HomeMy Public PortalAboutORD15786 BILL NO. 2017-132
SPONSORED BY Councilman Henry
ORDINANCE NO. /5'7ee
AN ORDINANCE OF THE CITY OF JEFFERSON, MISSOURI, AUTHORIZING THE
MAYOR AND CITY CLERK TO EXECUTE AN AGREEMENT WITH MUSSELMAN &
HALL CONTRACTORS, LLC, IN THE AMOUNT OF $148,571.16 FOR THE 2018 FOG
SEAL PROJECT.
WHEREAS, Musselman & Hall Contractors, LLC has become the apparent lowest and
best bidder on the 2018 Fog Seal project;
NOW, THEREFORE, BE IT ENACTED BY THE COUNCIL OF THE CITY OF
JEFFERSON, MISSOURI, AS FOLLOWS:
Section 1. The bid of Musselman & Hall Contractors, LLC is declared to be the
lowest and best bid and is hereby accepted for the 2018 Fog Seal project.
Section 2. The Mayor and City Clerk are hereby authorized to execute an
agreement with Musselman & Hall Contractors, LLC for the 2018 Fog Seal project.
Section 3. The agreement shall be substantially the same in form and content as
that agreement attached hereto as Exhibit A.
Section 4. This Ordinance shall be in full force and effect from and after the date
of its passage and approval.
Passed: )p17/ /to/ A/6 Approved: 7 0,p/e
Presiding Officer Mayor Carrie Tergin Vt
ATTEST: APPROVED AS TO FORM:
/` a
ad101 roll=
Ci Clerk City oun .-for
FINANCE DEPARTMENT
PURCHASING DIVISION
SUBJECT: Bid 2976-Project 32156-2018 Fog Seal
Public Works , Street Division -Opened March 20, 2018
RECOMMENDATION:
Staff recommends award of the bid to the lowest and best bid meeting specifications, Musselman
& Hall Contractors , LLC , Kansas City , MO in the amount of $148,571.16.
BIDS RECEIVED :
Musselman & Hall Contractors , LLC , Kansas City , MO
Innovative Roadway , St. Louis , MO
$148 ,571.16
$ 219,530.52
The project was advertised in News Tribune, posted on the city web site, sent to seven plan
rooms and the City's construction vendor list.
FISCAL NOTE:
45-990-577031
Street Resurfacing
Sales Tax G funds
2017-2018 Budget
E xpensed
Encumbered
Bid 2976
Balance
$1 , 339,156.74
1,047.50
31,892.28
$ 148,571.16
$1 ,157,645.80
PAST PERFORMANCE :
This bidder completed projects as specified and bid in the past. Staff feels the vendor will
complete this project as specified and bid.
ATTACHMENTS -S UPPORTING DOCUMENTATION
Signature ~~-W M2ft )
Pure as1 g Agent
Department of Public Works Memorandum
320 E . McCarty Street ·Jefferson City, Missouri 65101 • P 573-634-6410 • F 573-634-6562 • www.jeffcitymo.org
Date:
To:
From :
Subject:
March 20, 2018
Terry Stephenson , Purchasing Director , Finance
Britt E. Smith , PE ~
2018 Fog Seal
Project No. 32156
Bid No. 2976
Public Works has completed a review of the bids opened at 1:30 P.M. on March 20, 2018 for the
above noted project. As part of the review all the bids were tabulated to check for math errors
and to compare unit price quotes of the various contractors . Attached to this memo is the
tabulation of the Two (2) bids that were received for the project, as well as a listing of the
registered plan holders.
Based on our review, we recommend acceptance of the bid from the low bidder Musselman &
Hall Contractors, LLC , 4922 East Blue Banks, Kansas City, MO 64130. The total amount of the
contract will be $148,571 .16.
The project will be expensed as follows:
Musselman & Hall Contractors, LLC ($148,571.16):
Account Number: Amount Available: Required: Remaining:
45-990-577031 $1 ,306 ,216.96 $148,571 .16 $1 ,157,645.80
If you need any other information please feel free to contact me at extension 6450.
Attachments: Bid Tabulation Sheet, Plan Holders List
cc: Project file
Writer's file
Page 1
Date: 20/03/2018
Bid No. 2976
ITEM NO.
