HomeMy Public PortalAboutASSOCIATED SOILS ENGINEERING, INCCITY OF CARSON
LOS ANGELES COUNTY, CALIFORNIA
PROFESIONAL SERVICES AGREEMENT
FOR
CITY OF CARSON
PROJECT NO. 1301
ANNUAL SLURRY SEAL PROGRAM, CITYWIDE
With
Ai
Associated Soils Engineering, Inc.
77 -
CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
AGREEMENT FOR PROFESSIONAL SERVICES
(Associated Soils Engineers, Inc. / City of Carson )
THIS AGREEMENT FOR PROFESSIONAL SERVICES ("Agreement" herein) is made
and entered into this _& day of Ape,'L , 2009, by and between the local public agency or
agencies identified in Section I hereof (hereinafter called "Owner"), and Associated Soils
Engineers, Inc. (hereinafter called "Engineer").
RECITALS
WHEREAS, Owner desires to engage Engineer to perform Geotechnical investigation
and material testing services, as provided herein, in connection with the project identified as:
Project 1301 Annual Slurry Seal Program, City-wide
WHEREAS, the principal members of Engineer are qualified professional engineers duly
registered under the laws of the State of California, and Engineer desires to accept such
engagement;
NOW, THEREFORE, the parties agree as follows:
Parties to the Aareemen .
The parties to this Agreement are:
Owner: City of Carson , a body corporate and politic, having its principal office at
701 E. Carson Street, Carson, CA 90745.
Engineer: Associated Soils Engineering, Inc., having its principal office at 2860
Walnut Avenue, Signal Hill, CA 90755.
2. Rgpresentatives of the Parties and Service of Notices.
The representatives of the parties who are primarily responsible for the administration of
this Agreement, and to whom formal notices, demands and communications shall be
given, are as follows:
A. The principal representative of the Owner shall be:
Mr. M. Victor Rollinger, P.E.
Development Services General Manager / City Engineer
Engineering Division,
City of Carson
701 E. Carson Street
Carson, CA 90745
B. The principal representative of the Engineer shall be:
2 CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
Mr. Edward C. (Ted) Riddell
President, Principal Geologist
Associated Soils Engineering, Inc.
2860 Walnut Avenue,
Signal Hill, CA 90755.
C. Any notices, bills, invoices, or reports required by this Agreement shall be
deemed received on (a) the day of delivery if delivered by hand or overnight
courier service during recipient's regular business hours or by facsimile before or
during recipient's regular business hours; or (b) on the third business day
following deposit in the United States mail, postage prepaid, to the addresses
heretofore set forth in the Agreement, or to such other addresses as the parties
may, from time to time, designate in writing pursuant to the provisions of this
section.
D. If the name of the principal representative designated to receive the notices,
demands or communications, or the address of such person, is changed, written
notice shall be given within five (5) working days of said change.
3. Description of Work.
Owner hereby engages Engineer, and Engineer accepts such engagement, to perform the
technical and professional services set forth in the "Scope of Services" attached hereto as
Exhibit "A". Engineer shall perform and complete, in a manner satisfactory to Owner, all
work and services set forth in Exhibit "A". The City Engineer, or his designee, shall
have the right to review and inspect the work during the course of its performance at such
times as may be specified by the City Engineer.
4. Commencement and Completion of Work.
The execution of this Agreement by the parties does not constitute an authorization to
proceed. The services of Engineer shall commence when the Owner, acting by and
through its City Engineer, has issued a Notice to Proceed prescribing the work elements
authorized to be performed and the total price applicable to those work elements. Notices
to Proceed may be issued in stages. The work elements shall be as described in
Exhibit "A" as Project No. 1301. The final Notice to Proceed shall begin from the date
of that Notice to Proceed and end nine months after beginning of construction by the
Contractor that is awarded the contract by the Agency. The nine months stated above
includes one month of post -construction phase of construction management services
required to wrap up the project. Engineer shall have no claim for compensation for any
services or work which has not been authorized by the Owner's Notice to Proceed.
5. Extension of Time for Completion of W rk.
A. If, at any time, the work is delayed due to adjustment in the number of working
days with a construction contract change order or delay in the project caused by
the Contractor, then the Engineer shall be entitled to an extension of time equal to
3 CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
said delay, subject to the Owner's right to terminate this Agreement pursuant to
Section 11.
B. Engineer shall submit to Owner a vvritten request for an extension of time within
ten (10) days after the commencement of such delay, and failure to do so shall
constitute a waiver thereof. Owner shall, in its sole discretion, determine whether
and to what extent any extensions of time shall be permitted.
6. Administrative Requirements.
A. The Engineer agrees that the Contract Cost Principles and Procedures, 48 CFR,
Federal Acquisition Regulations System, Chapter 1, Part 31 et seq., shall be used
to determine the allowability of individual items of cost.
B. The Engineer also agrees to comply with Federal procedures in accordance with
49 CFR, Part 18, Uniform Administrative Requirements for Grants and
Cooperative Agreements to Federal, State and Local Governments.
C. Any costs for which payment has been made to Consultant that are determined by
subsequent audit to be unallowable under 48 CFR, Federal Acquisition
Regulations System, Chapter 1, Part 31 et seq., or 49 CFR, Part 18, Uniform
Administrative Requirements for Grants and Cooperative Agreements to State
and Local Governments, are subject to repayment by Consultant to Owner.
D. Any subcontract in excess of $25,000, entered into as a result of this contract,
shall contain all the provisions of this Section 6.
E. For the purpose of determining compliance with Public Contract Code
Section 10 115, et seq. and Title 2 1, California Code of Regulations, Chapter 2 1,
Section 2500 et seq., when applicable, and other matters connected with the
performance of the contract pursuant to Government Code Section 8546.7, the
Engineer, subconsultants, and the Agency shall maintain all books, documents,
papers, accounting records, and other evidence pertaining to the performance of
the contract, including but not limited to, the costs of administering the contract.
All parties shall make such materials available at their respective offices at all
reasonable times during the contract period and for three (3) years from the date
of final payment under the contract. The Owner, Federal, State, the State Auditor,
or any duly authorized representative of the Federal goverm-nent having
jurisdiction under Federal laws or regulations (including the basis of Federal
funding in whole or in part) shall have access to any books, records, and
documents of the Consultant that are pertinent to the contract for audits,
examinations, excerpts, and transactions, and copies thereof shall be furnished if
requested.
CrFY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
7. Data Provided to Engineer.
Owner shall provide to Engineer, without charge, all data, including reports, records,
maps, and other information, now in the Owner's possession, which may facilitate the
timely performance of the work described in Exhibit "A".
8. Independent Contractor.
Engineer is, and shall at all times remain as to Owner, a wholly independent contractor.
Engineer shall have no power or authority to incur any debt, obligation, or liability on
behalf of Owner or otherwise act on behalf of Owner as an agent. Engineer shall not, at
any time, or in any manner, represent that it or any of its agents or employees are in any
manner agents or employees of Owner. Engineer agrees to pay all required taxes and
hold Owner harmless from any and all taxes, assessments, penalties, and interest asserted
against Owner by reason of the independent contractor relationship created by this
Agreement. Engineer shall fully comply with the worker's compensation law regarding
Engineer and Engineer's employees. Engineer further agrees to indemnify and hold
Owner harmless from any failure of Engineer to comply with applicable worker's
compensation laws. Owner shall have the right to offset against the amount of any fees
due the Engineer under this Agreement any amount due to Owner from Engineer as a
result of Engineer's failure to promptly pay to Owner any reimbursement or
indemnification arising under this section.
9. Engineer's Personnel..
A. All services required under this Agreement will be performed by Engineer, or
under Engineer's direct supervision, and all personnel shall possess the
qualifications, permits and licenses required by State and local law to perform
such services, including, without limitation, a City of Carson business license as
required by the Carson Municipal Code.
