Loading...
HomeMy Public PortalAboutPinco 2-6-20DOCUMENT 00506 STANDARD FORM OF AGREEMENT BETWEEN OWNER AND CONTRACTOR r THIS AGREEMENT is dated as of the�day ofJr,the year 200P by eieel— _ hereinafter called CONTRACTo.t dba p^C OWNER and CONTRACTOR, in consideration of the mutual covenants hereinafter set forth, agree as follows: ARTICLE 1. WORK. CONTRACTOR shall complete all Work as specified or indicated in the Contract Documents. The Work is generally described as follows: Installation of one (1) 48" Triple Channel 2.0 Rotary Fan Press skid system and piping, electrical and other accessories including miscellaneous items as required and as shown on the plans to complete a full operational system. ARTICLE 2. ENGINEER. The Project has been designed by Thomas & Hutton Engineering Co. who is hereinafter called ENGINEER and who is to act as OWNER's representative, assume all duties and responsibilities and have the rights and authority assigned to ENGINEER in the Contract Documents in connection with the completion of the Work in accordance with the Contract Documents. ARTICLE 3. CONTRACT TIMES. All time limits for Substantial Completion and completion and readiness for finat payment as stated in the Contract Documents are of essence of the Contract. 3.1 The Work will be substantially completed within f66�tra�s after the date when the Contract Times commence to run as provided in paragraph 2.03 of the General Conditions and completed and ready for final payment in accordance with paragraph 14.07 of the General Conditions within after the date when the Contract Times commence to run, Included in the contract times are ten (10) days for rain delay. Time delays due to rain in excess of the above days shall be reported by the Contractor to the Engineer in writing. within thirty (30) days of each event. 3.2 Liquidated Damages. OWNER and CONTRACTOR recognize that time is of the essence of this Agreement and that OWNER will suffer financial loss if the Work is not completed within the times specified in paragraph 3.1 above, plus any extensions thereof allowed in accordance with Article 12 of the General Conditions. The parties also recognize the delays, expense, and difficulties involved in proving the actual loss suffered by OWNER if the Work is not substantially complete on time. Accordingly, instead of requiring any such proof, OWNER and CONTRACTOR agree that as liquidated damages for delay (but not 00506-1 1--28051.00'/ City ar Tybee Island W WTF Sludge Dewatering Press IFS/ August 19 as a penalty) CONTRACTOR shall posy OWNER Two Thousand and 001TOO dollars ($!2,DG4.B+4or each day that expires after the time specified in paragraph 3.1 for Substantial Completion until the Work is substantially complete. After Substantial completion, if CONTRACTOR shall neglect, refuse or fail to complete the remaining Work within the time specified in paragraph 3.1 for completion and readiness for final payment or any proper extension thereof granted by OWNER, CONTRACTOR, shall pay OWNER Two Thousand and 001100 dollars ($2,000.00) for each day that expires after the time specified in paragraph 3.1 for completion and readiness for final payment. ARTICLE 4. CONTRACT PRICE 4.1 UNIT PRICE WORK OWNER shall pay CONTRACTOR for completion of the Work in accordance with the Contract Documents an amount in current funds of the amounts determined for all Unit Price Work, an amount equal to the sum of the established unit price for each separately identified item of Unit Price Work times the estimoted quantity of that item as indicated in the CONTRACTOR'S UNIT PRICE SID (attached hereto as an exhibit), said arnount being: Five I jxhd ninety thousand, eight twedr+ed fifty dollars and no cents _ 00/100 dollars ($ 590.854.00 .00) As provided in paragraph 11,03 of the General Conditions estimated quantities are not guaranteed, and determinations of actual quantities and classification are to be made by ENGINEER as provided in paragraph 9,08 of the General Conditions. Unit prices have been computed as provided in paragraph 11.0.3E of the General Conditions. ARTICLE S. PAYMENT PROCEDURES. CONTRACTOR shall submit Applications for Payment in accordance with Article 14 of the General Conditions. Applications for Payment will be processed by ENGINEER as provided in the General Conditions. 5.1 Progress Payments; Retainage. OWNER shall make progress payments on account of the Contract Price on the basis of CONTRACTOR's Applications for Paymenf as recommended by ENGINEER, on or about the 25th day of each month during performance of the Work as provided in paragraphs 5.1.1., 5.1.1.2_ and 5.2. below. All such payments will be measured by the schedule of values established in paragraph 2.07 of the General Conditions (and in the case of Unit Price Work based on the number of units completed) as provided in the General Requirements. 5.1.1 For Cost of work: Progress payments on account of the Cost of the Work will be made: 5.1.1.1 Prior to Substantial Completion, progress payments will be made in an amount equal to the percentage indicated below, but, in each case, less the aggregate of payments previously made and less such amounts as ENGINEER shall determine, or OWNER may 00506-2 J-28051.001 City of Tybee Island WWI F Sludge dewatering Pass JFS/ Augusl 19 withhold,. in accordance with paragraph 14.02 of the General Conditions. 90%.of the Work completed (with the balance Eyeing retainage).. if Work has been 50% completed as determined by ENGINEER, and if the character and progress of the Work have been satisfactory to OWNER and ENGINEER, OWNER, on recommendation of ENGINEER. may determine that as long as the character and progress. of the Work remain satisfactory to them, there will be no additional retainage on. account .of Work Completed, in which case the remaining progress payments prior to Substantial Completion will. be Man amount equal to 100% of the Work completed. 907* of Cost of the work (with thebalance: being .retainage) applicable to materials and equipment not incorporated In the. Work (but delivered, suitably stored and accompanied by documentation satisfactory to. OWNER as. provided in paragraph 14.01A.1 of the General Conditions]. 5.1.1:2 Upon Substantial Completion. 1n an amount sufficient to increase the total payments to CONTRACTOR. to 98YD of the Cast of the Worts, (wifh'the balance being retainage), less such amounts as ENGINEER shall determine, or OWNER may withhold, in accordance with paragraph 14.7 of the General Conditions.. 