1
DESCRIPTION
Surface Seal, Onxy
TOTAL BASE BID
% OVER/UNDER ENGINEER'S EST.
TOTAL CONTRACT WITH ACCEPTED ALTERNATES
APPROX.
UNIT QUANTITY
SY 110874
CITY OF JEFFERSON
BID TABULATION
2018 FOG SEAL
PROJECT NO. 32156
ENGINEER'S ESTIMATE Musselman and Hall
UNIT UNIT
PRICE AMOUNT PRICE AMOUNT
$1.35 $149,679.90 $1.34 $148,571.16
$149,679.90 $148,571.16
-0.7%
$149,679.90 $148,571.16
Innovative Roadway
UNIT UNIT
PRICE AMOUNT PRICE AMOUNT
$1.98 $219,530.52
$219,530.52
46.7% I
$219,530.52
Exhibit#1
SCHEDULE OF QUANTITIES
LOCATION YEAR FROM TO WIDTH LENGTH AREA(S.Y.) Surface Mix
RESURFACED {ft.) {ft.) Type
McCarty St. 2014 Chestnut St. Locust St. 32 930 3,307 Fog
McCarty St. 2014 Lafayette St. Chestnut St. 38 890 3,758 Fog
McCarty St. 2014 Locust St. Clark Ave. 38 620 2,618 Fog
St. Louis Rd 2014 McCarty St. McCarty St. 27 7,415 22,245 Fog
Jefferson St. 2014 Capitol Ave. High St. 53 440 2,591 Fog
Jefferson St. 2014 High St. McCarty St. 53 440 2,591 Fog
Jefferson St. 2014 McCarty St. W. Expressway 46 780 3,987 Fog
McCarty St. 2014 BolivarS! Hwy 54 On Ramp 46 475 2,428 Fog
AlrViewDr. 2014 Southern Air Dr. Royal Air Dr. 30 250 833 Fog
Belair Dr. 2014 Hinsdale Dr. Twin Hlil Dr. 26 2.530 7,309 Fog
Belair Dr. 2014 Main St. Hillsdale Dr. 26 680 1,964 Fog
Fox Creek Rd. 2014 Schellrldge Dr. W. End 29 850 2,739 Fog
MainSt.W 2014 Jaycee Dr. 179 30 2,125 7,083 Fog
Old Gibler Rd 2014 Shellrldge Rd W. Sterling Price Rd 30 1,200 4,000 Fog
Schellrldge 2014 Country Club Jaycee Dr. 34 2,590 9,784 Fog
Schellridge West 2014 Shellrldge Rd Fox Creek Rd. 30 930 3,100 Fog
Southam Air Dr. 2014 Belair Dr. Eastern Air Dr. 28 840 2,613 Fog
Satinwood Dr. 2014 Stadium Cedar Brooke Dr. 31 1,300 4,478 Fog
Vieth Dr. 2014 Cedar Brooke Dr. Oakridge Dr. 32 1,120 3,982 Fog
WilllamsSt 2014 Dbc Rd. Sl Marys Blvd 25 1,150 3,194 Fog
Lafayette 2014 Jasen Gym Creek 17 660 1,247 Fog
Tanner Bridge Rd 2014 ERis Blvd Christy 32 4,225 15,022 Fog
110,874
SCHEDULE OF QUANTITIES
2018 FOG SEAL PROJECT
2018
2019
2020
7
total
9148,571.01
5141,907 86
50.00
900D
LOCATION
Program Year from I
2015
OVERLAY YEAR
WARD
FROM
TO
WIDTH
f t.
( )
LENGTH
(f .)
AREA
(S.Y.)
Area
(Lane
Mlles)
Surface
Mix Typo
Fog Seal
RUNNING TOTAL
01.34
Streets And Alleys
Year Year
McCarty St.
2018
2014
1
Chestnut St.
Locust St.
32
930
3307
0.51
Fog
84,430.93
94,430.93
McCarty 5t.
2018
2014
1
Lafayette St.
Chestnut St.
38
890
3758
0.58
Fog
95,035.42
99,466.36
McCarty St.
2018
2014
1
Locust St.
Clark Ave.
38
620
2618
0.41
Fog
03,507.82
512.974.18
SI. Louis Rd
2018
2014
1
McCarty St.
McCarty St.