B. Engineer shall be solely responsible for the satisfactory work performance of all
personnel engaged in performing services required by this Agreement, and
compliance with all reasonable performance standards established by Owner.
C. Engineer shall be responsible for payment of all employees' and subcontractor's
wages and benefits, and shall comply with all requirements pertaining to
employer's liability, workers' compensation, unemployment insurance, and Social
Security.
D. Engineer shall indemnify and hold harmless the Owner from any liability,
damages, claims, costs and expenses of any nature arising from alleged violations
of personnel practices.
10. Compensation..
Payment shall be made by Owner to Engineer for the services and work performed
hereunder within thirty (30) days following receipt and approval by Owner of original
5 CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
invoices therefore. Engineer's fees and charges for the services and work performed
monthly shall be invoiced on a monthly prorated basis, or at such other intervals as may
be mutually agreed upon, based upon the scope of work currently authorized to be
performed under the Notice to Proceed and the total price applicable to those work
elements. The Engineer's total fees and charges for all services and work to be
performed shall be the amount not to exceed $5,160.00 payable based on actual services
delivered as set forth in the Notice(s) to Proceed, and this agreement, and no further
payment shall be made unless specifically specified in this agreement.
11. Indemnity and Insurance.
A. Engineer agrees to indemnify, hold harmless and defend the Carson
Redevelopment Agency, the City of Carson, and their respective officials,
officers, employees, and volunteers from any and all liability or financial loss,
including legal expenses and costs of expert witnesses and Engineers, resulting
from any suits, claims, losses or actions brought by any person or persons, by
reason of injury and arising directly or indirectly from the negligent activities and
operations of Engineer, including its officers, agents, employees, subcontractors
or any person employed by Engineer, in the performance of this Agreement.
Engineer agrees that Engineer's covenant under this section shall survive the
termination of this Agreement.
B. Engineer will deliver to Owner a certificate of insurance in substantially the form
attached hereto as Exhibit "C" evidencing professional liability insurance
coverage in an amount not less than of $ 1,000,000.
C. (1) The Engineer, at its expense, shall maintain in effect at all times during the
performance of work under this Agreement not less than the following
coverage and limits of insurance, which shall be maintained with insurers
listed "A" or better in the Best's Insurance Guide and authorized to do
business in the State of California.
(a) Workers' Compensation and Employer's Liabilfty
1. Workers' Compensation --coverage as required by law.
2. Employer's Liability limits of at least $1,000,000 per
occurrence.
(b) Commercial General LiLbility
3. Combined Single Limit -$2,000,000 per occurrence and in
aggregate -
(c) Automobile Liabilit
4. Combined Single Limit-$ 1,000,000.
CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
The automobile and comprehensive general liability policies may
be combined in a single policy with a combined single limit of
$1,000,000. All of the Engineer's policies shall contain an
endorsement providing that written notice shall be given to Owner
at least thirty (30) calendar days prior to termination, cancellation
or reduction of coverage in the policy.
(2) Policies providing for bodily injury and property damage coverage shall
contain the following:
(a) An endorsement extending coverage to Carson Redevelopment
Agency, the City of Carson, and their respective officials, officers,
employees, and volunteers as additional insureds, as respects
Engineer's liability arising out of the Engineer's performance of
work under the agreement. Such insurance shall be primary
insurance as respects the interest of Owner, and any other
insurance maintained by Owner shall be considered excess
coverage and not contributing insurance with the insurance
required hereunder.
(b) "Severability of Interest" clause.
(c) Elimination of any exclusion regarding loss or damage to property
caused by explosion or resulting collapse of buildings or structures
or damage to property underground, commonly referred to by
insurers as the "XCU" hazards.
(d) Provision or endorsement stating that such insurance, subject to all
of its other terms and conditions, applies to the liability assumed
by Engineer under the Agreement, including without limitation
that set forth in Section I I C, with the exception of willful acts,
errors or omissions.
(3) Promptly on execution of this Agreement and prior to commencement of
any work Engineer shall make available to Owner copies of all required
policies and endorsements to the required policies at the Engineer's head
office in Walnut, California.
(4) The requirements as to the types and limits of insurance to be maintained
by Engineer are not intended to and shall not in any manner limit or
qualify Engineer's liabilities and obligations under this Agreement.
(5) Any policy or policies of insurance that Engineer elects to carry as
insurance against loss or damage to its equipment and tools or other
personal property used in the performance of this Agreement shall include
a provision waiving the insurer's right of subrogation against the Owner.
CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
12. Retention.
The Owner shall withhold, as retention, monies due to the Engineer at the rate of 10% of
all payments of up to 50% of the total not to exceed amount of the contract. Thereafter,
the owner shall withhold, as retention, monies due to the Engineer at the rate of 5% of all
payment of more than 50% of the total not to exceed amount of the contract. The owner
shall release the total withheld retention amount after the Engineer completes all work
per the scope of services provided in the contract.
13. Termination for Convenience.
The governing board of the Owner may terminate this Agreement at any time without
cause by giving fifteen (15) days written notice to Engineer of such termination and
specifying the effective date thereof. In that event, all finished or unfinished documents
and other materials shall, at the option of Owner, become its property. If this Agreement
is terminated by Owner as provided herein, Engineer will be paid the amount currently
due for the work elements authorized to be performed under the Notice to Proceed and
the total price applicable to those work elements, prorated based on the number of days
worked to -date, if any. In no event shall the amount payable upon termination exceed the
total maximum compensation provided for in this Agreement.
14. Termination for Cause.
A. The governing board of the Owner may, by written notice to Engineer, terminate
the whole or any part of this Agreement in any of the following circumstances:
(1) If Engineer fails to perform the services required by this Agreement within
the time specified herein or any authorized extension thereof, or
(2) If Engineer fails to perform the services called for by this Agreement or so
fails to make progress as to endanger performance of this Agreement in
accordance with its terms, and in either of these circumstances does not
correct such failure within a period of ten (10) days (or such longer period
as Owner may authorize in writing) after receipt of notice from Owner
specifying such failure.
B. In the event Owner terminates this Agreement in whole or in part as provided
above in paragraph A of this Section 12, Owner may procure, upon such terms
and in such manner as it may deem appropriate, services similar to those
terminated.
C. If this Agreement is terminated as provided above in paragraph A, Owner may
require Engineer to provide all finished or unfinished documents, data, studies,
drawings, maps, photographs, reports, etc., prepared by Engineer. Upon such
termination, Engineer shall be paid an amount equal to the contract amount, less
the cost of hiring another consultant to complete Engineer's services. In the event
no new consultant is employed, Engineer shall be paid an amount equal to the
value of the work performed. In ascertaining the value of the work performed up
8 CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
to the date of termination, consideration shall be given to both completed work
and work in progress, to complete and incomplete drawings, and to other
documents whether delivered to Owner or in possession of Engineer, and to
authorized reimbursement expenses.
D. If, after notice of termination of the Agreement under the provisions of this
Section 12, it is determined, for any reason, that Engineer was not in default, or
that the default was excusable, then the rights and obligations of the parties shall
be the same as if the notice of termination had been issued pursuant to Section 11.
15. Non -Discrimination and Equal EmploMent Opportunity.
A. In the performance of this Agreement, Engineer shall not discriminate against any
employee, subcontractor, or applicant for employment because of race, color,
religion, ancestry, sex, national origin, handicap or age. Engineer will take
affirmative action to ensure that subcontractors and applicants are employed, and
that employees are treated during employment without regard to their race, color,
religion, ancestry, sex, national origin, handicap or age. Affirmative action
relating to employment shall include, but not be limited to the following:
employment, upgrading, demotion or transfer; recruitment; layoff or termination;
rates of pay or other forms of compensation; and selection for training including
apprenticeship.
