HomeMy Public PortalAboutExhibit MSD 16X Due diligence questionnaire-direct loans ASSIGNMENTS 061609
STATE DIRECT LOAN
DUE DILIGENCE REQUEST FORM
(Governmental Participant)
The following information is requested from each participant (“Participant”) that is applying for financial
assistance from the Missouri Department of Natural Resources - Water Protection Program – Financial
Assistance Center. The information is also needed as part of the due diligence review required by federal and
state securities laws. It is necessary to obtain the following information for the Missouri Department of Natural
Resources to assess loan participant’s financial background information. By executing this questionnaire, the
Participant certifies that responses provided are true, correct, complete and do not contain material misstatements
or omissions.
If one of the following questions is not applicable, please indicate so. Attach additional sheets of paper, as
needed, or extend the form electronically, as needed, to answer the following questions. Return the completed
form to:
Joe Boland
Missouri Dept. of Natural Resources, WPP – FAC
P.O. Box 176
Jefferson City, MO 65102-0176
Phone: (573) 751-1192
Fax: (573) 751-9396
Please confirm that the following description of project to be financed with the State Direct Loan is accurate:
[insert project description from DNR’s FNSI] The District’s rate setting process as approved by the Rate
Commission assumes the use of a combination of SRF and stand alone debt totaling $75 million for fiscal year
2010. This loan request represents needs that the District has already contracted for in the first half of the fiscal
year for projects that are on the current fiscal year Intended Use Plan.. There are four projects from our capital
improvement program that are on the fundable list : Lemay Wastewater Treatment Plant Wet Weather Expansion
$11 million, L-52 Pump Station modifications $4 million, inflow and infiltration project pilot study $8 million
of the $16 million approved million and the Missouri River Wastewater Treatment Plant Digester Project $11
million that is on the ARRA intended use plan fundable list for both loan and grant funding.
I. General Information
1. Legal Name of Participant: The Metropolitan St. Louis Sewer District
2. Nature of governmental entity of the Participant (county, city, village, public water district, public
sewer district, or combination):
Sewer District
3. Authorized Representative/Daily Contact Person: Karl Tyminski
Address; 2350 Market Street St. Louis MO 63103
Phone #: 314-768-6222
Fax #: 314-768-2701
E-mail: kjtymi@stlmsd.com
3526051
2. Does any member of the Participant's governing body or any of its key administrative personnel have a
potential conflict of interest regarding the project to be financed with the Direct Loan by reason of such
membership or position?
Yes
X No
If yes, state whom and the nature of such conflict.
3. Date of Participant’s fiscal year end: June 30
4. Participant's Taxpayer Identification Number:
43-6011991
5. Has the Participant ever defaulted on a bond issue?
Yes
XX No
If yes, please describe:
6. Does the Participant’s last annual audit include a finding that the Participant is in non-compliance with
any bond covenants contained in any bond ordinances or resolutions?
Yes
X No
If yes, please describe:
7. Has the Participant ever failed to comply with any of the informational reporting responsibilities
contained in any financing document or instrument intended to comply with the requirements of Rule
15c2-12 of the Securities and Exchange Commission (regarding municipal securities disclosure)?
Yes
X No
If yes, please describe:
8. Participant’s local bond counsel:
Name: Gilmore & Bell PC
Address: One Metropolitan Square
211 N. Broadway, Suite 2350
St. Louis MO 63102
Phone #: 314-436-1000 Fax #: 314-436-1166
E-mail: rballsrud@gilmorebell.com
Name: White Coleman & Associates, LLC
Address: 500 North Broadway, suite 1300
St. Louis MO 63102-2110
Phone #: 314-621-7676 Fax #: 314-621-0959
E-mail: whitecoleman@whitecoleman.net
E-mail: smcfarlind@whitecoleman.net
9. Participant's financial advisor, if any:
Name: Public Financial Management (“PFM”)
Address : 2600 Grand Avenue, Suite 214, Terrace Place
Des Moines, Iowa 50312
Phone #: 515-243-2600 Fax #: 515-243-6994
E-mail: vandaj@pfm.com
E-mail: poolert@pfm.com
061609 -2-
Name: Valdés & Moreno, Inc.
Address: 1600 Genesee Street, Suite 630
Kansas City, MO 6402-1082
Phone #: 816-221-6700 Fax #: 816-221-1310
E-mail: marco@valdesmoreno.com
E-mail: bcookson32@gmail.com
II. Debt and Authorizing Information
1. What is the source of repayment of the Participant’s bonds securing the direct loan:
Combined Waterworks and Sewerage System Revenues
Waterworks System Revenues
X Sewerage System Revenues
Unlimited Property Tax Revenues (General Obligation)
Capital Improvement Sales Tax Revenues (Bonds)
Capital Improvement Sales Tax Revenues (annual appropriation) [note – must also check another
box]
Other (describe):
2. Is there a limitation on the final maturity date for the Participant's bonds imposed by election or
ordinance?
Yes
X No
If yes, please describe. Only that imposed by state law or by the SRF program.