27
7415
22245
3.45
Fog
529,808.30
542.782.48
Jefferson St.
2018
2014
2
Capitol Ave.
High St.
53
440
2591
0.40
Fog
53,472.09
546,254.57
Jefferson St.
2018
2014
2
High St.
McCarty St.
53
440
2591
0.40
Fog
93,472.09
049,726.66
Jefferson St.
2018
2014
2
McCarty St. W.
Expressway
46
780
3987
0.62
Fog
95,342.13
955,068.79
McCarty St.
2018
2014
2
Bolivar St
Hwy 54 On Ramp
46
475
2428
0.38
Fog
53,253.22
558,322.01
Air View Dr.
2018
2014
3
Southern Air Dr.
Royal Air Dr.
30
250
833
0.13
Fog
51.116.67
559,438.68
Belair Dr.
2018
2014
3
Hillsdale 13r.
Twin Hill Dr.
26
2530
7309
1.13
Fog
59,793.91
569,232.59
Belair Dr.
2018
2014
3
Main St.
Hillsdale Dr.
26
680
1964
0.30
Fog
52,632.36
571,864.94
Fox Creek Rd.
2018
2014
3
Schellridgo Dr. W.
End
29
850
2739
0.42
Fog
53,670.11
575,535.06
Main St. W
2018
2014
3
Jaycee Dr.
179
30
2125
7083
1.10
Fog
99,491.67
985,026.72
Old Gibler Rd
2018
2014
3
Shollridgo Rd W.
Sterling Price Rd
30
1200
4000
0.62
Fog
55,360.00
590,386.72
Schellridgo
2018
2014
3
Country Club
Jaycee Dr.
34
2590
9784
1.52
Fog
513,111.16
5103,497.88
Schellridge West
2018
2014
3
Shellridge Rd
Fox Creek Rd.
30
930
3100
0.48
Fog
94,154.00
5107,651.88
Southern Air Dr.
2018
2014
3
Bolalr Dr.
Eastern Alr Dr.
29
840
2613
0.40
Fog
53,501.87
5111,153.74
Satinwood Dr.
2018
2014
4
Stadium
Cedar Brooke Dr.
31
1300
4478
0.69
Fog
06,000.22
9117,153.97
Vieth Dr.
2015
2014
4
Cedar Brooke Dr.
Oakridge Dr.
32
1120
3982
0.62
Fog
55,336.18
5122,490.14
Williams St
2018
2014
4
Dix Rd.
St. Marys Blvd
25
1150
3194
0.50
Fog
94,280.56
5126,770.70
Lafayette
2018
2014
5
Jason Gym
Creek17
660
1247
0.19
Fog
51,670.53
5128,441.23
Tanner Bridge Rd
2018
2014
5
Ellis Blvd
Christy
32
4225
15022
2.33
Fog
520,129.78
5148,571.01
Cochise Ln
6
2015
1
Tomahawk Rd.
Mohawk Dr
33
1150
4217
0.65
Fog
55,650.33
S154,221.34
Marshall St.
2089
2015
1
State St.
Capital Ave.
24
450
1200
0.19
Fog
51,608.00
5155.829.34
Mohawk Dr.
2010
2015
1
Tomahawk Rd.
Indian Meadow Dr.
33
2900
10633
1.65
Fog
014,248.67
9170,078.01
Redwing Dr.
2019
2015
1
Mohawk Dr.
Dead End
32
1200
4267
0.66
Fog
55,717.33
5175,795.34
Tomahawk Rd
2019
2015
1
Algoa Rd
End
33
2635
9662
1.50
Fog
512,946.63
5188,741.98
Oolong Way
2019
2015
2
Atchison St. W
Hess Way
8
320
284
0.04
Fog
9381.16
5189,123.13
Dunklin St.
2510
2015
2
Jefferson St.
Madison St.
47.5
335
1768
0.27
Fog
52,369.19
9191,492.33
SCHEDULE OF QUANTITIES
2018 FOG SEAL PROJECT
2018
2019
2020
7
total
9148,571.01
5141,907.86
$0 00
50.00
5290,478.87
LOCATION
Program Yoar from
2015
OVERLAY YEAR
WARD
FROM
TO
WIDTH
(ft.)
LENGTH
(ft.)
AREA
(S.Y.)