B. The provisions of subsection A above shall be included in all solicitations or
advertisements placed by or on behalf of Engineer for personnel to perform any
services under this. Agreement. Owner shall have access to all documents, data
and records of Engineer and its subcontractors for purposes of determining
compliance with the equal employment opportunity and non-discrimination
provisions of this Section, and all applicable provisions of Executive Order
No. 11246 which is incorporated herein by this reference. A copy of Executive
Order No. 11246 is available for inspection and on file with the Engineering
Services Division.
C. To the greatest extent feasible, Engineer shall endeavor to employ residents of the
City of Carson in the rendering of the services required by this Agreement. All
solicitations for employment arising in whole or in part out of the execution of
this Agreement, whether full- or part-time, new or replacement hires, shall be
listed with the Carson Career Center and the Workforce Investment Network
Board. Inforrnation on how to list employment opportunities with these agencies
may be obtained at Carson City Hall.
16. Enizineer's Warranties and Representations.
Engineer warrants and represents to Owner as follows:
A. Engineer has not employed or retained any person or entity, other than a bona fide
employee working exclusively for Engineer, to solicit or obtain this Agreement.
CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
B. Engineer has not paid or agreed to pay any person or entity, other than a bona fide
employee working exclusively for Engineer, any fee, commission, percentage,
gift, or any other consideration contingent upon or resulting from the execution of
this Agreement. Upon any breach or violation of this warranty, Owner shall have
the right, in its sole discretion, to terminate this Agreement without further
liability, or, in the alternative, to deduct from any sums payable hereunder the full
amount or value of any such fee, commission, percentage or gift.
C. Engineer has no knowledge that any officer or employee of the Owner has any
interest, whether contractual, non -contractual, financial, proprietary, or otherwise,
in this transaction or in the business of the Engineer, and that if any such interest
comes to the knowledge of Engineer at any time, a complete written disclosure of
such interest will be made to Owner, even if such interest would not be deemed a
prohibited "conflict of interest" under applicable laws.
D. Upon the execution of this Agreement, Engineer has no interest, direct or indirect,
in any transaction or business entity which would conflict with or in any manner
hinder the performance of services and work required by this Agreement, nor
shall any such interest be acquired during the term of this Agreement.
17. Subcontracting, Delegation and Assi2nnIent.
A. Engineer will subcontract the surveying services, material testing services, and
community awareness and public relations services and other such services as
required to subconsultants as stated in Exhibit "B". The Engineer shall not
delegate, subcontract or assign any of its duties or rights hereunder, either in
whole or in part, without the prior written consent of the Owner; provided,
however, that claims for money due or to become due to Engineer from Owner
under this Agreement may be assigned to a bank, trust company or other financial
institution without such approval. Any proposed delegation, assignment or
subcontract shall provide a description of the services to be covered, identification
of the proposed assignee, delegee or subcontractor, and an explanation of why and
how the same was selected, including the degree of competition involved. Any
proposed agreement with an assignee, delegee or subcontractor shall include the
following:
(1) The amount involved, together with Engineer's analysis of such cost or
price.
(2) A provision requiring that any subsequent modification or amendment
shall be subject to the prior written consent of the Owner.
B. Any assigrunent, delegation or subcontract shall be made in the name of the
Engineer and shall not bind or purport to bind the Owner and shall not release the
Engineer from any obligations under this Agreement including, but not limited to,
the duty to properly supervise and coordinate the work of employees, assignees,
delegees and subcontractors. No such assignment, delegation or subcontract shall
10 CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
result in any increase in the amount of total compensation payable to Engineer
under this Agreement.
C. Any subcontract in excess of $25,000, entered into as a result of this contract,
shall contain all the provisions stipulated in this contract to be applicable to
subconsultants.
18. Ownership of Documents.
All plans, specifications, reports, studies, tracings, maps and other documents prepared or
obtained by Engineer in the course of performing the work required by this Agreement
shall be the property of the Owner. Basic survey notes, sketches, charts, computations
and similar data prepared or obtained by Engineer under this Agreement shall, upon
request, be made available to Owner without restriction or limitation on their use. Any
reuse of documents, prepared solely under this contract, by Owner for other projects or
other purposes shall not be the responsibility of the Engineer. The Owner shall hold
harmless and indemnify the Engineer from any and all liabilities arising from the reuse of
documents.
19. Entire Agreement and Amendments.
A. This Agreement supersedes all prior proposals, agreements, and understandings
between the parties and may not be modified or terminated orally.
B. No attempted waiver of any of the provisions hereof, nor any modification in the
nature, extent or duration of the work to be performed by Engineer hereunder,
shall be binding unless in writing and signed by the party against whom the same
is sought to be enforced.
20. Resolution of Disputes.
A. Disputes regarding the interpretation or application of any provisions of this
Agreement shall, to the extent reasonably feasible, be resolved through good faith
negotiations between the parties.
B. If any action at law or in equity is brought to enforce or interpret any provisions
of this Agreement, the prevailing party in such action shall be entitled to
reasonable attorneys' fees, costs and necessary disbursements, in addition to such
other relief as may be sought and awarded.
21. Exhibits.
The following exhibits to which reference is made in this Agreement are deemed
incorporated herein in their entirety:
Exhibit "A" Scope of Services
Exhibit "B" Professional not to exceed fees
CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
Exhibit "C" Professional Liability Special Endorsement or Insurance Company's
Certificate of Insurance
In the event of any material discrepancy between the express provisions of this
Agreement and the provisions of any document incorporated herein by reference, this
provisions of the Agreement shall prevail.
22. Governing Law.
This Agreement shall be governed by the laws of the State of California.
23. Effective Date.
This Agreement shall become effective as of the date set forth below on which the last of
the parties, whether Owner or Engineer, executes said Agreement.
12 CITY OF CARSON/
ASSOCIATED SOILS ENGINEERING, INC.
IN WITNESS WHEREOF, the parties have executed and entered into this Agreement as of the
date first written above
ATTEST:
f A 16
OET
HELL�'S KA)�VG 1�,MC/PMC
CITY CLERK
APPROV AS TO FORM:
City Attorney
CITY:
CITY OF CARSON,
a municip4l corporation
MAYOR JIM DEAR
Corporations require two notarized signatures: One from each of the following: A. Chairman of
Board, President, or any Vice President: and B. Secretary, Assistant Secretary, Treasurer,
Assistant Treasurer, or Chief Financial Officer).
CONSULTANT:
By:
Signature (Notarized)
60, W&A is e.
Print Name & Title
By:
Signaturl (Notarized)
Arlo
CANI&I �'yt&
Print Name & Title
Mailing Address: Z%C' LAJAI-A AVC.
-,�, " W 75��
Taxpayer Identification No:
13 CITY OF CA
RP
, RN/
ASSOCIATED SOILS E R , C.
CALIFORNIA ALL-PURPOSE ACKNOWLEDGMENT
State of California
County of U 5 k---. C -S
On ZS. I I -00c) before me,
Date Here insert Name and Title of the Officer
personally appeared L A , �\ S N �-,3 1-\ L,
Name($) of Signer(s) —
JEFF HERGESTEIMER
Commission # 1703733
;i California K
Notary Public >
Los Angeles CounTy
MyC nm.ExpiresNov9,2010
Place Notary Seal Above
who proved to me on the basis of satisfactory evidence to
be the person(s) whose name(s),A/are subscribed to the
within instrument and acknowledged to me that
h�/sye/they executed the same in hjg/6/r/their authorized
capacity(ies), and that by his/her/their signature(s) on the
instrument the person(s), or the entity upon behalf of
which the person(s) acted, executed the instrument.
I certify under PENALTY OF PERJURY under the laws
of the State of California that the foregoing paragraph is
true and correct.
WITNESS my hand and official seal.