5.2 Final Payment. Upon. :find completion and acceptance of .the Work in Caccordance with paragraph 14.07 ,of the. General Conditions, OWNER shall pay the remainder of the Contract Price as recommended by ENGINEER as provided in said. paragraph 14.13. ARTICLE 6. INTEREST. All moneys not paid when .due as provided in Article 14 of the General Condifions shall bear interest at the maximum rate allowed by law at the place of .fhe Project. ARTICLE 7. CONTRACTOR'S REPRESENTATIONS. In order to induce OWNER to enter into this Agreement CONTRACTOR makes the fallowing representations; 7.1CONTRACTOR has . examined and carefully studied the Contract. Documents (Including. the Addenda indicated in Article 8 hereinafter) and the other related data identified in the Bidding Documents. 7.2 CONTRACTOR has visifed. the site and become familiar with and is, satisfied as to the general, local and site conditions that may: affect cost, progress, performance or furnishing of the Work: 7.3 CONTRACTOR is familiar with and is satisfied as to all federal,: state and local laws and Regulations that may affect Cost, progress, performance and furnishing of the Work. 005016-3 . -290.51.60/ City of Tybee Island WWTF Sludge -Dewatering Press 1F51 August.] 9 7.4 CONTRACTOR has carefully studied all reports of explorations and test of subsurface conditions at or contiguous to the Site and. all. drawings of physical conditions in or relating to existing surface or subsurface structures at. or contiguous to :the Site (except Underground Facilities) which have been Identified in the Supplementary Conditions .as provided in the General Conditions.. CONTRACTOR acknowledges that such reportsand drawings are not Contract Documents and may not be complete for CONTRACTOR's purposes. CONTRACTOR. acknowledges that: OWNER and. ENGINEER do 'not assurne responsibility for the accuracy or completeness of information and data shown or indicated in the Contract Documents with respect to Underground Facilities at or contiguous to the site. CONTRACTOR has obtained and carefully studied (or assurnes responsibility for hating stone so) all such additional supplementary exa.rriinaiions; investigations, explorations, :tests, studies and data concerning conditions {surface, subsurface and Underground Facilities) at or contiguous to the site: or otherwise which may affect Gast; progress, performance . or furnishing of the construction to be employed by CONTRACTOR and safety precautions and programs incident thereto. CONTRACTOR does not consider that any additional examinations, investigations, explorations, tests, studies or data are necessary for the performance and furnishing of the Work at the Contract Price, within the Contract Times and in accordance with the other terms and conditions of the Contract Docua nests. 7.5 CONTRACTOR is aware of the general nature of work to be performed by OWNER. and _others at the site that relates to the Work as indicated in the Contract Documents. 7.6 CONTRACTOR is aware of the .City. of Tybee Island requirements for construction warranty period of tine (1) year for equipment; rnctterials, and workmanship. 7.7 CONTRACTOR has correlated the information known to CONTRACTOR, information and observations obtained from visits to the site, reports and drawings identified in .the Contract Documents and all additional examinations, investigations, explorations, tests, studies, and data with the ContractDocuments. 7.8 CONTRACTOR has given ENGINEER written notice of all conflicts, errors, `ambiguities,. or discrepancies that CONTRACTOR has discovered In the Contract Documents and the written resolution .thereof by ENGINEER is acceptable to CONTRACTOR.,..and. the Contract Documents are generally sufficient to.. indicate .and convey understanding of all terms and conditions for performance and furnishing of the Work, ARTICLE 8. CONTRACT DOCUMENTS. The Contract Documents which comprise the entire agreement between OWNER. and CONTRACTOR. concerning .the Work consist of the following: 8.1 This.Agreement. (pages 00546-1 to 00506-5, inclusive).. 8.2 Performance, Payment, and other Bonds as stated. 8.3 General Conditions (pages l to 42, inclusive). 00508--4 . 28051.00/ City vr.Tybee.islpnd WWU Sludge Oewatering Press /F5! August 0 8.4 Special Conditions. (pages 00710-1 to 00710-5, inclusive). 8.5 Supplementary Conditions. [pages 4¢815-1 to 00815--5Jnciusivej.. 8.6 Specifications consisting of 15 technical provisions; as listed in table of contents thereof, 8.7 Notice to Proceed. 8.8 Drawings consisting at sheets CO through EM with each sheet bearing the following general title: SHEET NO. TITLE Co Cover Sheet GIA General Notes C1.1 Sludge De pterin Building_Layout C2.1 Sludge Dewoiedng Plan View C2.2 Slud e,Deivaterin Section View C3.1 Handrait & Grating Details C3.2 Handrail. & Grating Details EIA Electrical Pian 8.9 Addenda slumbers ito 1 inclusive: Exhibits to this Agreement: a. CONTRACTOR'S Bid (page 003.13-1 through page :00313-7: inclusive) marked :"Exhibit A.." b, Any modification, including Change Orders; duly delivered after execution of Agreement.. C. Any modification. including Change Orders; duly delivered offer execution of agreement. There are no Contract ocument5 other than those listed above in this Article 8. The Contract Documents may only be amended, modified, or supplemented as provided in paragraphs 3.5 and 3.6 of the General Conditions. ARTICLE 9. MISCELLANEOUS. 9.1 Terms used in this Agreement which are defined in. Article 1 of the General Conditions will havethe meanings indicated in the General Conditions. 9.2 No. assignment by a party hereto of any rights under or interest's in the Contract Documents will be binding.on.another party Hereto without the written consent of the .party sought to be bound, and, specifically but without limitat"ion, moneys that may become due and moneys that are due may not be assigned without such 00506-s J-0051 =1 CI4y of iybee Island WWW Sludge Dewatering Press /FS/ August .19 consent (except to the extent that the effect of this restriction may be limited by low), and unless specifically stated to the contrary in any written consent to an assignment no assignment will release or discharge the assignor from any duty or responsibility under the Contract Documents. 9.3 OWNER and CONTRACTOR each binds itself, its -partners, successors, assigns. and: legal representatives to the otherparty hereto, its partners. successors, assigns and legal representatives in respect to all covenants, agreements and obligatlons, contained In the Contract Documents. 