Loading...
HomeMy Public PortalAbout2019 Agreement for repairs to the culvert and roadway on Cape Florida Drive .pdfS'ONTRA(1 FOR CONSTRUCTION BETWEEN VILLAGE OF KEY BISCAYNE ANDANHISLUTHEASTERLEIQINET iNG ONTRA TO S, IN THIS CONTRACT FOR CONSTRUCTION (this "Contract") on ziM. of January, 2019 ("Effective Date") is made by and between the Village of Key Biscayne, a Florida municipal corporation, whose mailing address is 88 West McIntyre Street, Key Biscayne, FL (hereinafter referred to as "Village"), and Southeastern Engineering Contractors, Inc. a Florida corporation, whose mailing address is 12054 NW 941h Avenue, Hialeah Gardens, FL (hereinafter referred to as "Contractor".) WITNESSETH WHEREAS, in response to the Village's solicitation of bids for culvert and roadway repairs to Cape Florida Drive ("Project"), Contractor submitted a proposal for the Project, which Proposal is incorporated herein by reference and made a part hereof, and includes the Schedule of Bid Items (Pricing) attached hereto as Exhibit "A"; and WHEREAS, Contractor submitted the lowest, responsive and responsible bid in response to the solicitation, and was selected and awarded this Contract for performance of the Work (as hereinafter defined); and WHEREAS, the Work or Project consists of needed repairs to the culvert and roadway on Cape Florida Drive; and WHEREAS, Contractor has represented to the Village that it possesses the necessary qualifications, experience and abilities to perform the Work or the Project, and has agreed to provide the Work on the terms and conditions set forth in this Agreement. NOW, THEREFORE, for and in consideration of the premises and the sum of TEN AND NO/100 DOLLARS ($10.00) and other good and valuable consideration, the receipt and sufficiency of which is hereby acknowledged, the parties hereto do hereby agree as follows: ARTICLE 1 SCOPE OF WORK 1.1 Contractor hereby agrees to furnish all of the labor, materials, equipment, services and incidentals necessary to perform all of the work described in the Contract Documents (the "Work" or the "Project") including, without limitation as described in the approved Task Order approved by the Village's Director of Public Works (the "Village's Project Consultant") dated November 20, 2018 (the "Plans") incorporated herein by reference and made a part of this Contract for the following Project: Cape Florida Drive Culvert and Roadway Repairs Cape Florida Drive Culvert and Roadway Repairs ARTICLE 2 CONTRACT TIME 2.1 Contractor shall be instructed to commence the Work by written instructions in the form of a Notice to Proceed providing a commencement date and issued by the Director of Public Works. The Notice to Proceed will not be issued until Contractor's submission to Village of all required documents and after execution of this Contract. 2.2 Time is of the essence throughout this Contract. The Contractor shall prosecute the Work with faithfulness and diligence and the Work shall be substantially completed within Fourteen (14) calendar days from the date specified in the Notice to Proceed ("Substantial Completion"). Substantial Completion shall be defined for this purpose as the date on which Village receives beneficial use of the Project. The Work shall be fully completed in accordance with the Contract Documents within fourteen (14) calendar days from the date certified by the Village's Director of Public Works as the date of Substantial Completion (`Final Completion") and on the date agreed to by the Village when all Work has been completed in accordance with the Contract Documents. 2.3 Upon failure of Contractor to complete the Contract within the specified period of time, Contractor shall pay to Village the sum of Three Hundred Dollars ($ 300.00) for each calendar day after the time specified in Section 2.2 for Final Completion and readiness for final payment. These amounts are not penalties but are liquidated damages payable by Contractor to Village for the failure to provide full beneficial occupancy and use of the Project as required. Liquidated damages are hereby fixed and agreed upon between the parties who hereby acknowledge the difficulty of determining the amount of damages that will be sustained by Village as a consequence of Contractor's delay and failure of Contractor to complete the Contract on time. The above -stated liquidated damages shall apply separately to each phase of the Project for which a time for completion is given. 2.4 Village is authorized to deduct the liquidated damages from monies due to Contractor for the Work under this Contract. In case the liquidated damage amount due to Village by Contractor exceeds monies due Contractor from Village, Contractor shall be liable and shall immediately upon demand by Village pay to Village the amount of said excess. ARTICLE 3 CONTRACT PRICE 3.1 The Village shall pay the Contractor in current funds for the performance of the Work, subject to additions and deductions by Change Order, in accordance with the Contractor's Proposal and Schedule of Bid Items (Pricing), attached hereto as Exhibit Page 2 of 19 Cape Florida Drive Culvert and Roadway Repairs "A". This sum ("Contract Price") shall be full compensation for all services, labor, materials, equipment and costs, including overhead and profit, associated with completion of all the Work in full conformity with the Contract Documents and adjusted only by written change order signed by both parties and approved as required by local law. The Contract price shall include all applicable sales taxes as required by law. The Contract Price shall not exceed $19,000 00 without an approved Change Order authorized by the Village Council. 