with payment due upon receipt.
Payment shall be considered overdue offer forty-five (45) days from
date of invoice, with interest charged at a monthly rate of 1.5
percent (18 percent annual rate).
CONSULTANT reserves the right to suspend work hereunder or any
other work to be performed by CONSULTANT for OWNER or any of Bs
affiliates under a separate agreement or agreements with
CONSULTANT in the event of delinquent payment by OWNER to
CONSULTANT hereunder or in the event of delinquent payment by
OWNER or its affiliates to CONSULTANT under a separate agreement or
agreements. For all purposes hereof, affiliate shall mean (i) in the case
of an individual. any relative of any person listed among the following.
(ii) any officer, director. trustee, partner, manager. employee or holder
of 5 percent or more of any class of the voting securities of or equity
interest in the OWNER; (ill) any corporation. partnership, limited liability
company, trust or other entity controlling. controlled by or under
common control with the OWNER; or (iv) any officer, director. trustee,
partner, manager, employee or holder of 5 percent or more of the
outstanding voting securities of any corporation. partnership, limited
liability company, trust or other entity controlling. controlled by, or
under common control with the OWNER.
In the event legal action is necessary to enforce the payment terms
of this Agreement, the CONSULTANT shall be entitled to collect from
the OWNER any judgment or settlement sums due, plus reasonable
attorneys' fees, court costs and other expenses incurred by the
CONSULTANT for such collection action and, in addition. the
reasonable value of the CONSULTANTS time and expenses spent for
such collection action, computed according to the CONSULTANTS
prevailing fee schedule and expense policies.
ASSIGNMENT
Neither party to this Agreement shall transfer. sublet or assign any
rights or duties under or interest in this Agreement, including but not
limited to monies that are due or monies that may be due, without
the prior written consent of the other party. Subcontracting to
subconsultants, normally contemplated by the CONSULTANT as a
generally accepted business practice, shall not be considered an
assignment for purposes of this Agreement.
OWNER'S RESPONSIBILITIES
A. Access
OWNER shall make provisions for the CONSULTANT to enter
upon public and private lands as required to perform such
work as surveys and inspections in development of the Project.
B. OWNER's Representative
The OWNER shall designate in writing one person to act as
OWNER'S Representative with respect to the work to be
performed under this Agreement. This Representative shall
have complete authority to transmit instructions, receive
information, interpret. and define OWNER's policy and
decisions, with respect to the product, materials, equipment.
elements, and systems pertinent to the work covered by this
Agreement.
Owner's Initials
�'%' Consultant's Initials
1 of 4
C. Fees
fie OWNER is responsible for payment of fees associated with
the project. Such fees include permit review and application
fees, impact fees, and capacity fees. The CONSULTANT will
notify the OWNER regarding the amount of fees and timing Of
payment.
CONSULTANT'S RESPONSIBILITIES
In providing services under this Agreement, the CONSULTANT shall
perform in a manner consistent with that degree of care and skill
ordinarily exercised by members of the same profession currently
practicing under similar circumstances at the same time and in the
same or similar locality. No other representation, expressed or
implied. and no warranty or guarantee is included or intended in
the Agreement, or in any report, opinion, document, or otherwise.
OWNERSHIP OF INSTRUMENTS OF SERVICE
All reports, drawings, specifications, computer files, electronic files,
BIM models, field data, notes and other documents and instruments
prepared by CONSULTANT as instruments of service shall remain the
property of the CONSULTANT. fie CONSULTANT shall retain all
common law, statutory, and other reserved rights, including, without
limitation, the copyrights thereto. The CONSULTANT shall retain
these records for a period of two (2) years following their
completion during which period paper copies will be mode
available to the Project OWNER at reasonable times.
ELECTRONIC FILES
In accepting and utilizing any drawings, reports and data on any
form of electronic media generated and fumished by the
CONSULTANT. the OWNER agrees that all such electronic files are
instruments of service of the CONSULTANT, who shall be deemed
the author, and shall retain all common law, statutory law and other
rights, without limitation, including copyrights.
The OWNER agrees not to reuse these electronic files, in whole or in
port, for any purpose other than for the Project. The OWNER agrees
not to transfer these electronic files to others without the prior
written consent of the CONSULTANT. The OWNER further agrees to
waive all claims against the CONSULTANT resulting in any way from
any unauthorized changes to or reuse of the electronic files for any
other project by anyone other than the CONSULTANT.