9.4 Any provision or part of the Contract Documents held to be void or unenforceable, under any Lara or Regulation shall be deemed stricken, and all remaining provisions shall. continue to be valid and binding upon OWNER and CONTRACTOR, who agree that the Contract Documents shall be reformed to replace such stricken provision or part thereof with a .valid .and enforceable provision that comes as close. as possible to expressing the intention of the stricken provision. IN WITNESS WHERECF, OWNER. and CONTRACTOR have signed this Agreement in five (5) counterparts. Two counterparts each have been. delivered to OWNER and. CONTRACTOR and one counterpart to ENGINEER. All portions of the Contract Documents have been signed, initialed.or Identified by Owner and Contractor or identified by. ENGINEER on their behalf. 00506-6 J-28451:00/ City of T.yhee Island WWTF Sludge DeWofering Press /F$1 August 17 PROJECT IDENTIFICATION: CONTRACT IDENTIFICATION. ARID NUMBER: THIS BID IS SUB1VliTl ED TO: ATTACHMENT G BID FORM SLUDGE PRESS ITB# 2019-746 City of ybde Island Wa.sfewater Treatment Facility New Sludge Dewatering Press J - 280 7.00DU Cify of TAae:island 1.. The undersigned BIDDER proposes and agrees, if this Bld Is accepted, to enter Into an agreement with OWNER in the form included in the Contract Documents to perform and furnish all work as specified or indicated in the Contract Documents for fhe Bid Price and with!n the Bid rimes indicated in this Bid and in accordance with the ether terms and conditions of the.ContractDocuments, 2 BIDDER accepts all of .the terms and conditions of the Adverfisement or Invitation to Bid jand.lnstructions to Bidders, €including without lirnitaflon those. dealingm ith the:disposition of Bid security.. This Bid will remailn subject to acceptance for 60 days after the. day of Bid opening, orforsuch longer period of time that BIDDER mayogreetoln vM ing upon request Of OWNER. 3. in submitting. this Bid. BIDDER represents; as more fully set forth in the Agreement, that: (a) BIDDER has examined and carefully studied the Floris. and Specifications for the work ..and contractual documents relative therato,. and has read all Technical. Provisions, Supplementary Conditions, and General Cond.Itions, furnished pilar to the opening of Bids: that BIDDER has satisfied himself relative to the work to be performed. (b) BIDDER further acknowledges hereby receipt: of the fallowing Addenda:. ADDENDUM NO. DATE drL� (cj BIDDER has visited the site and became familiar with and is satisfied as to the general, local and site conditions that.may affect cost, progress,. performance,. and fum€shing of the Work; 1d) BIDDER is familiar with and is satisfied as to all federal,. state, crrd local Laws: and Regulations that may affect cast,. progress, performance, and fumBhing of the. Work: (e) BIDDER has carefully studied all reports of explorations and tests. of'subsuduce. conditions at or contiguous to the site and all drawings of physical conditions in. or relating to existing surface or subsurface structure of or contiguous to the site .(except underground Facilities) have been identified in the Supplementary Conditions. BIDDER acknowfedges that such reports and. drawings are not Contract Documents and may not be. complete for.BiDDER`s purposes. BIDDER acknowledges that OWNER and Engineer do not assume responsibility for the Bidding Documents With respect to Underground Facilities at or contiguous to the site: BIDDER. has obtained and carefully studied jor assumes responsibility for having done so] all such additional or supplementary examinations, investigations. explorations, Nests, studies and data concerning.. condiSiorK..(surface, subsurface and Underground Facilities) at or contiguous to the site.or otherwise which may affect cost progress, performance or furnishing of the work or which relate to any aspect of the means, methods, techniques, sequences and procedures of construction to be employed by .BIDDER and safety precautions :and programs incident thereto.. BIDDER does not. consider that .sany additional .examinations; investigations, explorrations, tests, studies or data are necessary . for the determination of this Bid for performance and fumIshing of the Work in accordance with the. times, price and other terms and conditions of the Bidding Documents. [fy BIDDER is. aware of the general nature of Work to be performed by Qwner and otters at the site that relates to Work for which this Bid is submitted as indicated in the.B.idding Documents. (g} BIDDER has correlated the information [mown to BIDDER, Information and observations obtained from visits. to. the site, reports and drawingsidentified in the Bidding .Documents and all additional examinations, investigolions, explorations. tests, studies and data with the Bidding. Documents. (h) BIDDER has given ENGINEER written notice of all.conflich, errors, ambiguities..or discrepancies. -that BIDDER has discovered In the Bidding Documents and the: written resolution thereof by ENGINEER is acceptable to BIDDER. The Bidding Documents ore generally sufficient to Indicate and convey understanding of all terms and conditions for performing. and furnishing the Work for which this Bid is subrinifted. (i) This bid is. genuine, and not made in the- interest of or on behalf of any undisclosed person, .flrm:or corporation and !shot submitted, in conformity with any agreement. or rules of any. group, association, organ¢ation or corporation: BIDDER has riot directly or.indirectly induced. orsoliched any other Bidderto:submit a false or sham Bid; BIDDER has not solicited or induced any person, firm or corporation to refrain Frani bidding; and BIDDER has:.not sought by collusion to obtain for itself any advantage over any other Bidder or over OWNER.. { li Bidder is aware of the City of.Tybee Island requirement for construction Warranty period of no less than one (7) Year for equipment. materials, and wcffkmanship. 4. BIDDER will complete the Work in accordance with the Contract Documents for the fallowing price(s): Bid Form City of Tybee Island VVWTF New Sludge Dewatering Fan Press ITEM_ DESCRIPTION QUANT11. UNIT PRICE TOTAL PRICE i 1 MobilrzationlDemobilixation JOB LUMP SLIM $ 13,009.00 �� One (1) 48" Triple Channel 2.0 Rotary JOB ' Allowance $373,000.00 I=an Press Skid System 3 Press Installation, Misc. Yard Piping, JOB LUMP SUM $ 83,65D•00 Valves, etc. 4 Misc. Metals S Hand Rails JOB LUMP SUM $ 0,600.40 5 Electrical JOB LUMP SUM $ 49,400.00 Total Construction Cost $ 590,$50.00 * Indicate Firm or Manufacturer used as noted in Pre-bid Agenda. 