Signature
Signature of Notary Public
OPTIONAL
Though the information below is not required by law, it may prove valuable to persons relying on the document
and could prevent fraudulent removal and reattachment of this form to another document.
Description of Attached Document
Titl e or Type of Docu ment: 1114 e--AA501'j VAIA L_ 55QV, e_-�
Document Date:
Signer(s) Other Than Named Above: _coy&
Capacity(ies) Claimed by Signer(s)
Signer's Name: Z5�> ", A4��
1-1 Individual
Corporate Officer —Title(s): PkesloizUT—
Partner — El Limited Ll General
�:1 Attorney in Fact
Trustee Top of thumb here
Guardian or Conservator
Other:
Signer Is Representirl5l:
Number of Pages:
d � je6i5-te;,-,,7—
Pil
Signer's Name: !�,Q,4 ir 4 WU k 4
El Individual
?�Corporate Off icer — Title(s)���Ux -C�
Ll Partner — El Limited El Gen�ral
El Attorney in Fact
Ll Trustee
El Guardian or Conservator
Ll Other:
Signer Is Representing:
lat6,0r, C)l 's
RIGHTTHUMBPRINIT
OF SIGNER
Top of thumb here
02007 National Notary Association - 9350 De Soto Ave., PO.Box 2402 -Chatsworth, CA 91313-2402- www.NationaiNotary.org Item #5907 Reorder: Call Toll -Free 1-800-876-6827
MAR -23-2009 05:03P FROM:ASSOCIATED SOIL S ENG 5624261842 TO:913108355749 P.2
---- -- �age:'002
AMOR-D. CERTIFICATE OF LIABILITY INSURANCE
DATE ("MwYVj
1
CERTIFICATE MAY BE TSSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY TRIP POLICIES DESCRIBED 9ERFTN IS SUBJRCT TO ALL THE
3/23/2009
I-RODUCE14
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
Dealey, Renton & AsgctziaLes
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
F. 0. Box 10550
Santa Ana CA 92711-0550
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
GENERAL LIARLITV
INSURERS AFFORDING COVERAGE
IMUR40
Associated Sails Enqinearing, Inc.
2860 Walnut: Avenue
INSUHLRAHudson insurance gQMany
IN!qURI--R R
FIRE DAMAGE (Any ckne Are) S
Signal Hill CA 90755
-INSURIERC
INSURER 1)
INSURER F
r-CIVERACES
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSX1RED NAMED ABOVE FOR THE POLICY PERIM INDICATED.
NOTW17HSTANDING ANY REQUIREMENT, TEM OR CONDITION Or ANY CONTRACT OR CTII=R DOCUMENT WITH RESPECT TO WHICH THIS
CERTIFICATE MAY BE TSSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY TRIP POLICIES DESCRIBED 9ERFTN IS SUBJRCT TO ALL THE
TFRMS, rXCLUSTONS AND CONDITIONES OF CUCH POLTCTES- ACCRECATE LIMTTS SWOWN MAY HAVE BERN RrIMCED BY IPATn CLAIM-
INSR
FIN
I ryph Op INSURANCE
POLICY NUMBER
POLICY EFFECTIVE
POLICY SMIRATION
DAIEINININ)OHY1
LINIS
GENERAL LIARLITV
EACH OCCURRENCE $
FIRE DAMAGE (Any ckne Are) S
GOMMFRCIAL CFNhHAI- LIABILI ly
MED FXP (Any am pamn).-- $
CLAIMS MAnr, FIOCCUR
PFRSGNAI & ADV INLIUIRY
OFNENLAi AGGRFGATF
GENLAMREGATFLIMITAM�LIFS PER
PROOLICTS - COLIPIOP ArG $
-7 PRO F-1
POLICY I jrrT LOC
AUTOMOBILE
LIABILITY
COMBINECISNOILE! LIMII
ANY AU1 0
(Fa mcddwt)
BODILY INJURY $
ALLaWNE0AUFrOS
SCHEDULEDAUTOS
HIRFIGAUTUS
RnnILy WURY
NON-OVWFD AVITIS
(Por acadmt)
PROFIEWYCAMAGE $
(Pof wzwwi)
GARAGE LIABILJTY
AUTO ONLY h�F
OTHER THAN FA ACC $
ANYAUJO
AUTO ONLY AGO 6
EXCEaSLIABILI[V
EACH OCCURRENCE_ 5
AGGREGATE -
OCCUR 71 CLAIMS MADE
DEDUCTIBLE
REWNT [ON $
WORKERS COMPENAAFION ANI)
EMPLOYGRG'UAUIUTY
E L EACHACCIDENI $
E1.01SLASE EAEMPLOYEE S
L L 0ISIJkSjL - POLICY LJNnT
A
OTHER
AEE7197202
.12/l/200B
12/1/2009
P r C I a I M $1, non, coo
Professional Liability
A:nua! Aqgr. $2,C00,000
Claims Made
ULOCRIPTION OF OPERATION SILOCA FIONSIVFHICUESIEXCLU SIONS ADDED UY LNOORSENIEN USPECIAL PROVISIONS
PT. Anniial Rlurry Seal Proqram
INSUNIER
C!3-ty Of CarSOn
Attn: Rick Botitron
)01 E. Carson St.
Carnon CA 90749
OULD ANY Or I=, ABOVE DESCRIBED POLICIES BE CANCELLED
PORE THE RXPTRATTON nATR THFRFOP, THE TSSUTNC TNSURFR
LL ENDEAVOR TO MAIL 30 DAYS WRITTEN NOTICE TO THE
RTIPICATF HOLDER WA161ED TO THE LEFT, BUT FAILURE TO DO SO
RLL IMPOSE NO OBLTQATIOW OR LIABILITY OF ANY FIND UPON
9 INSUkER, TTS AGENTS OR REPRESENTATTVES.
AUTHORIZED
MAR -23-2009 05:03P FROMASSOCIRTED SOILS ENG 5624261842 TO:913108355749 P.3
rrom: jenna minnen 10. 1 DOZICeo I O'+Z rdgc- &V UdLa. 1V4j1zUVV 0.44.lp I r%vvl
ASSOS,01-011 HIJE
AC 2RQ
,,, CERTIFICATE OF LIABILITY INSURANCE
DATE (MAWWMV)
I 312312009
PRODUCER (888) 1254322
Bowermaster & Associates
P.O. Box 6026
10805 Holder Street - Suite 380
Cypress, CA 90630
THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION
ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE
HOLDER. THIS CERTIFICATE DOES NOT AMEND, EXTEND OR
ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW.
INSURERS AFFORDING COVERAGE
NAIC 0
�K_suRED __ Associated Soils Enigirkoering, Inc.
2880 Walnut Avenue
Signal Hill, CA 90765-
INSURM k Travelers lndemntty Company of CT
Nsumm a.. Travelers Propert & Casualty CID of Amoy
INSURER C:
GENERAL LIABILITY
. ......
INSURER D�
$
INSURER E!_
RMMMES (FA omwencb)
^%M A�=C
THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABCWI! FOR THE POLICY PERIOD INDICATED. NOTWITHSTANDING
ANY REQUIREMENT. TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR
MAY PERTAIN, THE INSURANCE A5FORDED BY T14E POLICIES DESCRIBED HEREIN is 5UEQECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH
POLICIES, AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS,
UMITS
POLICY NUMOM I
1.000,000
GENERAL LIABILITY
EACH OCCURRENCE
$
A X X COMMERCIAL GENERAL LIABILITY 6802254MIS7 V912008 41912009
RMMMES (FA omwencb)
-3 100,0001
ff, CLAIMS MADE I X � OCCUR
MEDMP(AnyawE!rvtF!L
5 5,00
PERSONAL &A11V INJURV
S i'()0G'wq
GFNFRAL AGGREGATE
S 2,000,1XIC
GrNI-AGOREGATE UMJI APPLIES MR:
PRO rs - cOMF4P AGO
S 2,000,00(
POLICY IF"
'jj�X] PRO- Lac
AUTOMOBILE
LIABILITY
COMBINED 31NULe LIMR`
S
B
X
X
BA2254M794
41912008
41912009
(Ea
ANY AUTO
ALL OWNED AUTOS
SOOLY INJUIty
(Per parw)
. ..........