The OWNER is aware that differences may exist between the
electronic files delivered and the printed hard -copy construction
documents. In the event of a conflict between the signed
construction documents prepared by the CONSULTANT and
electronic files. the signed or sealed hard -copy construction
documents shall govem.
In addition, the OWNER agrees, to the fullest extent permitted by
law, to indemnify and hold harmless the CONSULTANT, its officers,
directors, employees and sub -consultants (collectively,
CONSULTANT) against all damages, liabilities or costs, including
reasonable attorneys' fees and defense cosh, arising from any
changes made by anyone other than the CONSULTANT or from any
reuse of the electronic files without the prior written consent of the
CONSULTANT.
Under no circumstances shall delivery of electronic files for use by
the OWNER be deemed 0 sale by the CONSULTANT, and the
CONSULTANT makes no warranties, either express or implied, of
merchantability and fitness for any particular purpose. In no event
shall the CONSULTANT be liable for indirect or consequential
damages as a result of the OWNER's use or reuse of the electronic
files.
GENERAL PROVISIONS TO LETTER AGREEMENT FOR SERVICES BETWEEN
THOMAS P. HUTTON ENGINEERING CO. (CONSULTANT) AND THE CITY OF TYBEE ISLAND, GA (OWNER)
CONSTRUCTION AND FIELD OBSERVATION SERVICES FOR NORTH BEACH POST—MATTHEW DUNE REMEDIATION PROJECT
AUGUST 25, 2017
CERTIFICATIONS, GUARANTEES AND WARRANTIES
The CONSULTANT shall not be required to sign any documents. no
matter by whom requested, that would result in the CONSULTANT's
having to certify, guarantee or warrant the existence of conditions
whose existence the CONSULTANT cannot ascertain or any way
might. in the sole judgment of the CONSULTANT, increase the
CONSULTANT's contractual or legal obligations or risks, or adversely
affect the availability or cost of its professional or general liability
insurance. The OWNER also agrees not to make resolution of any
dispute with the CONSULTANT or payment of any amount due to
the CONSULTANT in any way contingent upon the CONSULTANTS
signing any such certification.
ACCESSIBILITY
The OWNER acknowledges that the requirements of the Americans
with Disabilities Act (ADA), Fair Housing Act (FHA) and other federal.
state and local accessibility laws. rules. codes, ordinances and
regulations will be subject to various and possibly contradictory
interpretations. The CONSULTANT, therefore, will use its reasonable
professional efforts and judgment to interpret applicable
accessibility requirements in effect as of the date of [the execution
of this Agreement, submission to building authorities, Or other
appropriate date] and as they apply to the Project. The
CONSULTANT, however, cannot and does not warrant or
guarantee that the OWNER's Project will comply with all
interpretations of the accessibility requirements and/or the
requirements of other federal, state, and local laws, rules. codes.
ordinances, and regulations as they apply to the Project. Any
changes in the applicable law or contrary interpretations of existing
law subsequent to the issues of permits which requires CONSULTANT
to perform redesign will be considered an additional service.
SUBSTITUTIONS
Upon the written request or direction of OWNER. CONSULTANT shall
evaluate and advise OWNER with respect to proposed or
requested changes in materials, products, or equipment.
CONSULTANT shall be entitled t0 rely on the accuracy and
completeness of the information provided in conjunction with the
requested substitution. CONSULTANT shall not be responsible for
errors, omissions. or inconsistencies in information by others or in any
way resulting from incorporating such substitution into the Project.
OWNER shall be invoiced for this service on a Time & Expense basis
unless both parties mutually agree on a lump sum fee.
OPINIONS OF PROBABLE COSTS
Since the CONSULTANT has no control over the cost of labor.
materials, or equipment. or over the Contractor's methods of
determining prices, or over competitive bidding or market
conditions, his opinions of probable construction costs provided for
herein are to be made on the basis of his experience and
qualifications. These opinions represent his best judgment as a
design professional familiar with the construction industry.
However, the CONSULTANT cannot and does not guarantee that
proposals, bids, or the construction cost will not vary from opinions
of probable construction costs prepared by him.
BETTERMENT
If, due to the CONSULTANT'S negligence, a required item or
component of the Project is omitted from the CONSULTANT'S
construction documents, the CONSULTANT shall not be responsible
for paying the cost required to add such item or component to the
extent that such item or component would have been required
and included in the original construction documents. In no event
will the CONSULTANT be responsible for any cost or expense that
provides betterment, upgrades. or enhances the value of the
Project.