3.2 Upon completion of the Project, the Village shall pay the Contractor, in arrears, a lump sum payment upon acceptance of the Work by the Village. Upon the Village's approval and acceptance of the completed Work, the Contractor shall deliver an invoice for the amount due to the Contractor. The Village shall pay the Contractor in arrears in accordance with the Florida Prompt Act. ARTICLE 4 CONTRACT DOCUMENTS 4.1 The Contract Documents, which comprise the entire agreement between the Village and the Contractor concerning the Work, consist of this Contract for Construction (including any change orders and amendments thereto), the Task Order approved by the Village dated November 20, 2018 (the "Plans"), the Technical Specifications, any Bidding Documents or procurement documents for the Project, the Contractor's Bid for the Project (including the Schedule of Bid Items -Pricing), Insurance Certificates, the Notice of Award, and the Notice to Proceed, all of which are deemed incorporated into and made a part of this Contract by this reference and govern this Project. In the event of any conflict among the foregoing, the documents shall govern in the order listed herein Contractor is reminded and hereby recognizes that all Work under this Contract must comply with all applicable federal, state and local law. Any mandatory clauses which are required by applicable law shall be deemed to be incorporated herein. 4.2 This Contract incorporates and includes all prior negotiations, correspondence, conversations, agreements, or understandings applicable to the matters contained herein and the parties agree that there are no commitments, agreements, or understandings concerning the subject matter of these Contract Documents that are not contained herein. Accordingly, it is agreed that no deviation from the terms hereof shall be predicated upon any prior representations or agreements, whether oral or written. 4.3 The Contract Documents shall remain the property of the Village. The Contractor shall have the right to keep one record set of the Contract Documents upon completion of the Project; however, in no circumstances shall the Contractor use, or permit to be used, any or all of such Contract Documents on other projects without the Village's prior written authorization. Page 3 of 19 Cape Florida Drive Culvert and Roadway Repairs ARTICLE 5 INDEMNIFICATION 5.1 Contractor shall defend, indemnify, and hold harmless the Village, its officers, agents and employees, from and against any and all demands, claims, losses, suits, liabilities, causes of action, judgment or damages, including legal fees and costs and through appeal, arising out of or, related to, or in any way connected with Contractor's performance or non-performance of this Contract or with Contractor's obligations or the Work related to the Contract, including by reason of any damage to property, or bodily injury or death incurred or sustained by any party. Contractor shall defend, indemnify, and hold the Village harmless from all losses, injuries or damages and wages or overtime compensation due its employees in rendering services pursuant to this Contract, including payment of reasonable attorneys' fees and costs in the defense of any claim made under the Fair Labor Standards Act, Title VII of the Civil Rights Act of 1964, the Age Discrimination in Employment Act, the Americans with Disabilities Act or any employment related litigation or worker's compensation claims under federal or state law. The provisions of this section shall survive termination of this Contract. ARTICLE 6 jll`ISURANCE 6.1 Insurance. Contractor shall secure and maintain throughout the duration of this Contract insurance of such types and in such amounts not less than those specified below as satisfactory to the Village, naming the Village as an Additional Insured, underwritten by a firm rated A -X or better by Bests Rating and qualified to do business in the State of Florida. Certificates of Insurance shall be provided to the Village, reflecting the Village as an Additional Insured, no later than ten (10) days after award of this Contract and prior to the execution of this Contract by Village and prior to commencing any Work. Each certificate shall include no less than (30) thirty -day advance written notice to Village prior to cancellation, termination, or material alteration of said policies or insurance. The insurance coverage shall be primary insurance with respect to the Village, its officials, employees, agents and volunteers naming the Village as additional insured. Any insurance maintained by the Village shall be in excess of the Contractor's insurance and shall not contribute to the Contractor's insurance. The insurance coverages shall include at a minimum the amounts set forth in this Section 6.1. (a) Commercial General Liability coverage with limits of liability of not less than a $1,000,000 per Occurrence combined single limit for Bodily Injury and Property Damage. This Liability Insurance shall also include Completed Operations and Product Liability coverages and eliminate the exclusion with respect to property under the care, custody and control of Contractor. The General Aggregate Liability limit (except for Products/Completed Operations) shall be in the amount of $2,000,000.00. The Commercial General Liability coverage shall include the following and the coverages and requirements set forth in this Agreement: Page 4 of 19 Cape Florida Drive Culvert and Roadway Repairs (i) personal injury, (ii) broad form property damage; (iii) blanket contractual liability; (iv) XCU coverage; and (v) products and completed operations for 10 years. (b) Workers Compensation and Employer's Liability insurance, to apply for all employees for statutory limits as required by applicable State and Federal laws. The policy(ies) must include Employer's Liability with minimum limits of $1,000,000.00 each accident. No employee, subcontractor or agent of the Contractor shall