IT
SCHEDULED AU rO8
.. ..
BODILY INJURY
WRE-0 Attros
ift1wZident)
NON -OWNED AtrrOS
PROPERTY DAMAGE
GARAORLIABILITY
ONLY - FA ACCIDENT
S
-AUTO
OTRER THAN EAACC
$
ANYAUTO
AUTO ONLY AGO
S
—
EACH OCCURRENCF
S 3,000,w
13
EXCESSIUMBRELLA LIABILITY
OCCUR CLPJMSMQDE
CUPS474YI413
V9=08
41912009
AGCnECATE
DEDUCTIBLE
RETENTION
A
WORKERS COMPENSATION AND
EMPLOYERS' LIABILITY
UB7092YR62
71V2008
M12009
F L, CACH ACCIDENT
9 11000,000
E L DISEASE - FA EMPLOYEE
5 130(10,00C
ANY PROP111FTORIPARTMERIEXECUTNE
OFFiCER44EMBeR EXCLUD509
14E -POLICY LUT S
El DISM
1,066,000
"be ull�
if lZu
SrEdI 'SIONS bialow
P
OTHER
DESCRWhON OF OPFRAYIONS ILOCATIONSIV F-3 f EXCLUSIONS ADDED By ENDORSEMENT I SPECIAL PROVISIONS
�11 0 Day Notice of Cancellation for Mon -Payment of Premium.
RE: Annual Slurry Seal Program, ClItywide
The City of Carson Is Additional Insured as respects to General Liability, per fwm CG03810906 attached.
nVLU
City of Carson
701 E. Carson Street
Carson, CA 9074B-
'K%'Vf%Lj.&0 JAUU 11%001
SHOUW ANY OF THE ABOVE DESCRMVD POLICIES Of CANCELLED BUM THE EMRATION
oATra TKReoF, THE ISSUING IMRERWILL ERMAVORTOMAIL 3q_ vAYswRnrEM
NOTICE TO THE CER70FIG^rE HOLDER NAMED TO THn LEFT, BUT FAILURE To Do So SMALL
jVpOSE No oaLtOATION OR UAINLITY OP AMY KIND UVON THE INSUREX ITS AGENTS OR
AUTHOFL70
la66—RD C&1i�0__F1kf*_N I isf
MOR -23-2009 05:03P FROM:RSSOCIRTED SOILS ENG 5624261842 TO:913loe355749 P.'q
ASSOSOI-01 HIJE
IMPORTANT
If the certificate holder is an ADDITIONAL INSURED, the policy(tes) must be endorsed. A statement
on trils certificate (toes not confer rights to the cedificate holder in lieu of such arxiorsement(s).
If SUBROGATION IS WAIVED. subject to the terms and conditions of the policy, certain policies May
require an endorsement. A statement on this cerUficate does not confer rights to the certifficate
holder in lieu of such endorsemeni(s).
DISCLAIMER
The Certificate of Insurance on the reverse side of this form does not Constitute a contract between
the issuing insurer(s), authorized representative or producer, and the cartificate holder, nor does It
affirmatively or negaUvely amend, extencl or alter the coverage affordpd by the policies listed thereon.
ACORD 26 (2001108)
MAR -23-2009 05:04P FROM:ASSOCIATED SOILS ENG 5624261842
Asgoditeid:40111[s
68a2264MI67
'Effective: 4?9148 t*,419)00
A..
'L
3.
TO:913108355749 P.5
t6fAMOICAL t3MERALWAUTY
THISf ENDORSEWENT CHANGE&THE FbLlt'y' OLEASO "AD rt eAREFLiLLY.
BLANKET AMT16NALIMSUR15-0
(ARCHITECTS1,JE . NGINMASAND 9URVEYORS)
loo,mAA8RC t�ENERAL. UNMUTI? cOVEJUGE PARY
W!40-!S,AN 1'MVUki5&JSectiofi 111)'lk 96016606
inoudean per4oij.0ro_Manfzeftn-thOt-YOu-69TOO
.Y
1(t.a 'con tratt Dragwilmerd- M
,
to Induoi,-as'a?i oddfron'd1".l"30* On this,covor;
-age Pall, t1w.,
mr Only mit.h a Uatfility for'budily Injure-,
orrupf§ffy orl!omorml Injury*; ' and
b- .11"Itid IdjuN -& daiwid0d- jrJ58$'60'iDf the Ott -
10 M -an* by. Vroft twytiue subdxlnftWo�. 'Pf,
"your worV. to:whkh kbe "an"all - bt Alftic-
.rne9t -Y-vW.-r
,kV IhsurapW apoles-Suelt 0&�,
soft :worgiKikation doevpio� qualify ps an
addhi�rlal Jrvt�jmd -vAth -rIespa-c!t to ifief r J`ndp-
p0ricidnt 'ws or for '.rxodity vnjuy.
-darniiWI* Or 'pOrsondl blutY' fbr wh'O. Mat
pemon,ov orgar&AfM� MS jisibft�dd Ilabill(V
The fnsu(anta: V?Wkkd to tho:additiorlbf itfwrlbd
01his OiRlor�ertWnl]s "lidd awfUlIdwst
u. ljhis kit=nca Was nof appilyorr xrTbasis.*
-anV 7W�wh of,dilganizatiort for.which -cover.
-age s*S An -Oddifl is.
addiad by, a-mothet eriddrsd0nent:1o, f* 6;vtv.6
a�$ Pait,
b.- This insurince doos jm t -aWy to 1he Mnder�
i)t
!Ing:of :*prolessional
We to m,nder any
c. lhe. llinitt V 1h9ikgWcb ANdided lo ifiers'dd'p
11orwal 'insured shah be '11her ririlitd. M11611 9w
agreed -to. provide in Ahak"cootradt or zarae6
Meql.�mquinng #0suraAce-j. -or-'the liv*&O-own
�In toe beilar4dons I I�byerage Part,
whictleyor are TNs e ndoMMOK.- does
th#-ffM1r1f bF lnsuranLo sialoffl.n
(hb LIMMOVINSUR-ANCg flli)Jer,
ift adv6rAp
Th*-'h*dvAAQ is add0d 10' Pgragrapo- ;'4 vt 1C
*1ther ThsiRadeb its 664MtRd!At-. -GOP-RAL
11AIMIL117Y CONDMONS (SM11dr! IV).
4.
' d�61
provided 116 iki ddditibridi 'Ifiluted uAder M C60-
eMe Pad -must appf� -06'-9 MMOT bWS, Ve d
WIMpry p�*),nonicoro"Gry b"Si. this INISUMM6
-is odmat-k jo''*er , Insufarice be is wallatile !a'
kith autleInai 1muted -w" r4yefistich acfdl-
fidii.al kj6trft0 M'.'a'dahM inpatO,-Arlif m& -Will. -not
shafe; Wtb OW atiferIftu're h rA,'0-ro(jWd Mat
%odly.injue vr !'.'proper�jdmagO' (or
*N* 6uvarpowls sbludht owum and
�fii' -00eimml 1hor (of Whith uw is
sawg hk Arises out W irfidUM66 ObiNfftkil
ace ru Ifave -orgentil Ird'o. t"Pt, �ed*ad 60
-6grortr66M )*JkjKvW- JAWWW. But WIS JhSuf-
�Pcv'affl is-.&x6bM--bv0'V , a lid a . 9w wNdfibWohet
insurancgowwheupfifflary, -excbsl. 66011kV661 br
pn any oilief Omis, *W11smavagabiffic the Irisukid.