12: Prime Solution TOTAL BIC) FOR Total Construction Costs: FW hundred ninety thauseM, eight hundred fifty dollars and no tents Unit Prices have been computed in accordance with paragraph 11.03.11 of the General Conditions. BIDDER acknowledges that estimated quantities are not guaranteed and are solely for the purpose of comparison of Bids, and final payment for all Unit Price Bid items will be based on actual quantities determined as provided. determined as provided in the Contract Documents. 5. BIDDER agrees that the Work will be substantially complete within 917 calendar days after the date when the Contract Times commence to run as provided in paragraph 2.03 of the General Conditions and completed and ready for final payment in accordance with paragraph 14.07.6 of the General Conditions within ieTcoiendor days after the date when the Contract Times commence to run. 6. BIDDER accepts the provisions of the Agreement as to liquidated damages in the event of failure to complete the work within the times specifled in the Agreement. 7. The following documents are attached to and made a condif[on of this Bid: (a) Required Bid Security in the form of 10% of the Bid Total FriC 8. The undersigned further agrees that in case of fciiure on his part to execute the said contract and the Bond within fifteen (15) consecutive calanda� days after written notice being given of the award of the contract, the check or bid bond accompanying this bid. and the monies payable thereon shall be paid into the funds of the Owner as liquidated damages for such failure. otherwise, the check or bid bond accompanying this proposal shall be rMumed to the undersigned. i 0. Terms used in this Bid which are defined in the General Conditions or Instructions will hove the meanings indicated in the General Conditions of Instructions. SUBMITTED on 12/10/19 ADDRESS, 136 Airport Park Drive Garden City, &A 31408 Pinhalstcr iorstructicn L1.C, dba PINCO CONTRACTOR'S NAME BY:� Scott L. pInNister State Utility Contractor License No.__ UC 300119 003]3—S J -2W51 �O City of Tybee island WWTF/Sludge Dewatering Press Jft" _ 2M This Agreement will be effective vn_ . � (which is the Effective Dote of the Agreement). OWNER: of Nbee Island By BY ATTES Address fior�gglving " noticesdress for giving n 40 Butler Avenue CORPORATE SEAL CONTRACTOR: moi.: ��+ e By Scott L. Firhotster,- h ATTEST _1 otices L.L'lt J1ILR�• � � 6ardm City,8A 31408 License No.rt C SM119 GCCO 00100 Agent for service of process: CORPORATE SEAL 00506-7 J-28051.00! City of TyUee Island WWTF Sludge Dewotering Press !FS! August 19 ADDENDUM WHEREAS, the city of Tybee Island as "Owner" and Pinholster Construction. LLC, d/b/a Pinco as "Contractor" have agreed for the performance of the construction and installation of sludge dewatering press following a hid procedure; and WHEREAS, the time of commencement of the performance is in need of clarification; and NOW THEREFORE, notwithstanding any other provision of any of the contract documents, the provisions hereof shall control as to time of performance. The parties agree as follows: 1. It is hereby agreed that Contractor w&estimates submittal of shop drawings within four (4-5) weeks of the -receipt of notice to proceedd^t�= It is estimated that manufacturing will take ten (10) to fourteen (14) weeks after shop drawing approval. Once the unit is manufactured and delivered, installation, start up, trials, training and demonstration is estimated to take three (3) weeks thereafter. 2. Time is of the essence of the agreement and of this document and therefore, Contractor shall complete the project in accordance with the above time estimates in the absence of express written authorization by Owner extending such time estimates. This f, day of .202o. Attest: This 100 day of February , 2020. City of Tybee Island, GA (Owner) 403 Butler Ave. Tybee Isla d A 31325 By: •.L,f it's `7�0_ Title - Approved form City Attorney Pinholster Construction, LLC (C actor) dlbla Pinco `~ By: Sco . Pinholster It's Man a er DOCUMENT 00611 PERFORMANCE BOND Band # 5003364 KNOW ALL MEN BY THESE PRESENTS, that we Plnholster Construction. LLC, dba PINGO and: F.CCI Insurance Company; 6300nit� versity Parkway,%Sarasoto, Ft,:34240 (Name.&.Address of Surefyl hereinafter called the "Surety" pre field and flrnnly bound unto The City of Tybee island, hereinafter called the "Owner" in the penal .sum .of: Five hundred ninety thousand, .eight. hundred fifty arz 0 71�a daflerrs �! 590,850.00 .p0 1 lawful money of the United Sfcites of America.; to be paid to OWN ER, for the payment whereof well and truly to .be made we do bind ourselves, our respective executors, adm nistrators, successors and assigns,.jointly.and severoll.y, firmly by these presents. WHEREAS,. the above bounden Principal has entered into. a certain confract with the Ownerdated the 5th ay of February Qopfor the. construction 'of, City of Tybee Island Wastewater Treatment facility, New Sludge Dewatering. Press which said contract is incorporated hereby by reference. and made a part hereof and is hereinafter referred to as the Construction Contract. NOW TH REFORE, THE CONDITION. OF. THIS OBLIGATION is such that, if the: Principal shall promptly and faithfully. perform and comply with the terms anct conditions of said contract; and shall indennnify and save horirnless the. Owner against and. from all costs, expenses, damages, injury or loss to which said Owner riiay be subjected by reason: of any wrongdoing,. including portent in Frin9ement, misconduct, want .of :care .or skill, default, or failure .of. performance on the. part of said Principal, his agents, subcontractors or employees,. in the execution or. perform. once of said Consfruction Contract, then fhis obligation shall be null.and void; of h.erwise: it shall remain in full force and effect. The Contractor and the Surety,jointlyand severally, bind fherhselves, their heirs; executors, administrafors, successors. and assigns to. the. Owner for the performance of the Construction Confrocf. which is incorporated herein. by. reference. 