CH ED CONDITIONS
Owner's Initials
S
GCo uHanYs Initials
2 of 4
If, during the term of this Agreement, circumstances or conditions
that were not originally contemplated by or known to the
CONSULTANT are revealed, to the extent that they affect the scope
of services, compensation. schedule. allocation of risks or other
material terms of this Agreement, the CONSULTANT may call for
renegotiation of appropriate portions of this Agreement. The
CONSULTANT shall notify the OWNER of the changed conditions
necessitating renegotiation. and the CONSULTANT and the OWNER
shall promptly and in good faith enter into renegotiation of this
Agreement to address the changed conditions. If terms cannot be
agreed to, the parties agree that either party has the absolute right
to terminate this Agreement in accordance with the Termination
provision hereof.
CODE COMPLIANCE
The CONSULTANT shall exercise usual and customary professional
care in its efforts to comply with applicable laws, codes and
regulations in effect as of the date of this agreement was written.
Design changes made necessary by newly enacted laws, codes
and regulations after this date shall entitle the CONSULTANT to a
reasonable adjustment in the schedule and additional
compensation in accordance with the Additional Services
provisions of this Agreement.
In the event of a conflict between laws. codes and regulations of
various governmental entities having jurisdiction over this Project,
the CONSULTANT shall notify the OWNER of the nature and impact
of such conflict. The OWNER agrees to cooperate and work with
the CONSULTANT in an effort to resolve this conflict.
VALUE ENGINEERING
(If) OWNER has elected to engage in value engineering of the
Project, OWNER has established cost as a primary project objective
over other programming. performance, and aesthetic objectives
and recognizes that in doing so, it has limited the available design
and product options. These limitations may impact the overall
project cost, schedule, and performance. OWNER has accepted
these risks and impacts in recognition of the importance it has
placed on project cost.
DELEGATED DESIGN
Where any design services are provided by persons or entities not
under CONSULTANTs direct control, CONSULTANTS role shall be
limited to its evaluation of the general conformance with the design
intent and the interface with CONSULTANTS design and portion of
the project. Except to the extent. it is actually aware of a
deficiency, error, or omission in such design by others, CONSULTANT
shall have no responsibility for such design and may rely upon its
adequacy, accuracy, and completeness in all respects.
LIMITS OF LIABILITY
Nothing contained in this Agreement shall create a contractual
relationship with or a cause of action in favor of a third party
against either the OWNER or the CONSULTANT. The CONSULTANT's
services under this Agreement are being performed solely for the
OWNER's benefit, and no other party or entity shall have any claim
against the CONSULTANT because of this Agreement or the
performance or nonperformance of services hereunder. The
OWNER and CONSULTANT agree to require a similar provision in all
contracts with contractors, subcontractors, sub -consultants,
vendors, and other entities involved in this Project to carry out the
intent of this provision.
e'er p.e.:ye^
gee a^'
9 +0 a'
66
the^, "e ""9 6`A'"'E7 a^d
9 y
B c1^4—'^e e..we.ot ��
GENERAL PROVISIONS TO LETTER AGREEMENT FOR SERVICES BETWEEN
THOMAS & HUTTON ENGINEERING CO. (CONSULTANT) AND THE CITY OF TYBEE ISLAND, GA (OWNER)
CONSTRUCTION AND FIELD OBSERVATION SERVICES FOR NORTH BEACH POST -MATTHEW DUNE REMEDIATION PROJECT AUGUST 25, 2017
it e^y,,^y Wed te-tho w_$_, a. ,,.e "yeemyr"•e^ a^y ,.,., ..
,.,,..-„" ^e' excee" Scnpnn _. .._ rQ..eILT.MT.e Fee Fac
. e ., . _ .,_,.... .ee-a-... , ..
...,.:-D "Rh"- .Nr.r -Hide Pruni .:F_w by I-.., Twi. m.r.aer
TIME BAR TO LEGAL ACTION
All legal actions by either party against the other arising out of or in
any way connected with this Agreement or the services to be
performed hereunder shall be barred and under no circumstances
shall any such legal action be initiated by either party after five (5)
years from the date of Substantial Completion. unless this
Agreement shall be terminated earlier, in which case the date of
termination of this Agreement 5hall be the date on which such
period shall commence. Nothing in this Agreement is construed to
waive any protections granted under existing laws of the state in
which the work is performed.