,mart the Insutod is wl addR*a.l ifiwed under
WOW iiisuranml
The- ful (cwA, h 0 -b atkied W _P a4ig �_S. 0-1- .4' Trbhiki
J:W RlgWtir Of �Racovery A46644-0theis TOM
-in dbmMi9RcixL OERMAL UARIUTV COW
fgection ft
W
-, we Ay, ave
6 VA
against, Rimy nibrk & arg4iftaitI0 1ibimbW bf
pe
psVmentswu make for wtZdfly Idjure. lowpedy
4amageO t..6r Versonat WW� artWng duf bf '�*yd&
,work0;pv'#oTmod,by,yw.*or an your behalf, under-
' nf.requirinlyInsuran6e wiltv
A-n9t. pd-tsog. or otgawabPff. Wo� 901WR Ihm
-Nntgo,Vy hhve agtwed,to do, po- as
Wly tlich Orsod or dfU6fliWl6.rr entdftd
Intd by.ybu.beioi*,. aM Iii'040(wheb. R*Oddillj
-injury' w #'�PrCpedy damage- - accuM Of the Aw-
'S. AA F11g0ktt I proiViddld 16.11W oddi-
,tionel insured by INS 1ei1ddft0M6ht (heRMWW
CG'0*41 2 0-61
Fade -1 of 2
Mat
,MAR -23-2009 05:05P FROM:ASSOCIATED SOILS ENG 562q26ie42 TO:913108355749 P.6
'Will.
C0MUERCM--GEW.AA1; U.AWL1T*
:iilcoWad of agre;eMent entered AtO iNal torilract ar
-al- -Aftee'YOU7 hAva
-means thal part OfSn� dbdfi�4 df, A&—kM''ent 0A.- 00(86��;-
der lwhk_h- you are rcqcdredAcY,-fndud&..1 06(tiM dt Whowifini imft dutho'bdAtrict
'm -:as *afv ad0onal rnsured- ov,1t&.r_ov- ; and
glWalijoa.
grago -.Paft, pro ded-1hat ihw 'bodily-1*W- and
4 tc. #afte t"e and. if, Pd#q'PB�W.
prop -eft" danvao6ll -OMM.. SO he "Porsonal in -
'go commiked: Al 4ibeffemts-bf VoUf*0ovcyT.efvia1r);1ft sania;
Page 2 of 2
$I dij tit
City of Carson
Report to Mayor and City Council
March 18, 2009
New Business Consent
SUBJECT: CONSIDER AN AWARD OF A CONSTRUCTION CONTRACT FOR PROJECT"
NO. 1301: ANNUAL SLURRY SEAL PROGRAM, CITYWIDE
Submitted by M. Vi&Wa_01_fiW;6�_
Development Services General Manager
SUNMARY
Approved tYckrAne 11r Groomes
On February 3, 2009, the City Council approved plans, specifications and
estimates (PS&E), and instructed the staff to advertise the work and call for bids
for Project No. 1301: Annual Slurry Seal Program, Citywide (Exhibit Nos. I
and 2). Four bids were received and opened by the City Clerk on March 4,
2009. The lowest responsible bidder is American Asphalt South, Inc. with a bid
in the amount of $300,394.72.
This project is subject to the requirement of the city's master Project Labor
Agreement (PLA). The selected contractor and all subcontractors have an
obligation to comply with all of the terms of the PLA.
RECOMMENDATION
TAKE the following actions:
1. AWARD a construction contract for Project No. 1301: Annual Slurry Seal
Program, Citywide in the amount of $300,394.72, to the lowest responsible
bidder, American Asphalt South, Inc.
2. AUTHORIZE construction contingencies in the amount of $45,060.00 (15 %)
for change orders such as the removal and remediation of contaminated soil,
substructure conflicts, and other unforeseen construction work that may be
required to complete this project.
3. AUTHORIZE the Mayor to execute the contract following approval as to
form by the City Attorney.
4. AUTHORIZE a material testing service agreement in the amount of
$5,160.00 by Associated Soils Engineering, Inc. Consulting Geotechnical
Engineers.
5. AUTHORIZE the Project Labor Agreement service fees for monitoring and
compliance of construction in the amount of $2,800.00 (1 %) by The
Employee Consulting Group, a management -labor relations consultant.
City of Carson Report to Mayor and City Council
March 18, 2009
III. ALTERNATIVES
1. REJECT all bids.
2. TAKE another action the City Council deems appropriate.
IV. BACKGROUND
The Annual Slurry Seal Program is listed in the city's Capital Improvement
Program (CIP) for FY 2008/09.
In recent years, the city has been utilizing rubberized slurry seal, which has
superior benefits over conventional slurry seal. The project locations were
selected based on the recommendation of the city's Pavement Management
System (PMS) MicroPaver Program and the available budget. In an effort to
obtain an economy of scale, staff concentrated on one section of the city within
maintenance zone no. 4 that is in the highest need for this type of surface
treatment, in order to prevent deterioration of existing pavement.
This section is bordered by 213th Street, 220th Street, Wilmington Avenue and
the 1-405 freeway.
The attached Location List identifies the street names and limits of the slurry seal
areas (Exhibit No. 3).
The PS&E was prepared by city Engineering Division staff.
On February 3, 2009, the City Council approved PS&E, and instructed the staff
to advertise the work and call for bids for Project No. 1301: Annual Slurry Seal
Program, Citywide.
On March 4, 2009, four bids were received and opened by the City Clerk as
listed below:
Bidder
1. American Asphalt South, Inc
2. Bond Blacktop, Inc.
3. All American Asphalt, Inc.
4. Pavement Coatings Co.
Place of Business
Total Bid
Fontana, CA
$300,394.72
Union City, CA
$325,880.64
Corona, CA
$335,998.60
Cypress, CA
$338,592.08
Staff has reviewed the bids and finds that the lowest responsible bidder,
American Asphalt South, Inc. is a bona fide contractor licensed by the state of
California. The bid bond, in the amount of 10 % of the total bid, as supplied by
The Guarantee Company of North America USA, under the laws of the state of
Michigan is in order and was submitted with the bid. The contractor 9 S
references have been checked, and it has been verified that the contractor has
completed similar projects in an acceptable manner.
0,
City of Carson Report to Mayor and City Council
March 18, 2009
The contractor is not a member of the Construction Labor Union of Southern
California; therefore, the contractor must join the Construction Labor Union of
Southern California, for this project only, to comply with the PLA requirements.
There will be a need to use the services of The Employee Consulting Group, a
management -labor relations consultant for monitoring and compliance of
construction.
This project requires the engagement of a materials testing firm. The city has
utilized the services of the county of Los Angeles and several private consultants
for the field observations, material sampling and testing services. On
February 24, 2009, Engineering Services solicited proposals for these services
from Associated Soils Engineering, Inc. and Hushmand Associates,
Incorporated. On March 2, 2009, two proposals were received and rated by
staff. The lowest responsible and responsive proposal was from Associated Soils
Engineering, Inc. in the amount of $5,160.00.
The accomplished and anticipated timeline for this project is as follows:
Approval of PS&E
Completed
Advertise Notice Inviting Bids
Completed
Award of construction contract
March 18, 2009
Completion of construction
May 2009
V. FISCAL IMPACT
The total estimated construction cost of this improvement project is $383,000.00.
Funds for this project, in the amount of $250,000.00, are included in the
FY 2008/09 budget, which is a combination of Proposition 1B-LSR funds in the
amount of $125,000.00 and the Agency fund in the amount of $125,000.00.
However, it is proposed to substitute Agency funds with Proposition 42 funds.