be allowed to provide Work pursuant to this Contract who is not covered by Worker's Compensation insurance. (c) Business Automobile Liability with minimum limits of $1,000,000.00 per Occurrence, combined single limit for Bodily Injury and Property Damage. Coverage must be afforded on a form no more restrictive than the latest edition of the Business Automobile Liability policy, without restrictive endorsements, as filed by the Insurance Services Office, and must include Owned, Hired, and Non -Owned Vehicles. (d) Builder's Risk property insurance upon the entire Work to the full replacement cost value thereof This insurance shall include the interest of Village and Contractor and shall provide All -Risk coverage against loss by physical damage including, but not limited to, Fire, Extended Coverage, Theft, Vandalism and Malicious Mischief. (e) Contractor acknowledges that it shall bear the full risk of loss for any portion of the Work damaged, destroyed, lost or stolen until Final Completion has been achieved for the Project, and all such Work shall be fully restored by the Contractor, at its sole cost and expense, in accordance with the Contract Documents. (f) Certificate of Insuranc. On or before the Effective Date of this Contract, the Contractor shall provide the Village with Certificates of Insurance for all required policies. The Contractor shall be responsible for assuring that the insurance certificates required by this Section remain in full force and effect for the duration of this Contract, including any extensions or renewals that may be granted by the Village. The Certificates of Insurance shall not only name the types of policy(ies) provided, but also shall refer specifically to this Contract and shall state that such insurance is as required by this Contract. The Village reserves the right to inspect and return a certified copy of such policies, upon written request by the Village. If a policy is due to expire prior to the completion of the Work, renewal Certificates of Insurance shall be furnished thirty (30) calendar days prior to the date of their policy expiration. Each policy certificate shall be endorsed with a provision that not less than thirty (30) calendar days' written notice shall be provided to the Village before any policy or coverage is cancelled or restricted Acceptance of the Certificate(s) is subject to approval of the Page 5 of 19 Cape Florida Drive Culvert and Roadway Repairs Village. (g) Additional Insured. The Village is to be specifically included as an Additional Insured for the liability of the Village resulting from Work performed by or on behalf of the Contractor in performance of this Contract. The Contractor's insurance, including that applicable to the Village as an Additional Insured, shall apply on a primary basis and any other insurance maintained by the Village shall be in excess of and shall not contribute to the Contractor's insurance. The Contractor's insurance shall contain a severability of interest provision providing that, except with respect to the total limits of liability, the insurance shall apply to each Insured or Additional Insured (for applicable policies) in the same manner as if separate policies had been issued to each. (h) peductibles. All deductibles or self -insured retentions must be declared to and be reasonably approved by the Village. The Contractor shall be responsible for the payment of any deductible or self -insured retentions in the event of any claim. (i) The provisions of this section shall survive termination of this Contract. ARTICLE 7 CONTRACTOR'S REPRESENTATIONS ANI) WARRANTIES In order to induce the Village to enter into this Contract, the Contractor makes the following representations and warranties: 7.1 Contractor represents the following: 7.1.1 Contractor has examined and carefully studied the Contract Documents and the other data identified in the bidding documents, including, without limitation, the "technical data" and plans and specifications and the Plans. 7.1.2 Contractor has visited the Project site and become familiar with and is satisfied as to the general and local conditions and site conditions that may affect cost, progress, performance or furnishing of the Work. 7.1.3 Contractor is familiar with and is satisfied as to all federal, state and local laws, regulations and permits that may affect cost, progress, performance and furnishing of the Work. Contractor agrees that it will at all times comply with all requirements of the foregoing laws, regulations and permits, including but not limited to the Village's Noise Ordinance codified in Chapter 17 of the Village Code. 7.1.4 Contractor has made, or caused to be made, examinations, investigations, tests Page 6 of 19 Cape Florida Drive Culvert and Roadway Repairs and/or studies as necessary to determine surface and subsurface conditions at or on the site. Contractor acknowledges that the Village does not assume responsibility for the accuracy or completeness of information and data shown or indicated in the Contract Documents with respect to underground or ground facilities at, contiguous or near the site or for existing improvements at or near the site. Contractor has obtained and carefully studied (or assumes responsibility for having done so) all such additional supplementary examinations, investigations, explorations, tests, studies and data concerning conditions (surface, subsurface and underground facilities and improvements) at, contiguous or near to the site or otherwise which may affect cost, progress, performance or furnishing of the Work or which relate to any aspect of the means, methods, techniques, sequences and procedures of construction to be employed by Contractor and safety precautions and programs incident thereto. Contractor does not consider that any additional examinations, investigations, explorations, tests, studies or data are necessary for the performance and furnishing of the Work at the Contract Price, within the Contract Time and in accordance with the other terms and conditions of the Contract Documents. 