ACTS OF OTHERS
The CONSULTANT shall not be responsible for the means. methods,
techniques, sequences. or procedures of construction selected by
Contractor(s) or the safety precautions and programs incident to
the work of Contractor(s). CONSULTANT shall not be responsible for
the failure of Contractor(s) to perform the work in accordance with
the Contract Documents.
The CONSULTANT shall not be responsible for the acts or omissions of
any Contractor, or sub -contractor. or any of the Contractor(st, or
sub -contractors agents, or employees or any other persons (except
CONSULTANT'S own employees and agents) at the site or otherwise
performing any of the Contractor(s)! work. However, nothing
contained herein shall be construed to release CONSULTANT from
liability for failure to perform properly the duties undertaken by
CONSULTANT in the Contract Documents.
The CONSULTANT shall not be responsible for the acts, omissions,
means, methods, or specifications of other design professionals not
directly retained by CONSULTANT.
INDEMNIFICATION
The CONSULTANT agrees, to the fullest extent permitted by law, to
indemnify and hold harmless the OWNER, its officers, directors and
employees (collectively, OWNER) against all damages, liabilities or
costs. including reasonable attorneys' fees and defense casts. to
the extent caused by the CONSULTANT'S negligent performance of
professional services under this Agreement and that of its
subconsultants or anyone for whom the CONSULTANT is legally
liable.
The OWNER recognizes that Thomas & Hutton did not prepare the
Contract Documents for the project, The City of Tybee Island
agrees to make no claim and hereby waives, to the fullest extent
permitted by low, any claim or cause of action of any nature
against the Consultant. its officers, directors. employees, agents or
subconsultants, which may arise out of the Contract Documents or
other services not specifically performed by Thomas & Hutton.
CONSEQUENTIAL DAMAGES
Notwithstanding any other provision of this Agreement, and to the
fullest extent permitted by law, neither the OWNER nor the
CONSULTANT, their respective officers, directors, partners,
employees. contractors or subconsultants shall be liable to the
other or shall make any claim for any incidental. indirect or
consequential damages arising out of or connected in any way to
the Project or to this Agreement. This mutual waiver of
consequential damages shall include, but is not limited to, loss of
useyl ass of profit. loss of business, loss of income, loss of reputation
Owner's Initials
7Consultant's Initials
3 of 4
and any other consequential damages that either party may have
incurred from any cause of action including negligence, strict
liability, breach of contract and breach of strict or implied warranty.
Both the OWNER and the CONSULTANT shall require similar waivers
of consequential damages protecting all the entities or persons
named herein in all contracts and subcontracts with others involved
in this project.
DISPUTE RESOLUTION
Any dispute or claim arising out of or relating to this Agreement shall
be determined as follows: CONSULTANT and OWNER will negotiate
in good faith to reach agreement. If negotiations are unsuccessful,
CONSULTANT and OWNER agree the dispute shall be settled by
mediation. In the event the dispute or any issues remain unresolved
after the above steps, the disagreement shall be decided by such
remedies of law as they are available to the parties. The
appointment of a mediator and location will be subject to
agreement between CONSULTANT and OWNER with each party
being responsible for their portion of those costs.
JOBSITE SAFETY
Neither the professional activities of the CONSULTANT, nor the
presence of the CONSULTANT or its employees and subconsultants
at a construction/project site, shall impose any duty on the
CONSULTANT, nor relieve the General Contractor of its obligations,
duties and responsibilities including, but not limited to, construction
means, methods, sequence, techniques or procedures necessary
for performing, superintending and coordinating the Work in
accordance with the Contract Documents and any health or
safety precautions required by any regulatory agencies. The
CONSULTANT and its personnel have no authority to exercise any
control over any construction contractor or its employees in
connection with their work or any health or safety programs or
procedures. The OWNER agrees that the General Contractor shall
be solely responsible for jobsite and worker safety and warrants that
this intent shall be carried out in the OWNER'S contract with the
General Contractor. The OWNER also agrees that the General
Contractor shall defend and indemnify the OWNER, the
CONSULTANT and the CONSULTANT's subconsultants. The OWNER
also agrees that the OWNER. the CONSULTANT and the
CONSULTANT'S subconsultants shall be made additional insureds
under the General Contractors policies of general liability
insurance.