4. Please attach a list of the Participant’s outstanding bonds that are secured by the same source of
revenues that will secure repayment of the direct loan indicated in II-1 above, showing outstanding
balance, source of payment, and principal and interest payable by fiscal year
The MSD Sewer Service charge Revenue has been pledged to all the bond issues on the attached
schedule of MSD debt dated June 30, 2009. The 2004A, 2006C and 2008A issues are senior lien
debt. The 2005A, 2006 A & B and 2008B issues are subordinate lien debt securities.
5. Describe the amount and type of any authorized but unissued bond debt for the type of bonds secured
by the same source of revenues that will secure repayment of the direct loan, including the bonds to
be issued in connection with this financing.
In August 2008 MSD successfully passed a bond authorization election for $275 million. To date $40
million has been issued against that authorization. With this request an additional $214 million of
authorization remains after this loan including the stimulus component. ($275mm; less $30mm 2008A
;issue, $23mm; 2009A loan. Less $8mm stimulus loan)
5. If sales tax is an anticipated source of repayment for the direct loan, list and describe all sales taxes
imposed by the Participant (including the sales tax described above as a source of repayment for this
financing): Not Applicable
Please provide a copy of the ballot authorizing such sales tax(es) and ordinance(s) establishing the sales
tax(es). Not Applicable
6. Does the Participant anticipate issuing any bonds simultaneously with or within one year after the bonds
to be issued by the Participant in connection with this direct loan?
061609 -3-
X Yes
No
If yes, please describe and provide an official statement, if available: The District is contemplating a
$52 million Build America Bond issue in the November 2009 to February 2010 timeframe.
III. Project and Finance Structure Information
1.A. Amount of financial assistance required:
Lemay Wastewater Treatment Plant Wet Weather Expansion
Description Direct Loan
Amount
Other
Sources
(SRF Oct
2008 Issue)
Other Sources
(Possible Build
America Bond Issue
after srf loans are
exhausted)
Other Sources
(Cash Pay Go)
Total Project
Cost
Planning and design $ - $4,147,600 $4,147,600
Reimbursement of prior
construction
$10,644,547 10,644,547
Refinance outstanding
bonds/notes
Project construction
(including construction
engineering)
$260,369 $39,351,102 $19,650,000 $27,644,002 $86,905,473
Capitalized interest
(through _________)
Local bond counsel * $19,872 $50,000 $50,000 $119,872
Local financial advisor* $4,783 $25,000 $50,000 $79,783
Other (including cost of
DNR construction
permit)*
$70,429 $573,898 $250,000 $894,327
Total $11,000,000 $40,000,000 $20,000,000 $30,792,104 $101,697,024
* Pro rated
Note: The Participant’s of Direct Loan Program costs of issuance will be added to the total above.
(DNR’s program counsel and Escrow Agent).
1B. Amount of financial assistance required: L52 Pump Station
Description Direct Loan
Amount
Other Sources
(SRF 2006 B)
Other Sources
(Cash Pay Go )
Total Project
Cost
Planning and design $ $575,000 $575,000
Reimbursement of prior
construction
$1,618,517 $1,618,517
Refinance outstanding
bonds/notes
Project construction
(including construction
engineering)
$1,253,126 $14,193,132 $2,320,000 $17,766,258
Capitalized interest (through
_________)
Local bond counsel $1,470 $26,500 $27,470
Local financial advisor $1,739 $15,000 $16,739
Other (including cost of DNR
construction permit)
31,400 $216,426 $247,826
Total $4,000,000 $14,205,000 $2,895,000 $21,100,000
061609 -4-
1C. Amount of financial assistance required: Pilot Inflow & Infiltration Study
Description Direct Loan
Amount
Other Sources
(Cash Pay Go )
Total Project
Cost
Planning and design
Reimbursement of prior
construction
$679,577 $679,577
Refinance outstanding bonds/notes
Project construction
(including construction
engineering)
$7,246,388 $500,000 $7,746,388
Capitalized interest (through
_________)
Local bond counsel $14,452 $14,452
Local financial advisor $8,696 $8,696
Other (including cost of DNR
construction permit)
$51,287
$51,287
Total $8,000,000 $8,500,000
1D. Amount of financial assistance required: Missouri River Digester Project (Fundable Stimulus Project)
Description Direct Loan
Amount
Other Sources
(Grant Funded)
Total Project
Cost
Planning and design $359,764 $135,237 $495,000
Reimbursement of prior
construction
Refinance outstanding bonds/notes
Project construction
(including construction
engineering)
$7,620,976 $2,864,763 $10,485,739
Capitalized interest (through
_________)
Local bond counsel
Local financial advisor
Other (including cost of DNR
construction permit)
Total $7,980,739 $3,000,000 $10,980,739
2. Structure for Participant bonds
Amortization Method: X Standard - Level debt.
Non-standard: Provide proposed amortization and rational.
Are revenues available to pay interest on the Participant’s bonds from date of issuance?
X Yes
No
If no, please describe special circumstances:
061609 -5-
Will this financing utilize all remaining voter authorization?
Yes
X No
3. Anticipated Project Schedule:
Please provide a separate project schedule for each project that will be completed pursuant to a separate
construction contract.
