Loading...
HomeMy Public PortalAboutORD14363 BILL NO. 2008-14 SPONSORED BY COUNCILMAN Penfold ORDINANCE NO. AN ORDINANCE OF THE CITY OF JEFFERSON, MISSOURI, AUTHORIZING THE MAYOR AND CITY CLERK TO EXECUTE AN AGREEMENT WITH STOCKMAN CONSTRUCTION CORPORATION FOR CONSTRUCTION OF THE LOCUST STREET IMPROVEMENTS. WHEREAS, Stockman Construction Corp has become the apparent lowest and best bidder on the Locust Street Improvements project; NOW, THEREFORE, BE IT ENACTED BY THE COUNCIL OF THE CITY OF JEFFERSON, MISSOURI, AS FOLLOWS: . Section 1. The bid of Stockman Construction Corporation is declared to be the lowest and best bid and is hereby accepted. Section 2.The Mayor and City Clerk are hereby authorized to execute an agreement with Stockman Construction Corporation for Locust Street Improvements. • Section 3. The agreement shall be substantially the same in form and content as that agreement attached hereto as Exhibit A. Section 4. This Ordinance shall be in full force and effect from and after the date of its passage and approval. Passed: OA-Ixe- A pp r iding Officer Mayor ATT ST: APPROVED S TO FORM: City CI rk City Counselor tLA • - CONTRACT DOCUMENTS _ m_ CITY OF • TA Aya ZA gg jj l5 • }�{ � i 'S s a -�i , y _ 3fy. G a x I V7 3 1' AV 5 .{� ' ' Hk�,`' it �... � ' - - g •�' 41W F i - -fix. _ - _ •_.. 1}. �.�{ SPECIFICATIONS AND CONTRACT DOCUMENTS I PROJECT NO. 32095 - Locust Street.Improvements ' Jefferson City Department of Community Development ' May, 2008 • ' TABLE OF CONTENTS ' Advertisement for Bids ' Notice to.Bidders • Information for Bidders ' Bid Form • Bid Bond • Anti-Collusion Statement " ' Contractor's Affidavit ' Minority Business Enterprise Statement • Minority Business Utilization Agreement • Affidavit of Compliance wi th Prevailing Wage Law ' Prevailing Wage Determination • Affidavit of Compliance Public Works Contracts Law • Excessive Unemployment Exception Certification • Construction Contract • Performance, Payment, and Guarantee Bond • General Provisions • Special Provisions ' Attachments • Addendums ( If Any ) ' ("' INDICATES THIS ITEM INCLUDED IN BID PACKET FOR SUBMISSION OF BID) ' ADVERTISEMENT FOR BIDS ' Sealed bids will be received at the office of the Purchasing Agent, 320 East McCarty Street,Jefferson City, Missouri 65101, until 1:30 PM,on Tuesday, May 6,2008. The ' bids will be opened and read aloud in the Council Chambers at 1:30 PM on that same, day. ' The proposed work for the project entitled "Project No. 32095, Locust Street Improvements" will include the furnishing of all material, labor, and equipment to reconstruct approximately 600 feet of the 700 block of Locust Street including curb and ' gutter, stormwater inlets and piping, sidewalk, asphalt pavement, and associated earthwork. ' A pre-bid conference will be held at 9:00 AM, on Tuesday, April 29, 2008 in the Thomas Jefferson Conference Room of City Hall, 320 E, McCarty Street, Jefferson City, MO 65101. All prospective bidders are urged to attend. ' Copies of the contract documents required for bidding purposes may be obtained from the Director of Community Development, 320 East McCarty Street, Jefferson City, ' Missouri. A non-refundable deposit of Twenty Dollars ($20.00) will be required_for . each set of plans and specifications. Individual full size sheets of the plans may be obtained for Three Dollars ($3.00) per sheet. The contract will require compliance with the wage and labor requirements and the q P 9 payment of minimum wages in accordance with the Schedule of Wage Rates ' established by the Missouri Division of Labor Standards. The City reserves the right to reject any and all bids and to waive informalities therein, to determine which is the lowest and best bid and to approve the bond. ' CITY OF JEFFERSON Terry Stephenson ' Purchasing Agent ' Publication Date Sunday, April 20, 2008 ' NOTICE TO BIDDERS ' Sealed bids will be received at the Office of the Purchasing Agent, City Hall, 320 East McCarty Street, Jefferson City, Missouri, until 1:30 PM on Tuesday, May 6,2008. The ' bids will be opened and read aloud in the Council.Chambers at 1:30 PM on that same day., The proposed work for the project- entitled "Project No. 32095, Locust Street Improvements. will include the furnishing of-all material, labor, and equipment to reconstruct approximately 600 feet of the 700 block of Locust Street including curb and ' gutter, stormwater inlets and piping, sidewalk, asphalt pavement, and associated earthwork. A pre-bid conference will be held at 9:00.AM, on Tuesday,April 29, 2008 in the Thomas Jefferson Conference Room of City Hall, 320 E. McCarty Street, Jefferson City, MO 65101. All prospective bidders are urged to attend. All equipment, material, and workmanship must be in accordance with the plans, specifications, and contract documents on file with the Director of Community ' Development, Jefferson City, Missouri. Copies of the contract documents required for bidding purposes may be obtained from ' the Director of Community Development, 320 East McCarty Street, Jefferson City, . Missouri. A non-refundable deposit of Twenty Dollars ($20.00) will be required for each set of plans and specifications. Individual full size sheets-of the plans may be ' obtained for Three Dollars ($3.00) per sheet. ' A certified check on a solvent bank or a bid bond by a satisfactory surety in an amount equal to five (5) percent of the total amount of the bid must accompany each proposal. A one-year Performance and Guarantee Bond is required. The owner reserves the right to reject any or all bids and to waive informalities therein to determine which is the lowest and best bid and to approve the bond. CITY OF JEFFERSON, MISSOURI ' Patrick E. Sullivan, PE Director of Community Development i INFORMATION FOR BIDDERS IB-1 SCOPE OF WORK ' The work to be done under this contract includes the furnishing of all technical personnel, labor, materials, and equipment required to perform the work included in the project entitled"Project No.32095,Locust Street Improvements in accordance with the plans and specifications on ' file with the Department of Community Development. _ The proposed work for this project will include the furnishing of all material, labor,-and ' equipment to reconstruct approximately 600 feet of the 700 block of Locust Street including curb and gutter, storrr►water inlets and piping, sidewalk, asphalt pavement, and associated earthwork tI113-2 INSPECTION OF PLANS, SPECIFICATIONS, AND SITE OF WORK The bidder is required to examine carefully the site of the proposed work, the bid, plans, ' specifications,:supplemental specifications,special provisions,and contract documents before. submitting a bid. Failure to do so will not relieve a successful bidder of the obligation to furnish all materials and labor necessary to carry out the provisions of the contract. ' I13-3 INTERPRETATION OF CONTRACT DOCUMENTS ' If the bidder has any questions which arise concerning the true meaning or intent of the Plans, . Specifications or any part thereof, which affect the cost, quality, quantity, or character of the project, he shall request in writing, at least five (5) days prior to the date fixed for the bid ' opening, that an interpretation be made and an addendum be issued by the City, which shall then be delivered to all bidders to.whom Plans and Specifications have.been issued. All addenda issued shall become part of the contract documents. Failure to have requested an ' addendum covering any questions affecting the interpretation of the Plans and Specifications shall not relieve the Contractor from delivering the completed project in accordance with the intent of the Plans and Specifications to provide a workable. project. ' I113-4 QUALIFICATIONS OF BIDDERS The City of Jefferson may make such investigations as deemed necessary to determine the ability of the bidder to perform the work and the bidder shall furnish to the City all such information and data for this purpose as the City may request. The City reserves the right to reject any bid if the evidence submitted by the bidder or investigation of such bidder fails to ' satisfy the City that such bidder is properly qualified to carry out the obligations of the Contract and to complete the work contemplated therein. ' I13-5 EQUIVALENT MATERIAL Wherever definite reference is made in these Specifications to the use of any particular material ' or equipment, it is to be understood that any equivalent material or equipment may be used which will perform adequately the duties imposed by the general design,subject to the approval of the City. • IB-6 BID SECURITY Each bid must be accompanied by a certified check or bid bond made payable to the City of Jefferson for five percent (5%) of the amount of the bid. Bid securities will.be returned after award of the contract except to the successful bidder. ' Should the successful bidder fail or refuse to execute the bond-and the contract required within seven (7)days after he has received notice of acceptance of his bid,'he shall forfeit to the City as liquidated damages for such failure or refusal, the security deposited with his bid. ' IB-7 PREPARATION OF BIDS ' Bids must be made upon the prescribed forms attached in these Contract Documents. Only sealed bids will be considered, all bids otherwise submitted will be rejected as irregular. ' All blank spaces in the bid must be filled in and no change shall be made in the phraseology of the bid, or addition to the items mentioned therein. Any conditions, limitations or provisions attached to bids will render them informal and may be considered cause for their rejection. Extensions of quantities and unit prices shall be carried out to the penny. ' IB-8 PRICES The price submitted for each item of the work shall include all costs of whatever nature involved ' in its construction, complete in place, as described in the Plans and Specifications. Section 144.062 RSMo provides that the City's sales tax exemption may be used for the purchase of goods and materials for this project. The contract for the project will authorize and direct the Contractor to utilize the City's sales tax exemption in the purchase of goods and materials for the project. This provision shall apply to only those purchases totaling over$500 from an individual supplier. ' All sales taxes on those items which do not qualify for the use of the City's sales tax exemption and for which sales tax might lawfully be assessed against the City are to be paid by the ' Contractor from the monies-obtained in satisfaction of the Contract. It being understood by the bidder, that the bid prices submitted for those items shall include the cost of such taxes. ' IB-9 APPROXIMATE QUANTITIES In cases where any part or all of the bidding is to be received on a unit price basis, the ' quantities stated in the bid will not be used in establishing final payment due the successful Contractor. The quantities stated on which unit prices are so invited are approximate only and each bidder shall make his own estimate from the plans of the quantities required on each item and calculate his unit price bid for each item accordingly. Bids will be compared on the basis ' of number of units stated in the bid. Such estimated quantities, while made from the best information available, are approximate only. Payment of the Contract will be based on actual number of units installed on the complete work. r IB-10 LUMP SUM ITEMS Payment for each lump sum item shall be at the lump sum bid for the item, complete in place, ' and shall include the costs of all labor, materials, tools and equipment to construct the item as described herein and to the limits shown on the Plans. ' IB-11 SUBMISSION OF BIDS The Bid and the Bid Security guaranteeing the same shall be placed in a sealed envelope and marked "Project No. 32095, Locust Street Improvements IB-12 ALTERNATE BIDS ' In making he award, if alternate bids have been requested, the alternate bid which will be in 9 q , the best interest of the City will be used. ' IB-13 WITHDRAWAL OF BIDS ' If a bidder wishes to withdraw his bid, he may do so before the time fixed for the opening, without prejudice to himself. No bidder may withdraw his bid for a period of ninety (90) days after the scheduled closing time for the receipt of bids. ' No bids received after the time set for opening for bids will be considered. ' IB-14 RIGHT TO REJECT BIDS . The City reserves the right to reject any or all bids,to waive any informality in the bids received, or to accept the bid or bids that in its judgement will be in the best interests of the City of Jefferson. IB-15 AWARD OF CONTRACT If, within seven (7)7 days after he has received notice of acceptance of his bid the successful Y p , bidder or bidders shall refuse or neglect to come to the office of the Director of Community ' Development and to execute the Contract and to furnish the required Performance and Payment Bonds and Insurance, properly signed by the Contractor and the Surety and Sureties satisfactory to the City of Jefferson as hereinafter provided, the bidder or bidders shall be ' deemed to be in default and shall forfeit the deposit. IB-16 PERFORMANCE AND PAYMENT BOND ' A Performance and Payment Bond in an amount equivalent to one hundred percent (100%) of the Contract price, must be furnished and executed by the successful bidder or bidders. A form for the bidders use is contained in these Contract Documents. 1 The issuing Surety shall be a corporate Surety Company or companies of recognized standing ' licensed to do business in the State of Missouri and acceptable to the City of Jefferson. IB-17 INDEMNIFICATION AND INSURANCE The Contractor agrees to indemnify and hold harmless the City from all claims and suits for loss of or damage to property, including loss of all judgments recovered therefore, and from all expense in defending said claims, or suits, including court costs, attorney fees and other- expense caused by any act or omission of the Contractor and/or his subcontractors, their ' respective agents, servants or employees. The Contractor shall be required to provide the City of Jefferson with a Certificate of Insurance. ioutlining the coverage provided. IB-18 BID SECURITY RETURNED TO SUCCESSFUL BIDDER ' Upon the execution of the Contract and approval of Bond, the Bid Security will be returned to the bidder unless the same shall have been presented for collection prior to such time, in which ' case the amount of the deposit will be refunded by the City. IB-19 NONDISCRIMINATION IN EMPLOYMENT Contracts for work under this bid will obligate the Contractor and subcontractors not to discriminate in employment practices. ' I13-20 PREVAILING WAGE LAW The principal contractor and all subcontractors shall pay not less than the prevailing wage hourly rate for each craft or type of workman required to execute this contract as determined by the Department of Labor and Industrial Relations of Missouri, pursuant to Sections 290.210 through 290.340 inclusive of the Revised Statutes of Missouri, 1994 as amended. (See Determination included herewith.) IB-21 GUARANTEE- The Contractor shall guarantee that the equipment, materials and workmanship furnished under this contract will be as specified and will be free from defects for a period of one year from the date of final acceptance. In addition,the equipment furnished by the Contractor shall be guaranteed to be free from defects in design. ' -Within the guarantee period and upon notification of the Contractor by the City, the Contractor shall promptly make all needed adjustments, repairs or replacements arising out of defects which, in the judgment of the City become necessary during such period. ' The cost of all materials, parts, labor, transportation, supervision, special tools, and supplies required for replacement of parts, repair of parts or correction of abnormalities shall be paid by the Contractor or by his surety under the terms of the Bond. The Contractor also extends the terms of this guarantee to cover repaired parts and all replacement parts furnished under the guarantee provisions for a period of one year from the ' date of installation thereof. 