2, if the Contractor pefforrns the Corisfruction Contract, fhe Surety .and the Contractor shall have no obligation. under this .Bond, except to` polrticipate `in .conferences. as: provided: in Subparagraph 3J. 3. If there is no Owner Default.; the Surety's obligafions: under this .Bond shall arise after:. OOfrl i-1 J-28D5I.000I1 City of Tybee Isfond. WWTF Sludge Dewatering Press /W August 19 3.1. The Owner has notified the Contractor and the, Surety at. Its address described. in Paragraph 10 below, that t.h.e. Owner is consldering declaring a Contractor Default and has requested: and.:a#tempfed to :arrange a conference with the Contractor and the Surety. to. be held not later than fifteen days after .receipt of such notice to discuss methods of performing the 'Construction Contract, If the Owner, the Contractor and the Surety agree, the Cont:roctocsholl be allowed a reasonable time to perform the Construction .Contract; but .such do .agreement shall not waive the Owner's right, if any, subsequenfly to declare a Contractor Default; and 3.2 The Owner has declared a Contractor Default and formally terminated the Contractor's right to :complete; the contract, Such Contractor Default shall not be declared earlier than twenty .days after the contractor. and the -Surety have received notice as.provfded in Subporca.graph.31;. and 3:3 The Owner has agreed to pay the Balance of the Contract Price to the Surety in accordance with. the. fe.rms.o€ the Construction Confract or to a contractor selectedto perform the Construction. Contract in accordance with the terms of the contract with the Owner. 4. When the.Owner has sdtisifed the conditions of Paragraph 3, the: 5urefy shall Promptly ond.at theSurety's.expense, take one of the. following actions: 4.1 Arrange for the. Contractor., with consent of the Owner; to perforin and complete the Construction Contract; or 4.2 Undertake to perform and complete the. Construction Contract itself, through Its agents or through lndependent contractors;.or 4.3 Obtain bids or negotiated proposals from qualified contractors acceptable to fhe.Owner for a contract for performance. and completion of the Construc#ion Contract, arrange. for a contract to be prepared for execution by the Owner and the contractor selected with the Owner's concurrence, '10 be secured with performance and payment bonds .executed. by a qualified surety equivalent to the bonds issued on the Constructlon Cohtracf, .and pay to the: Owner the amount of damages .cis described in :Paragraph .5 in excess of the. Balance .of the Contract Price incurred by the Own er.resulfing from the Contractor`s detault; or 4.4 Waive Its right to perform andcomplete, arrange for completion, or obtain a new .con.troctor and with reasonable promptness under the. clrcumsta noes: 4.4.1 After investigation, determine. the amount for .which it may be liable to the Owner and, as soon as practicable, after the amount is determined, tender payment therefor to the Owner, or 4.4.2 Deny liability in whole .or in part and notify the Owner cifing reasons therefor., . 00hii-Z J-28050DOW City of iybee Island WWTF Sludge dewatering Press IFS/ August 19 5. It the Surety .does hot proceed..as provided in paragraph. 4. with reasonable promptn.ess,. the:.Surety shall be -deemed to be in default on this Bond fifteen days after receipt of an .additlonol written notice from the Owner to the: Surety demanding that .the .Surety perform its. obligations under this Bond, and the Owner shall be entitled. to enforce any remedy .available to the Owner. If the Surety proceeds:as provided in Subparagraph 4.4, and the Owner refuses the payment tendered:.or the Surety has denied liability, in whole or in part, without further notice the Owner .sholI be entitled to enforce any remedy available to the Owner. .61 .After the Owner has terminated the. Confract.or"s right to complete. the Construction Contract, and. if the Surety elects to act under Subparagraph 4.1, 4,2, or 4.3:cabove, thea the responsibilities of the Surety #o the Owner shall hat be greater than those of the.. Contractor under the Construction Contract. To the. limit of the amount of this Bond, b.uf subject to commitment by the Owner of the Balance of the Contract Price to mitigation of :costs and damages on the Construction..Contract,. the. Surety it. obEigclted without duplicatic h. for: 6..1 The re5p.onsibilities: of the Contractor for correction. of defective work. and completion of the Construction Contract: 612 Additional legal, design professional and. delay costs rewiffng from the Contractor's Default, and resulting From the actions or faiture to act of the Surety .under Parograph.4; and 6.3 Liquidated damages,. or If no liquidated damages are specified in the Construction Contract, actual damages caused by delayed performance. or non-performance of the .Contractor.. 7. The Surety shall not be. liable to the .Owner or Others for obligafions .of. the Contractor that are unrelated to the Contract, and the Balance of the -Contract Price shall .nof reduce:or set off on account of any .5uch unrelated gbllgafions, No right of .action sho11 accrue. on this Bond to ony person or erifity other. than the. Owner or its. heirs, executors, administrators, or successors, 8. The Surety hereby waives notice of any changes, including' changes of time, to. the .Construction Contract or torelated subcontracts, purchase :orders and Other. obligations, Any proceeding, legal or equitable, under this Bond may be instituted in any court of competent jurisdiction in the -location in which thework or part. ofthe work is located and.shall be instituted within two years after Contractor Default or within two years after the. Contractor ceased working or within .two years after the.. Surefy ref uses. or fails to perforin its obtgations .under this. Bond,whichever occurs: first., If the. provisions of this Paragraph arewolid or'prohibited by law, Jhe minimum period of limitotion:available to sureties as a defense. jn the.jurlsdictlon of the suit shall be applicable. 10.. Notice to the Surety, the Owner or the Confractor shall be mailed or delivered to the address to the .address shown on tiie signature page, 00511-3 J-28451.0000/ city of Tyree €_00nd VWWTF Sludge Dewatering Press /FS/ -August 19 When this Bond }las. been furnished. to comply with o statutory or other legal requirement in thelocation where the Construction was to be performed,any provision in this Bond conflicting' with said statutory or legal requirement shall be deemed deleted:here.from and provisions conforming to such statutory or .other legal requirement shall be deemed incorporated herein. The intent is t1lof this Bond shall be construed as a statutory band ond-not as a common law bond, 1 DIEFINmoNs. 