Lemay Wastewater Treatment Plant Wet Weather Expansion
Event Projected Date (month/year)
Contract 1
Projected Date (month/year)
Contract 2
Advertising for Bids 5/1/07
Bid Opening 6/29/07
Construction Contract
Award
9/10/07
Initiation of Operations* 12/30/09
Construction Completion 4/29/10
Project Completion 4/29/11
L-52 Pump Station
Event Projected Date (month/year)
Contract 1
Projected Date (month/year)
Contract 2
Advertising for Bids 2nd week Nov. 2006
Bid Opening 3rd week Dec. 2006
Construction Contract
Award
3/8/07
Initiation of Operations* February 2010
Construction Completion April 2010
Project Completion Oct. 2010
Pilot I & I Study
Event Projected Date (month/year)
Contract 1
Projected Date (month/year)
Contract 2
Advertising for Bids No, professional Service
Bid Opening No, professional Service
Construction Contract
Award
No, professional Service
Initiation of Operations* 7/1/2009
Construction Completion No, professional Service
Project Completion 10/31/2010
061609 -6-
Missouri River Treatment Plant Digester Project ARRA Project
Event Projected Date (month/year)
Contract 1
Projected Date (month/year)
Contract 2
Advertising for Bids 8/4/09
Bid Opening 9/15/2009
Construction Contract
Award
11/15/09
Initiation of Operations* 2/26/12 (staged with final for 2/26/12)
Construction Completion 4/26/12
Project Completion 10/26/12
* “Initiation of operations” is not project completion. It is the date upon which operations commence or
beneficial occupancy is achieved under a construction contract awarded in connection with this
financing.
Please add an additional page if the above table does not contain sufficient columns for the separate
projects financed by this direct loan.
6. Estimated Construction Draw Schedule. Note: Construction draws should equal the financial
assistance requested as shown in the chart above (other than costs of issuance). Please provide a
separate draw schedule for each of the contracts identified above.
See attached Schedule.
5. Are sales tax revenues an anticipated source of repayment?
Yes
X No
If yes, please furnish the following information:
Is there a tax increment financing district within the district/city that would capture a portion of the
sales tax revenues that are anticipated to be a source of repayment for the participant’s bonds?
Collection data for the past five (5) years (and collections for current year-to-date) for those sales tax
revenues available to pay debt service on the Participant’s bonds:
20__ $ N/A (year-to-date)
20__ $ N/A
20__ $ N/A
20__ $ N/A
20__ $ N/A
20__ $ N/A
Rate of sales tax available:
061609 -7-
Permissible uses for the sales tax:
Restrictions on the use of sales tax:
Sunset date for sales tax, if any:
6. Note: Question 6 is applicable only if the Participant is refinancing outstanding notes/bonds with
the direct loan.
Does the project include a refinancing of outstanding notes or bonds?
Yes
X No
If yes, please describe the bonds or notes to be refinanced, the amount of the proceeds that have been
spent, the amount of bonds or notes outstanding and the call date:
Are there any unexpended proceeds from the bonds or notes being refinanced?
Yes
X No
If yes, please provide an expected disbursement schedule. (Include the last date on which any
remaining proceeds from the bonds or notes to be refinanced may be disbursed.)
Has DNR reviewed expenditures of the proceeds of the bonds or notes to be refinanced to determine if
such expenditures qualify as “eligible costs?”
Yes
X No
Were these projects covered under a FNSI or a categorical exclusion?
Yes
No
Not Applicable
If financing is being requested for the purpose of refunding outstanding notes or bonds, please provide a
copy of the resolution or ordinance authorizing the issuance of the bonds or notes to be refunded.
7. Are there any proposed leases or management contracts with or occupancy by nongovernmental entities
(other than contracts for janitorial, office equipment repair, billing or other services that are solely
incidental to the primary governmental function(s)) of the project financed with the proceeds of the
direct loan?
Yes
X No
If yes, briefly describe:
8. Will a nongovernmental entity use more than 5% of the project financed with the proceeds of the direct
loan?
Yes
X No
If so, will such user receive treatment different than that afforded to a member of the general public, or
is the project designed in any way to accommodate the needs of such user? For this purpose, the term
“use” may include, among other things, ownership or the actual or beneficial use of property pursuant
061609 -8-
to any number of other arrangements, such as a lease, a management, service or incentive payment
contract, a research agreement or certain other arrangements, such as a take or pay or other output-type
contract.
Yes
No
If yes, briefly describe the arrangements concerning such user. Include any special fee(s) to be charged
to such user that are outside the approved user charge ordinance:
IV. System Information and Revenues
1. Other than the project being financed with this direct loan, describe generally any plans to expand,
improve or equip the system within the next two years: The District is in the second phase of a multi-
decade and multi phase capital improvement plan. The existing phase that covers fiscal years 2008
through 2012 and totals $661 million.