1 If within ten days after the City ives the Contractor notice of defect, failure, or abnormality of ty ty • the work, the,Contractor neglects to make, or undertake with due diligence to make,.the ' necessary repairs or adjustments, the City is hereby authorized to make the repairs or adjustments itself or order the work to be done by a third party, the costs of the work to be paid by the Contractor. ' In the event of an emergency where, in the judgment of the City delays would cause serious . loss or damage, repairs or adjustments may be made by the City or a third party chosen by the City without giving notice to the Contractor, and the cost of the work shall be paid by the ' Contractor or by his surety under the terms of the Bond. IB-22 NOTICE TO PROCEED ' A written notice to begin construction work will be given to the Contractor by the City of Jefferson within ten (10)days after the Contract is approved by the City Council. The time for ' completion of the project shall begin to run on the date established in this notice. IB-23 WORK SCHEDULE To insure that the work will proceed continuously through the succeeding operations to its completion with the least possible interference to traffic and'inconvenience to the public, the ' Contractor shall, at the request of the City, submit for approval a complete schedule of his proposed construction procedure,stating the sequence in which various operations of work are to be performed. ' IB-24 CONTRACT TIME • i ' The contract time shall be 51 calendar days. IB-25 LIQUIDATED DAMAGES Liquidated damages shall be assessed at the rate of Five Hundred Dollars ($500.00) per calendar a n e work a day until th o k is complete, should the project not be completed within the contract time. ' IB-26 POWER OF ATTORNEY ' Attorneys-in-fact who sign bid bonds or contract bonds must file with each bond a certified and effectively dated copy of their power of attorney. ' IB-27 BID PACKET Each bid must be submitted on the prescribed forms and contain certain certifications and ' documentation. Each bid must be submitted in a sealed envelope bearing on the outside the name of the bidder, the bidder's address, and the name of the project for which the bid is being submitted. If forwarded by mail, the sealed envelope containing the bid must be enclosed in another • envelope addressed as follows: 1 ' Purchasing Agent • City of Jefferson, MO ' 320 E. McCarty Street Jefferson City, MO 65101 For the convenience of bidding this project, a "BID PACKET" has been included with the ' project manual. This packet contains the necessary forms to be submitted with the bid proposal. The contents of this packet include the following: t1) BID FORM 2) BID BOND 3) ANTI-COLLUSION STATEMENT ' 4) CONTRACTOR'S AFFIDAVIT 5) MINORITY BUSINESS UTILIZATION AGREEMENT END OF INFORMATION FOR BIDDERS • • 1 ' BID FORM ' Name of Bidder - °. ✓M'0,U CX.'_P . a Address of Bidder 1 A i To: CITY OF JEFFERSON ' 320 East McCarty'Street Jefferson City, Missouri 66101 ' THE UNDERSIGNED BIDDER,having examined the plans,specifications, regulations of the Contract, Special Conditions, other proposed contract documents and all ' addenda thereto; and being acquainted with and fully understanding (a)the extent and character of the work covered by this Bid; (b)the location, arrangement,,and specified requirements for the proposed- work; (c) the location,, character, and condition of ' existing streets, roads, highways, railroads, pavements, surfacing, walks, driveways, curbs, gutters, trees, sewers, utilities, drainage courses, structures, and other installations, both surface and underground which may affect or be affected by the ' proposed work; (d) the nature and extent of the excavations to be made and the type, character, and general condition of materials to be excavated; (e) the necessary handling and rehandling of excavated materials;(f)the location and extent of necessary ' or probable dewatering requirements; (g)the difficulties and hazards to the work which • might be caused by storm and flood water, (h) local conditions relative to labor, transportation,hauling,and rail delivery facilities;and (i)all otherfactors and conditions affecting or which may be affected by the work. HEREBY PROPOSED to furnish all required materials, supplies, equipment,tools,and ' plant; to perform all necessary labor and supervision; and to construct, install, erect, and complete all work stipulated, required by, and in accordance with the proposed, contract documents and the drawings, specifications, and other documents referred to ' therein (as altered, amended, or modified by addenda) in the manner and time prescribed and that he will accept in full payment sums determined by applying to the quantities of the following items, the following unit prices and/or any lump sum payments provided, plus or minus any special payments and adjustments provided in the specifications and he understands that the estimated quantities herein given are.not 1 guaranteed to be the exact or total quantities required for the completion of the work shown on the drawings and described in the specifications, and that increases or decreases may be made over or under the Contract estimated quantities to provide for needs that are.determined during progress of the work and that prices bid shall apply to such increased or decreased quantities as follows: Page 1 of 2 CITY OF JEFFERSON • ITEMIZED.BID.FORM ' LOCUST STREET IMPROVEMENTS, PROJECT NO. 32095 ITEM . APPROX. UNIT ' NO; DESCRIPTION UNIT QUANTITY PRICE AMOUNT 1 Mobilization LS 1 jq,300 ' 2 Construction Signage and Traffic Control LS 1 3,0 . 3 Silt Fence LF 475 ` -`� l®�S, ' 4 Removals LS 1 awco 5 Earthwork LS 1 [�nj Sdu�. S Ste• ' 6 Rock Excavation CY 10 T�. 7 4'x 3'Type A Inlet EA 1 Ono = des-cam 8 6'x 3'Type A Inlet EA 1 9 .4'x 4'Type C Inlet EA 1 L"" ' 10 4'x 4'Junction Box EA 1 (cW (cgc9 11 15"Dia. RCP Class III LF 63 ©. ' 12 18" Dia. RCP Class III LF ` " 39 Lt4 .' 771, � • 13 Fowable Fill for Pipe Abandonment CY 2 ' 14 Temporary Surfacing TON 50 j�90 15 Sub Grade Stabilization TON 600 �V- s� � 16 3"Thick Rolled Stone Base SY 2360 0, 17 Type.A Curb and Gutter _ LF 1120 �3-^ (y �9d ' 18 6"Thick PCC Residential Drive Approach SY 20 (co 5-0" r' 19 6"Thick Residential Drive SY 19 , , ' 20 8"Thick PCC Street/Commercial Approach SY 96 Jf 7 r �©, 21 7"Thick PCC Street Pavement(Dunklin St.) SY 118 (;�, .'— ��®• ' 22 6 1/2"Thick AC Base SY 1847 a, 23 1 1/2"AC Surface BP-1 SY 1847 ' .24. 4"Thick PCC Sidewalk SY 393 Ls 25 6"Thick PCC Sidewalk Ramps SY 34 ' 26 Detectable Warning Panels SF 44 �1•� al�' "�. 27 Adjust Sanitary Sewer Manhole EA 2 1 . Page 2 of 2 ' ITEM APPROX., UNIT • NO. DESCRIPTION UNIT QUANTITY PRICE AMOUNT ' 28 Seeding AC 0.1 " n, TOTAL BASE BID 17 I 5-Y3, ' ALTERNATE A-CONCRETE PAVEMENT 30 6 1/2"Thick AC Base SY -1847 i ' 31 1 1/2"AC Surface BP-1 SY_. -1847 32 6"Thick PCC Pavement SY 1847 r .5- ��- ' TOTAL ALTERNATE A 9 76 f Signature of Bidder Date • 1 1 1 SUBCONTRACTORS lie if the Bidder intends to use any subcontractors in the course of the construction, he shall list them. � �� ors• TIME OF COMPLETION ' The undersigned hereby agrees to complete the project within 51 calendar days, , subject to the stipulations of the regulations of the Contract and the Special Provisions. ' It is unders t ood and agreed that if this bid is accepted, the prices quoted above.include all applicable state taxes and that said taxes shall be paid by the Contractor. ' the I persons or firms interested The undersigned, as Bidder, hereby declares that only p ' in the bid as principal or principals is or are named herein and that no other persons or firms than herein mentioned have any interest in this bid or in the Contract to be entered into; and this bid is made without connection with any other person, company, or parties making a bid; and that it is in all respects fair and in good faith, without ' collusion or fraud. The undersigned agrees that the accompanying bid deposit shall become the property of the Owner, should he fail or refuse to execute the Contract or furnish Bond as called • for in the specifications within the time.provided. If written notice of the acceptance of this bid is mailed, telegraphed, or delivered to the undersigned within sixty (60) days after the date of opening of bids, or any time thereafter before this bid is withdrawn, the undersigned will, within ten (10) days after the date of such mailing,telegraphing, or delivering of such notice, execute and deliver a Contract in the form of Contract attached. The undersigned hereby designates as his office to which such notice of acceptance may be mailed, telegraphed, or.delivered: ' `S'17nf k-dd&kA 6M5 J4,, ... i::;C r n. ct.el �r Sn,� C cX) 1✓V�^ It is understood and agreed that this bid may be withdrawn at any time prior to the b �� scheduled time for the opening of bids or any authorized postponement thereof. ' Attached hereto is a Bid Bond for the sum of >�. y Dollars (cashier's check), make payable to the City of Jefferson. . 1 ._ Signature of Bidder: If an individual, , doing business as If.a partnership, "J� , member of firm. �. If corporation, -Pie L_ w� by Title. r � ' SEAL ' Business Address of Bidder • W10 S o9 If Bidder is a corporation, supply the following information: State in which incorporated AA-0 Name and Address of its: ' President / c� ' Secretary 6eill'te Date �p g BID BOND KNOW ALL MEN BY THESE PRESENTS, that we the I undersigned,______________________________________as Principal, and as Surety, are hereby held and firmly bound unto the CITY OF JEFFERSON, MISSOURI , as owner; in the penal sum of for the payment of which, well and ' truly to be made, we hereby jointly and severally bind ourselves, our heirs, executors, administrators, successors and assigns, this day of ;200 ' The condition of the above obligation is such that whereas the Principal has submitted to the CITY OF JEFFERSON, MISSOURI a certain Bid, attached hereto and hereby made a part hereof to enter into a contract in writing, for the project entitled: "Project No. 32095, Locust Street Improvements" NOW, THEREFORE, .(81) If said Bid shall be rejected, or in the alternate, ' (b) If said. Bid shall be accepted and the Principal shall execute and deliver a contract in the .Form of Contract attached hereto (properly completed in accordance with said Bid) and shall furnish a bond for his faithful performance ' of said contract, and for the payment of all persons performing labor or furnishing materials in connection therewith, shall in all other respects perform the agreement created.by the acceptance of said Bid, ' then this obligation shall be void, otherwise the same shall remain in force and effect; it being expressly.understood and agreed that the liability of the Surety for any and all claims hereunder shall, in no event, exceed the penal amount of this obligation as herein stated. The Surety,for value received, hereby stipulates and agrees that the obligations of said Surety and its bond shall be in no way impaired or affected by.the extension the time within which the Owner may accept such Bid; and said Surety does hereby waive notice of any such extension. 1 IN WITNESS WHEREOF, the Principal and the Surety have hereunto set their hands and seats,and such of them as are corporations have caused their corporate seats to be hereto affixed and these presents to be signed by their proper officers,the day and year first set forth above. (L.S.) Principal By: SEAL ' Surety . By. i ANTI-COLLUSION STATEMENT STATE OF ✓1���sS�ri ) COUNTY OF le-- ) I . being first I duly swom, deposes and says that he is of ' TITLE OF PERSON SIGNING Czee ' NAME OF.BIDDER that all statements made and facts set out in the bid for the above project are true and ' correct; and that the bidder (the person, firm, association, or corporation making said bid)has not,either directly or indirectly,entered into any agreement, participated in any collusion, or otherwise taken any action in restraint of free competitive bidding in 1 connection with such bid of any contract which result from its acceptance. Affiant further certifies that bidder is not financially interested in, or financially affiliated with, any other bidder for the above project. (BY) I "4- , a--- czz (BY) Sworn to before me this�+� day of '' , 200 NO RY PUBLIC qq My commission expires: 1 CONTRACTOR'S AFFIDAVIT This affidavit is hereby made a part of the Bid, and an executed copy thereof shall accompany each Bid submitted. STATE OF Nd•ssn�� ) COUNTY OF L'. ) ss The undersigned, o.+�•-t� �- �• , ' of lawful age, being.first duly swom states upon oath that he is of ' the contractor submitting the attached bids that he knows of his own knowledge and states it to be a fact that neither said bid nor the computation upon which it is based include any amount of monies, estimate or allowance representing wages, moneys or • expenses, however designated, proposed to be paid to persons who are not required to furnish material or actually perform services upon or as a part of the proposed ' project. AFFIANT 1 - Subscribed and sworn to.before me, a Notary Public, in and for the County and Sate aforesaid, this!,o% day of new , 20 '9J NOTARY PUBLIC 1 y My Commission Expires: I ' - 1 MINORITY BUSINESS ENTERPRISE STATEMENT Contractors bidding on City contracts shall take the following affirmative steps to assure. that small,women owned,and minority business are utilized when possible as sources ' of suppliers, services, and construction items. ' 1. Contractor's will submit the names and other information if any, about their MBE sub-contractors along.with their bid submissions. ' 2. Sufficient and reasonable efforts will be made to -use qualified MBE sub- contractors when possible on City contracts. ' 3. Qualified small, women owned, and minority business will be included on solicitation lists as sub-contractors for City supplies, services, and construction. ' 4. Qualified small, women owned, and minority business will be solicited whenever they are potential sources. ' 5. When economically feasible, Contractors will divide.total requirements into smaller tasks or quantities so as to permit maximum small, women owned, and minority business participation. • 6. Where the requirement permits, Contractor will establish delivery schedules which will encourage participation by small, .women owned and minority businesses. . 