12.1 Balance of the Contract Price: The fatal amount .payable by the Owner to. the Contractor under the Construction Contract after all proper adjustments: have been made,. includin0 allowance to the Contractor of any amounts received or to.. be received by the Owner In seftlemenf of insurance or:other claims for damages to which the.Coniractorls entitled, reduced by all valid .and proper:poyments made .to .or on behalf of the Contractor under the. Construction Contract. 12.2 Construction Contract: The agreement between the. Owner and the Contractor identified. -on the signature page, including all Contract Documents and changes thereto; 1.2.3 Contrcctvr Defdult: Failure. of the Contractor, which hds neither been remedied: nor waived, to. perform or otherwise to comply with the t.erms.of the Construction Contract, 12.4 Owner Defqult: Failure of the Owner, which has. neither been remedied nor waived, fo. pay the. Contractor as required by the Construction .Contract or to perform and complete or comply with the other terms. thereof. 00611--4 J-28651 bwo/-clty or Tgbee Island WWTF Sludge Dewatering Press /FS/ August 19 IN WITNESS WHEREOF, this instrument is executed in six {6J counterparts, each one of which shall be deemed an original, and th1s the 6th day of Fe ruary, 2020, 2019. CONTRACTOR A5 PRINCIPAL: (SEAL]. r � 1 Witness . s o Principal 136 Airport Paris Drive Address Garden City, GA 31408 { � tea.: i� A • ! Audria R. Ward, Witness (Surety) Secretary (SEA` VV Witness as to Surety - 6300, 1.1nivergity.P.a rkwZy Address Sarasota, FL 34240 Pinholster Construction L.ic, dha PINCO L ';;;1-r -�- By: (Signature & Title) Scott L. Pinholster, M r. FCCI Insurance Company Surety (Company) n001 sy: Att r y-in_F Georgia Resident gent Mari n A. 1319meAZI40 1-14,17 / 2- 00611-5 J-28051.0000/ City of Tybee island WWTF Sludge Dewatering Press /FS/ August 19 DOCUMENT 00621 PAYMENT BOND. Bond #.5003364 Pinholster Construction LLC, dba P1NCO. KNOW ALL MEN B.Y. THESE PRESENTS, that we, .and; FCCI Insurance Company 5300 University Parkway Sara.soto, FL 34240 (Name & Address -of Surefyj of Hartford, CT, hereinafter called the "Surety are held and firmly bound: unto The City of Tybe.e Island, hereinafter called the ".Owner" in the penal sum of; �rL4�iiifeT.f%!i ■ ■ - a ■ _ ■ r - ■ ■ all ■ ■ - • !1! !! ► • a 590,850.00 Lawful money of the Uni.f.ed States of America, to he paid to OWNER; for th& payment whereof well and truly to' :be. rnade we do bind ourselves, :our <resp.ecfive executors; administrators,. successors and.assigns, joinfly and seyeral.ly, firmly by Ihese `presents, WHEREM, the above: bounden ff ipal has entered into a certain contract with the Owner dated the 6th day of February for the construction of: City of Tyiaee Island Wastewater Treatment F.acMy, New Sludge dewafering Press which said contractis incorporated hereby by reference and made, a part hereof and is hereinafter referred to as the Construction Contract. NOW THEREFORE, THE: CONDITION OF TH15 OBLIGATION is such that,. if the Principal shall promptly make payment to all :claimants: as hereinafter defined, fpr all labor and materials supplied in the prosecution of the work provided for in said Construction Contract, then this obligation shall be void; .otherwise it shall remain in full force and.effect;. subject, however, to the fallowing co editions: The Contractor and the. Surety, jointly and severally, bind themselves; their heirs: executors, administrafors, successors and assigns to the Owner for the performance :af the Construction Contract, .which is incorporated. herein by reference. 2. With respect to the owner., this obligation shall be null and.va.id if the Contractor: 2..1 Promptly makes payment, .directly or indirectly, for ail sums. due Claimants; and 00621-1 J-28051.0000 Cilyof Tybee Island WWtF. Sludge dewatering Riess IFS/ August 19 2.2 Defends, indemnifies and holds harmless the Owner from claims, demands, liens or suits. by any person .or entity whose claim, demand, lien or suit is for payment for Libor, materials or equipment furnished for use in the performance of the Construction Contract, provided the Owner has promptly notified the Contractor and the Surety (at the -address described in Paragraph 12) of any Claims, demands: liens .or suits and tendered defense.of such clairr,s, demands, liens or suits to. the Contractor and the Surety, and provided there is no Owner Default, 3. With respect to Claimants. Phis obligation shall be. null and void if the Contractor promptly makes payment, directly or indirectly;. for all sums due. 4. The Surety shall have no obligation fa Clairnant:s under this Bond until: 4,1 Claimants who. are employed by or have a direct. contract with the Contractor have :given notice to the.Surety (at the address. described in Paragraph 12) and sent a:copy, or notice thereof, to the.Owner,.sfating that 6 ciairn is being made under this .Bond and, .with substantial accuracy, the amount of.claim. 4.2 Claimants. who do not have.d direct contract with the Contractor: 4.211 Have furnished written na.tice. to the Contract and sent a copy, or notice. thereof, to the Owner, within 90 days after having last performed.iabor or last furnished materials or equipment included in. the claire stating, with substantial accuracy., the amount of the clpimand the. name of the party to whom the materials were furnished or supplied or for whom the labor was done or performed: and 4.2.2 Have either received a rejection :In whole. or in part from the Contractor, or not received within.30 days of furnished the .above notice any Communication. from the. Contractor by which the Contractor .has. indicated the claim. will be paid directfy or indirectly; and 4.2.3 Not having been paid.within 30°days, have sent a written notice to the Surety (at the address described in Paragraph 12) and sent a copy, or notice.thereof 'to the :Owner, stating that aclaim. is being made under this Bond. and enclosing o copy of the previous wdtferi notice furnished to the Contractor, 5. If a notice required by:parograph 4 is given :by the Owner to the .Contractor or to, the Surety that is.sufficient compliance, 6. When the Claimant has satisfied the conditions of Paragraph A,. .the Surety shall promptly and at the Surety's expense take the following actions: 6.1 Send an answer to. the Claimant, with a copy to..the Owner, within 45: days. after receipt of the claim :stating the amounts. that are undisputed and. that basis for challenging a.ny.amounts that are disputed. 