Area
Milos)
Surface
Mix Typo
Fog Seal
RUNNING TOTAL
51.34
Guehlman Way
2019
2015
2
Atchison St. W
Hess Way
10
230
256
0.04
Fog
9342.44
5191,834.77
Hess Way
2019
2015
2
Jefferson St.
Washington St.
12
500
667
0.10
Fog
5893.33
5192,728.11
Madison
2219
2015
2
Capital Ave.
State St.
44
440
2151
0.33
Fog
52,882.49
0195,610.59
Miller St.
_.
2015
2
Broadway SL
Mullbery St.
25
1000
2778
0.43
Fog
53,722.22
5199,332.82
Monroe St.
_
2015
2
Dunklin St. E
Hickory St.
30
1225
4083
0.63
Fog
55,471.67
5204,804.48
State SL
2222
2015
2
Madison St.
Marshall SI.
28
1900
5911
0.92
Fog
57,920.89
5212,725.37
Constitution Blvd
2019
2015
3
Truman Blvd
Williamsbury Way
30
1600
5333
0.83
Fog
57,146.67
9219,872.04
Madelines Park Cir.
2019
2015
3
Section 1
23
2600
7156
1.11
Fog
99,588.44
5229,460.48
Virginia Trail
2017
2015
3
Constitution Dr
417 Virginia Trail
28
1450
4511
0.70
Fog
56,044.89
I235,505.37
Foxboro Dr
_
2015
4
Nob Hill
Concrete
30
29D
967
0.15
Fog
51,295.33
5236,800.71
Harpers Ferry
...
2015
4
Edgewood Dr.
End of Concrete
33
225
825
0.13
Fog
51,105.50
5237,906.21
Harpers Ferry
2,
2015
4
End of Concrete
Gettysburg PI
33
600
2200
0.34
Fog
52,948.00
5240,854.21
Nob Hill
2019
2015
4
Fairway Dr
Concrete
30
1780
5933
0.92
Fog
$7,950.67
5248,804.87
Shermans Hollow
2019
2015
4
Wildwood Dr.
Geltyburg PI
30
1900
6333
0.9B
Fog
58,486.67
5257,291.54
South Country Club Dr.
2212
2015
4
Concrete N. of
Edgewood Dr.
1000' North
33
1000
3667
0.57
Fog
94,913.33
5262,204.87
Leslie Blvd
2015
5
1000 Leslie Blvd
Chestnut
40
925
4111
0.64
Fog
55,508.89
5267,713.76
Leslie Blvd
..
2015
5
Moreau Dr.
Rosevalley Dr
40
930
4133
0.64
Fog
55,538.67
9273.252.43
Leslie Blvd
2019
2015
5
Rosevalley Dr
1000 Leslie Blvd
20
600
1333
0.21
Fog
51,786.67
5275,039.09
Rosevalley Dr
2019
2015
5
1323 Rosevalley Dr.
Carol St.
28
625
1944
0.30
Fog
52,605.56
9277,644.65
Rosevalley Dr
2019
2015
5
Leslie Blvd
1323 Rosevalley
14
500
778
0.12
Fog
51,042.22
9278,686.87
Southwest Blvd
2019
2015
5
Cedar Ridge Rd
Stadium Blvd
33
2400
8800
1.36
Fog
511,792.00
9290,478.67
EXHIBIT A
CITY OF JEFFERSON
CONSTRUCTION CONTRACT
THIS CONTRACT made and entered into the date last executed by a party as indicated
below, by and between Musselman & Hall Contractors, LLC hereinafter referred to as
"Contractor", and the City of Jefferson, Missouri, a municipal corporation of the State of
Missouri, hereinafter referred to as "City".
WITNESSETH: That Whereas, the Contractor has become the lowest responsible
bidder for furnishing the supervision, labor, tools, equipment, materials and supplies and
for constructing the following City improvements:
Project No. 32156, 2018 Fog Seal.
NOW THEREFORE, the parties to this contract agree to the following:
1. Scope of Services.
Contractor agrees to provide all labor, equipment, hardware and supplies to perform the
work included in the project entitled "2018 Fog Seal" in accordance with the plans and
specifications on file with the Department of Public Works.