7. Contractor will use the services and assistance of the Small Business ' Administration, the Office of Minority Business Enterprise, and the Community Services Administration. ' 8. Forms for determining Minority Business Enterprise eligibility may be obtained from the Department of Public Works. 1 MINORITY BUSINESS UTILIZATION AGREEMENT A. The bidder agrees to attempt to expend at least.two (2) % of the contract, if awarded,for Minority Business Enterprise(MBE). For purposes of this goal,the term "Minority Business Enterprise".shall mean a business: 1. Which is at least 51 percent_owned.by one or more minorities or women, or, in the case of a publicly owned business, at least 51 percent of the stock of which is owned-by one or more minorities or women; and ' 2. Whose management and daily business operations are controlled by one or more such individuals. ' "Minority Group Member"or"Minority"means a person who is a citizen or lawful permanent resident of the United States, and who is: ' 1. Black(a person having origins in any of the black racial groups of Africa); 2. Hispanic (a person of Spanish or Portuguese culture with origins in Mexico,South or Central America, or the Caribbean Island, regardless of race); 3. Asian American (a person.having origins in any of the original peoples of the Far East, Southeast Asia, the Indian sub-continent, or the Pacific Islands); 4. American Indians and Alaskan Native (a person having-origins in any of ' the original peoples of North America); 5. Member of other groups, or other individuals, found to be economically and socially disadvantaged by the Small. Business Administration under Section 8(a) of the Small Business Act, as amended [15 U.S.C. 637(a)). ' 6. A female person who requests to be considered as.an MBE, and who "owns" and "controls" a business as defined herein. . 1 Minority Business Enterprises may be employed as contractors,subcontractors, or suppliers. 1 i ' B. The bidder must indicate the Minority Business Enterprise(s) proposed for utilization as part of this contract as follows: ' Name and Addresses Nature of Dollar Value of of Minority Firms Participation Participation �4 Total Bid Amount: 7 f Total: O ' Percentage of Minority Enterprise Participation: % ' C.. The bidder agrees to certify that the minority firm(s) engaged to provide materials or services in the completion of this project: (a) is a bona fide Minority Business Enterprise;and(b)has executed a binding contract to provide specific ' materials or services for a specific.dollar amount. A roster of bona fide Minority Business Enterprise firms will be fumished by the ' City of Jefferson. The bidder will provide written notice to the Liaison Officer of . the City of Jefferson indicating the Minority Business Enterprise(s) it intends to use in conjunction with this contract. This written notice is.due five days after . notification to the lowest.bidder: Certification that the Minority Business Enterprise(s) has executed a binding ' contract with the bidder for materials or services should be provided to the MBE Coordinator at the time the bidder's contract is submitted to the MBE Coordinator. ' D. The undersigned hereby certified that he or she has read the terms of this 9 Y ' agreement and is authorized to bind the bidder to the agreement herein set forth: � 1 - AO� NAME OF AUTHORIZED OFFICER DATE r --fl ' e,31GNATURE OF AUTHORIZED OFFICER • 1 • BID BOND ' KNOW ALL MEN BY THESE PRESENTS, that we, the undersigned,_ ,Stockman construction' rQ_, as Principal, . and Employers Mutual Casualty Company as Surety, are hereby held and firmly ' bound unto".the CITY OF JEFFERSON, MISSOURI ' as owner, in the' penal sum Of Five Percent (5%) of Price Bid----------for the payment of which, well and truly to be made,- we'hereby jointly and severally bind_ ourselves, our heirs, executors, administrators, successors and assigns,this 6th day of May 200 8 ' The condition of the above obligation is such that whereas the Principal has submitted ' to the CITY OF JEFFERSON, MISSOURI a certain Bid, attached hereto and hereby mad' ade a .part hereof to enter into a contract in writing,for the project entitled: ' "Project No.32095, Locust Street Improvements" NOW, THEREFORE, ' (a) If said Bid shall be rejected, or in the alternate, (b) If said Bid shall be accepted and the Principal shall execute and deliver a ' contract in the Form of Contract attached hereto (properly completed- in accordance with said Bid)and shall fumish a bond for his faithful performance of said contract, and for the payment of all persons performing labor or ' furnishing materials in connection therewith, shall in all other respects perform the agreement created by the acceptance of said Bid, then this obligation shall be void, otherwise the same shall remain in force and effect; it.being expressly understood and agreed that the liability.of the Surety for any and all claim_s hereunder shall,in no event,exceed the penal amount of this obligation as herein Stated, ' The Surety,for value received,hereby stipulates and agrees that the obligations of said Surety and its bond shall be in no way impaired or affected by the extension of the time within which the Owner may accept such Bid;and said Surety does hereby waive notice of any such extension. '. IN WITNESS WHEREOF,the Principal and the Surety have hereunto set their hands and seals,and such of them as are corporations have caused their corporate seals to be hereto ' affixed and these presents to be signed by their proper officers, the day and-year first set forth above. Stockman Construction Corp. ' Principal By: c c SEAL f� m lo. ers Mutual Casualty Company ure By. ' Tera Huesgen, A orney-In-Fact 1 ' • •o 0 0 0 -e a e a oo • o e R It • `S: ... r`r y W . Mc: -surance Cipanle& � 1 r'r t P® t3ou 712 Des Moines,IA 50306-0712 I,V 9 ,i. CER IF A., �F AUTHORIT INCIVID�9AL ATTOI NE -9N FACT W ALL:MEW BY THESE PRESENTS, that I Em la ers:Mutual Casua Com an ::an low r o► oration ' p Y p y' p S Dakota Fire Insurance Comparry,a North Dakota,Corporation 2 EMCASCO`Thsurail Company,an•I©wa Corporation 611 EMG;Propertj $Casualty Company,amlowa':Corporation, ?3 Union Insurance Company of Ptovidenil art;Iowa Corporation 7; Hamilton Mutual Insurance Cori a p =! 4 Ithnois EMCASCt)Insurance:Corhparry,an Iowa Corporation p hy,an Iowa Cor oration ' hereinafter referred to severally as- Company"and collectively as"Companies.;each does by these presents make constitute and appoint h, THOMAS S: NAUGHT,HARRY NAUGHT,TERESA STEPHENSON,.SARAH NAUGHT.BARGFREDE,WILMA•KEISER,:TIMOTHY.P'. " EAS hN,_RICHARD, NAUGHT,STEVE NAUGHT;BETH NATIONS,NATALIE,LURVEY,TERA HUES GEl INDIVIDUALLY,JEFFERSON CITY MISSOURI .'.. ... .................................................. :- its true'and-lawful attorrie �n fact;with fulls ower and;authon conferred to.si ri;seal,and execute its lawful bonds,undertaken s and other obh ato instruments of a zt,. y. .. P ry:: 9. 9. g.:. ry similar:nature.as;follows :. ANY::AND'ALL BONDS and`to 6ind:`each Company thereby,as fu9y.:i d to'the:same extent as bf:"such':instruments were signed bythe•duly aiithorized`offcers of each such Company;and all of 'the acts of'said'attorrie ursuantto the authon hereb even are hereb'ratified:and conliirmetl: t YP tY Y9 y i y� The authority hereby granted shall expireF APRILA 80.11' unless:sooner revoked z UTHORITY FOR POSER ®F ATTORNEY j This Rower of Attorney es:made,'Md executed pursuant to and by the authority-of the f ollowing,resoluteon'.of the Boards of Directors of;each of the:Companies at a ..I ' regularly scheduled meeting of each company duly called and held in 1999. RE$OL"VED The President and Chief EAll(3f6cer,any, il ce President,the T66:asurer:al the Secretary of Employers Mutual Casualty Company shall have power and authority to (1) appoint attorneys m fact and authorize them to execute on behalf;of each.Company and attsch the seal of the Co thereto, bonds and :.undertakings,.recognizances contracts of indemnityand other writings:obligatory in the nature thereof,and(2)`to remove anysuch attorney-in fact of any time and revoke the power and:authority given to him or her:Attorneys in fact shall have_power and authority,subject to the terms and Imitations oftfie power ofattorney issued to them; to execute and deliver:ori behalf iif the.Cl any and Jo attach the seal of the Company thereto, bonds and undertakings recognizanEes,contracts of:indemnity,and ,= other writings:oblegatory.in the nature thereof,and any such instniment executed:.by.any such attorney err-.fact.shalfbe fully and in all respects bmdmg uporT the Company. ' rtification as.to the validity of ar{y power of attorney authonzed Herein made'b an officer of`Em to ers Mutual,Casual Coma shall be'foil and:in all res ects Y P Y ty P nY s Y R., ing upon this Company The,facsim�e:or mechanically reprbduced.signature.of such officer, whether made:heretofore or:.hereaffer,.wherever appearing:upon a.11 :• ertified copyof:any power of attorney of the;Company shall`be vafid::and binding upon the Company with the'same force and'affect asfhough manually'3ffixed ,Z.IN WITNESS WHEREOF,'the Companies have caused these presents to be signed for each by their officers as shown,:and the Corporate seals to tie hereto affixed this 1$TI F-day.of EBr„,n oy 2 d. ' 7{ s„Sea ls d. , _'Bruce G-.Kelley, hairman(/ -Jil 5 Birdsley oPS� iNSU q o���Our of .R E s of Companies 2,3 4,5& President Assistant Secretary OPP0P4A y`'” 0Q_4°PPflA,t4 O OftPaflgl y of Company 1,Vice Chairman and o SEAL 3 0 1.953 CEO of Company 7 Z ZS`L POflNC�CO �N4$6 i.UAC " „ Notary I c rn and for the StgtERof:owa. ersonat[ a 2QDR before me a. _ - ry P Y ppeared_Bruce G.Kelley and.Jeffrey S. ° ; r� .Birdsley,who,being by me duly sworn did:say that they are'and are known to mil be the SEAL '' SEAL i SEAu Chairman, President, Vice Chairman and CFO and/or Assistant Secrets res ectivel of P eac. of The Companies above that the seals affixed to this instrument the seals of said r •: owP , "ORr„u�ao-� HDoi c0� corporations;.that said:instrument was signed and sealed on.behalfof each ;of.the Companies. ' ^ '� by authority of their respective Boards of Directors; and that the said Brucil Kelley and UiuA�DNS Jeffrey S.Birdsley, as such officers, acknowledge the execution of said.in to be the uTUq�U� voluntary act deed of each of the_Com anies and p a My Commission Expires September.,30 2009. RU CA3CRUiVItNS Eoipmissiom Number 176255 ,�Me.AAry .A'`�. t" 'Occh URA Q M comm U Set 30.2009 }4 : SMOINES.�� ' P t? Notary Public in and for the State of Iowa CERTtFeCATE I David L.Hixenbaugh;Vice President of the Companres,:do herebycertify that the foregoing resolution of the Boards of Directors byeach of the Ponies and;this Po�ier of Attorney issued pursuant thereto on FEBRUARY 18,2008 ehalf of homas S`Naught�Harry Naught,Teresa'Stephenson, Sarah'Naught Bargfrede,`Wltma Keiser;Timothy P Eastin.,Richard ' „ are true and correct and are stililin II force and effffect:Naufit, Steve Naught;Beth Nations,Natali Lurvey, :era: Htiesgen InTestimony Whereof I have subscnbedrnyname and.8 heed the facsimile seal of each Company this,.. t17<day of..` May'.... 2008. I Vice President Form a licatiopsol e.?auth,;e.ntr ityy hie.-Pim 6f,'Aftill y,.Gu:may call:(514 S45- 6 8 91 I • ADDENDUM NO. I ' PROJECT NO.32095 LOCUST STREET ROADWAY IMPROVEMENTS MAY 2,2008 ' The bidder will acknowledge receipt of this Addendum and his acceptance of its conditions by signing this Addendum and including it with his bid. 1 � BIDDER: S ' BY: ' TITTLE: 1� _ 1. The pre-.bid minutes by there inclusion herein are made part of the contract. 1 - CITY OF JEFFERSON,MISSOURI ' PATRICK E.SULLIVAN,P.E. DIRCTOR OF COMMUNITY DEVELOPMENT 1 ;'" .. - -�§',gg�•"fl"'S. •.it.�a ut.t 3:.o:Y.1a_�h��9` F. .., ,. ... ,. .. .. , - ._•t.'- .., ... . �,. 1-. . ,. .1'f 1 1 • • Missouri rrD,vis�on of Labor Standards ' WAGE AND HOUR SECTION In 1 F THE S °Opvu su O� 1 �y Mo-Cc XX 1 MATT BLUNT, Governor Annual Wage Order No. 14 Section 026 ' COLE COUNTY In accordance with Section 290.262 RSMo 2000, within thirty. (30) days after a certified copy of this 1 Annual Wage Order has been filed with the Secretary of State as indicated below, any person who may be affected by this Annual Wage Order may object by filing an objection in triplicate with the Labor and Industrial Relations Commission, P.O. Box 599, Jefferson City, MO 65102-0599. Such objections must ' set forth in writing the specific grounds of objection. Each objection shall certify that a copy has been furnished to the Division of Labor Standards, P.O. Box 449, Jefferson City, MO 65102-0449 pursuant to 8 CSR 20-5.010(1). A certified copy of the Annual Wage Order has been filed with the Secretary of State of Missouri. 1 Original Signed by Allen E. Dillingham, Director Division of Labor Standards This Is A True And Accurate Copy Which Was Filed With The Secretary of State: March 9. 2007 Last Date Objections May Be Filed: April 9,2007 • Prepared by Missouri Department of Labor and Industrial Relations 1 Building Construction Rates for REPLACEMENT PAGE Section 026 ' COLE County • "Effective Basic Over- OCCUPATIONAL TITLE Date of Hourly Time Holiday Total Fringe Benefits Increase Rates Schedule Schedule Asbestos Worker 10/07 $27.74 55 60 $14.61 Boilermaker 9/07 $28.90 57 7 $18.75 ' Bricklayers-Stone Mason $26.06 1 59 1 7 $10.71 Carpenter 1 $22.181 60 1 15 1 $9.77 Cement Mason $21.59 9 3 $9.70 ' Electrician Inside Wireman $27.21 28 7 $10.69+ 13% Communication Technician USE ELECTRICIAN INSIDE WIREMAN RATE Elevator Constructor 1/08 a $38.715 26 54 $17.675 Operating Engineer ' Group 1 5/07 $25.02 86 66 $16.42 -Group II 5/07 $25.02 86 66 $16.42 Group III 5/07 $23.77 86 66 $16.42 Group III-A 5/07 $25.02 86 66 $16.42 ' Group IV 5/07 $22.79 86 66 $16.42 Group V 5/07 $25.72 86 66 $16.42 Pipe Fitter 7/07 b $32.00 91 69 $18.68 , Glazier $15.00 FED $1.42 Laborer(Building): General $18.37 110 7 $8.99 First Semi-Skilled $20.37 110 7 $8.99 Second Semi-Skilled $19.37 110 7 $8.99 Lather JUSE CARPENTER RATE Linoleum La er&Cutter JUSE CARPENTER RATE , Marble Mason $26.06 59 7 $10.71 • Millwright $23.18 60 15 $9.77 Iron Worker 8/07 $24.65 11 8 $15.87 Painter 2/08 $20.40 18 7 $8.77 ' Plasterer $20.61 94 1 5 $9.49 Plumber $22.00 FED $3.31 Pile Driver $23.18 60 15 $9.77 Roofer 9/07 $25.75 12 4 $10.69 ' Sheet Metal Worker 7/07 $26.12 40 23 $11.93 Sprinkler Fitter $16.00 FED $2.55 Terrazzo Worker $26.06 59 7 $10.71 ' Tile Setter $26.06 59 7 $10.71 Truck Driver-Teamster Group 1 $21.15 101 5 $8.00 Group II $21.85 101 5 $8.00 ' Group III $21.55 101 5 $8.00 Group IV $21.85 101 5 $8.00 Traffic Control Service Driver Welders-Acetylene&Electric ' Fringe Benefit Percentage is of the Basic Hourly Rate Attention Workers: If you are not being paid the appropriate wage rate and fringe benefits contact the Division , of Labor Standards at(573)751-3403. "Annual Incremental Increase • 'SEE FOOTNOTE PAGE ANNUAL WAGE ORDER NO. 14 1/08 , Building Construction Rates for REPLACEMENT PAGE Section 026 COLE County Footnotes ' Effective Basic Over- OCCUPATIONAL TITLE Date of Hourly Time Holiday Total Fringe Benefits Increase Rates Schedule Schedule 1 Welders receive rate prescribed for the occupational title performing operation to which welding is incidental. Use Building Construction Rates on Building(s)and All Immediate Attachments.Use Heavy Construction rates for remainder of project. For the occupational titles not listed in Heavy Construction Sheets,use Rates shown on Building Construction Rate Sheet. a-Vacation: Employees over 5 years-8%; Employees under 5 years-6% ' 'b- All work over$7 Million Total Mechanical Contract-$32.00,Fringes-$18.68 All work under$7 Million Total Mechanical Contract-$30.66,Fringes-$14.24 1 • ' 'Annual Incremental Increase ANNUAL WAGE ORDER NO.14 7/07 COLE COUNTY OVERTIME SCHEDULE-BUILDING CONSTRUCTION .FED: Minimum requirement per Fair Labor Standards Act means time and one-half(1 '/2).shall be paid for all work in excess of forty(40)hours per work week. ' NO.9: Means the regular workday starting time of 8:00 a.m.