7.1.5 Contractor is aware of the general nature of Work to be performed by the Village and others at the site that relates to the Work as indicated in the Contract Documents. 7.1.6 Contractor has correlated the information known to Contractor, information and observations obtained from visits to the site, reports and drawings identified in the Contract Documents and all additional examinations, investigations, explorations, tests, studies and data with the Contract Documents. 7.1.7 Contractor has given Village written notice of all conflicts, errors, ambiguities or discrepancies that Contractor has discovered in the Contract Documents and the written resolution thereof by Village is acceptable to Contactor, and the Contract Documents are generally sufficient to indicate and convey understanding of all terms and conditions for performance and furnishing of the Work. 7.1.8 The Contractor agrees and represents that it possesses the requisite qualifications and skills to perform the Work and that the Work shall be executed in a good and workmanlike manner, free from defects, and that all materials shall be new and approved by or acceptable to Village, except as otherwise expressly provided for in the Contract Documents. The Contractor shall cause all materials and other parts of the Work to be readily available as and when required or needed for or in connection with the construction, furnishing and equipping of the Proj ect. 7.2 Contractor warrants the following: Page 7 of 19 Cape Florida Drive Culvert and Roadway Repairs 7.2.1 Anti -Discrimination: Contractor agrees that it will not discriminate against any employees or applicants for employment or against persons for any other benefit or service under this Contract because of race, color, religion, sex, national origin, or physical or mental handicap where the handicap does not affect the ability of an individual to perform in a position of employment, and agrees to abide by all federal and state laws regarding non-discrimination. 7.2.2 Anti -Kickback: Contractor warrants that no person has been employed or retained to solicit or secure this Contract upon an agreement or understanding for a commission, percentage, brokerage or contingent fee, and that no employee or officer of the Village has any interest, financially or otherwise, in the Project. For breach or violation of this warranty, the Village shall have the right to annul this Contract without liability or, in its discretion, to deduct from the Contract Price or consideration, the full amount of such commission, percentage, brokerage or contingent fee. _ 7.2.3 Licensing and Permits: Contractor warrants that it shall have, prior to commencement of Work under this Contract and at all times during said Work, all required licenses and permits whether federal, state, County or Village. Contractor acknowledges that it is the obligation of Contractor to obtain all licenses and permits required for this Project, including Village building permits. 7.2.4 Scrutinized Companies: Contractor represents and warrants that it and its subcontractors are not on the Scrutinized Companies that Boycott Israel List. Pursuant to Section 287.135, F.S., the Village may immediately terminate this Agreement at its sole option if the Contractor or its subcontractors are found to have submitted a false certification; or if the Contractor, or its subcontractors are placed on the Scrutinized Companies that Boycott Israel List or is engaged in the boycott of Israel during the term of the Contract ART CLE 8 »EFAULT AND TERMINATION 8.1 If Contractor fails to timely begin the Work, or fails to perform the Work with sufficient workers and equipment or with sufficient materials to insure the prompt completion of the Work within the Contract Time as specified in Article 2, or shall perform the Work unsuitably, or cause it to be rejected as defective and unsuitable, or shall discontinue the prosecution of the Work pursuant to the accepted schedule or if the Contractor shall fail to perform any material term set forth in the Contract Documents or if Contractor shall become insolvent or be declared bankrupt, or commit any act of bankruptcy or insolvency, or shall make an assignment for the benefit of creditors, or from any other cause whatsoever shall not carry on the Work in an acceptable manner, Village may, upon seven (7) days written Notice of Termination, terminate the services of Contractor, exclude Contractor from the Project site, provide for alternate prosecution of the Work, appropriate Page 8 of 19 Cape Florida Drive Culvert and Roadway Repairs or use any or all materials and equipment on the Project site as may be suitable and acceptable, and may finish the Work by whatever methods it may deem expedient. In such case, Contractor shall not be entitled to receive any further payment until the Project is completed. All damages, costs and charges incurred by Village, together with the costs of completing the Project, shall be deducted from any monies due or which may become due to Contractor. In case the damages and expenses so incurred by Village shall exceed monies due Contractor from Village, Contractor shall be liable and shall pay to Village the amount of said excess promptly upon demand therefore by Village. In the event it is adjudicated that Village was not entitled to terminate the Contract as described hereunder for default, the Contract shall automatically be deemed terminated by Village for convenience as described below. 