2. Provide actual operating expenses of the system for the previous two (2) years and projected operating
expenses of the system for the current year and the next (4) fiscal years. Please do not include current
or anticipated debt service payments. Denote the year in which new project is to come on line. (Paul
L)
Year Operating Expenses
FY06 (previous) 118,816,017
FY07 (previous) 129,348,891
FY08 (current) 141,917,888
FY09 (next) 151,260,220
FY10 (next) 163,038,000
FY11 (next) 169,544,000
FY12 (next) 173,131,000
3. If system revenues are an anticipated source of repayment of the bonds securing the direct loan, please
provide the following information in connection with the Participant's system (or the portion of the
system from which the Participant anticipates drawing revenues to repay the direct loan): (
Last five (5) years 2008 2007 2006 2005 2004
System Revenue $203,674,746 $193,556,431 $199,470,786 $180,732,026 $149,672,393
Investment Income $13,277,548 $13,501,751 $6,135,347 $4,356,643 $1,630,215
Other Income $5,306,631 $7,391,655 $5,988,302 $1,359,916 7,182,897
Total Revenue $222,258,925 $214,449,837 $211,594,435 $186,448,585 $158,485,505
Operating Expenses
(excluding depreciation)
$164,789,198 $138,089,529 $131,909,717 $117,930,992 $108,000,500
Net Revenues available
for DS
$57,469,727 $76,360,308 $79,684,718 $68,517,593 $50,485,005
Annual Debt Service
(existing)
$26,334,791 $24,329,929 $19,242,832 $15,926,902 $924,164
Debt Service Coverage 31,134,936 52,030,379 60,441,886 52,590,691 49,560,841
Existing covenant coverage required, if any: ____1.25_____
061609 -9-
4. Ten (10) largest users and % of system use.
User % of System Use % of System Revenues
Anheuser Busch 3.70% 2.91%
Mallinckrodt Inc 0.87% 0.41%
Chrysler Corporation 0.46% 0.21%
City of St. Louis
Zoological Gardens
Sigma-Aldrich
Sensient Colors Inc
Washington University
GKN Aerospace N America Inc
St. Joseph’s Convent of Mercy
0.45%
0.41%
0.40%
0.34%
0.33%
0.30%
0.29%
0.20%
0.20%
0.18%
0.19%
0.15%
0.13%
0.13%
Has there been a 5% or greater change in the number of system users during the past two-year period?
Yes
X No
If so, please explain.
5. Identify system use (gallons per day) for billing purposes, actual billings, and collections for each of
last five (5) years. If the system is a combined waterworks and sewerage system, please provide the
following information separately for the waterworks and sewerage components of the combined
system.( Mike & Michelle)
Year System Use (gal.) Billings ($) Collections ($)
FY 08
FY 07
_______
198,992,581
199,474,088
FY 06 _______ 203,880,320 198,449,849
FY 05 _______ 183,512,398 177,872,543
FY 04 _______ 150,518,591 143,667,321
FY 03 _______ 123,694,300 123,269,772
6. Current and Proposed Rate Structure.
Please provide the Participant’s current rate structure and its effective date and any proposed new rate
structure and date of adoption for the same. If the Participant has a combined waterworks and sewer
system, the rate structure for both water and sewer users should be included.
Current Rate Proposed Rate
Schedule Effective Date Structure Date of Adoption
Residential users See accompanying presentation
061609 -10-
Commercial users
Industrial users
Please provide a copy of the ordinance imposing the most recent rate increase in connection with the
current SRF financing.
7. Please provide information on previous rate increases and effective dates within the last five (5) years. .
See accompanying presentation
8. Does the Participant's investment policy relative to funds of the system or otherwise securing the direct
loan comply with the State Treasurer’s model investment policy and any other state law requirements
(see www.treasurer.mo.gov/invest/policy2.doc model policy)?
9. Please provide a certificate or other evidence of insurance coverage against the risks of property and
casualty loss, public liability, and any other insurance maintained by the Participant, including type of
coverage, amount of coverage, annual premiums, name of insurer, and term
See accompanying information
V. Litigation and Other Proceedings
1. Provide a description of all contracts and commitments of the Participant under which any default has
occurred or is claimed to have occurred. In December 2003, the District entered into a construction
contract with the Baumgartner Tunnel Joint Venture (BTJV) group for the construction of a 4 – mile
long 200 foot deep tunnel with placement of pipe the length of the tunnel and the creation of 3 access
shafts and 5 drop shafts. The project was located in South St. Louis County and had an initial
completion date of December 2005 which was revised to March of 2006. The BTJV made a claim for
additional fees based on a soft tunnel invert causing problems during pipe placement. MSD denied the
claim based upon the BTJV’s failure to notify the District of a changed condition causing the delay.
The District is also charging BTJV liquidated damages based upon late completion. Through
negotiation this matter was settled prior to litigation.
2. Describe (1) any pending or possible litigation and contractual disputes and (2) any consent decrees,
prospective judgments, writs, injunctions, court orders, settlement agreements or judgments, or
correspondence regarding the same, to which the Participant either is or has been a party within the past
three (3) years or that are threatened against the Participant. Supply copies of all letters concerning any
litigation against the Participant that have been provided by all legal counsel to the Participant’s
independent public accountants in connection with audit opinions for the last three (3) fiscal years.