(and resulting quitting time of 4:30 p.m.)may be moved forward to 6:00 a.m. or delayed one hour to 9:00 a.m. All work performed in excess of the regular work day and on Saturday shall be compensated at one and one-half(1'/2) times the regular pay. In the event time is lost during the work week due to weather conditions,the Employer may schedule work on the following Saturday at straight time. All work accomplished on Sunday and holidays shall be compensated for at double the regular rate of wages. The work week shall be Monday through Friday,except for , midweek holidays. NO. 11: Means eight(8)hours shall constitute a day's work,with the starting time to be established between 6:00 a.m. and 8:00 a.m.from Monday to Friday. Time and one-half(1'/2)shall be paid for first two(2)hours of overtime Monday through Friday and_ the first eight(8) hours on Saturday. All other overtime hours Monday through Saturday shall be paid at double(2)time rate. Double(2)time shall be paid for all time on Sunday and recognized holidays or the days observed in lieu of these holidays. NO. 12: Means the work week shall commence on Monday at 12:01 a.m. and shall continue through the following Friday, inclusive of each week. All work performed by employees anywhere in excess of forty(40)hours in one(1)work week,shall be paid for at the rate of one and one-half(1%2)times the regular hourly wage scale. All work performed within the regular working hours which shall consist of a ten(10)hour work day except in emergency situations. Overtime work and Saturday work shall be ' paid at one and one-half(1%2)times the regular hourly rate. Work on recognized holidays and Sundays shall be paid at two(2) times the regular hourly rate. NO. 18: Means the regular work day shall be eight(8)hours. Working hours are from six(6)hours before Noon(12:00)to six ' (6)hours after Noon(12:00). The regular work week shall be forty(40)hours,beginning between 6:00 am.and 12:00 Noon on Monday and ending between 1:00 p.m. and 6:00 p.m. on Friday. Saturday will be paid at time and one-half(1'/2). Sunday and Holidays shall be paid at double(2)time. Saturday can be a make-up day if the weather has forced a day off,but only in the week ' of the day being lost. Any time before six (6)hours before Noon or six (6)hours after Noon will be paid at time and one-half • NO.26: Means that the regular working day shall consist of eight(8)hours worked between 6:00 a.m.,and 5:00 p.m.,five(5) ' days per week,Monday to Friday,inclusive.Hours of work at each jobsite shall be those established by the general contractor and worked by the majority of trades. (The above working hours may be changed by mutual agreement). Work performed on Construction Work on Saturdays, Sundays and before and after the regular working day on Monday to Friday,inclusive,shall be , classified as overtime,and paid for at double(2)the rate of single time. The employer may establish hours worked on a jobsite for a four(4)ten(10)hour day work week at straight time pay for construction work;the regular working day shall consist of ten(10) hours worked consecutively,between 6:00 a.m.and 6:00 p.m.,four(4)days per week,Monday to Thursday,inclusive. Any work performed on Friday,Saturday,Sunday and holidays,and before and after the regular working day on Monday to Thursday where ' a four(4)ten(10)hour day workweek has been established,will be paid at two times(2)the single time rate of pay. The rate of pay for all work performed on holidays shall be at two times(2)the single time rate of pay. 1 • ANNUAL WAGE ORDER NO. 14 A W 14 026 OT.doc Page 1 of 4 Pages ' COLE COUNTY ' OVERTIME SCHEDULE-BUILDING CONSTRUCTION • NO. 28: Means a regular workday shall consist of eight(8) hours between 7:00 a.m. and 5:30 p.m., with at least a thirty(30) ' minute period to be taken for lunch. Five(5)days a week,Monday through Friday inclusive, shall constitute a work week. The Employer has the option for a workday/workweek of four(4)ten(10)hour days(4-10's)provided: -The project must be for a minimum of four(4)consecutive days. -Starting time may be within one(1)hour either side of 8:00 a.m. -Work week must begin on either a Monday.or Tuesday: If a holiday falls within that week it shall be a consecutive work day. (Alternate: If a holiday falls in the middle of a week, then the regular eight (8) hour schedule may be implemented). ' -Any time worked in excess of any ten(10)hour work day(in a 4-10 hour work week)shall be at the appropriate overtime rate. ' All work outside of the regular working hours as provided,Monday through Saturday,shall be paid at one&one-half(1%2)times the employee's regular rate of pay. All work performed from 12:00 a.m.Sunday through 8:00 am. Monday and recognized holidays shall be paid at double(2)the straight time hourly rate of pay. Should employees work in excess of twelve(12) consecutive hours they shall be paid double time(2X)for all time after twelve(12)hours. Shift work performed between the hours of 4:30 p.m.and 12:30 a.m.(second shift)shall receive eight(8)hours pay at the regular hourly rate of pay plus ten(10%) percent for seven and one-half(7'/2)hours work. Shift work performed between the hours of 12:30 a.m.and 8:00 a.m.(third shift) shall receive eight(8)hours pay at the regular hourly rate of pay plus fifteen(15%)percent for seven(7)hours work. A lunch ' period of thirty(30)minutes shall.be allowed on each shift. All overtime work required after the completion of a regular shift shall be paid at one and one-half(1'/z)times the shift hourly rate. NO.40: Means the regular working week shall consist of five(5)consecutive(8)hour days'labor on the job beginning with Monday and ending with Friday of each week. Four(4) 10-hour days may constitute the regular workweek. The regular working day shall consist of eight(8)hours labor on the job beginning as early as 7:00 a.m.and ending as late as 5:30 p.m. All full or part time labor performed during such hours shall be recognized as regular working hours and paid for at the regular hourly rate. All ' hours worked on Saturday and all hours worked in excess of eight(8)hours but not more than twelve(12)hours during the regular working week shall be paid for at time and one-half(1'/2)the regular hourly rate. All hours worked on Sundays and holidays • and all hours worked in excess of twelve(12)hours during the regular working day shall be paid at two(2)times the regular hourly rate. In the event of rain,snow,cold or excessively windy weather on a regular working day,Saturday may be designated as a"make-up"day. Saturday may also be designated as a"make-up"day,for an employee who has missed a day of work for personal or other reasons. Pay for"make-up"days shall be at regular rates. NO.55: Means the regular work day shall be eight(8)hours between 6:00 a.m.-and 4:30 p.m. The first two(2)hours of work ' performed in excess of the eight(8) hour work day,Monday through Friday,and the first ten(10) hours of work on Saturday, shall be paid.at one&one-half(1'/z)times the straight time rate. All.work performed on Sunday,observed holidays and in excess of ten(10)hours a day,Monday through Saturday,shall be paid at double(2)the straight time rate. NO.57: Means eight(8)hours per day shall constitute a day's work and forty(40)hours per week,Monday through Friday,shall constitute a week's work. The regular starting time shall be 8:00 a.m. The above may be changed by mutual consent of authorized personnel. When circumstances warrant,the Employer may change the regular workweek to four(4)ten-hour days at ' the regular time rate of pay. It being understood that all other pertinent information must be adjusted accordingly. All time worked before and after the established workday of eight(8)hours,Monday through Friday,all time worked on Saturday,shall be paid at the rate of time and one-half(1'/2) except in cases where work is part of an employee's regular Friday shift. All time ' worked on Sunday and recognized holidays shall be paid at the double(2)time rate of pay. 1 ANNUAL WAGE ORDER NO.14 ' A W 14 026 OT.doc Page 2 of 4 Pages r COLE COUNTY , OVERTIME SCHEDULE-BUILDING CONSTRUCTION NO.59: Means that except as herein provided,eight(8)hours a day shall constitute a standard work day,and forty(40)hours per week shall constitute a week's work. All time worked outside of the standard eight(8)hour work day and on Saturday shall be classified as overtime and paid the rate of time and one-half(1'/2). All time worked on Sunday and holidays shall be classified as ' overtime and paid at the rate of double(2)time. The Employer.has the option of working either five(5)eight hour days or four (4) ten hour days to constitute a normal forty (40) hour work week. When the four (4) ten-hour work week is in effect, the , standard work day shall be consecutive ten(10)hour periods between the hours of 6:30 a.m.and 6:30 p.m. Forty(40)hours per week shall constitute a weeks work,Monday through Thursday,inclusive. In the event the job is down for any reason beyond the Employer's control,then Friday and/or Saturday may,at the option of the Employer,be worked as a make-up day;straight time not to exceed ten(10)hours or forty(40)hours per week. When the five_day(8)hour work week is in effect, forty(40)hours per ' week shall constitute a week's work,Monday through Friday, inclusive. In the event the job is down for any reason beyond the Employer's control,then Saturday may, at the option of the Employer,be worked as a make-up day; straight time not to exceed eight(8)hours or forty(40)hours per week. The regular starting time(and resulting quitting time)may be moved to 6:00 a.m.or delayed to 9:00 a.m. Make-up days shall not be utilized for days lost due to holidays. , NO.60: Means the Employer shall have the option of working five 8-hour days or four 10-hour days Monday through Friday. If an Employer elects to work five 8-hour days during any work week,hours worked more than eight(8)per day or forty(40)per ' week shall be paid at time and one-half(1'/z) the hourly wage rate plus fringe benefits Monday through Friday. SATURDAY MAKE-UP DAY: If an Employer is prevented from working forty(40)hours, Monday through Friday, or any part thereof by reason of inclement weather(rain or mud),Saturday or any part thereof may be worked-as a make-up day at the straight time rate. It is agreed by the parties that the make-up day is not to be used to make up time lost due to recognized holidays. If an Employer , elects to work four 10-hour days,between the hours of 6:30 a.m.and 6:30 p.m. in any week,work performed more than ten(10) hours per day or forty (40) hours per week shall be paid at time and one half(1'/2) the hourly wage rate plus fringe benefits Monday through Friday. If an Employer is working 10-hour days and loses a day due to inclement weather,the Employer may ' work ten(10)hours on Friday at straight time. Friday must be scheduled for no more than ten(10)hours at the straight time rate, but all hours worked over the forty(40)hours Monday through Friday will be paid at time and one-half(1'/z)the hourly wage rate plus fringe benefits. All Millwright work performed in excess of the regular work day and on Saturday shall be compensated for at time and one-half (1'/z)the regular Millwright hourly wage rate plus fringe benefits. The regular work day starting of 8:00 a.m. ' (and resulting quitting time of 4:30 p.m.) may be moved forward to 6:00 a.m. or delayed one (1) hour to 9:00 a.m. All work accomplished on Sundays and recognized holidays,or days observed as recognized holidays,shall be compensated for at double (2) the regular hourly rate of wages plus fringe benefits. NOTE: All overtime is computed on the hourly wage rate plus an amount equal to the fringe benefits. ' NO.86: Means the regular work week shall consist of five(5)days,Monday through Friday,beginning at 8:00 a.m.and ending at 4:30 p.m. The regular work day beginning time may be advanced one or two hours or delayed by one hour. However, the , Employer may have the option to schedule his work week from Monday through Thursday at ten(10)hours per day at the straight time rate of pay with all hours in excess of ten(10)hours in any one day to be at the applicable overtime rate. If the Employer elects to work from Monday through Thursday and is stopped due to circumstances beyond his control, inclement weather or holiday,he shall have the option to work Friday at the straight time rate of pay to complete his forty(40)hours. If an employee ' declines to work Friday as a make-up day,he shall not be penalized. All overtime work performed on Monday through Saturday shall be paid at time and one-half(1'/2)of the hourly rate plus an amount equal to one-half('/z)of the hourly Total Indicated Fringe Benefits. All work performed on Sundays and recognized holidays shall be paid at double(2) the hourly rate plus an amount equal to the hourly Total Indicated Fringe Benefits. ' NO.91:Means eight(8)hours shall constitute a day's work commencing at 8:00 a.m.and ending at 4:30 p.m,allowing one-half ('/2)hour for lunch. The option exists for the Employer to use a flexible starting time between the hours of 6:00 a.m.and 9:00 a.m. ' The regular workweek shall consist of forty(40)hours of five(5)workdays,Monday through Friday. The workweek may consist of four(4)ten(10)hour days from Monday through Thursday,with Friday as a make-up day. If the make-up day is a holiday,the employee shall be paid at the double(2)time rate. The employees shall be paid time and one-half(1'/2)for work performed before the regular starting time or after the regular quitting time or over eight(8)hours per work day (unless working a 10-hour work ' day,then time and one-half(1'/2) is paid for work performed over ten(10)hours a day)or over forty(40)hours per work week. Work performed on Saturdays,Sundays and recognized holidays shall be paid at the double(2)time rate of pay. • 1 ANNUAL WAGE ORDER NO. 14 A W 14 026 OT.doc Page 3 of 4 Pages , COLE COUNTY OVERTIME SCHEDULE-BUILDING CONSTRUCTION • NO.94: Means eight(8)hours shall constitute a days work between the hours of 8:00 a.m.and 5:00 p.m. The regular workday ' starting time of 8:00 a.m.