8.2 This Contract may be terminated by the Village for convenience upon seven (7) calendar days' written notice to the Contractor. In the event of such a termination, the Contractor shall incur no further obligations in connection with the Project and shall, to the extent possible, terminate any outstanding subcontractor obligations. The Contractor shall be compensated for all services performed to the satisfaction of the Village. In such event, the Contractor shall promptly submit to the Village its Application for Payment for final payment which shall comply with the provisions of the Contract Documents. ARTICLE 9 MISCELLANEOUS 9.1 No Assignment. Neither party shall assign the Contract or any sub -contract in whole or in part without the written consent of the other, nor shall Contractor assign any monies due or to become due to it hereunder, without the previous written consent of the Director of Public Works. 9.2 Contractor's Responsibility for Damages and Accidents: 9.2.1 Contractor shall accept full responsibility for the Work against all loss or damage of any nature sustained until final acceptance by Village, and shall promptly repair any damage done from any cause. 9.2.2 Contractor shall be responsible for all materials, equipment and supplies pertaining to the Project. In the event any such materials, equipment and supplies are lost, stolen, damaged or destroyed prior to final acceptance by Village, Contractor shall replace same without cost to the Village. 9.2.3 Contractor shall be responsible for promptly notifying the Village of any damage to sidewalks, roads, irrigation systems, buildings or other structures, vehicles, or property or possessions, which occur as a result of the Work performed by Page 9 of 19 Cape Florida Drive Culvert and Roadway Repairs Contractor pursuant to this Contract, or the improper or negligent activities of the Contractor. 9.3 Defective Work, Warranty and Guarantee: 9.3.1 Village shall have the authority to reject or disapprove Work which the Village finds to be defective. If required by the Village, Contractor shall promptly either correct all defective Work or remove such defective Work and replace it with non -defective Work. Contractor shall bear all direct, indirect and consequential costs of such removal or corrections including cost of testing laboratories and personnel. 9.3.2 Should Contractor fail or refuse to remove or correct any defective Work or to make any necessary repairs in accordance with the requirements of the Contract Documents within the time indicated in writing by the Village, the Village shall have the authority to cause the defective Work to be removed or corrected, or make such repairs as may be necessary at Contractor's expense. Any expense incurred by Village in making such removals, corrections or repairs, shall be paid for out of any monies due or which may become due to Contractor. In the event of failure of Contractor to make all necessary repairs promptly and fully, Village may declare Contractor in default. 9.3.3 The Contractor shall unconditionally warrant and guarantee all materials and equipment furnished and Work performed for a period of one (1) year from the date of Substantial Completion. If, within one (1) year after the date of substantial completion, any of the Work is found to be defective or not in accordance with the Contract Documents, Contractor, after receipt of written notice from Village, shall promptly correct such defective or nonconforming Work within the time specified by Village without cost to Village. Nothing contained herein shall be construed to establish a period of limitation with respect to any other obligation which Contractor might have under the Contract Documents including but not limited to any claim regarding latent defects. Contractor shall provide and assign to Village all material and equipment warranties upon completion of the Work hereunder. 9.3.4 Failure to reject any defective Work or material shall not in any way prevent later rejection when such defect is discovered. 9.4 Leial Restrictions and Hours of Work. Contractor shall conform to and obey all applicable laws, regulations, or ordinances with regard to labor employed, hours of Work and Contractor's general operations. Contractor shall conduct its operations so as not to interfere with or close any thoroughfare, without the written consent of the Village or governing jurisdiction. Work is anticipated to be performed Monday through Friday in accordance with the requirements and limitations of applicable law including, without limitation, the Village Code of Ordinances. The Page 10 of 19 Cape Florida Drive Culvert and Roadway Repairs Contractor shall not perform Work beyond the time and days provided above without the prior written approval of the Village. 9.5 Examination and Retention of Contractor's Records. 9.5.1 The Village or any of its duly authorized representatives shall, until three (3) years after final payment under this Contract, have access to and the right to examine any of the Contractor's books, ledgers, documents, papers, or other records involving transactions related to this Contract for the purpose of making audit, examination, excerpts, and transcriptions. In addition, the Contractor agrees to comply specifically with the provisions of Section 119.0701, Flonda Statutes 9.5.2 The Contractor agrees to include in any subcontractor contracts for this Project corresponding provisions for the benefit of Village providing for retention and audit of records. 9.5.3 The right to access and examination of records stated herein and in any subcontracts, shall survive termination or expiration of this Contract and continue until disposition of any mediation, claims, litigation or appeals related to this Project. 