HAZARDOUS MATERIAL
Both parties acknowledge that the CONSULTANT's scope of services
does not include any services related to the presence of any
hazardous or toxic materials and/or mold. In the event the
CONSULTANT or any other person or entity involved in the project
encounters any hazardous or toxic materials and/or mold, or should
it become known to the CONSULTANT that such materials may be
present on or about the jobsite or any adjacent areas that may
affect the performance of the CONSULTANTS services, the
CONSULTANT may, at its sole option and without liability for
consequential or any other damages, suspend performance of its
services under this Agreement until the OWNER retains appropriate
qualified consultants and/or contractors to identify and abate or
remove the hazardous or toxic materials and warrants that the
jobsite is in full compliance with all applicable laws and regulations.
APPLICATIONS FOR PERMITS AND CERTIFICATES REQUESTED ON
BEHALF OF OWNER
The OWNER shall indemnify and hold the CONSULTANT harmless
from and against any and all judgments, losses, damages, and
expenses (including attorney fees and defense costs) arising from or
related to claims by third parties to challenge the issuance of
permits or certificates for the Project by agencies with jurisdiction in
the premises. Defense costs shall include the time and expenses of
the CONSULTANT's personnel to assist in the defense of the issuance
of the permit or certificate.
GENERAL PROVISIONS TO LETTER AGREEMENT FOR SERVICES BETWEEN
THOMAS & HUTTON ENGINEERING CO. (CONSULTANT) AND THE CITY OF TYBEE ISLAND, GA (OWNER
CONSTRUCTION AND FIELD OBSERVATION SERVICES FOR NORTH BEACH POST—MATTHEW DUNE REMEDIATION PROJECT
AUGuST25,2017
TERMINATION
In the event of termination of this Agreement by either party, the
OWNER shall within fifteen (15) calendar days of termination pay
the CONSULTANT for all services rendered and all reimbursable costs
incurred by the CONSULTANT up to the date of termination, in
accordance with the payment provisions of this Agreement.
Either party may terminate this Agreement for the convenience
and without cause upon giving the other party not less than fifteen
(15) calendar clays' written notice.
Either party may terminate this Agreement for cause upon giving
the other party not less than seven (7) calendar days written notice
for any of the following reasons:
• Substantial failure by the other party to perform in
accordance with the terms of this Agreement and through no
fault of the terminating party;
• Assignment of this Agreement or transfer of the Project by
either party to any other entity without the prior written
consent of the other party;
• Suspension of the Project or the CONSULTANT's services by the
OWNER for more than ninety (90) calendar days, consecutive
or in the aggregate:
• Material changes in the conditions under which this
Agreement was entered into, the Scope of Services or the
nature of the Project, and the failure of the parties to reach
agreement on the compensation and schedule adjustments
necessitated by such changes.
In the event of any termination that is not the fault of the
CONSULTANT, the OWNER shall pay the CONSULTANT, in addition to
payment for services rendered and reimbursable costs incurred, for
all expenses reasonably incurred by the CONSULTANT in
connection with the orderly termination of this Agreement,
including but not limited to demobilization, reassignment of
personnel, associated overhead costs and all other expenses
directly resulting from the termination.
SIGNAGE
OWNER agrees to allow CONSULTANT to place a sign on the job site
during construction. The sign will include general information
relative to the CONSULTANT. CONSULTANT shall be responsible for
the sign installation and removal.
AMENDMENT
This Agreement for Services can be amended by addenda if
agreed to in wiling and signed by both parties.
1C -Owner's Initials
Ci
C n ultant's Initials
4 of 4
Consulting Services On A Time And Expense Basis
Z
O
H
z
too
0
z
IF
January 1, 2017
as
U C
O
' W
U
O =p
E
E
-o
c
T
co -
a
CSI
aiv
o s
L
c
c
O
O
% R 0-
-c > c
0 >
O ns y
c
U Y '—
.- C
"FA O
Q
o
NCo
E
E —0
N
CO a
co
v0
2 2
C
O E
0 a)
O N
v
O O y
a a
O
N U
C 8
a o
O =
OU C
C C O
X.
V .0
O O 20
U C
O 0
O
)Ts
> C
c a 6)
(0 0 O
3 C L N
O U I— X
O a) (0
CO '"
(n -o (n —
o
y `O 0 7..