2. Manner and time for Completion.
Contractor agrees with the City to furnish all supervision, labor, tools, equipment,
materials and supplies necessary to perform said work at Contractor's own expense in
accordance with the contract documents and any applicable City o rdinances and state
and federal laws, within 90 calendar days from the date Contractor is ordered to
proceed, which order shall be issued by the Director of Public Works within ten (10)
days after the date of this contract.
3. Prevailing Wages.
To the extent that the work performed by Contractor is subject to prevailing wage law,
Contractor shall pay a wage of no less than the "prevailing hourly rate of wages" for
work of a similar character in this locality, as established by Department of Labor and
Industrial Relations of the State of Missouri, and as established by the Federal
Employment Standards of the Department of Labor. Contractor acknowledges that
Contractor knows the prevailing hourly rate of wages for this project because Contractor
has obtained the prevailing hourly rate of wages from the contents of the current
Annual Wage Order No. 24, Section 026, Cole County rates as set forth. The
Contractor further agrees that Contractor will keep an accurate record showing the
names and occupations of all workmen employed in connection with the work to be
performed under the terms of this contract. The record shall show the actual wages
paid to the workmen in connection with the work to be performed under the terms of this
contract. A copy of the record shall be delivered to the Purchasing Agent of the
Jefferson City Finance Department each week. In accordance with Section 290.250
RSMo, Contractor shall forfeit to the City One Hundred Dollars ($100.00) for each
workman employed, for each calendar day or portion thereof that the workman is paid
less than the stipulated rates for any work done under this contract, by the Contractor or
any subcontractor under the Contractor.
4. Insurance.
(a) The Contractor shall obtain and maintain during the term of the Project
and this Contract the insurance coverages at least equal to the coverages set forth in
this paragraph 7, and as further provided in the General Conditions, but no event less
than the individual and combined sovereign immunity limits established by Section
537.610 RSMo. Insurance policies providing required coverages shall be with
companies licensed to do business in the State of Missouri and rated no less than AA
by Best or equivalent. All costs of obtaining and maintaining insurance coverages are
included in the Bid Amount and no additional payment will be made therefor by the City.
Comprehensive General Liability Insurance
(including coverage for Bodily Injury and
Property Damage)
$3,000,000 per occurrence
$3,000,000 aggregate
Comprehensive Automobile Liability
Insurance
(including coverage for Bodily Injury and
Property Damage)
$3,000,000 per occurrence
$3,000,000 aggregate
Employer’s Liability $3,000,000 bodily injury by
accident (each accident)
$3,000,000 bodily injury by
disease (each employee)
$3,000,000 bodily injury policy
limit
(b) Worker’s Compensation - In addition, the Contractor and all
subcontractors shall provide Worker’s Compensation Insurance in at least statutory
amounts for all workers employed at the Project site.
(c) Builder’s Risk - The Contractor shall also provide a policy of Builder’s Risk
Insurance in the amount of 100% of the complete insurable value of the Project, which
policy shall protect the Contractor and the City, as their respective interests shall
appear.
(d) Owner's Protective Liability Insurance - The Contractor shall also obtain at
its own expense and deliver to the City an Owner's Protective Liability Insurance Policy
naming the City of Jefferson as the insured, in an amount not less than the individual
and combined sovereign immunity limits established by Section 537.610 RSMo., except
for those claims governed by the provisions of the Missouri Workmen's Compensation
Law, Chapter 287, RSMo. No policy will be accepted which excludes liability for
damage to underground structures or by reason of blasting, explosion or collapse.
(e) Before commencing any work, the Contractor shall provide to the City
certificates of insurance evidencing the issuance and maintenance in force of the
coverages required by this paragraph 4. Each such certificate shall show t he City, and
such other governmental agencies as may be required by the City to be insured by
underlying grant or contract relating to the Project, as an additional insured, and shall
bear an endorsement precluding cancellation of or change in coverage wit hout at least
thirty (30) days written notice to the City. The City may waive any insurance coverages
or amounts required by this paragraph 4 when the City deems such waiver to be in the
interest of the public health, safety, and general welfare.
(f) Subcontracts - In case any or all of this work is sublet, the Contractor shall
require the Subcontractor to procure and maintain all insurance required in
Subparagraphs (a), (b), and (c) hereof and in like amounts.