(a) On or about July 29, 2002, the District entered into a Settlement Agreement with Missouri
Department of Natural Resources, (MDNR) the Missouri Clean Water Commission, (Commission) and
the Missouri Attorney General regarding the Baumgartner Sewage Treatment Facility (Baumgartner).
Previously, the State filed the case of State of Missouri ex rel. William L. Webster, et al. v. The
Metropolitan St. Louis Sewer District, No. 864-00250, against MSD with respect to certain alleged past
and continuing violations of the Federal Water Pollution Control Act, 33 U.S.C. §§1251 et seq., the
Missouri Clean Water Law §§ 644.006, et seq., RSMo, and Missouri State Operating Permits issued to
various sewage treatment facilities and other facilities owned and operated by MSD. An Amended
Consent Judgment was entered by the circuit court on January 20, 1989.
Paragraph XXIV of the Amended Consent Judgment further provided, in pertinent part, that the
Amended Consent Judgment shall terminate when MSD has achieved substantial compliance with the
final effluent limitations for the Bissell Point and Baumgartner Sewage Treatment Facilities for a period
of one year. One of the purposes of the Amended Consent Judgment was for MSD to achieve and then
continue to achieve compliance with its Missouri State Operating Permit effluent limitations at
Baumgartner.
061609 -11-
Under said settlement agreement the District agreed to take certain measures to achieve temporary
compliance with fecal coliform permit limits at Baumgartner. Ultimately, the District is to take the
Baumgartner lagoon offline on or before December 31, 2006. This will be done by connecting the
sewage flow going to Baumgartner to a new Meramec Wastewater treatment facility. Furthermore, the
parties agreed that MSD will complete closure of the Baumgartner lagoon pursuant to 10 CSR 20-
6.010(12) within 24 months of taking the Baumgartner lagoon offline. As of May 31, 2003, a
moratorium on further sewer connects to Baumgartner will be enacted should the District be unable to
meet identified effluent limits.
In addition, should the District fail to meet any of the deadlines set out in the Settlement Agreement or
violate any of the terms contained therein, the penalties for each missed deadline could reach a
maximum of $10,000 per day, per violation.
The July 29, 2002 Settlement Agreement was modified on January 3, 2007. In compliance with the
Modification to the July 29, 2002 Settlement Agreement the Baumgartner Lagoon was taken offline on
March 1, 2007. The District will complete closure of the Baumgartner lagoon pursuant to 10 CSR 20-
6.010(12) within 24 months of taking the Baumgartner lagoon offline. The lagoon was properly closed
and inspected by MDNR representatives on November 13, 2008. A Satisfaction of Judgment regarding
the Amended Consent Judgment was filed by the Attorney General’s office on March 5, 2009.
(b) US and State of Missouri v. Metropolitan St. Louis Sewer District; In the US District Court for
the Eastern District of Missouri; Case No. 07-1120. A lawsuit was filed by the Department of Justice
on behalf of the United States Environmental Protection Agency (“EPA”) for various alleged violations
of the Clean Water Act. The district has been the subject of several investigatory actions by EPA over
the past several years. Negotiations have been ongoing with EPA and the Missouri Department of
Natural Resources (“MDNR”) regarding the sewer collection system, both the combined system and the
sanitary system, for several years. The Missouri Coalition for the Environment (“MCE”) gave Notice
of Intent to Sue the District under the citizen suit provisions of the Clean Water Act. EPA and MDNR
then brought the suit on June 11, 2007, and MCE moved to intervene on August 13, 2007. Intervention
was granted on August 29, 2007. The District filed its answer to the complaint filed by US and
Missouri on September 21, 2007, including in its response filing counterclaims against the State of
Missouri. Concurrently with the answer and counterclaims, the District filed a motion to dismiss all
claims and penalties that occurred before July 11, 2002, as barred by the applicable statue of limitations.
Following a responsive pleading filed by the U.S. Department of Justice and a reply by the District, on
October 4, 2007, the Court granted the District’s motion to dismiss, thus barring all of plaintiffs’ claims
for civil penalties attributable to any and all of the District’s alleged violations of the Clean Water Act
that occurred before June 11, 2002 from this litigation.
A group of companies called the MIEC filed a Motion to Intervene. This motion was denied on
September 12, 2008. Further, the original judge in this matter, and the subsequently assigned judge,
have either been recused or rejected by a party from presiding over this case. The current judge is Carol
E. Jackson, Chief United States District Judge. The suit is based on violations of the Clean Water Act
as a result of overflows in the combined and sanitary sewer systems causing pollutants to reach waters
of the United States. There are other counts involving violations of permit conditions. Also, the suit
alleges that the District does not have an approved Long-Term Control Program (“LTCP”) for the
combined system. The District has been working on these issues for several decades. The District has
asked voters to approve bonds and rate increases to rehabilitate and maintain the collection system. The
District finished this year’s process required by its Charter to increase rates which will continue to fund
the improvements sought by EPA and MDNR. The Judge made a major ruling on September 12, 2008,
putting in place a Stay while the parties mediate the issues.