9.5.4 The Village may cancel and terminate this Contract immediately for refusal by the Contractor to allow access by the Director of Public Works or his designees to any Records pertaining to work performed under this Contact that are subject to the provisions of Chapter 119, Florida Statutes 9.6 No Damages for Delay: No claim for damages or any claim, other than for an extension of time shall be made or asserted against Village by reason of any delays. Contractor shall not be entitled to an increase in the Contract Price or payment or compensation of any kind from Village for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to, costs of acceleration or inefficiency, arising because of delay, disruption, interference or hindrance from any cause whatsoever, whether such delay, disruption, interference or hindrance be reasonable or unreasonable, foreseeable or unforeseeable, or avoidable or unavoidable or whether or not caused by Village. Contractor shall be entitled only to extensions of the Contract Time as the sole and exclusive remedy for such resulting delay. Notwithstanding the above Contractor may be granted an extension of time and suspension of liquidated damages for any delay beyond the control of the Contractor. Should any delay, disruption, interference or hindrance be intentionally caused by the Village, for a continuous period or cumulative period of thirty (30) days, the Contractor may terminate the Contract upon seven days written notice to the Village. Page 11 of 19 Cape Florida Drive Culvert and Roadway Repairs 9.7 Authorized Representative. 9.7.1 Before commencing the Work, Contractor shall designate a skilled and competent authorized supervisor and representative ("Authorized Representative") acceptable to Village to represent and act for Contractor and shall inform Village, in writing, of the name and address of such representative together with a clear definition of the scope of his authority to represent and act for Contractor. Contractor shall keep Village informed of any subsequent changes in the foregoing. Such representative shall be present or duly represented at the Project site at all times when Work is actually in progress. All notices, determinations, instructions and other communications given to the authorized representatives of Contractor shall be binding upon the Contractor. 9.7 2 The Authorized Representative, project managers, superintendents and supervisors for the Project are all subject to prior and continuous approval of the Village. If, at any time during the term of this Contract, any of the personnel either functionally or nominally performing any of the positions named above, are, for any reasonable cause whatsoever, unacceptable to the Village, Contractor shall replace the unacceptable personnel with personnel acceptable to the Village. 9.8 Taxes. Contractor shall pay all taxes, levies, duties and assessments of every nature which may be applicable to any Work under this Contract. The Contract Price and any agreed variations thereof shall include all taxes imposed by law at the time of this Contract. Contractor shall make any and all payroll deductions required by law. Contractor herein indemnifies and holds Owner harmless from any liability on account of any and all such taxes, levies, duties and assessments. 9.9 Utilities. Contractor shall, at its expense, arrange for, develop and maintain all utilities at the Project to perform the Work and meet the requirements of this Contract. Such utilities shall be furnished by Contractor at no additional cost to Village. Prior to final acceptance of the Work, Contractor shall, at its expense, satisfactorily remove and dispose of all temporary utilities developed to meet the requirements of this Contract. 9.10 Safety Contractor shall be fully and solely responsible for safety and conducting all operations under this Contract at all times in such a manner as to avoid the risk of bodily harm to persons and damage to property. Contractor shall continually and diligently inspect all Work, materials and equipment to discover any conditions which might involve such risks and shall be solely responsible for discovery and correction of any such conditions. Page 12 of 19 Cape Florida Drive Culvert and Roadway Repairs Contractor shall have sole responsibility for implementing its safety program. Village shall not be responsible for supervising the implementation of Contractor's safety program, and shall not have responsibility for the safety of Contractor's or its subcontractor's employees. Contractor shall maintain all portions of the Project site and Work in a neat, clean and sanitary condition at all times. Contractor shall assure that subcontractors performing Work comply with the foregoing safety requirements. 9.11 Cleaning Up Contractor shall, at all times, at its expense, keep its Work areas in a neat, clean and safe condition. Upon completion of any portion of the Work, Contractor shall promptly remove all of its equipment, construction materials, temporary structures and surplus materials not to be used at or near the same location during later stages of Work. Upon completion of the Work and before final payment is made, Contractor shall, at its expense, satisfactorily dispose of all rubbish, unused materials and other equipment and materials belonging to it or used in the performance of the Work and Contractor shall leave the Project in a neat, clean and safe condition. In the event of Contractor's failure to comply with the foregoing, the same may be accomplished by Village at Contractor's expense. 9.12 Rights and Remedies. The duties and obligations imposed by the Contract Documents and the rights and remedies available thereunder and in accordance with this Contract shall be in addition to and not a limitation of any duties, obligations, rights and remedies otherwise imposed or available by law. 9.13 Public Entity Crimes Affidavit Contractor shall comply with Section 287.133, Florida Statutes, and (Public Entity Crimes Statute) notification of which is hereby incorporated herein by reference, including execution of any required affidavit. 