(g) Scope of Insurance and Special Hazard. The insurance required under
Sub-paragraphs (b) and (c) hereof shall provide adequate protection for the Contractor
and its subcontractors, respectively, against damage claims which may arise from
operations under this contract, whether such operations be by the insured or by anyone
directly or indirectly employed by it, and also against any special hazards which may be
encountered in the performance of this contract.
NOTE: Paragraph (f) is construed to require the procurement of Contractor's protective
insurance (or contingent public liability and contingent property damage policies) by a
general contractor whose subcontractor has employees working on the project, unless
the general public liability and property damage policy (or rider attached thereto) of the
general contractor provides adequate protection against claims arising from operations
by anyone directly or indirectly employed by the Contractor.
5. Contractor's Responsibility for Subcontractors.
It is further agreed that Contractor shall be as fully responsible to the City for the acts
and omissions of its subcontractors, and of persons either directly or indirectly
employed by them, as Contractor is for the acts and omissions of persons it directly
employs. Contractor shall cause appropriate provisions to be inserted in all
subcontracts relating to this work, to bind all subcontractors to Contractor by all the
terms herein set forth, insofar as applicable to the work of subcontractors and to give
Contractor the same power regarding termination of any subcontract as the City may
exercise over Contractor under any provisions of this contract. Nothing contained in this
contract shall create any contractual relations between any subcontractor and the City
or between any subcontractors.
6. Liquidated Damages.
The Contractor agrees and acknowledges that time is of the essence of this Agreement
and that delay in the prosecution of the Work and the Project will inconvenience the
public and increase administrative costs of the City, the costs of which the Contractor
and the City are incapable of ascertaining at this time. Should the Contractor, or in the
case of Contractor’s default, the surety, fail to complete the Work within the time
stipulated in this Agreement, or within such extension of time a s may be allowed by the
City in the manner set forth in the Contract Documents, the Contractor (or surety, as
applicable) shall pay to the City as liquidated damages, and not as a penalty, the sum of
Five Hundred Dollars ($500.00) for each calendar day that the Work remains
uncompleted after the time allowed for the completion, including approved extensions.
In the sole discretion of the City, the amount of the liquidated damages may be
deducted from any money due the Contractor under this Agreement. Perm itting the
Contractor to finish the Work or any part thereof after the expiration of the time for
completion or any approved extension, shall in no way operate as a waiver of the City of
any of rights under this Contract.
7. Termination.
The City reserves the right to terminate this contract by giving at least five (5) days prior
written notice to Contractor, without prejudice to any other rights or remedies of the City
should Contractor be adjudged a bankrupt, or if Contractor should make a genera l
assignment for the benefit of its creditors, or if a receiver should be appointed for
Contractor or for any of its property, or if Contractor should persistently or repeatedly
refuse or fail to supply enough properly skilled workmen or proper material, o r if
Contractor should refuse or fail to make prompt payment to any person supplying labor
or materials for the work under the contract, or persistently disregard instructions of the
City or fail to observe or perform any provisions of the contract.
8. City's Right to Proceed.
In the event this contract is terminated pursuant to Paragraph 7, then the City may take
over the work and prosecute the same to completion, by contract or otherwise, and
Contractor and its sureties shall be liable to the City for any costs over the amount of
this contract thereby occasioned by the City. In any such case the City may take
possession of, and utilize in completing the work, such materials, appliances and
structures as may be on the work site and are necessary for completion of the work.
The foregoing provisions are in addition to, and not in limitation of, the rights of the City
under any other provisions of the contract, City ordinances, and state and federal laws.
9. Indemnity.
To the fullest extent permitted by law, the Contractor agrees to defend with counsel
selected by the City, and indemnify and hold harmless the City, its officers, engineers,
representatives, agents and employees from and against any and all liabilities,
damages, losses, claims or suit, including costs and attorneys’ fees, for or on account of
any kind of injury to person, bodily or otherwise, or death, or damage to or destruction of
property, or money damages, or trespass, or any other circumstances, sustained by the
City or others, arising from the Contractor’s breach of the Contract or out of services or
products provided by the Contractor or its subcontractors under the terms of this
agreement. The Contractor shall not be liable for any loss or damage attributable solely
to the negligence of the City. To the extent required to enforce this provision, the
Contractor agrees that this indemnification requires the Contractor to obtain insurance
in amounts specified in the Contract Documents and that the Contractor has had the
opportunity to recover the costs of such insurance in the compensation set forth in this
Agreement.