On October 14, 2008, the MIEC appealed the denial of the Motion to Intervene. That motion was
denied by the Eighth Circuit Court of Appeals on June 22, 2009. In addition, the State of Missouri filed
an appeal of the September 12, 2008 ruling which disallowed the State’s claim of sovereign immunity
as to the counterclaims made by the district. On August 3, 2009, this decision was upheld by the Eighth
Circuit Court of Appeals. The parties have been in mediation over the past year. A status report on the
Stay is due on November 2, 2009. The District submitted its LTCP, which is currently under review.
061609 -12-
(c) In the matter of Metropolitan St. Louis District, Respondent. Proceedings under Section 309(a)(3)
of the Clean Water Act, 33 U.S.C. § 1319(a)(3); filed on April 30, 2007, and amended on May 22,
2007, Docket No. CWA-07-2007-0042, has been amended for a second time on July 18, 2008. This is a
Unilateral Administrative Order (“UAO”) issued by the United States Environmental Protection
Agency Region VII requiring that the District: (1) provide notice to EPA of the District’s intent to
comply with the Amended Order; (2) post signs according to the instructions and schedule contained in
the UAO; (3) forward notices to customers and post a notice on the District’s website as described in
the UAO; and (4) provide notice to EPA and MDNR of all known discharged from constructed Sanitary
Sewer System Overflows (“SSOs”) on a quarterly basis, beginning in August 2007. The District is
complying with the UAO. EPA has been notified of the District’s intent to comply with the Amended
Order, subject to the District’s legal authority and capabilities. The notices have been forwarded to
customers and a copy posted on the District’s website. Signs have been posted as instructed. The
district has notified EPA and MDNR of all known discharges from construction SSOs for the quarter
May 2007 through July 2007, and continues such notifications on a quarterly basis. The Second
Amended Order required additional information, signs, and adjusted the non-constructed SSO sign
inspection schedule as well as requested electronic raw data. The District has sent such information to
EPA and complied with all requests subject to the District’s legal authority and capabilities and
continues to do so.
(d) William Zweig et al. v. MSD. This case was filed on July 18, 2008 in the Circuit Court for St. Louis
County. The lawsuit, as amended, contends that MSD Ordinances No. 12560 and No. 12789, which
enacted increases in MSD’s stormwater user charge based on the amount of impervious area on the
customer’s property, are unconstitutional. The lawsuit claims the ordinances violate the so-called
Hancock Amendment, Mo. Const. art. X, § 22(a), because the stormwater user charge is in reality a tax
that requires voter approval. MSD’s Board of Trustees passed the ordinances in December 2007 and
December 2008, respectively, without submitting them to the voters. MSD contends the stormwater
user charge is not a tax and, thus, not subject to voter approval. The original plaintiff, William Zweig,
is an MSD stormwater customer residing in Chesterfield, Missouri, who seeks to represent a class of all
MSD stormwater customers. In July 2009, two more plaintiff class representatives, David Milberg and
Mark Kurz, were added to the lawsuit. The lawsuit seeks (1) a declaration that the stormwater user
charge is unconstitutional, (2) a refund of all stormwater user charges collected, and (3) payment of the
plaintiffs’ costs, including attorneys’ fees.
On August 27, 2008, we filed on MSD’s behalf an answer and affirmative defenses to the original
petition, and on August 6, 2009, we filed MSD’s answer and affirmative defenses to the Second
Amended Petition. Since the case was filed, the parties have engaged in extensive discovery, including
depositions of the original plaintiff and several MSD witnesses. Discovery is continuing, including
depositions of the new plaintiffs and expert witness discovery. Plaintiffs’’ motion for class certification
was filed in May 2009, but has not been fully briefed and has not been argued to the court. A motion to
intervene was filed in February 2009 on behalf of a number of putative class members who allege they
are not adequately represented by the plaintiffs. The plaintiffs and MSD both oppose the motion to
intervene. The class certification and intervention motions are set for hearing in early October 2009.
The pace of the case has been significantly slowed due to the retirement of the judge originally assigned
to the case, the assignment and subsequent recusal of a replacement judge, and then the recusal of all
the judged in the St. Louis County Circuit Court, presumably because they are all putative class
members as MSD customers. In August 2009, the Missouri Supreme Court assigned a judge from
Lincoln County to hear the case. At this point, there is no trial date set, but we anticipate the case will
go to trial in Spring 2010. MSD is vigorously defending the lawsuit. While we believe MSD’s position
that its stormwater user charge is a fee, not a tax, is meritorious, we cannot predict with certainty that
Missouri’s courts will agree.
If is our understanding that MSD has collected approximately $46,000,000 to date from the stormwater
user charge, and is continuing to collect approximately $3,000,000 each month, which would be subject
to plaintiffs’ request for a refund should the ordinances be declared unconstitutional. MSD has
significant legal and factual arguments in opposition to any refund, but we cannot predict with any
certainty at this time whether, or in what amount, MSD may be required to make a refund should the
061609 -13-
ordinances be declared unconstitutional. In addition, if plaintiffs’ were to prevail and the ordinances
were found unconstitutional, plaintiffs would be entitled to their attorneys’ fees and costs under the
Hancock Amendment (Mo. Const. art. X, § 23). While we cannot estimate these fees and costs with
certainty, the amount sought could be in excess of $1,000,000.