00621--2 J48051.M/ City of iybee Islond WWTF Sludge Dewatering.Rress lFS[August 1.9' 6.2 Pay or arrange forpayment of any.undisputed amounts. The Suretys.fotal.:obllgotion shall not exceed the amount of this Bond, and the amount of thiis::Bond shall be credited for any payments made :In. good faith by the Surety, 8. Amounts owed by the Qwner to the Contractor under the Construction Contract shall be used. for the performance .of the Construction Contract and to satisfy claims, if .any, under any Construction Performance Band. By the Contractor furnishing and the .Owner accepting this: Bond,. they agree shot all funds. earned by the. Contractor in the performance: of the Construction. Contract are dedicated to satisfy obligations of the Contractor and the Surety under this Bond; subject to the Owner's. priority to use the funds for thecompletion of the. work.. 9. The Surety shot! not be Gabl& to the Owner,. Clairnants or others for obligations of the.Confrdctor.that pre unrelated. td th6 Consfrucf!or) Cant ract. The Owner shall not b8 liable for payment of ony :casts or expenses of any Claimant under this Bond, and..shall.have under this Bond no: obligations to make pays leafs to, give nofices.on behalf of, .or otherwise have .obFgations to.Cialrrla.nts under this Bond. 1.0.. The .Surety hereby waives notice of any change, incWIng changes. of time, to the Constructi.onContract or to related subcontracts, purchase orders and other obligations. No suit or action shall be.:commenced by a Claimant under this bond other than in a court of competent jurisdiction in the location in which the work or part of the work is located or offer the. expiration of one year from Ihe.date (1) on which the Claimant gave the notice required by Subparagraph 4.:1 or Clause 4.2 {iii), or (2} an which the. lost labor or.service was performed by anyone or the last maferials or equipment were furnished by anyone under the Construction Contract, whichever of ( l) or (2) first occurs. if 1he provisions of this. Poragroph are void or prohibited by low, the minimum: period of limitation available: to sureties as a defense. in the Jurisdiction of the suit shat[ be.dpplicable.. 12. Notice to fhe Surety, the Ownerbr the Contractor shall be mailed or delivered to the oddress.shown ort the signature page. Actual receipt of:notice by Surety, the Owner or the Contractor, however accomplished, shall. be sufficient compliance .as. of the date received at the. address shown on.the.signoture page: 13. When. this Bond has been furnished to comply with a statutory or other legal requirement in the location where the construction. was to be performed, any provision in the Bond conflicting With sold slatutory. or legal requirement shall be deemed deleted herefrom and provisions. conforming.' to, such.: statutory or'other .legal requirement shall be deemed :incorporpted..:herein. The intent is. that this Banct.shoil.be construed as.a siotufory bond. and not as cI common.: law bond. 14. Upon request of any person or entify oppeoring to be a potential. beneficiary of this bond, the Contractor shall promptly furnish a copy of this Bond or.sholl perrriit a copy to be made. 15. DENNITIONS: 00621-3 J-2W51..00001.City of.Tybee Island WWTF Sludge Dewatering Press 1F51 August 19 15.1 Claimant: An individual or entity having a direct contract with the Contractor or with a subcontractor of the Contractor to furnish labor, material, or equipment for use in the performance of the Contract. The Intent of this Bond shall be to include without limitation in the terms "labor, materials or equipment," that part of water, gas, power, light, heat, oil, gasoline, telephone service or rental equipment used in the Construction Contract, architectural and engineering services required for performance of the work of the Contractor and the Contractor's subcontractors, and all other Items for which a mechanic's lien may be asserted in the jurisdiction where the labor, materials or equipment were fumished. 15.2 Construction Contract: The agreement between the Owner and the Contractor identified on the signature page, including all Contract Documents and changes thereto. 15.3 Owner Default: Failure of the Owner, which has neither been remedied nor waived, to pay the Contractor as required by the Construction Contract or to perform and complete or comply with the other terms thereof. IN WITNESS WHEREOF, this instrument is executed in six j61 cmt rparts, each one of which shall be deemed an original, this the 6th day of February, 2019 CONTRACTOR AS PRINCIPAL: By: (Signature & Title) {SEALS Scott L, Pinholster Witness caps to Principal -- -- ...1.36 Airport Park Drive Address Garden City, GA 31408 00621-4 J--28051.00001 City of Tybee Island WWTF Shidge De-atering Press IFS/ August 19 SURETY: a vlt�� A &�O� Audria R. Ward, Witness (Surety) Secretary ;S �A R Witness as to Surety 6300 University Parkway Address 6arasota, FE 74240 FCC[ Insurance Company Surety {Company} By: �}[ Atto y -in -Fa Genr is Resident Agent Marilyn Lome .� yQ meq/ 00621-5 J-28051 MOO/ City of Tybee Island W WTF Sludge Dewatering Press /FSI Avgvsf 19 FCCI® INSURANCE GROUP Nfore than a policy. A promise. GENERAL POWER OF ATTORNEY 10-00049007 Know all men by these presents: That the FCCI Insurance Company, a Corporation organized and existing under the laws of the State of Florida (the "Corporation") does make, constitute and appoint: Marilyn Ann Blome, Audria R. Ward Each, its true and lawful Attorney -In -Fact, to make, execute, seal and deliver, for and on its behalf as surety, and as its act and deed in all bonds and undertakings provided that no bond or undertaking or contract of suretyship executed under this authority shall exceed the sum of (not to exceed $7,500,000): This Power of Attorney is made and executed by authority of a Resolution adopted by the Board of Directors. That resolution also authorized any further action by the officers of the Company necessary to effect such transaction - The signatures below and the seal of the Corporation may be affixed by facsimile, and any such facsimile signatures or facsimile seal shall be binding upon the Corporation when so affixed and in the future with regard to any bond, undertaking or contract of surety to which it is attached - In witness whereof, the FCCI Insurance Company has caused these presen s to be signed by its duly authorized officers and its corporate Seal to be hereunto affixed, this 2511 day of Se tember 2016. Attest: Crai hn n, President _;"P ,� Thom . Koval Esq., EVP, Chie Officer, FCCI nsur ce Company SEAL Gov ment Affairs and Corporate Secretaryoti�r: r FCCI Insurance Company State of Florida County of Sarasota Before me this day personally appeared Craig Johnson, who is personally known to me and who executed the foregoing document for the purposes expressed therein. e-'► Arlene A k XW My commission expires: 9/25/2020 *** No�raTM� sur<ar Ccmmu onNe.GC isrm P4 c� Notary Public State of Florida County of Sarasota Before me this day personally appeared Thomas A- Koval, executed the foregoing document for the purposes expressed therein. 