In any and all claims against the City or any of its agents or employees by any
employee of the Contractor, any Subcontractor, anyone directly or indirectly employed
by any one of them or anyone for whose acts any of them may be liable, this
indemnification obligation shall not be limited in any way by any limitation on the amount
or type of damages, compensation or benefits payable by or for the Contractor or any
Subcontractor under workmen’s compensation acts, disability benefit acts or other
employee benefit acts.
The Contractor shall reimburse to the City any costs and attorneys’ fees that the City
may reasonably incur in pursuit of any remedies at law or equity or enforcement of any
rights established in this Contract, which may result from the Contractor’s breach of the
Contract, the Contractor’s failure to perform any obligation or requirement contained
herein, or the City’s enforcement of this Contract.
10. Payment for Labor and Materials.
The Contractor agrees and binds itself to pay for all labor done, and for all the materials
used in the construction of the work to be completed pursuant to this contract.
Contractor shall furnish to the City a bond to ensure the payment of all materials and
labor used in the performance of this contract.
11. Supplies.
The Contractor is hereby authorized and directed to utilize the City's sales tax
exemption in the purchase of goods and materials for the project as set out in Sect ion
144.062 RSMo 1994 as amended. Contractor shall keep and maintain records and
invoices of all such purchases which shall be submitted to the City.
12. Payment.
The City hereby agrees to pay the Contractor for the work done pursuant to this contract
according to the payment schedule set forth in the Contract Documents upon
acceptance of said work by the Director of Public Works and in accordance with the
rates and/or amounts stated in the bid of Contractor dated March 19, 2018 which are by
reference made a part hereof. No partial payment to the Contractor shall operate as
approval or acceptance of work done or materials furnished hereunder. The total
amount of this contract shall not exceed One Hundred Forty-Eight Thousand Five
Hundred Seventy-One Dollars and Sixteen Cents ($148,571.16).
13. Performance and Materialman’s Bonds Required.
Contractor shall provide a bond to the City before work is commenced, and no later than
ten (10) days after the execution of this contract, guaranteeing the Contractor's
performance of the work bid for, the payment of amounts due to all suppliers of labor
and materials, the payment of insurance premiums for workers compensation insurance
and all other insurance called for under this contract, and the payment of the pr evailing
wage rate to all workmen as required by this contract, said bond to be in a form
approved by the City, and to be given by such company or companies as may be
acceptable to the City in its sole and absolute discretion. The amount of the bond shall
be equal to the Contractor's bid.
14. Knowledge of Local Conditions.
Contractor hereby warrants that it has examined the location of the proposed work and
the attached specifications and has fully considered such local conditions in making its
bid herein.
15. Severability.
If any section, subsection, sentence, or clause of this Contract shall be adjudged illegal,
invalid, or unenforceable, such illegality, invalidity, or unenforceability shall not affect the
legality, validity, or enforceability of the contract as a whole, or of any section,
subsection, sentence, clause, or attachment not so adjudged.
16. Governing Law.
The contract shall be governed by the laws of the State of Missouri. The courts of the
State of Missouri shall have jurisdiction over any dispute which arises under this
contract, and each of the parties shall submit and hereby consents to such courts
exercise of jurisdiction. In any successful action by the City to enforce this contract, the
City shall be entitled to recover its attorney's fees and expenses incurred in such action.
17. Contract Documents.
The contract documents shall consist of the following:
a. This Contract f. General Provisions
b. Addenda g. Special Provisions
c. Information for Bidders h. Technical Specifications
d. Notice to Bidders i. Drawing and/or Sketches
e. Signed Copy of Bid
This contract and the other documents enumerated in this paragraph, form the Contract
between the parties. These documents are as fully a part of the contract as if attached
hereto or repeated herein.
18. Complete Understanding, Merger.
Parties agree that this document including those documents described in the section
entitled “Contract Documents” represent the full and complete understanding of the
parties. This contact includes only those goods and services specifically set out. This
contract supersedes all prior contracts and understandings between the Contractor and
the City.
19. Authorship and Enforcement.
Parties agree that the production of this document was the joint effort of both parties
and that the contract should not be construed as having been drafted by either party.