9.14 Capitalized Terms, Capitalized terms shall have their plain meaning as indicated herein. 9.15 independent Contractor. The Contractor is an independent contractor under the Contract. This Contract does not create any partnership nor joint venture. Services provided by the Contractor shall be by employees of the Contractor and subject to supervision by the Contractor, and not as officers, employees, or agents of the Village. Personnel policies, tax responsibilities, social security and health insurance, employee benefits, purchasing policies and other similar Page 13 of 19 Cape Florida Drive Culvert and Roadway Repairs administrative procedures, applicable to services rendered under the Contract shall be those of the Contractor. 9.16 Payment to Sub -Contractors. Certification of Payment to Subcontractors: The term "subcontractor", as used herein, includes persons or firms furnishing labor, materials or equipment incorporated into or to be incorporated into the Work or Project. The Contractor is required to pay all subcontractors for satisfactory performance of their contracts as a condition precedent to payment to Contractor by the Village. The Contractor shall also return all retainage withheld to the subcontractors within 30 days after the subcontractor's work is satisfactorily complete and accepted by the Village. 9.17 Liens., Contractor shall not permit any mechanic's, laborer's or materialmen's lien to be filed against the Project site or any part thereof by reason of any Work, labor, services or materials supplied or claimed to have been supplied to the Project. In the event such a lien is found or claimed against the Project, Contractor shall within ten (10) days after notice of the lien discharge the lien or liens and cause a satisfaction of such lien to be recorded in the public records of Miami -Dade County, Florida, or cause such lien to be transferred to a bond, or post a bond sufficient to cause the Clerk of the Circuit Court of Miami -Dade County, Florida, to discharge such lien pursuant to Chapter 713.24, F.S. In the event Contractor fails to so discharge or bond the lien or liens within such period as required above, Village shall thereafter have the right, but not the obligation, to discharge or bond the lien or liens. Additionally, Village shall thereafter have the right, but not the obligation, to retain out of any payment then due or to become due Contractor, one hundred fifty percent (150%) of the amount of the lien and to pay Village 's reasonable attorneys' fees and costs incurred in connection therewith. 9.18 Governing Law This Contract shall be construed in accordance with and governed by the laws of the State of Florida. Venue for any litigation arising out of this Contract shall be proper exclusively in Miami- Dade County, Florida. 9.19 Waiver of Jury Trial, Village and Contractor knowingly, irrevocably, voluntarily and intentionally waive any right either may have to a trial by jury in State and or Federal court proceedings in respect to any action, proceeding, lawsuit or counterclaim based upon the Contract for Construction, arising out of, under, or in connection with the Construction of the Work, or any course of conduct, course of dealing, statements or actions or inactions of any partY. Page 14 of 19 Cape Florida Drive Culvert and Roadway Repairs 9.20 Notices/Authorized Representatives. Any notices required by this Contract shall be in wnting and shall be deemed to have been properly given if transmitted by hand -delivery, by registered or certified mail with postage prepaid return receipt requested, or by a private postal service, addressed to the parties (or their successors) at the following addresses: For the Village: Andrea Agha Village Manager Village of Key Biscayne 88 West McIntyre Street Key Biscayne, FL 33149 With a copy to: For the Contractor: Chad Friedman, Esq. Village Attorney Weiss Serota Helfman Cole & Bierman, P.L. 2525 Ponce de Leon Blvd., Suite 700 Coral Gables, FL 33134 Southeastern Engineering Contractors, Inc. Attn: Eduardo Dominguez, Jr. 12054 NW 98th Avenue Hialeah Gardens, Florida 33018 Phone. (305) 557-4226 Email: 9.21 Prevailing Party: Attorneys' Fees. In the event of any controversy, claim, dispute or litigation between the parties arising from or relating to this Contract (including, but not limited to, the enforcement of any indemnity provisions), the prevailing party shall be entitled to recover reasonable costs, expenses and attorneys' fees including, but not limited to, court costs and other expenses through all appellate levels. ARTICLE 10 SPECIAL CONDITIONS 10.1 The following provisions supersede any provisions contained in this Contract only to the extent of any conflict with same. These provisions are particular to a given transaction and are transaction specific: None. [THE REMAINDER OF THIS PAGE LEFT INTENTIONALLY BLANK; SIGNATURE PAGES FOLLOW ON NEXT PAGES] Page 15 of 19 Cape Florida Drive Culvert and Roadway Repairs IN WITNESS WHEREOF, the parties hereto have made and executed this Contract on the respective dates under each signature: VILLAGE OF KEY BISCAYNE, FLORIDA, signing by and through its Village Manager authorized to execute same, and Southeastern Engineering Contractors, Inc. signing by and through its duly authorized to execute same. VILLAGE: ATTEST: lfer Media, Village lerk, C ► , APPROVED AS TO FO AND LEGAL SUFFICIEN WEISS SEROTA HELFMAN COLE & BIERMAN, P.L. VILLAGE ATTORNEY VILLAGE OF KEY BISCAYNE, a Florida municipal corporation By: Andrea Agha, Vi lage Manager 14 Executed: Page 16 of 19 Cape Florida Drive Culvert and Roadway Repairs CONTRACTOR MUST EXECUTE TI-IIS CONTRACT AS INDICATED BELOW. USE CORPORATION FORMAT, AS APPLICABLE. CONTRACTOR: SOUTHEASTERN ENGINEERING CONTRACTORS, INC., a Florida c. •oration ATTEST: [Corporate Seal)] Date Executed: t \ 4;;A 19 By: Print Name: Title: Page 17 of 19 Cape Florida Drive Culvert and Roadway Repairs JXHIBIT "A" IMO CON o rM loonu.Ir 0•Yr. M Margot YM2W .A. T COITM0 0 {0.0 Ora n 00$*,*. Crn000ors, no. l.ti roar 21.4.4111.211, Fr 1g10 Pow.120!1 SS74770 7..