(e) There are four cases associated with the September 14, 2008 flooding. They are as follows:
Angela Holland v. The Metropolitan St. Louis Sewer District. St. Louis County Circuit Court, Cause
No. 08SL-CC04922. On November 25, 2008, Plaintiff Angela Holland filed this action against the
District in the Circuit Court of St. Louis County for wrongful death and property damage arising out of
the flash flooding of the River Des Peres in the aftermath of heavy rains from Hurricane Ike on
September 14, 2008. The initial Petition alleged that the District was liable for the wrongful death of
Louise Bryant who was swept away by the flood waters and drowned while trying to save her car. The
petition alleged that the District was liable because (1) it failed to construct adequate stormwater
facilities along the River Des Peres, such as levees, retaining walls, and water detention basins; and (2)
it failed to forecast and warn plaintiff and her decedent about the potential dangers of flash flooding on
September 14, 2008. The petition further alleged that the District’s sovereign immunity was waived
under the circumstances of the case under the “dangerous condition” waiver of sovereign immunity
contained in RSMo. § 537.600.
On February 23, 2009, the District moved to strike certain allegations of petition and to make the
petition more definite and certain. As grounds for the motion to strike, the District argued that the
allegations failed to state a claim against the District arising out of the alleged dangerous condition of
public property and that the District had no private duty to plaintiff or plaintiff’s decedent to construct
stormwater facilities along the River Des Peres or to warn plaintiff or plaintiff’s decedent of potential
flash flooding of the River Des Peres on September 14, 2008.
In response to the District’s Motion, plaintiff Holland filed her first amended petition on April 13, 2009.
The First Amended Petition sounded in two Counts. Count I purports to state a claim for negligence
and a dangerous condition of public property, alleging basically the same grounds for liability as in the
initial petition but omitting claims of liability arising out of the District’s alleged failure to forecast and
warn of the flooding on the River Des Peres. Count II purports to state a claim for inverse
condemnation and damage to Louise Bryant’s residence on Wilson Avenue in University City,
Missouri. The first amended petition seeks damages for Ms. Bryant’s wrongful death and residential
property damage as a result of the River Des Peres flooding.
The District answered the first amended petition on May 4, 2009, denying liability and raising
affirmative defenses.
The parties have exchanged written discovery requests and responses and have produced documents.
At present, there is no discovery deadline for this matter but a case management conference is
scheduled for December 21, 2009.
Frederick Eppenberger, et al. vs. The Metropolitan St. Louis Sewer District. St. Louis County Circuit
Court, Cause No. 08SL-CC05270. On December 17, 2008, plaintiffs Frederick Eppenberger, Maxine
Smith and William Bain, as individuals and as putative class representatives filed this action against the
District in the Circuit Court of St. Louis County for property damages arising out of the flash flooding
of the River Des Peres in the aftermath of heavy rains from Hurricane Ike on September 14, 2008.
Like the Holland petition, the initial Eppenberger Petition alleged that the District was liable for the
property damage to their homes and personal property caused by the flash flooding of the River Des
Peres. Like the Holland Petition, the Eppenberger petition alleged that the District was liable because
(1) it failed to construct adequate stormwater facilities along the River Des Peres, such as levees,
retaining walls, and water detention basins; and (2) it failed to forecast and warn plaintiffs and the
plaintiff class about the potential dangers of flash flooding on September 14, 2008. The petition further
alleged that the River Des Peres was owned by and under the exclusive control of the District; that it
was in a dangerous condition for which the District was responsible; and that plaintiffs’ damages
resulted from the dangerous condition of the River Des Peres.
061609 -14-
On February 23, 2009, the District moved to dismiss the petition for failure to state a claim and,
alternatively, to strike certain allegations. The District moved to dismiss on grounds that plaintiffs
failed to plead essential facts establishing a waiver of the District’s sovereign immunity. As grounds
for the motion to strike, the District argued that the allegations failed to state a claim against the District
arising out of the alleged dangerous condition of the public property and that the District had no private
duty to plaintiffs or the plaintiff class to construct stormwater facilities along River Des Peres or to
warn plaintiffs or the plaintiff class of potential flash flooding of the River Des Peres on September 14,
2008.
In response to the District’s motion, plaintiffs filed their first amended petition on April 13, 2009. The
first amended petition sounded in two Counts. Count I purports to state a claim for negligence and a
dangerous condition of public property, alleging basically the same grounds for liability as in the initial
Petition but omitting claims of liability arising out of the District’s alleged failure to forecast and warn
of the flooding on the River Des Peres. Count II purports to state a claim for inverse condemnation and
damage to the homes and personal property of plaintiffs and the plaintiff class. The first amended
petition seeks monetary relief for plaintiffs and the plaintiff class to compensate them for flood damage
to their property.
The District answered the first amended petition on May 4, 2009, denying liability and raising
affirmative defenses.
The parties have exchanged written discovery requests and responses and have produced documents.