00—fto Anent Alonso My commission expires: 9/25/2020 **�r camomtian Now 39777 �"� My Carte E�dnr OVfkS:l� CERTIFICATE Esq., who is personally known to me and who Notary Public I, the undersigned Secretary of FCCI Insurance Company, a Florida Corporation, DO HEREBY CERTIFY that the foregoing Power of Attorney remains in full force and has not been revoked, and furthermore that the February 24, 2011 Resolution of the Board of Directors, referenced in said Power of Attorney, is now in force. Dated this 6th day of February 2020 ThomW4. Koval, Esq., EVP, Legal Officer, Gov4jnent Affairs and Corporate ary 1-I O NA -3592 -N A-04. 9116 DocuGard x`04346 contains a-,;ywdty'pntogmph, we haskground, heal-mnsi9`ve M, cafe-mactive natermarX and microtwa pd9ng on border. Sectidn 00641 NOTICE -TO PROCEEo. Dated-, F 6rugy 7T 21]20: To 5,.at# Pintidtster. 136 Airp.prt Park Dr. SMnnaht.Ca k408 •OVllN8R,s JOB. NO, J 2 51 l ,r r=, Fress CONTRACT FOR; Installation of one (1)4& " Tripie•Channe12.O 0oba'yr Fan Press slad'systern;.and. pipjh4.; eledtrical and attter accessories includirIg miscellaneous,Items as required,and as shown :on the,plons. to complete'.a full op.eratlonal system - YOU are notified that the Contract Times under the: above contract will.comm.ence to rum on February 7, 2020, By that -date, yncr are. to start performing your obilgations uri.der the Contract Uocoments: In..accard•a•n`ce with Artidle.3 of the Agreernerlt the dates of SubMahtial Comrrpletipn and: completion.:an.d readirre)ss,j r final paymrrent a.re (see attached.addend,uM.) Before you may start any VVork•at the.sit� 2.7 of the al Conditiaris provides that you :and OMER must- a h :deliver -to the Other (vylth copies to.. DMEER .and pther]dentified additional insureds),;�certi€icates of insurance which each Is required to purchase and maintain in accordance.witti tete Contract ©ocumonts. Before you maystartany. Work -at the site,you must have. supmltted the fallowing: 1; Certificate oflnsuramice 2: Perfoanance.B0hd I. P-aym-ent bond. J-28051:4 OW City-,of�•Tytiee Island V1vVrFSludgeDewatarin.g.press 114! 1Mugust 19 Client#: 1988528 595PINHOCON ACORD,. CERTIFICATE OF LIABILITY INSURANCE DATE 7/2020 (MMfDD1YYYY] 1r0(MMfDD THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER. THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(ies) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer any rights to the certificate holder In lieu of such endarsament(s). PRODUCERCONTACT NAME: _ McGriff Insurance Services PHON_E ATC 7391 Hodgson Memorial Drive E-MAIL Ext 912 544-5050 A1C, Nc _ Savannah, GA 31406 912 544-$�$� INSURER(S) AFFORDING COVERAGE MAIC #3 INSURER A. Westfield Insurance Company 24112 INSURED INSURER B. Traveler$ Property Casualty Co of Amer 25574 PlnholsterConstruction, LLC INS dba PINCO URER C. 136 Airport Park Drive INSURER D. Savannah, GA 31408 INSURER E: COVERAGES CERTIFICATE NUMRFR- RFVlrinN NLIIMRER THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING ANY REl3UIREMENT, TERM OR CONDITION OF ANY CONTRACTOR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, AND CONDITIONS OF SUCH POLICIES. LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. IV LTR TYPE OF INSURANCE ADDL SUER POLICY NUNSER MEND Y E F MpC P LIMITS A XI COMMERCIAL GENERALLIABILIY CLAIMS -MADE F7x OCCUR CWP1670287 0612512019061251202 EACHOCCURRENCE$1000000 PIiE14118 aE r once S100,000 MED EXP (Am one person) 65,000 X PD Ded:1,000 PERSONAL rt ADV INJURY $1,000,000 GENESIAL AGGREGATE 0,000,000 GEN'L AGGREGATE LIMIT APPLIES PER: RO- _LplorLICY F]JECT LIjLOC PRoaums • CQMPIOP AGa s2,000,000 HER.S A AUTOMOBILE UA81UTY CWP1670281 6/2512019 06/2&2020 COME„$1,00,000 BODILY INJURY (Pea pareon) s is ANY AUTO DWNED SCHEDULED AUTOS ONLY AUTOS X AtiRl€oS ONLv )( NON -OWNED AUTOS ONLY BODILY INJURY (Per �dent) S PROPERTY DAMAGE S -.(Per accident) _ A X UMBRELLA LIAB 'X OCCUR CWP1670281 6/2512019 06125120id EACH OCCURRENCE $5,00 EXCESS LIAB L CLAIMS -MADE AGGREGATE S5000.000 DED I X RETENTION SG $ B WORKERS COMPENSATION AND EMPLOYERS' LIABILITY ANY PROPRIETORIPARTN EVEXECUnVE� OFFICERIMEMBER EXGLU�E67 N N 1 A 6JUBSH02114418 2/21/2019 0$1$11$02 X 1PER oTH- -3�TATlI EFL E.L. EACH ACCIDENT S500,000 E.L. DISEASE - EA EMPLOYEE $500,000 (Mandatory In NH) I1 yes, describe under DESCRIPTION OF OPERATIONS below. CWPIS70281 10161251207 06/251202 E.L. DISEASE - POLICY LIMIT $500 ,000 $300,000 any one Item A LeasedlRented Eqp $304,400 any one occ. DESCRIPTION DF OPERATIONS I LOCATIONS 1 VEHICLES (ACORD 101, Add ltlonaI Remarks Schedule, may be attached If more space Is requIred l City of Tybee is listed as additional insured for general, auto and umbrella liability but only as respects operations performed by or on behalf of the named Insured when required by written contract and subject to the terms, conditions and exclusions of the policy(ies). City of Tybee 403 Butler Avenue Tybee Island, GA 31328 ACORD 25 (2016103) 1 011`1 #S24984178/M23808414 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS, AUTH OR IZEh REPRESENTATIVE Q 1988.2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD DRAKE P NC. CITY OF TYBEE ISLAND" `a' CONTRACTOR REGISTRATION CERTIFICATE PINHOLSTER CONSTRUCTION LLC, DBA PINCO 136 AIRPORT PARK DRIVE GARDEN CITY GA 31408 Business Location: OFF TYBEE. Certificate #: 4003814 Date Issued: 111512.020 99:18 REGISTRATION CONTRACTORS This Certificate must be displayed in a conspicuous place in your business establishment. Tybee Island City Hall must be notified of any change in status. This Certificate is Non -Transferable and is subject to being revolted if abused. This Certificate expires on 12131.12020 /] Li.-ta'L. Schaaf Zoning Specialist P., Q. Sot. 2749 , 403 Butler Avenue s Tybee Island? Georgia 31328-3749. (912) 786-4573 � FAX'(912) 78675737