(and resulting quitting time of 4:30 p.m.)may be moved forward to 6:00 a.m.or delayed one(1)hour to 9:00 a.m. All work performed in excess of the regular work day and on Saturday shall be compensated at one and one-half(1'/2) times the regular pay. In the event time is lost during the work week due to weather conditions,the Employer may schedule work on the following Saturday at straight time. All work accomplished on Sunday and holidays shall be compensated at double the regular rate of wages. NO.101: Means that except as provided below,eight(8)hours a day shall constitute a standard work day,and forty(40)hours per ' week shall constitute a week's work,which shall begin on Monday and end on Friday. All time worked outside of the standard work day and on Saturday shall be classified as overtime and paid the rate of time and one-half(1'/2)(except as herein provided). All time worked on Sunday and recognized holidays shall be classified as overtime and paid at the rate of double (2) time. The regular starting time of 8:00 a.m. (and resulting quitting time of 4:30 p.m.)may be moved forward to 6:00 a.m. or delayed one(1)hour to ' 9:00 a.m. The Employer has the option of working either five(5)eight-hour days or four(4)ten-hour days to constitute a normal forty(40)hour work week. When a four(4)ten-hour day work week is'in effect,the standard work day shall be consecutive ten (10)hour periods between the hours of 6:30 a.m.and 6:30 p.m. Forty(40)hours per week shall constitute a week's work Monday through Thursday,inclusive. In the event the job is down for any reason beyond the Employer's control,then Friday and/or Saturday ' may, at the option of the Employer,be worked as a make-up day; straight time not to exceed ten(10)hours per day or forty(40) hours per week. Starting time will be designated by the employer. When the five(5)day eight(8)hour work week is in effect,forty (40)hours per week shall constitute a week's work,Monday through Friday,inclusive. In the event the job is down for any reason ' beyond the Employer's control,then Saturday may,at the option of the Employer,be worked as a make-up day;straight time not to exceed eight(8)hours per day or forty(40)hours per week. Make-up days shall not be utilized for days lost due to holidays. NO.110: Means eight(8)hours between the hours of 8:00 a.m.and 4:30 p.m shall constitute a work day. The starting time may ' be advanced one(1)or two(2)hours: Employees shall have a lunch period of thirty(30)minutes. The Employer may provide a lunch period of one (1)hour, and in that event,the workday shall commence at 8:00 a.m. and end at 5:00 p.m. The workweek shall commence at 8:00 a.m. on Monday and shall end at 4:30 p.m. on Friday(or 5:00 p.m. on Friday if the Employer grants a ' lunch period of one(1)hour), or as adjusted by starting time change as stated above. All work performed before 8:00 a.m. and after 4:30 p.m (or 5:00 p.m.where one(1)hour lunch is granted for lunch)or as adjusted by starting time change as stated above or on Saturday, except as herein provided,shall be compensated at one and one-half(1'/2)times the regular hourly rate of pay for the work performed. All work performed on Sunday and on recognized holidays shall be compensated at double(2)the regular hourly rate of pay for the work-performed If an Employer is prevented from working forty(40)hours,Monday through Friday,or any part thereof by reason of inclement weather(rain and mud),Saturday or any part thereof may be worked as a make-up day at the straight time rate. The Employer shall have the option of working five eight(8)hour days or four ten(10)hour days Monday ' through Friday. If an Employer elects to work five(5)eight(8)hour days during any work week,hours worked more than eight (8)per day or forty(40) hours per week shall be paid at time and one-half(1'/2)the hourly rate Monday through Friday. If an Employer elects to work four(4)ten(10)hour days in any week,work performed more than ten(10)hours per day or forty(40) hours per week shall be paid at time and one-half(1'/2)the hourly rate Monday through Friday. If an Employer is working ten(10) ' hour days and loses a day due to inclement weather, they may work ten (10) hours Friday at straight time. Friday must be scheduled for at least eight(8)hours and no more than ten(10)hours at the straight time rate,but all hours worked over the forty (40)hours Monday through Friday will be paid at time and one-half(1'/2)overtime rate. 1 I ANNUAL WAGE ORDER NO.14 AW 14 026 OT.doc Page 4 of 4 Pages - COLE COUNTY HOLIDAY SCHEDULE-DILDING CONSTRUCTION , NO3 All work done on New Yeats Day,Decoration Day,July 4th,Labor Day,Veteran's Day,Thanksgiving Day and • Christmas Day shall be paid at the double time rate of pay. Whenever any such holidays fall on a Sunday,the following ' Monday shall be observed as a holiday. N0.4All work done on New Year's Day,Memorial Day,Inde pendence Day,Labor.Day,Thanksgiving and Christmas Day shall be paid at the double time rate of pay. If any of the above holidays fall on Sunday,Monday will be observed as the recognized holiday. If any of the above holidays fall on Saturday,Friday will be observed as the recognized holiday. NO.5 All work that shall be done on New Year's Day,Memorial Day,Fourth of July,Labor Day,Veteran's Day, Thanksgiving Day,and Christmas Day shall be paid at the double(2)time rate of pay. N0.9Al1 work done on New Year's Day,Memorial Day,Indepe ndence Day,Labor Day,Veteran's Day,Thanksgiving Day, and Christmas Day shall be paid at the double time rate of pay. If a holiday falls on a Sunday;it shall be observed on the , following Monday. If a holiday falls on a Saturday,it shall be observed on the preceding Friday. NO.8All work performed on New Year's Day,Memorial Day, Independence Day,Labor Day,Veteran's Day,Thanksgiving Day,and Christmas Day,or the days observed in lieu of these holidays,shall be paid at the double time rate of pay. ' N05A11 work accomplished on the recognized holidays of New Year's Day,Decoration Day(Memorial Day),Independence Day(Fourth of July),Labor Day,Veteran's Day,Thanksgiving Day and Christmas Day,or days observed as these named ' holidays,shall be compensated for at double(2)the regular hourly rate of wages plus fringe benefits. If a holiday falls on Saturday,it shall be observed on the preceding Friday. If a holiday falls on a Sunday,it shall be observed on the following Monday. No work shall be performed on Labor Day,Christmas Day,Decoration Day or Independence Day except to preserve life or property. ' NO3 :All work done on New Year's Day,Memorial Day,Independence Day,Labor Day,Veteran's Day,Thanksgiving Day, Christmas Day and Sundays shall be recognized holidays and shall be paid at the double time rate of pay. When a holiday falls on Sunday,the following Monday shall be considered a holiday. ' NOAA11 work performed on New Year's Day,Memorial Day, Independence Day,Labor Day,Veteran's Day,Thanksgiving • Day,the Friday after Thanksgiving Day,and Christmas Day shall be paid at the double(2)time rate of pay. When a holiday ' falls on Saturday,it shall be observed on Friday. When a holiday falls on Sunday,it shall be observed on Monday. NO.6 All work performed on New Year's Day,Armistice Day(Veteran's Day),Decoration Day(Memorial Day), Independence Day(Fourth of July),Thanksgiving Day and Christmas Day shall be paid at the double time rate of pay. No , work shall be performed on Labor Day except when triple(3)time is paid. When a holiday falls on Saturday,Friday will be observed as the holiday. When a holiday falls on Sunday,the following Monday shall be observed as the holiday. NO.6 All work performed on Sundays and the following recognized holidays,or the days observed as such,of New Year's , Day,Decoration Day,Fourth of July,Labor Day,Veteran's Day,Thanksgiving Day and Christmas Day,shall be paid at double (2)the hourly rate plus an amount equal to the hourly Total Indicated Fringe Benefits. Whenever any such holidays fall on a Sunday,the following Monday shall be observed as a holiday. NO.6 All work performed on New Year's Day,Decoration Day,July Fourth,Labor Day,Veteran's Day,Thanksgiving Day ' or Christmas Day shall be compensated at double(2)their straight-time hourly rate of pay. Friday after Thanksgiving and the day before Christmas will also be holidays,but if the employer chooses to work these days,the employee will be paid at straight ' -time rate of pay. If a holiday falls on a Sunday in a particular year,the holiday will be observed on the following Monday. • ANNUAL WAGE ORDER NO. 14 , AW014 026 BHol.doc Page] of 1 Page Heavy Construction Rates for REPLACEMENT PAGE Section 026 COLE County ' *Effective Basic over- OCCUPATIONAL TITLE Date of Hourly Time Holiday Total Fringe Benefits Increase Rates Schedule Schedule ' CARPENTER Journeymen 5/07 $27.21 7 1-6 $9.76 ' Millwright 5/07 $27.21 7 16 $9.76 Pile Driver Worker 5/07 $27.21 7 16 $9.76 OPERATING ENGINEER Group 1 5/07 $24.10 21 5 $16.34 ' Group II 5/07 $23.75 21 5 . $16.34 Group III 5/07 $23.55 21 5 $16.34 Group IV 5/07 $19.90 21 5 $16.34 ' Oiler-Driver 5/07 $19.90 .21 5 $16.34 ' LABORER ' General Laborer 5/07 $22.97 2 4 $8.78 killed Laborer 5/07 $23.57 2 4 $8.78 TRUCK DRIVER-TEAMSTER - Group 1 5/07 $25.02 22 19 $8.35 ' Group 11 5/07 $25.18 22 19 $8.35 IGroup III 5/07 $25.17 22 19 $8.35 Grou IV 5/07 $25.29 22 19 $8.35 For the occupational titles not listed on the Heavy Construction Rate Sheet, use Rates shown on the Building Construction Rate Sheet. 1 "Annual Incremental Increase ANNUAL WAGE ORDER NO. 14 6/07 1 COLE COUNTY OVERTIME SCHEDULE—HEAVY CONSTRUCTION ' NO.2: Means a regular workweek shall be forty(40)hours and will start on Monday and end on Friday. The regular work day shall be either eight(8)or ten(10)hours. If a crew is prevented from working forty (40)hours Monday through Friday,or any part thereof,by reason of inclement weather,Saturday or any , part thereof may be worked as a make-up day at the straight time rate. Employees who are part of a regular crew on a make-up day,notwithstanding the fact that they may not have been employed the entire , week,shall work Saturday at the straight time rate. A workday shift is to begin at the option of the - Employer,between 6:00 a.m. and not later than 9:00 a.m- However,the project starting time may be advanced or delayed if required. If workmen are required to work the enumerated holidays or days , observed as such or Sundays,they shall receive double(2)the regular rate of pay for such work. NO. 7: Means the regular work week shall start on Monday and end on Friday,except where the Employer elects to work Monday through Thursday,ten(10)hours per day. All work over ten(10)hours , in a day or forty(40)hours in a week shall be at the overtime rate of one and one-half(1'/2)times the regular hourly rate. The regular work day shall be either eight(8)or ten(10)hours. If a job can't work forty(40)hours Monday through Friday because of inclement weather or other conditions beyond the ' control of the Employer,Friday or Saturday may be worked as a make-up day at straight time(if working 4-10's). Saturday may be worked as a make-up day at straight time(if working 5-8's). Make-up days shall not be utilized for days lost due to holidays. A workday is to begin at the option of the.Employer but not later than 11:00 a.m. except when inclement weather,requirements of the owner or other ' conditions beyond the reasonable control of the Employer prevent work. Except as worked as a make-up day,time on Saturday shall be worked at one and one-half(1'/2)times the regular rate. Work performed on Sunday shall be paid-at two(2)times the regular rate. Work performed on recognized holidays or days ' observed as such,shall also be paid at the double(2)time rate of pay. NO. 21: Means the regular workday for which employees shall be compensated at straight time hourly , rate of pay shall,unless otherwise provided for,begin at 8:00 a.m. and end at 4:30 p.m. However,the project starting time may be advanced or delayed at the discretion of the Employer. At the discretion of the Employer,when working a five(5)day eight(8)hour schedule, Saturday may be used for a make-up day. If an Employer is prohibited from working on a holiday,that employer may work the following ' Saturday at the straight time rate. However,the Employer may have the option to schedule his work from Monday through Thursday at ten(10)hours per day at the straight time rate of pay with all hours in excess of ten(10)hours in any one day to be paid at the applicable overtime rate. If the Employer elects ' to work from Monday through Thursday and is stopped due to circumstances beyond his control,he shall have the option to work Friday or Saturday at the straight time rate of pay to complete his forty(40) hours. If an Employer is prohibited from working on a holiday,that Employer may work the following Friday or Saturday at the straight time rate. Overtime will be at one and one-half(1'/2)times the regular rate. If workmen are required to work the enumerated holidays or days observed as such,or Sundays, they shall receive double(2)the regular rate of pay for such work. NO.22: Means a regular work week of forty(40)hours will start on Monday and end on Friday. The regular work day shall be either eight(8)or ten(10)hours. If a crew is prevented from working forty (40)hours Monday through Friday,or any part thereof by reason of inclement weather, Saturday or any , part thereof may be worked as a make-up day at the straight time rate. Employees who are part of a regular crew on a make-up day,notwithstanding the fact that they may not have been employed the entire week,shall work Saturday at the straight time rate. A workday is to begin between 6:00 a.m. and.9:00 ' a.m. However,the project starting time may be advanced or delayed if mutually agreed to by the interested parties. For all time worked on recognized holidays, or days observed as such,double(2)time shall be paid. ANNUAL WAGE ORDER NO. 14 AWO)4026 HOT.doc Page 1 of 1 Page COLE COUNTY ' HOLIDAY SCHEDULE—HEAVY CONSTRUCTION • NO. 4: All work performed on New Year's Day,Memorial Day, Independence Day,Labor Day, Thanksgiving ' Day, Christmas Day, or days observed as such, shall be paid at the double time rate of pay. When a holiday falls on a Sunday,Monday shall be observed. NO.5: The following days are recognized as holidays: New Year's Day,Memorial Day,Fourth of July,Labor Day,Thanksgiving Day and Christmas Day. If a holiday falls on a Sunday,it shall be observed on.the following Monday. If a holiday falls on a Saturday, it shall be observed on the preceding Friday. No work shall. ' be performed on Labor Day except in case of jeopardy to work under construction. This rule is applied to protect Labor Day. When a holiday falls during the normal work week,Monday through Friday, it shall be counted as eight(8)hours toward a forty (40) hour week; however,no reimbursement for this eight(8)hours is to be paid the workman unless worked. If workmen are required to work the above recognized holidays or days . observed as such, or Sundays,they shall receive double(2)the regular rate of pay for such work. The above shall apply to the four 10's Monday through Thursday work week. The ten.