At present, there is no discovery deadline for this matter. However, a case management conference was
held on September 15, 2009 and plaintiffs’’ counsel indicated an intent to file their motion for class
certification on or before January 25, 2010, the date of the next scheduled case management conference.
Peggy Sausville v. The Metropolitan St. Louis Sewer District. St. Louis City Circuit Court, Cause No.
0922-CC01248. On April 1, 2009, plaintiff Peggy Sausville filed this against the District in the Circuit
Court of the City of St. Louis for property damages arising out of the flash flooding of the River Des
Peres in the aftermath of heavy rains from Hurricane Ike on September 14, 2008. The case arises out of
the same facts and circumstances as the Holland and Eppenberger lawsuits and the allegations of the
petition mirror the initial Holland petition. Plaintiff Sausville alleges that she sustained damages to her
home and personal property as a result of the flooding on September 14, 2008.
The petition sounds in two Counts. Count I purports to state a claim for negligence, nuisance and a
dangerous condition of public property, alleging basically that the District was liable because (1) it
failed to construct adequate stormwater facilities along the River Des Peres, such as levees, retaining
walls, and water detention basins; and (2) it failed to forecast and warn plaintiff about the potential
dangers of flash flooding on September 14, 2008. Count II purports to state a claim for inverse
condemnation and damage to plaintiff’s home and personal property caused by the flash flooding of the
River Des Peres.
On April 21, 2009, the District moved to dismiss and transfer venue to the Circuit Court of St. Louis
County. The motion was briefed, argued and remains under submission by the Court. On August 31,
2009, the District answered the petition, without waiver of its venue objection. The District’s answer
denied liability and raised affirmative defenses.
There has been limited discover at this time.
William & Louise Gaddy v. The Metropolitan St. Louis Sewer District. St. Louis County Circuit
Court, Cause No. 09SL-CC03426. On August 7, 2009, plaintiffs William and Louise Gaddy, husband
and wife, filed this action against the District in the Circuit Court of St. Louis County for property
damages arising out of the flash flooding of Maline Creek in the aftermath of heavy rains from
Hurricane Ike on September 14, 2008. This litigation is similar to the Holland, Eppenberger and
Sausville cases and mirrors the pleadings in those cases. However, plaintiffs allege damages as a result
of the flooding of Maline Creek on September 14, 2008 (upstream of the River Des Peres). Plaintiffs
alleged they sustained damage to their homes and personal property on September 14, 2008 as a result
061609 -15-
of the flooding of Maline Creek.
Plaintiffs allege that the District is liable for flood damage to their homes and personal property because
(1) it failed to construct adequate stormwater facilities along the River Des Peres, such as levees,
retaining walls, and water detention basins; and (2) it failed to forecast and warn plaintiffs and the
plaintiff class about the potential dangers of flash flooding on September 14, 2008. The petition further
alleged that the Maline Creek was owned by and under the exclusive control of the District; that it was
in a dangerous condition for which the District was responsible; and that plaintiffs’’ damages resulted
from the dangerous condition of the Maline Creek.
3. Has the Missouri Department of Natural Resources initiated or threatened any enforcement action
against the Participant with regard to the system?
Has the MDNR initiated or threatened any enforcement action?
Yes, US & State of Missouri v MSD
Case # 4:07-cv-1120-JCH
Allege Clean Water Violations
4. Is the Participant under an administrative or judicial compliance order?
No.
5. Please provide any report or investigation made by any governmental agency or administrative
regulatory body concerning the Participant within the last five (5) years.
EPA has conducted a number of inspections. On May 6 – 7, 2002 EPA Region VII conducted a nine
minimum controls inspection of the Bissell system. A favorable, formal, report was received. On
February 10 – 11, 2003 EPA Region VII conducted a nine minimum controls inspection of the Lemay
system. A formal report was never received. On November 8 – 10, 2004 EPA Region VII conducted
an inspection of MSD’s system. No report was ever received.
VI. Requested Documents
Please provide a copy of the following:
1. All annual reports or audited financial statements and auditor’s reports, including any management
letters, for the Participant, and for the Participant’s system, if available, for the last two (2) fiscal years
(if available on a website, please indicate so and provide a web address).
http://www.stlmsd.com/MSD/About
2. Any bond ordinances or resolutions adopted in connection with outstanding system revenue bonds or
any other document that contains restrictions on the use of system revenues.
3. All reports prepared by or for the Participant (including reports by inside or independent consultants)
that describe or evaluate the Participant or its system. Include all reports that detail future operating
costs of the system for the next five (5) years, such as any recent rate studies or operating budget or
engineering reports.
4. Any agreements relating to any grants and/or loans to the Participant relating to its system, including
any USDA Rural Development loans/grants and/or HUD Community Development Block Grants.
5. The most recent official statement, if any, regarding a bond issue or other financing.
6. One copy of this completed form, including supporting documentation, on a compact disk (CD) in
Acrobat Adobe (pdf) format.
061609 -16-
061609 -17-
Executed this _22_ day of September, 2009.
CITY OF St. Louis, MISSOURI
By:
Name: Karl J. Tyminski
Title: Secretary-Treasurer