20. Amendments.
This contract may not be modified, changed or altered by any o ral promise or statement
by whomsoever made; nor shall any modification of it be binding upon the City until
such written modification shall have been approved in writing by an authorized officer of
the City. Contractor acknowledges that the City may not be responsible for paying for
changes or modifications that were not properly authorized.
21. Waiver of Breach .
Failure to Exercise Rights and Waiver: Failure to insist upon strict compliance with any
of the terms covenants or conditions herein shall not be deemed a waiver of any such
terms, covenants or conditions, nor shall any failure at one or more times be deemed a
waiver or relinquishment at any other time or times by any right under the terms,
covenants or conditions herein.
22. Assignment.
Neither party may sell or assign its rights or responsibilities under the terms of this
agreement without the express consent of the remaining party.
23. Nondiscrimination.
Contractor agrees in the performance of this contract not to discriminate on the groun d
or because of race, creed, color, national origin or ancestry, sex, religion, handicap,
age, or political opinion or affiliation, against any employee of Contractor or applicant for
employment and shall include a similar provision in all subcontracts let or awarded
hereunder.
24. Illegal Immigration.
Prior to commencement of the work:
A. Contractor shall, by sworn affidavit and provision of documentation, affirm its
enrollment and participation in a federal work authorization program with respect
to the employees working in connection with the contracted services.
B. Contractor shall sign an affidavit affirming that it does not knowingly employ any
person who is an unauthorized alien in connection with the contracted services
Contractor agrees in the performance.
C. If contractor is a sole proprietorship, partnership, or limited partnership,
contractor shall provide proof of citizenship or lawful presence of the owner prior
to issuance of the Notice to Proceed.
25. OSHA Training
Prior to commencement of the work:
A. Contractor shall provide a ten-hour Occupational Safety and Health
Administration (OSHA) construction safety program for their on-site employees
which includes a course in construction safety and health approved by OSHA or
a similar program approved by the department which is at least as stringent as
an approved OSHA program.
B. All employees subject to this provision are required to complete the program
within sixty days of beginning work on such construction project.
C. Any employee, agent or subcontractor of the Contractor subject to this provision
found on the worksite without documentation of the successful completion of the
course shall be afforded twenty days to produce such documentation after which
time they shall be removed from the project.
D. If Contractor fails the provisions of subsection A, B, or C, the Contractor shall
forfeit as a penalty two thousand five hundred dollars plus an additional one
hundred dollars for each employee employed by the contractor or subcontractor,
for each calendar day, or portion thereof, such employee is employed without the
required training. The penalty shall not begin to accrue until the time period in
subsections B or C, whichever is applicable, of this section have elapsed.
E. The City shall withhold and retain from any amount due under the contract, all
sums and amounts due and owing as a result of any violation of this section
when making payments to the contractor under the contract. The contractor may
withhold from any subcontractor, sufficient sums to cover any penalties the City
has withheld from the contractor resulting from the subcontractor’s failure to
comply with the terms of this section.
26. Transient Employers.
Every transient employer, as defined in section 285.230, RSMo, enclosed in the laws
section, must post in a prominent and easily accessible place at the work site a clearly
legible copy of the following: (1) The notice of registration for employer withholding
issued to such transient employer by the director of revenue; (2) Proof of coverage for
workers’ compensation insurance or self -insurance signed by the transient employer
and verified by the department of revenue through the records of the division of workers’
compensation; and (3) The notice of registration for unemployment insurance issued to
such transient employer by the division of employment security. Any transient employer
failing to comply with these requirements shall, under section 285.234, RSMo, enclosed
in the laws section, be liable for a penalty of $500 per day until the notices required by
this section are posted as required by that statue.
27. Notices.
All notices required to be in writing may be given by first class mail addressed to City of
Jefferson, Department of Public Works, 320 East McCarty, Jefferson City, Missouri,
65101, and Contractor at 4922 East Blue Banks, Kansas City, MO 64130. The date
of delivery of any notice shall be the second full day after the day of its mailing.
CITY OF JEFFERSON
QgM-��
Mayor: Carrie Tergin
(e, / iq
Dat :
ATTEST:
C clerk
APPROVED AS TO FORM:
CONTRACTOR
,pqC SS�
Title CFD
q/3
Date(.
ATTEST:
Title: jvw ILI A -oma