(10)hours shall be applied to the forty(40)hour work week. NO. 16: The following days are recognized as holidays: New Year's Day,Memorial Day,Fourth of July, Labor Day, Thanksgiving Day and Christmas Day. If a holiday falls on Sunday, it shall be observed on the following Monday. If a holiday falls on Saturday, it shall be observed on the preceding Friday.No work shall be performed on Labor Day except in case of jeopardy to work under construction.This rule is applied to ' protect Labor Day.When a holiday falls during the normal work week,Monday through Friday, it shall be counted as.eight(8)hours toward the forty(40)hour week; however,no reimbursement for this eight(8)hours is to be paid to the worker unless worked. If workers are required to work the above recognized holidays or days observed as such, they shall receive double(2)the regular rate of pay for such work. ' NO. 19: The followin g days s are recognized as holidays: New Year's Day,Memorial Day,Independence Day, b'n Y Y Labor Day, Thanksgiving Day and Christmas Day. If a holiday falls on a Sunday, it shall be observed on the following Monday. No work shall be performed on Labor Day except in case of jeopardy to work under construction. This rule is applied to protect Labor Day. When a holiday falls during the normal work week, Monday through Friday, it shall be counted as eight(8)hours toward the forty(40)hour week;however,no ' reimbursement for this eight(8)hours is to be paid the workmen unless worked. An Employer working a four (4)day,ten (10)hour schedule may use Friday as a make up day when an observed holiday occurs during the work week. Employees have the option to work that make up day. If workmen are required to work the above ' enumerated holidays, or days observed as such, they shall receive double(2)the regular rate of pay for such work. I AWO14 026 HHoLdoc ANNUAL WAGE ORDER NO. 14 Page]of]Page 1 1 ` REPLACEMENT PAGE ' OUTSIDE ELECTRICIAN These rate s are to g be used for the following counties: • Adair,Audram,Boon e,Callaway,Camd en,Carter Charito n,Clar k,Cole Cooper,Crawfor d,Dent Franklin, , Gasconade,Howard,Howell,Iron,Jefferson,Knox,Lewis,Lincoln,Linn,Macon,Manes,Marion,Miller,Moniteau, Monroe,Montgomery,Morgan,Oregon,Osage,Peary,Phelps,Pike,Pulaski,Putnam,Rails,Randolph,Reynolds, , Ripley,St.Charles,St.Francois,St.Louis.City,St.Louis County,Ste.Genevieve,Schuyler,Scotland,Shannon,Shelby, Sullivan,Texas,Warren,and Washington COMMERCIAL WORK Occupational Title Basic Total Hourly Fringe ' Rate Benefits *Journeyrnan Lineman $32.38 $4.75+41.55% *Lineman Operator $27.96 $4.75+41.55% ' *Groundman $21.62 $4.75+41.55% OVERTIME RATE:Eight(8)hours shall constitute a work day between the hour;of 7:00 a.m.and 4:30 p.m.Forty (40)hours within five(5)days,Monday through Friday inclusive,shall constitute the work week.Work performed in the 9th and 10th hour,Monday through Friday,shall be paid at time and one-half(1'/z)the regular straight time rate of pay. Contractor has the option to pay two(2)hours per day at the time and one-half(1'/2)the regular straight time rate of pay 1 between the hours of 6:00 a.m.and 5:30 p.m.,Monday through Friday.Work performed outside the regularly scheduled working hours and on Saturdays,Sundays and recognized legal holidays,or days celebrated as such,shall be paid for at the rate of double(2)time. ' HOLIDAY RATE:All work performed on New Year's Day,Memorial Day,Fourth of July,Labor Day,Veteran's Day, • Thanksgiving Day,Christmas Day,or days celebrated as such,shall be paid at the double time rate of pay. When one of the foregoing holidays falls on Sunday,it shall be celebrated on the following Monday. ' UTILITY WORK Occupational Title Basic Total ' Hourly Fringe Rate Benefits , *Journeyrnan Lineman $32.38 $4.75+37.55% *Lineman Operator $27.96 $4.75+37.55% *Groundman $21.62 $4.75+37.55% OVERTIME RATE:Eight(8)hours shall constitute a work day between the hours of 7:00 a.m.and 4:30 p.m.Forty ' (40)hours within five(5)days,Monday through Friday inclusive,shall constitute the work week.Work performed in the 9th and 10th hour,Monday through Friday,shall be paid at time and one-half(1'/2)the regular straight time rate of pay. Contractor has the option to pay two(2)hours per day at the time and one-half(1'/2)the regular straight time rate of pay between the hours of 6:00 am.and 5:30 p.m.,Monday through Friday. Worked performed in the first eight(8)hours on , Saturday shall be paid at the rate of one and eight tenths(1.8)the regular straight time rate. Work performed outside these hours and on Sundays and recognized legal holidays,or days celebrated as such,shall be paid for at the rate of double(2)time. HOLIDAY RATE:All work performed on New Year's Day,Memorial Day,Fourth of July,Labor Day,Veteran's Day, , Thanksgiving Day,Christmas Day,or days celebrated as such,shall be paid at the double time rate of pay. When one of • the foregoing holidays falls on Sunday,it shall be celebrated on the following Monday. ' *Annual Incremental Increase ANNUAL WAGE ORDER NO. 14 9/07 OUT MAW 14 o,a.doc AFFIDAVIT OF COMPLIANCE PUBLIC WORKS CONTRACTS LAW • I, the.undersigned, , of lawful age, first ' being duly sworn, state to the.best of.my information and belief as follows: That I am employed as - by _. 2. That was awarded a public works contract for Project No. 32095, Locust Street Improvements. ' 3. That I have read and am familiar with Section 290.290 RSMo (1994 as amended)an act relating to public works contracts, which impose certain requirements upon contractors and subcontractors engaged in a public -works construction project in the State of Missouri. ' 4. That has fully complied with the provisions and requirements of Section 290.290 RSMo (1994 as amended) • FURTHER AFFIANT SAYETH NAUGHT. AFFIANT Subscribed and sworn to before me this day of , 20 ' NOTARY PUBLIC ' My Commission Expires: ' STATE OF MISSOURI ) ss COUNTY OF ) 1 • EXCESSIVE UNEMPLOYMENT EXCEPTION CERTIFICATION • ' I, the undersigned, , of lawful age, first being duly sworn, state to the best of my information and belief as follows: ' 1 That I am employed as by 1 2. That was awarded a public . works contract for Project No. 32095, Locust Street Improvements. 1 3. . That I have read and am familiar with Section 290.290 RSMo (1994 as 1 amended)an act relating to public works contracts, which impose certain requirements upon contractors and subcontractors engaged in a public .' works construction project in the State of Missouri. 4. Although there is a period of excessive unemployment in the State of Missouri, which requires the employment of only Missouri laborers and laborers from non-restrictive states on public works projects or 1 improvements, an exception applies as to the hiring of since no Missouri ' laborers or laborers from non-restrictive states are available or capable of performing FURTHER AFFIANT SAYETH NAUGHT. 1 AFFIANT Subscribed and sworn to before me this day of , 20 1 NOTARY PUBLIC 1 My Commission Expires: APPROVED BY: Director of Community Development, City of Jefferson, MO 1 i 1 ' CITY OF JEFFERSON • CONSTRUCTION CONTRACT ' THIS CONTRACT, made and entered into this day of , 2008, by and between Stockman Construction Corp.hereinafter r rred to as"Contractor', ' and the City of Jefferson, Missouri, a municipal corporation of the State of Missouri, hereinafter referred to as "City". ' WITNESSETH: That Whereas, the Contractor has become the lowest responsible bidder for furnishing the supervision, labor, tools, equipment, materials and supplies and for constructing the following City improvements: ' Project No.:32095, Locust Street Improvements. ' NOW THEREFORE, the parties to this contract agree to the following: 1. Scope of Services. ' Contractor agrees to provide all labor, equipment, hardware and supplies to perform the work included in the project entitled"Locust Street Improvements"in accordance with the plans and specifications on file with the Department of Community ' Development. ' 2. Manner and time for Completion. • Contractor agrees with the City to furnish all supervision, labor, tools, equipment, materials and supplies necessary to perform said work at Contractor's own expense in ' accordance with the contract documents and any applicable City ordinances and state and federal laws, within 51 calendar days from the date Contractor is ordered to proceed,which order shall be issued by the Director of Community Development within ' ten (10) days after the date of this contract. 3. Prevailing Wages. ' To the extent that the work performed by Contractor is subject to prevailing wage law, Contractor shall pay a wage of no less than the "prevailing hourly rate of wages" for work of a similar character in this locality, as established by Department of Labor and Industrial Relations of the State of Missouri, and as established by the Federal Employment Standards of the Department of Labor. Contractor acknowledges that t Contractor knows the prevailing hourly rate of wages forthis project because Contractor has obtained the prevailing hourly rate of wages from the contents of the current Annual Wage Order No. 14, Section 026, Cole County rates as set forth. The ' Contractor further agrees that Contractor will keep an accurate record showing the names and occupations of all workmen employed in connection with the work to be performed under the terms of this contract. The record shall show the actual wages ' paid to the workmen in connection with the work to be performed under the terms of this contract. A copy of the record shall be delivered to the Purchasing Agent of the • Jefferson City Finance Department each week. In accordance with Section 290.250 ' RSMo, Contractor shall forfeit to the City Ten Dollars ($10.00) for each workman employed, for each calendar day or portion thereof that the workman is paid less than 1 1 i ' the stipulated rates for any work done under this contract, by the Contractor or any • subcontractor under the Contractor. ' 4. Insurance. Contractor shall procure and maintain at its own expense during the life of this contract: ' (a) Workmen's Compensation Insurance for'all of its employees to be engaged in work under this contract. ' (b) Contractor's Public Liability Insurance in an amount not less than $2,000,000 for all claims arising out of a single occurrence and $300,000 for any one ' person in a single accident or occurrence, except for those claims governed by the provisions of the Missouri Workmen's Compensation Law, Chapter 287, RSMo., and Contractor's Property Damage Insurance in an amount not less than $2,000,000 for all ' claims arising out of a single accident or occurrence and $300,000 for any one person in a single accident or occurrence. ' (c) Automobile Liability Insurance in an amount not less than$2,000,000 for all claims arising out of a single accident or occurrence and $300,000 for any one person in a single accident or occurrence. ' (d) Owner's Protective Liability Insurance -.The Contractor shall also obtain at its own expense and deliver to the City an Owner's Protective Liability Insurance Policy naming the City of Jefferson as the insured, in an amount not less than $2,000,000 for all claims arising out of a single accident or occurrence and $500,000 for any one person in a single accident or occurrence,except forthose claims governed by-the provisions of the Missouri Workmen's Compensation Law, Chapter 287, RSMo. No policy will be accepted which excludes liability for damage to underground structures or by reason of blasting, explosion or collapse. ' (e) Subcontracts-In case any or all of this work is sublet,the Contractor shall require the Subcontractor to procure and maintain all insurance required in ' Subparagraphs (a), (b), and (c) hereof and in like amounts. (f) Scope of Insurance and Special Hazard. The insurance required under ' Sub-paragraphs(b)and (c)hereof shall provide adequate protection for the Contractor and its subcontractors, respectively, against damage claims which may arise from operations under this contract,,whether such operations be by the insured or by anyone directly or indirectly employed by it, and also against any special hazards which may be encountered in the performance of this contract. ' NOTE: Paragraph(f)is construed to require the procurement of Contractor's protective insurance (or contingent public liability and contingent property damage policies) by a ' general contractor whose subcontractor has employees working on the project, unless the general public liability and property damage policy(or rider attached thereto)of the general contractor provides adequate protection against claims arising from operations by anyone directly or indirectly employed by the Contractor. 1 5. Contractor's Responsibility for Subcontractors. • It is further agreed that Contractor shall be as fully responsible to the City for the acts and omissions of its subcontractors, and of persons either directly or indirectly ' employed by them, as Contractor is for the acts and omissions of persons it directly employs. . Contractor shall cause appropriate provisions to be inserted . in all subcontracts relating to this work, to bind all subcontractors to Contractor by all the ' terms herein set forth, insofar as applicable to the work of subcontractors and to give Contractor the same power regarding termination of any subcontract as'the City may exercise over Contractor under any provisions of this contract. Nothing contained in this contract shall create any contractual relations between any subcontractor and the City or between any subcontractors. 6. Liquidated Damages. The City may deduct Five Hundred Dollars($500.00)from any amount otherwise due under this contract for every day the Contractor fails or refuses to prosecute the work, or any separable part thereof, with such diligence as will insure the completion by the time above specified, or any extension thereof, or fails to complete the work by such ' time, as long as the City does not terminate the right of Contractor to proceed. It is further provided that Contractor shall not be charged with liquidated damages because of delays in the completion of the work due to unforeseeable causes beyond ' Contractor's control and without fault or negligence on Contractor's part or the part of its agents. 