0) -0 = c6
C6 C O a
.0 co 7.
co 0
m y am
C y,._U
0 c X
X- a) 0 0
O a C .-
a a) 0 c
a O
7
CO c6 0 O
C (0 0 Q
O 7..-5
L E
C N >' C
o =p TD
0) O 0N
U a.> 0 O
U
o ca ,- U
0) a) m
O 0 H p
O Cl) a
O ca
C
O 0 O N
a -O a -c
C O O
O U0 O =
C L
1 ca 0 m
O L
06 0 (n O C
(n L U 12
6) 0 O fd N
0 H 0 cc) c
•
H r N
Owner's Initials
The current hourly rate charges for each skill position for 2017 are as follows:
"I- Consultant's Initials
4)
N
N
O
0 N
y =
m<
a
Senior Manager
Senior Application Developer IV,
Software/Computer Consultant IV
Senior Application Developer III,
Software/Computer Consultant III
Senior Application Developer II,
Software/Computer Consultant II
Senior Application Developer I,
Software/Computer Consultant I
Application Developer IV
Application Developer III
Application Developer II
Application Developer I,
Permit Coordinator II Admin IV
Permit Coordinator I
C
C
.a
¢
C
0)
a
¢
Quality Control
4)
0
U
Senior Manager
Construction Administrator II
Construction Administrator I
Field Representative V
Field Representative IV
Field Representative III
Field Representative II
Field Representative I
L7
Consultant
Senior Manager
GIS Manager V
GIS Manager IV
GIS Manager III
GIS Manager II
GIS Manger)
GIS Analyst IV
N
A
co
Q
N
C7
T
Q
0)
C7
?
Q
N
C7
GIS Technidan III
GIS Technician II
GIS Technician I
Landscape
Consultant
Senior Manager
Landscape Architect V
Landscape Architect IV
Landscape Architect III
Landscape Architect II
Landscape Architect I
Landscape Designer IV
Landscape Designer III
Landscape Designer II
Landscape Designer I
Landscape Technician III
Landscape Technician II
Landscape Technician I 1
0
0
CO
O
c
U
Senior Manager
Survey Party (3—Men)
Survey Manager V
Project Surveyor V
Survey Manager IV
Project Surveyor IV
Survey Manager III
Project Surveyor III
Survey Manager II
Project Surveyor II
Survey Manager I
Project Surveyor I
Staff Surveyor IV
Survey Field Supervisor
Survey Party (2—Men)
Staff Surveyor III
Staff Surveyor II
Survey Party (1—Man)
Staff Surveyor I
Survey Technician III
Survey Technician II
Survey Technician
Engineer
Consultant
Senior Manager
Project Manager V
Project Engineer V
Project Manager IV
Project Engineer IV
Project Manager III
Project Engineer III
Project Manager II
Project Engineer II
Project Manager I
Project Engineer I
Designer IV
Engineering Technician IV
Designer III
Engineering Technician III
Designer II
Engineering Technician II
Designer I
Engineering Technician I
CADD Technician III
CADD Technician II
CADD Technician I
Expert Witness
o
T. 0
= R— it5
O Q. N
o
O
0
11 $ 180.00
0
0
0
0
0
gn
Y$ 140.00
0
O
0,
$ 125.00
0
O
-
_
0
O
coO
0
O
=
'
0
0
tri0)
0
0
00
0
0
O
m
N $ 75.00
0
O
1+
II $ 365.00
ai
(0
a)
CJ)
cL
U
(0
0
0
C
O O
N (0
Ea
L
(0
r O
ca O
o E
To.-`
a) nsy
Q 0)E
c
150L0
` a r
O
0 E >`0 N
-E F
> • (0 a)
L
0 C —
O
a) U
O
O O
O O
O- 0 c
E 2 co
O 7
E C
c 8
aS C
a O
-o
� C O
0 0
O U
C
N U
a mc
F.2
0
O
U it
O C
.0 0) O
L
O
(n a5yO
E .0 L
r E
>
O 0
aN
a) f6
0)
R O E
$ c c
C U al
O O O
E E
Travel in company or private vehicles will be billed at $0.54 per
O
O
0)
L
0)
O
U
a
c
(0
0
(0
0)
m
z
O
E
(0
w
(0
a)
CA
C
a5
L
U
0
.0
7
N
`)
c0
0
0)
0
a3
R
.0
(0
E
c
0
U
0
Q
caO
C
4)
a
C
a0
� m
cas
L
U
00 O
N,-
E
O
)
U
7
O
w
O .0
> 0)
V
O C
`) U
a) 0
0)
O
0)
c6 U
L
U
a T
c0 O
cam
@ N
_ E
Q E
LL')
W W W.THOMASANDHUTTO N.COM