•11061!)7 NA _1/121 tON/MQMIIOIR sWMI0.Cr06C step ...r..- .-.wln u•:..1:++1kr+ LC 'mum CDNTIL.CI ad 71.1. CDi1: MOWS f20 Tp V.71.pel dry i.wW.r *$ Wool WMOM•St..w rot lardWCd, 4. Ul•. CRY 03441111-7. 131 wows WI: .NORCT 0.Y4 Coo 770416 Co Sk41RN .R1LR LO 111O1 101 CAM RO7..O 4,0(13100 L' UM0O1Q*0110: 1 /:0720111 I&WMOAf 07 MOp 7 We? Muffing Rani INC.I01a IM COA..LT RIM RGr G13[AS110M W Owl NNR MOLL iOLpL{11CI *0..L0id 1.11...11: 7... dry SI ITN •• D.MIM11JaMGOtW. 'Ott 11, p.V..11111.0407 lm Oda W.... 71: drr SI . 1»r 11 C2101001LMP *Oro.•f0* *Oro.*Oro. 51.. , 21.00'WI 1 1047137.047O1•17.57711.IWIIC.VIL/ 10177001 ww1-Wil.:, 0.11 7 HO SI,. s0 on.. 21 mo 7ar mown, *Amt. .O1 1.5 Goo 100% UV 02107 MIT pORO10M1K1LM 1 .in S.7S0 p*r 11 L.N.,IOCAIOL+WDLwnnoo list -p. r...1MLM1 PAM% •r0. 51.1!.00 $1•.r rr&2W L.C.vu0.N 10 R.4TAc $7 LSO 117{(2 •. •LOOytllu 50 ..I}.1. 2200.00 YM.1 •. I wALLGUvfI004M1017.LROMT1011(1R10)1'LfVWRI,L)YA6 O/0122 .0 .. _•.: 0=0 311.119 MI Id 1. 0.010400110100001. i• .4 00., •72. 70 Y`0 `-r.sr Yµ0 .1 010 oo4st...YO10IY ter u. S Ilrr w ,. t1 . AorO.Y r meli.00 salt isms 120000! 721 Inl.elord 15,05 mew •, I. ,..a O./11C ONO LtLW A. I IK GO Or 2 0 Y., 2775.00 holm w1 . . . _ nsa7R0ila MMOftf 4Li00, s apt* vtr.: 21 21(2(2 Ka .*02(210.0 f:. 24.7.4 100114, t». .. ,. .0 ..r.rtre ,.. .. 1777 ma - '0 cw. /arc/ SA a: Mill 721 r...., 1ryV•..G-r.c,...0:.<'IM MrOw MIQ ned r<- ft. 1,. 02121.7 1.) 0.%n 1103),../014 W V lOPGoO C007MSOr1414ru0 71x1 a 51.00 000.0 r+ ...1] n/V0M11..MlOVai 12*0 1LMµ0V W21I I00.1M1mO R fan .. _ 51.00 OM SI 71 re0 IOU maw= 03,40.1.1010N•C2Mi0I MIDNA.LI rar 51.20 SOONSOON5Pl In jAta 11,0J.M161/1 .14D.M:CI 1003 ri. f100 WOO, foal tddhlabendWJIs Crewe 021,06700 Page 18 of 19 Cape Florida Drive Culvert and Roadway Repairs _EXHIBIT "B" (Attach Contractor's Certificates of Insurance) Page 19 of 19 SOUTENG-01 STWIGGS CCPR'CIP CERTIFICATE OF LIABILITY INSURANCE DATE (MMIDDIYYYY) 01/2412019 THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE HOLDER THIS CERTIFICATE DOES NOT AFFIRMATIVELY OR NEGATIVELY AMEND, EXTEND OR ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. THIS CERTIFICATE OF INSURANCE DOES NOT CONSTITUTE A CONTRACT BETWEEN THE ISSUING INSURER(S), AUTHORIZED REPRESENTATIVE OR PRODUCER, AND THE CERTIFICATE HOLDER. IMPORTANT: If the certificate holder Is an ADDITIONAL INSURED, the policy(les) must have ADDITIONAL INSURED provisions or be endorsed. If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). PRODUCER Collinsworth, Alter, Fowler & French, LLC 8000 Governors Square Blvd Suite 301 Miami Lakes, FL 33016 INSURED Southeastern Engineering Contractors, Inc 12054 NW 98th Avenue Hialeah Gardens, FL 33018 prio NC,,No, Fart) (305) 822-7800 FAX Ne).(305) 362-2443 ADDf2ESS INSURER(S) AFFORDING COVERAGE NAIC # INSURER A• Federal Insurance Company 20281 I INSURER B Commerce & Industry Insurance Company 19410 INSURER Ironshore Specialty Insurance Company INSURER D . INSURER E I INSURER F . COVERAGES CERTIFICATE NUMBER: REVISION NUMBER: THIS IS TO CERTIFY THAT THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD , INDICATED NOTWITHSTANDING ANY REQUIREMENT, TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN, THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS, EXCLUSIONS AND CONDITIONS OF SUCH POLICIES LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS IlN.TR 1 TYPE OF INSURANCE N50ISVWD I POLICY NUMBER I (MMIDq/YTr11 I lMNVO YD/YYI^r) XP LIMITS A X 1 COMMERCIAL GENERAL LIABILITY 1 CLAIMS -MADE , X I OCCUR ' X 154309780 09/22/2018 _ _ 09122/2019 EACH OCCURRENCE $ 1,000,000 DAMAGE TO RENTED PREMISES (Ee NTED rrce) 5 100,000 MED EXP (Any one person) $ 5,000 PERSONAL 8 ADV INJURY 5 1,000,000 _ GEM. AGGREGATE LIMIT APPUES PER '-- POLICY X 1 P - _. LOC OTHER GENERAL AGGREGATE $ 2,000,000 PRODUCTS - COMP/OPAGG $ 2,000,000 S A AUTOMOBILE UABILITY X ANY AUTO _ 54309779 09/22/2018 OWNED SCHEDULED I AUTOSRE�ONLY AUUTNOSyy�Ep X AUTOS ONLY X AUTO ONLY 1 09/22/2019 COMBINED SINGLE UMIT (Eaacaden(( 5 1,000,000 BODILY INJURY (Per person) s BODILY INJURY (Per accident.) S PROPERTY accident) DAMAGE s 5 B X UMBRELLA LIAR X I OCCUR I EXCESS LAB CLAIMS -MADE 1BE028291980 01/31/2018 01/31/2019 EACH OCCURRENCE S 3,000,000 AGGREGATE 5 3,000,000 DED I RETENTION 5 5 A WORKERS COMPENSATION AND EMPLOYERS' UABILITY Y / N STATUTE ANY PROPRIETOR/PARTNER/EXECUTIVE /54309781 09!2212018 �FFICEwFtIMMEMgER EXCLUDED? N / A I lendatory In NR) -- H es descnbe under DESCRIPTION OF OPERATIONS below 09/22/2019 I PER 1OTH- ER E L EACH ACCIDENT S 1,000,000 E L DISEASE -EA EMPLOYEES 1,000,000 E L DISEASE -POLICY LIMIT 5 1,000,000 A C Equipment Floater 45468421 03/26/2018 Pollution Liability (003214101 06/29/2018 03/26/2019 Leased/Rented 06/29/2019 Aggregate/Occurrence 500,000 1,000,000 DESCRIPTION OF OPERATIONS 1 LOCATIONS / VEHICLES (ACORD 101, Addltlonal Remarks Schedule, may be attached H more space Is required) Existing Culvert Pavement Settlement Repairs Certificate holder is additional Insured CERTIFICATE HOLDER CANCELLATION Village of Key Biscayne 88 West McIntyre Street Key Biscayne, FL 33149 SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF, NOTICE WILL BE DELIVERED IN ACCORDANCE WITH THE POLICY PROVISIONS. AUTHORIZED REPRESENTATIVE araimommonsommb ACORD 25 (2016/03) © 1988-2015 ACORD CORPORATION. All rights reserved. The ACORD name and logo are registered marks of ACORD