7. Termination. The City reserves the right to terminate this contract by giving at least five(5)days prior written notice to Contractor,without prejudice to any other rights or remedies of the City should Contractor be adjudged a bankrupt, or if Contractor should make a general assignment for the benefit of its creditors, or if a receiver should be appointed for Contractor or for any of its property, or if Contractor should persistently or repeatedly ' refuse or fail to supply enough properly skilled workmen or proper material, or if Contractor should refuse or fail to make prompt payment to any person supplying labor or materials for the work under the contract, or persistently disregard instructions of the ' City or fail to observe or perform any provisions of the contract. ' 8. Cm's Right to Proceed. In the event this contract is terminated pursuant to Paragraph 7,then the City may take over the work and prosecute the same to completion, by contract or otherwise, and ' Contractor and its sureties shall be liable to the City for any costs over the amount of this contract thereby occasioned by the City. In any such case the City may take possession of, and utilize in completing the work, such materials, appliances and ' structures as may be on the work site and are necessary for completion of the work. The foregoing provisions are in addition to, and not in limitation of, the rights of the City under any other provisions of the contract, city ordinances, and state and federal laws. ' 9. Indemnity. • To the fullest extent permitted by law, the Contractor will indemnify and hold harmless ' the City, its elected and appointed officials, employees, and agents from and against any and all claims,damages, losses,and expenses including attorneys'fees arising out 1 ' of or resulting from the performance of the work, provided that any such claim,damage, • loss or expense (1) is attributable to bodily injury, sickness,::disease, or death, or to injuryto ordestruction of tangible property(other than the Work itself)including the loss ' of use resulting therefrom and (2) is caused in whole or in part by any negligent act or omission of contractor,any subcontractor,anyone directly or indirectly employed by any ' of them or anyone for whose acts any of them may be liable, regardless of whether or not it is caused in part by a party indemnified hereunder. Such obligation shall not be construed to negate, abridge, or otherwise reduce any other right or obligation of indemnity which would otherwise exist as to any party or person described in this Paragraph. . ' 10. Payment for Labor and Materials. The Contractor agrees and binds itself to pay for all labor done,and for all the materials used in the construction of the work to be completed pursuant to this contract. ' Contractor shall furnish to the City a bond to insure the payment of all materials and labor used in the performance of this contract. ' 11. . Supplies. The Contractor is hereby authorized and- directed to utilize the City's sales tax exemption in the purchase of goods and materials for the project as set out in Section ' 144.062 RSMo 1994 as amended. Contractor shall keep and maintain records and invoices of all such purchases which shall-be submitted to the City. ' 12. Payment. • The City hereby agrees to pay the Contractor for the work done pursuant to this contract according to the payment schedule set forth in the Contract Documents upon acceptance of said work by the Director of Community Development and in accordance with the rates and/or amounts stated in the bid of Contractor dated May 6, 2008 which are by reference made a part hereof. No partial payment to the Contractor shall ' operate as approval or acceptance of work done or materials furnished hereunder. The total amount of this contract shall not exceed One Hundred Seventy Three Thousand Five Hundred Seventy Eight Dollars and Zero Cents ($173,578.00). ' 13. - Performance and Materialman's Bonds Required. Contractor shall provide a bond to the City before work is commenced, and no later ' than ten (10) days after the execution of this contract, guaranteeing the Contractor's performance of the work bid for, the payment of amounts due to all suppliers of labor and materials, the payment of insurance premiums for workers compensation ' insurance and all other insurance called for under this contract, and the payment of the prevailing wage rate to all workmen as required by this contract, said bond to.be in a form approved by the City, and to be given by such company or companies as may be ' acceptable to the City in its sole and absolute discretion. The amount of the bond shall be equal to the Contractor's bid. ' 14. Knowledge of Local Conditions. - • Contractor hereby warrants that it has examined the location of the proposed work and the attached specifications and has fully considered such local conditions in making its ' bid herein. 1 • 15. Severability. ' If any section, subsection, sentence,or clause of this Contract shall be adjudged illegal, invalid, or unenforceable, such illegality, invalidity, or unenforceability shall not affect the legality, validity, or enforceability of the contract as a whole, or of any section, ' subsection, sentence, clause, or attachment not so adjudged. 16. Governing Law. The contract shall be governed by the laws of the State of Missouri. The courts of the State of Missouri shall have jurisdiction over any dispute which arises under this ' contract, and each of the parties shall submit and hereby consents.to such courts exercise of jurisdiction. In any successful action by the City to enforce this contract,the City shall be entitled to recover its attorney's fees and expenses incurred in such action. 17. Contract Documents. The contract documents shall consist of the following: ' a. This Contract f. General Provisions b. Addenda g. � Special Provisions c. Information for Bidders h. Technical Specifications ' d. Notice to Bidders I. Drawing and/or Sketches e. Signed Copy of Bid ' This contract and the other documents enumerated in this paragraph,form the Contract • between the parties. These documents are as fully a part of the contract as if attached hereto or repeated herein. ' 18. Complete Understanding, Merger. Parties agree that this document including those documents described in the section ' entitled "Contract Documents"represent the full and complete understanding of the parties. This contact includes only those goods and services specifically set out. This contract supersedes all prior contracts and understandings between the Contractor and the City. 19. Authorship and Enforcement. ' Parties agree that the production of this document was the joint effort of both parties and that the contract should not be construed as having been drafted by either party. In the event that either party shall seek to enforce the terms of this contract through ' litigation, the prevailing party in such action shall be entitled to receive, in addition to any other relief, its reasonable attorneys fees, expenses and costs. 20. Amendments. This contract may not be modified,changed or altered by any oral promise or statement ' by whomsoever made; nor shall any modification of it be.binding upon the City until such written modification shall have been approved in writing by an authorized officer • of the City. Contractor acknowledges that the City may not be responsible for paying for changes or modifications that were not properly authorized. 21. Waiver of Breech • Failure to Exercise Rights and Waiver: Failure to insist upon strict compliance with any of the terms covenants or conditions herein shall not be deemed a waiver of any such terms, covenants or conditions, nor shall any failure at one or more times be deemed a waiver or relinquishment at any other,time or times by any right under the terms, covenants or conditions herein. 22. Assignment. Neither party may sell or assign its rights or responsibilities under the terms of this agreement without the express consent of the remaining party. 23. Nondiscrimination. Contractor agrees in the performance of this contract not to discriminate on the ground or because of race, creed, color, national origin or ancestry, sex, religion, handicap, age, or political opinion or affiliation, against any employee of Contractor or applicant for employment and shall include a similar provision in all subcontracts let or awarded hereunder. ' 24. Notices. All notices required to be in writing may be given by first class mail addressed to City of Jefferson, Department of Community Development, 320 East McCarty, Jefferson City, Missouri, 65101, and Contractor at 2021 Idlewood Road, Jefferson City, Missouri 65109 . The date of delivery of any notice shall be the second full day after ' the day of its mailing. - • i IN WIT SS WHEREOF,the parties hereto have set their hands and seals this • .day of , 2008. JEFFERSON CITY OF JEFFN CONTRACTOR i - - yor Title: s•. ' ATTEST: ATTEST: City CleK Title: Secre ry • APPROVED AS TO FORM: i City Counselor • • IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies).must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract.between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. • CORD 25(2001108) stTrued Choke- ' Naught-Naught Agency "° '"_' 1 Insurance • Bonds ' 5/20/2008 City of Jefferson 320 E. McCarty Street Jefferson City, MO 65101 RE: Performance and Payment Bond# S278282— Project No. 32095, Locust Street ' Improvements - Open Bid Date To Whom It May Concern: Please use this letter as your authority to date the bonds & power of attorney the same ' date as the contract. Upon signing of the contract, please advise us of the contract date, or forward us a copy of the dated and signed contract. Thank you for your assistance and please call if you have any questions. ' Sincerely, era Huesgen Attorney-In-Fact Naught-Naught Insurance Agency ' 1441 Christy Dr. • Jefferson City,MO 65101 ' Jefferson City• Carrollton•Columbia•Eldon• Osage Beach• Owensville• Fulton•Concordia Ph: 573-634-2727 0 Marshall•Grain Valley•Springfield• Versailles• Boonville• Ozark Fax:866-779-8102 u•u�4•.naught-naught.ctmt IMPORTANT If the certificate holder is an ADDITIONAL INSURED, the policy(ies) must be endorsed. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). If SUBROGATION IS WAIVED, subject to the terms and conditions of the policy, certain policies may require an endorsement. A statement on this certificate does not confer rights to the certificate holder in lieu of such endorsement(s). DISCLAIMER The Certificate of Insurance on the reverse side of this form does not constitute a contract between the issuing insurer(s), authorized representative or producer, and the certificate holder, nor does it affirmatively or negatively amend, extend or alter the coverage afforded by the policies listed thereon. • ACORD 25(2001108) OP ID TH DATE(MM/DD/YYYY) ACORD CERTIFICATE OF LIABILITY INSURANCE STOCK04 1 05/20/08 jPRODUCER THIS CERTIFICATE IS ISSUED AS A MATTER OF INFORMATION aught-Naught / Jefferson City ONLY AND CONFERS NO RIGHTS UPON THE CERTIFICATE 441 Christy Drive HOLDER.THIS CERTIFICATE DOES NOT AMEND,EXTEND OR 0 Box 1768 ALTER THE COVERAGE AFFORDED BY THE POLICIES BELOW. e rson City MO 65102 : 573-634-2727 Fax:866-779-8102 INSURERS AFFORDING COVERAGE NAIC# SURED INSURER A: Cincinnati Insurance Company INSURER B: Stockman Construction INSURER C: 2021 Idlewood Drive INSURER D: Jefferson City MO 65109 INSURER E: COVERAGES THE POLICIES OF INSURANCE LISTED BELOW HAVE BEEN-ISSUED TO THE INSURED NAMED ABOVE FOR THE POLICY PERIOD INDICATED.NOTWITHSTANDING ANY REQUIREMENT,TERM OR CONDITION OF ANY CONTRACT OR OTHER DOCUMENT WITH RESPECT TO WHICH THIS CERTIFICATE MAY BE ISSUED OR MAY PERTAIN,THE INSURANCE AFFORDED BY THE POLICIES DESCRIBED HEREIN IS SUBJECT TO ALL THE TERMS,EXCLUSIONS AND CONDITIONS OF SUCH POLICIES.AGGREGATE LIMITS SHOWN MAY HAVE BEEN REDUCED BY PAID CLAIMS. TR NSR TYPE OF INSURANCE POLICY NUMBER POLICY ATE MWDD/YY PDATE MM/DD/YY LIMITS GENERAL LIABILITY EACH OCCURRENCE $ 1,0 0,000 A X COMMERCIAL GENERAL LIABILITY CPP0832388 03/31/08 03/31/09 PREMISES(Ea occureence) $ 100,000 CLAIMS MADE rX] OCCUR MED EXP(Any one person) $ 10,000 PERSONAL&ADV INJURY $ 1,000,000 GENERAL AGGREGATE $ 2,000,000 GENT AGGREGATE LIMIT APPLIES PER: PRODUCTS-COMP/OP AGG s2,000,000 J( POLICYE1J`ER Cj LOC AUTOMOBILE LIABILITY COMBINED SINGLE LIMIT $ 1,000,000 A X ANY AUTO CPA0832388 03/31/08 03/31/09 (Ea accident) ALL OWNED AUTOS BODILY INJURY SCHEDULED AUTOS (Per person) $ HIRED AUTOS BODILY INJURY NON-OWNED AUTOS (Per accident) $ PROPERTY DAMAGE $ (Per accident) GARAGE LIABILITY AUTO ONLY-EA ACCIDENT $ ANY AUTO OTHER THAN EA ACC $ AUTO ONLY: AGG $ EXCESS/UMBRELLA LIABILITY EACH OCCURRENCE $ 5,000,000 A X OCCUR � CLAIMSMADE CPP0832388 03/31/08 03/31/09 AGGREGATE $ E DEDUCTIBLE $ X RETENTION $O $ WORKERS COMPENSATION AND TORY LIMITS X ER A EMPLOYERS'LIABILITY WC2111585 03/31/08 03/31/09 E.L.EACH ACCIDENT $ 1,000,000 ANY PROPRIETOR/PARTNER/EXECUTIVE OFFICER/MEMBER EXCLUDED? E.L.DISEASE-EA EMPLOYEE $ 1,000,000 Des.describe under SPECIAL PROVISIONS below E.L.DISEASE-POLICY LIMIT $ 1 000 000 OTHER A Equipment Floater CPPOS32388 03/31/08 03/31/09 Leased or $50,000 Rented E ESCRIPTION OF OPERATIONS/LOCATIONS I VEHICLES/EXCLUSIONS ADDED BY ENDORSEMENT I SPECIAL PROVISIONS CERTIFICATE HOLDER CANCELLATION CITYJEI SHOULD ANY OF THE ABOVE DESCRIBED POLICIES BE CANCELLED BEFORE THE EXPIRATION DATE THEREOF,THE ISSUING INSURER WILL ENDEAVOR TO MAIL 10 DAYS WRITTEN . NOTICE TO THE CERTIFICATE HOLDER NAMED TO THE LEFT,BUT FAILURE TO DO SO SHALL City of Jefferson IMPOSE NO OBLIGATION OR LIABILITY OF ANY KIND UPON THE INSURER,ITS AGENTS OR 320 E. McCarty REPRESENTATIVES. Jefferson City MO 65101 REPRESENTATI CORD 25(2001/08) ©ACORD CORPORATION 1988 Bond# S278282 ' PERFORMANCE. PAYMENT AND GUARANTEE BOND • ' KNOW ALL MEN BY THESE PRESENTS, that we, the undersigned Stockman Construction Corp. , 2021 Idlewood Rd. , Jefferson City, MO 1 hereinafter, referred to as "Contractor" and ' Employers Mutual Casualty Company ' a Corporation organized under the laws of the State of Iowa and authorized to transact business in the State of ' Missouri as Surety, are held and firmly bound unto the City of Jefferson hereinafter referred to as"Owner" One Hundred Seventy Three Thousand Five Hundred in the penal Sum of Seventy Eight Dollars and Zero Cents ---------- DOLLARS ' ($ 173,578.00 ), lawful money of the United.States of America for the payment of which sum, well and truly to be made; we bind ourselves and our heirs, • executors, administrators, successors, and assigns, jointly and severally by these 1 presents. Project No. 32095, Locust Street Improvements t THE CONDITION OF THE FOREGOING OBLIGATION IS SUCH THAT; II ' WHEREAS, the above bounded Contractor has on the day of ,20 ,entered into a written contract with the aforesaid Owner ' forfumishing all materials,equipment,tools,superintendence, labor,and otherfacilities and accessories, for the construction of certain improvements as designated, defined ' and described in the said Contract and the Conditions thereof, and in accordance with the specifications and plans therefore; a copy of said Contract being attached hereto ' and made a part hereof: ' NOW THEREFORE, if the said Contractor shall and will, in all particulars,well,duly and • faithfully observe, perform and abide by each and every covenant, condition, and part tof the said Contract, and the Conditions, Specifications, Plans, Prevailing Wage Law 1 1 ' and other Contract Documents thereto attached or, by reference, made a part thereof, • according to the true intent and meaning in each case, and if said contractor shall ' replace all defective parts, material and workmanship for a period of one year after acceptance by the Owner, then this obligation shall be and become null and void; ' otherwise it shall remain in full force and effect. ' PROVIDED FURTHER, that if the said Contractor fails to duly pay for any labor, materials, sustenances, provisions, provender, gasoline, lubricating oils, fuel oils, greases, coal repairs, equipment and tools consumed or used in said work, groceries and foodstuffs, and all insurance premiums, compensation liability, and otherwise, or ' any other supplies or materials used or consumed by such Contractor or his, their, or its subcontractors in performance of the work contracted to be done,the Surety will pay ' the same in any amount not exceeding the amount of this Obligation, together with interest as provided by law: 1 ' PROVIDED FURTHER,that the said Surety, for value received, hereby stipulates and • agrees that no change, extension of time, alteration, or addition to the terms of the ' contract, or the work to be performed thereunder, or the specifications accompanying the same, shall in any wise affect its obligation on this bond and it does hereby waive notice of any change, extension of time, alteration, or addition to the terms of the contract, or to the work, or to the specifications: ' PROVIDED FURTHER,that if the said Contractor fails to pay the prevailing hourly rate of wages, as shown in the attached schedule, to any workman engaged in the ' construction of the improvements as designated, defined and described in the said ' contract, specifications and conditions thereof, the Surety will pay the deficiency and any penalty provided for by law which the contractor incurs by reason of an act or ' omission, in any amount not exceeding the amount of this obligation together with interest as provided by law: • 1 1 ' IN TESTIMONY WHEREOF, the said Contractor has hereunto set his hand, and the • said Surety has caused these presents to be executed in its name, and its corporate ' seal to be hereunto affixed, by it attorney-in-fact duly authorized thereunto so to do, at ' Jefferson City on this the .day of , 20 ' Employers Mutual Casualty Company Stockman Construction Corp. SURETY COMPANY CONTRACTOR BY Tera Huesgen, Attorney-InISEAL) BY _ 1C /- ;§Urks (SEAL) ' Fact .5mee74Ery ' B (SEAL) BY �✓GL', (SEAL) Attorney-in-fact (State Representative) ' (Accompany this bond with Attorney-in-fact's authority from the Surety Company certified to include the date of the bond.) 1 • 1 ' THE FACE OF DOCUMENT HAS COLORED BACKGROUND ON PAPER BACK OF DOCUMENT HAS A SIMULATED • •AT • • /EMCInsurance Companies No. P.O Box 712•Des Moines, IA 50306-0712 . 