In addition, funding provided by utility companies who pay an in -lieu fee when
applying for excavation permits, which is deposited in the Slurry Seal
Account -71 fund, will be utilized for this project. As of March 4, 2009, the
balance of this fund is $135,155.66. The project funding sources, account
numbers and the amounts are as follows:
Fund Source
Account No.
Amount
Proposition 42
67-80-500-004-7020/0130 101
$125,000.00
Proposition lB-LSR
66-80-999-004-7020/0130 101
$125,000.00
Slurry Seal Account -71
71-00-999-000-2401/3046503
$135,155.66
TOTAL
$383,641.62
City of Carson Report to Mayor and City Council
March 18, 2009
V1. EXHIBITS
1. Location Map. (pg. 5)
2. Minutes, February 3, 2009, Item #9. (pg. 6)
2. Location List. (pgs. 7-12)
G:\ENGINEERING DIVISION\PROJECTS\1301 Annual Slurry Seal FY 2008-09\AGENDAS\03-18-09 CC AWARD CONSTRUCTION
CONTRACT.doc
Prepared by: Rick Boutros, P.E., Associate Civil Engineer
sf:Rev06l9O2
Reviewed bv:
City Clerk
City Treasurer
Administrative Services
Development Services
Economic -e4bpm�fit Services��'-'
P
Public Services
V J
Date
Action taken by City Council
Action
III
> d)
> F- rn
S'T
<
> C RI
2 3THV
\\Sft\\VAXJ1-,
213TH ST
T 0
r
27H ST
rT --q
-S-USAN-DR iiiiiw
T
ORD-ST-;,i� z 214TH S/T
G E 2 4T M
2 5 H S
CALIFON --i
C'. Lrr I >
<
215TH P 215TH ST 2177H �PL ------------
Cn 2 6TH S j
0
CARSON ST 0 >
-CARSON 8 1
>
HIV ILL ST 0
w
> M
C 'ER13 w > >
<
C > < M
2.1 8TH ST w z
pi
8 H > LU
w >
< < AB
M
CCALBAS ILA. S
-2)�THST\ >
LU > M14
T
S T r
GkOVE
n
LU -R\ rn ABILA ST 2 �1 ST
k�'� " I i\
C' 06Ltz -"J
00,
r 'idship
r JJ" F Lne i
Pafk
> A M
-ABRI,
F
�ST >�
ark JAY T 7
-R
ENTON M
M
22
--JOEI:--ST-'! --405-FRE-EWAy---
-223RD 22 3RD ST
r
M
91
6
T
C::)
C)
Project 1301
Qw� Slurry
Location Map
Project No. 1301
Annual Slurry Seal Program (Section 1)
12123f2008 EXHIBIT NO. I
MXD: GAENG NEER ING DIVISIMI-ocalon MapsWXD5�Projedl 301 Ex fibal ;-d
PDF G:'ENGINEERING DIVISIOWI-ocation Map&\ProjeOl 301 Exhibdl pdf
Unofficial Until Approved By
City Council
ITEM NO. (9) CONSIDER APPROVAL OF PLANS, SPECIFICATIONS, AND ESTIMATES
AND AUTHORIZATION TO ADVERTISE FOR BIDS FOR PROJECT NO.
1301: ANNUAL SLURRY SEAL PROGRAM, CITYWIDE
(DEVELOPMENT SERVICES)
RECOMMENDATION for the City Council:
TAKE the following actions:
APPROVE the plans, specifications, estimates, location map, and location list and order
the work for Project No. 1301: Annual Slurry Seal Program, Citywide.
2. AUTHORIZE staff to advertise the work and call for bids for Project No. 1301: Annual
Slurry Seal Program, Citywide.
ACTION: It was moved to approve New Business Consent Item Nos. 7, 8, 9, 10, 11, 12, 13,
14, and 15 on motion of Dear, seconded by Gipson and unanimously carried by the following
vote:
Ayes: Mayor Dear, Mayor Pro Tern Gipson. Council Member Santarina, Council Member
Williams, and Council Member Davis -Holmes
Noes: None
Abstain: None
Absent: None
rAl
Ca -on City Council
February 3, 2009
PAGE 14
r—%,Fs &.Aft — —
Annual Slurry Seal Program, Citywide -Project No. 1301 FY 2008 /09
Name
From
To
Section
Rank
Surface
Length
Width
True Area
213TH ST
SELWYN AVE
CHICO ST
C
ss
955
40
38,200
213TH ST
CHICO ST
TROYTON LN
C
ss
175
38
6,650
213TH ST
TYOYTON LN
THOMAS DR
C
SS
640
38
24,320
5:'�`; 213TH ST
THOMAS DR
ALVAR PL
C
SS
265
38
10,070
213TH ST
ALVAR PL
PERRY ST
C
ss
265
38
10,070
.7",.2113TH ST
PERRYST
WEISER AVE
C
ss
785
38
29,830
213TH ST
WEE' ER AVE
VERA AVE
C
SS
535
38
20,330
213TH ST
VERA AVE
LOSTINE AVE
C
SS
815
38
30,970
213TH ST
LOSTINE AVE
C
ss
260
38
9,880
213TH ST
LEGEND AVE
MARTIN ST
C
SS
275
38
10,450
213TH ST
IN S
PONTINE AVE
C
ss
305
38
11,590
�iw
"IX1.7- 213TH ST
PONTINE AVE
MILPOINT AVE
C
ss
390
38
14,820
213TH ST
INT AVE
WATER ST
C
ss
280
38
10,640
213TH ST
WATER ST
OAKFORT AVE
C
SS
760
38
28,880
16.- 213TH ST
OAKFORT AVE
WILMINGTON
C
SS
310
38
11,780
17 214TH ST
WEISER AV
END(E)
0
AC
435
26
11,310
18 214TH ST
AV
END(E)
0
AC
590
34
20,060
1 9 214TH ST
WATER ST
END (E)
11
0
ss
560
28
15,680
21STH PIL
VERA AVE
LOSTINE AVE
0
ss
810
32
25,920
215TH PL
ALVAR PL
PERRYRT
0
ss
250
32
8000
22.- 215TH PL
0
AC
415
Maint. AREA # 4
LOCATION LIST.1
3/2/20
EXHIE31T NO.
0 2
Annual Slurry Seal Program, Citywide -Project No. 1301 FY 2008 /09
To
Section
Rank
Surface
Length
FWidth
TT.eA,.a
,�r:.23'��"" 215TH PL
ROSITA DR
PERALTA DR
36
9,000
x 4', 215TH PL
LOSTINE AVE
LEGEND AVE
0
AC
275
36
9,900
215TH PL
LEGEND AVE
MARTIN ST
AC
255
36
9,180
��i 21 STH PL
MARTIN ST
WATER ST
0
AC
1,145.00
36
215TH PL
WATER ST
END (E)
0
ss
386
30
11,580
28 215TH ST
WEISER AV
END (E)
-
0
ss
415
32
13,280
29 215TH ST
WATER ST
END (E)
0
SS
475
32
15,200
Z, "216TH ST
PERRYST
ROSITA DR
0
AC
225
36
8,100
w'216TH ST
ROSITA DR
PERALTA DR
NO!
0
SS
325
36
11,700
Pl� 216TH ST
PERALTA DR
WEISER AVE
0
AC
248
36
8,928
216TH ST
WEISER AVE
END(E)
0
Ss
460
26
11,960
34 218TH ST
VERA AV
END(E)
0
AC
575
30
17,250
35 218TH ST
WATER ST
OAKFORT AVE
0
SS
330
32
10,560
36 218TH ST
END(W)
ACARUS ST
0
SS
180
30
5,400
37 218TH ST
LOSTINE AVE
MARTIN ST
0
AC
440
34
14,960
219TH ST
WATER ST
END (E)
0
ss
170
30
5,100
39 220TH ST
LOSTINE AVE
MARTIN ST
C
ss
500
24
12,000
40 220TH ST
WATER ST
WILMINGTON AVE
C
ss
165
26
4,290
ABILA ST
END(E)
VERA AVE
0
AC
505
30
15,150
ABILA ST
END(W)
MARTIN ST
0
AC
605
30
18,150
43 ABILA ST
END (E)
0
ss
130
Maint. AREA # 4
LOCATION LIST.2
3/2/2009
Annual Slurry Seal Progratnq Citywide -Project No. 1301 FY 2008 /09
Name From ITo
44 ACARUS AVE
VERA AVE
45 ACARUS AVE
DABLON AVE
ACARUS AVE
WEISER AVE
47 ACARUS AVE
218TH ST
48446
ACARUS AVE
CLOVERBRO ST
49 ACARUS AVE
ASHMILL ST
ALBREDA ST
MARTIN ST
51 ALVAR PL
215TH PL
5��ALVAIR PL
_4A
WINGATE DR
—
40
9,200
ANNALEE AV
:NALEE AV
: AN
DOMIN
DOMINGUEZ ST
BALARD . T
54 BALARD ST
PONTINE AVE
.55 BALARD ST
MILLPOINT AVE
AC
565
40
22,600
,56.'.�'' BEDMAR ST
BELSHAW AVE
57 BELSHAW AVE
DOMINGUEZ ST
58 BELSHAW AVE
BURGROVEST
- V
36
BONITA ST
END(S)
60 BURGROVEST
BELSHAW AVE
61 BURGROVEST
TILLMAN AVE
62 CALIFON ST
�:7�
�MARTIN �ST
63 CARSON PLAZA CT AVALON BL
54 CARSO:N PLAZA :DRJDEL AMO BLVD
DABLON AVE
WEISER AVE
?18TH ST
CLOVERBRO ST
C CARSON ST
A SON ST
END (E)
WINGATE DR
213TH ST
BURGROVEST
MILLPOINT AVE
WATER ST
BELSHAW AVE
BEDMAR ST
[END(N)_
DOMINGEZ
TILLMAN AVE
ANNALEE AVE
MILLPOINT AVE
CARSON PL DR
CARSON PL CT
I Section
L:Znk
C
I Surface
AC
AC
I Length
3'
330
Width
40
True Area
13,200
C—
AC
355
—
14,200
c
ss
515
g3
40
20,600
C
AC
2—
—
40
9,200
C
ss
240
40
9,600
C
AC
565
40
22,600
0
0
AC
650
34
22,100
ss
325
36
11,700
0
Ss
::520
36
18,720
0 AC
425
36
15,300
0 AC
275
36
9,900
0 AC
835
30
25,050
Maint. AREA # 4 LOCATION LIST.3
3/2/200
Z\
Annual Slurry Seal Program, Citywide -Project No. 1301 FY 2008 /09
Name
lFrom
ITo
secificiiiii
.......
.......... ...
1
Ra I I l�:
..............
2 rici I I 1
1 1 VVidthTT,..
Area
t: "65.� CARSON PLAZA DR CARSON PL CT
END
66 CLARION ST
OAKFORT AVE
END (E)
0
ss
150
30
4,500
67 CLARION ST
PONTINE AVE
END (E)
0
SS
180
40
7,200
CLOVERBROOK ST
END(W)
ACARLISST
0
SS
295
30
8,850
DABLON AVE
ACARLISST
END(N)
0
SS
475
26
12,350
DOMINGUEZ ST
n'
BONITA ST
LEAPWOOD AVE
4 1P I DOMINGUEZ ST
LEAPWOOD AVE
CHICO ST
DOMINGUEZ ST
BELSHAW AVE
ANNALEE AVE
73 DOVLEN PL
LEAPWOOD AVE
CAMPAIGN RD
LEAPWOOD AVE
DOMINGUEZ ST
DOVLEN PL
75 LEAPWOOD AVE
DOVLEN PL
DEL AMO BLVD
76 LEGEND AVE
END(S)
218TH ST
0
SS
305
26
7,930
77 LEGEND AVE
215TH PL
213TH ST
0
AC
850
30
25,500
LOSTINE AVE
END(S)
218TH ST
0
SS
320
26
8,320
,"M?" LOSTINE AVE
215TH PL
213TH ST
0
SS
850
30
25,500
80 MARTIN ST
CALIFON ST
ALBREDA ST
c
SS
285
40
11,400
81 MARTIN S
ALBREDA ST
213TH ST
C
SS
265
40
10,600
82 MARTIN ST
213TH ST
END(N)
0
SS
1,375.00
20
27,500
MILLPOINT AVE
220TH ST
END(N)
0
SS
490
26
12,740
8 4!_':t MILLPOINT AVE
BALARDE ST
END(S)
0
SS
490
26
12,740
MILLPOINT AVE
CALIFON ST
213TH ST
0
Ar.
Maint. AREA # 4 LOCATION LISTA
3/2/20
z
Annual Slurry Seal Program, Citywide -Project No. 1301 FY 2008 /09
Maint. AREA # 4
From
ITo
Section
I
Rank
Surface Lengt�
h
W�IdthTrue
Area
213TH ST
END(N)
0
AC
315
40
12,600
216TH ST
215TH ST
0
SS
200
36
7,200
END(S)
SUSAN DR
p
SS
125
30
3,750
215TH PL
SUSAN DR
0
AC
450
40
18,000
SUSAN DR
213TH ST
0
AC
500
32
16,000
CARSON ST
215TH PL
0
AC
340
40
13,600
213TH ST
CLARION DR
0
SS
205
40
8,200
END(S)
BALARD ST
0
AC
240
36
8,640
CLARION DR
END(N)
0
SS
130
40
5,200
216TH ST
215TH PL
0
SS
200
36
7,200
SUSAN DR
END(S)
0
SS
125
34
4,25D
PERRY ST
SOUTH ROS DR
0
ss
245
40
9,800
SOUTH ROS DR
S-PERALTA
0
SS
290
40
11,600
WINGATE DR
213TH ST
0
SS
550
40
22,000
ABILA ST
218TH ST
0
SS
250
40
10,000
218TH ST
CARSON ST
0
Ss
520
40
20,800
CARSON ST
215TH PL
0
AC
455
56
25,480
215TH PL
214TH ST
S
SS
450
56
25,200
214TH ST
213TH ST
S
AC
445
21
9,345
213TH ST
END(N)
S
Ss
1,375.00
20
27,500
220TH ST
219TH ST
0
ss
360
36
12,960
215TH PL
215TH ST
0
AC
28.9
LOCATION LIST.5
3/2/200
?Z\
Annual Slurry Seal Program, Citywide -Project No. 1301 FY 2008 /09
IN me
jFrom
ITo
Section
Rank
Surface
is I 1.�
Ildth
True Area
-10&, WATER ST
"pd
213TH ST
BALARD ST
0
AC
1,280.00
36
4 080
WATER S
215TH ST
214TH ST
0
ss
295
10,620
116" WATER ST
214TH ST
213TH ST
0
Ss
275
36
9,900
WATER ST
218TH ST
219TH ST
0
ss
275
36
112 WEISERAVE
215TH PL
215TH ST
0
AC
275
18
4, 950
113 WEISER AVE
ACARUS ST
END(N)
0
AC
270
26
7,020
114 WEISER AV
216TH ST
215TH PL
0
AC
245
36
8,820
115 WEISER AV
215TH PL
214TH ST
0
AC
270
36
9,720
1 * 16 WEISER AVE
214TH ST
213TH ST
0
AC
265
36
9,540
117: WINGATE DR
THOMAS DR
ALVAR PL
0
42,899
1,452,493
Maint. AREA # 4
LOCATION LIST.*6
3/2/2009