933 ' CERTIFICATE:OF AUTHORITY INDIVIDUAL ATTORNEY-IN-FACT APW ALL MEN BY THESE PRESENTS,that: mployers;Mutual Casualty Company;an Iowa Corporation 5. Dakota Fire Insurance Company;a North:Dakota Corporation 2 EMCASCO Insurance Company,an Iowa Corporation 6. EMC Property,8 Casualty Company,an Iowa Corporation 3 Union Insurance;Company afProvidence,an Iowa Corporation 7, Hamilton Mutualinsurance Company,an Iowa;Gorporation 4:' Illinois EMCASCO Insurance:Coi party,an Iowa Corporation s. ' herefnafterreferred to severally as"Company"and collectively as"Companies",each does,by these presents,make constitute and appoint: THOMAS S.;NAUGHT;HARRY NAUGHT,.TERESA STEPHENSON, SARAH NAUGHT-BARG'FREDE WILMA KEISER,TIMOTHY P. EASTIN, RICHARD NAUGHT, STEVE NAUGHT, BETH NATIONS, NATALIE LURVEY TERA HUESGEN, tNDIVI'DUALLY,JEFFERSON CITY, MISSOURI .... its true and lawful attomey-in fact with full power and authority conferred to sign,seal,and execute its lawfut bon ds,undertakings,and other obligatory instruments:of a similar nature as follows.- ' ANY AND ALL BONDS and to bind each Company thereby as f4yyand to theaame extent as if such instruments were signed by the duly authorized officers of each such Company;and:all of.. the acts of said attorney pursuant to the author ityhereby given are hereby ratified and confirmed. ' The authority hereby granted shall exp APRIL x o� unless sooner revoked RI u ,z nn„n � AUTHORITY FOR POWER OF.ATTORNEY ' -This Power of Attorney is made and executed pursuant to and by the authority of the following resolution of.the Boards of Directors of each of the Companies at a regularly scheduled meeting of each company duly called and held in 1999: RES.&YB6:16 President and Chief Executive Officer,any:Vice President,the Treasurer and the Secretary.of Employers Mutual Casualty Company shall have power ' and'authori y to (1) appoint attorneys in fact and authorize them to execute on behalf of each Company and attach the seal of the:Company thereto, bonds and underfakiilgs,recogn¢ances contracts of indemnity and other writings obligatory in the nature thereof,and(2)to remove any such attomey in-fact at any time_and revoke the power and authority giver.totiim or..her.Attorneys In-fact shall have power and authority,subject to the`terms and limitations of tie power-&=attorney issued to them, to execute and deliver.,on behalf of:the Company and:ao attach the seal of the Company thereto, bonds and undertakings recognrzances contracts of indemnity:and other writings obligatory.in the nature thereof,and any such•instrument executed by any such attomey-in-fact shaft be fully and in all respects binding upon the Company. ification as to the validity of any power of-attomey."authorized herein made by an officer of Employers:.Mutual Casualty.Company shall be fully and in all respects rig upon this Cpmpariy..The facslmileor mechanically reproduced signature of such officer, whether made:Heretofore or:hereafter, wherever appearing upon a ified copy of any power�of=attorney of.the Company,shall be valid and binding upon the Company with the same force and affect.as though.manually affixed.: ' IN WITNESS WHEREOF,the Companies Piave caused these presents:to be signed for each by their officers as.shown;::and the Corporate:seals to be hereto affixed this 8TIt- day 2008 , Seals ' Bruce G.Kelley, hairman J 'ey S Birdsley Sip INS4gg2, Q,t�N�H Co.:pFA �Y:g,cqs of Companies 2,3,4,5 8 ;President Assistant Secretary _:��. OpFUBgi',�'`�• =yJ 4°PP�R41 9 ,o p°PP�A4t y of Company a 1;Vice Chairman and o SEAL 83 CEO of Copany? 2 - n * rOWp.�` • iowP 4 ip ��NS,°eaN�FO Q�,�suegy�s �q �TUQi c9 On this day of— AD 2001 before me a -HV . p,PUNq O y ' PPOBq s� Notary u is in and for the STa o owa personally appeared.Bruce G Kelley and Jeffrey S. °;. '� �° .� _ Birdsley,who,being by me duly.sworn did.say that they are, and are known to:me. to be the SEAL g SFAI z SEAL Chairman, President, Vice Chairman and CEO and/or Assistant Secretary, respectively,of :,• y o t :of each of The Companies above that the seals affixetl to this instrument are the seals ofaaid iwl Iowa �Pq/H DA- o� ♦i rL/DINES�O�P; corporations; that said instrument,was signed and sealed on behalf of each? of the Companies by authority of their respective Boards of Directors; and that the said Bruce G.Kelley and USUAL/N Jeffrey S.Birdsley, as such officers, acknowledge the,execution of said instrument to be`the uruq voluntary act and deed of each of th.a Companies �o v� My Commission Expires September 30 2009., RUTAKRUMINS' o � a commission Number 176255 oFS�sURA \ Q " My Conim.Exp.Sept.30,2009 Notary Public in'and.forthe Iowa::. MO NES, ry State of CERTIFICATE ' I,David L.Hixenbaugh:`ice President'of:the Companies,do hereby certify that the foregoing resolution of the Boards`of Directors byeach of the panies and this Powerof Attorney issued pursuant thereto on F€l�RI�ARY 1 r� �A®S half of Thomas and Nati ht Harr�r Naucght Teresa Stephenson, Sarah Naught Bargfrede,Wilma Keiser;Timothy P Eastin , Richard ' e true and correct an: are still�n fall fore and a ecl'. N4u ht, StevVe Naugqht,Beth Nations;Natalie Lurvey Tera Huesgen In Testimony Whereof I have subscribed my name anal amxed the facsimile seal of each Company this day ot.: ' Vice-President Power.Form7832(10-07SCD) "For verification of the authenticity of the ' GENERAL PROVISIONS • FORWARD The following Articles GP-1 through GP-48 are"General Provisions of the Contract",modified as set forth ' in the Special Provisions. GP-1 CONTRACT DOCUMENTS ' It is expressly understood and agreed that the Contract Documents comprise the Notice to Bidders, Instruction to Bidders,General Provisions,Special Provisions,Bid,Contract,Performance and One Year Guarantee Bond, Specifications, other documents listed in the Table of Contents and bound in this Volume. Plans,all Addenda thereto issued prior to the time of opening bids for the work,all of which are hereto attached,and other drawings,specifications,and engineering data which may be furnished by the Contractor and approved by the Owner,together with such additional drawings which may be furnished by the Engineer from time to time as are necessary to make clear and to define in greater detail the intent of the specifications and drawings, are each and all component parts to the agreement governing the work to be done and the materials equipment to be furnished. All of these documents are hereby defined as the Contract Documents. ' The several parts of the Contract Documents are complementary,and what is called for by any one shall be as binding as if called for by all. The intention of the Documents is to include the furnishing of all materials,labor,tools,equipment and supplies necessary for constructing complete and ready to use the ' work specified. Materials or work described in words which so applied have a well known technical or trade meaning shall be held to refer to such recognized standards. The Contract shall be executed in the State and County where the Owner is located. Three (3) copies ' of the contract documents shall be prepared by the Contractor, each containing an exact copy of the Contractor's bid as submitted,the Performance Bond properly executed,a Statutory Bond where required, and the contract agreement signed by both parties thereto. These executed contract documents shall be filed as follows: One (1)with the City Clerk of the City of Jefferson One (1)with the Jefferson City Director of Community Development One (1)with the Contractor ' GP-2 DEFINITIONS ' Wherever any work or expression defined in this article, or pronoun used in its stead, occurs in these contract documents, it shall have and is mutually understood to have the meaning herein given: 1. "Contract"or"Contract Documents"shall include all of the documents enumerated in the previous article. 2. "Owner "City", or words "Party of the First Part", shall mean the party entering into contract to secure performance of the work covered by this Contract and his or its duly authorized officers or agents. Generally this will be the"City of Jefferson". 3. "Contractor"or the words"Party of the Second Part"shall mean the party entering into contract for the performance of the work covered by this contract and his duly authorized agents or legal t representatives. 4. "Subcontractors"shall mean and refer to a corporation, partnership,or individual having a direct ' contract with the Contractor,for performing work at the job site. 5. "Engineer"shall mean the authorized representative of the Director of Community Development, 1 (i.e., the Engineering Division Director); 1 6. "Construction Representative"shall mean the engineering or technical assistant duly authorized , by the Engineer limited to the particular duties entrusted to him or them as subsequently set forth • herein. ' 7 Date of of Contract" or words equivalent thereto shall mean the date upon which the successful bidder's proposal is accepted by the City. 8. "Day"or"days", unless herein otherwise expressly defined, shall mean a calendar day or days , of twenty-four hours each. 9. "The work" shall mean the work to be done and the equipment, supplies and materials to be ' furnished under this contract, unless some other meaning is indicated by the context. 10. "Plans"or"drawings"shall mean and include all drawings which may have been prepared by the ' Engineer as a basis for proposals, all drawings submitted by the successful bidder with his proposal and by the Contractor to the City, if and when approved by the Engineer, and all drawings submitted by the City to the Contractor during the progress of the work,as provided for herein. , 11. Whenever in these contract documents the words"as directed","as required","as permitted","as allowed", or words or phrases of like import are used, it shall be understood that the direction, , requirement, permission, or allowance of the City and Engineer is intended. 12. Similarly the words"approved","reasonable","suitable","acceptable","properly","satisfactory", or words of like effect and import, unless otherwise particularly specified herein, shall mean t approved,reasonable,suitable,acceptable,proper or satisfactory in the judgment of the Cityand Engineer. 13. Whenever any statement is made in these Contract Documents containing the expression"it is , understood and agreed"or any expression of the like import,such expression means the mutual • understanding and agreement of the Contractor and the City. 14. "Missouri Highway Specifications" shall mean the latest edition of the "Missouri Standard ' Specifications for Highway Construction"prepared by the Missouri Highway and Transportation Commission and published before the date of this contract. ' 15. "Consultant" shall mean the firm, company, individual, or its/his/her duly authorized representative(s) under separate agreement with the City of Jefferson that prepared the plans, specifications, and other such documents for the work covered by this contract. ' GP-3 THE CONTRACTOR It is understood and agreed that the Contractor, has by careful examination satisfied himself as to the nature and location of the work,the conformation of the ground,the character,quality and quantity of the materials to be encountered, the character of the equipment and facilities needed preliminary to and during the prosecution of the work, the general local conditions, and all other matters which can in any ' way affect the work under this Contract. No verbal agreement or conversation with any officer, agent or employee of the City,either before or after the execution of this contract,shall affect or modify any of the terms or obligations herein contained. The relation of the Contractor to the City shall be that of an independent contractor. GP-4 THE ENGINEER ' The Engineer shall be the City's representative during the construction period and he shall observe the • work in process on behalf of the City by a series of periodic visits to the job site. He shall have authority to act on behalf of the City. 1 ' The Engineer assumes no direction of employees of the Contractor or subcontractors and no supervision • of the construction activities or responsibility for their safety. The Engineer's sole responsibility during construction is to the City to endeavor to protect defects and deficiencies in the work. ' Any plan or method of work suggested by the Engineer, or other representative of the City, to the Contractor,but not specified or required,if adopted or followed by the Contractor in whole or in part,shall ' be used at the risk and responsibility of the Contractor; and the Engineer and the City will assume no responsibility therefore. GP-5 BOND ' Coincident with the execution of the Contract, the Contractor shall furnish a good and sufficient surety bond in the full amount of the contract sum. This surety bond, executed by the Contractor to the City, ' shall be a guarantee: (a) for the faithful performance and completion of the work in strict accordance with the terms and intent of the contract documents; (b) the payment of all bills and obligations arising from this contract which might in any manner become a claim against the City; (c) for the payment to the City of all sums due or which may become due by the terms of the contract, as well as by reason of any '. violation thereof by the Contractor; and fora period of one year from and immediately following the acceptance of the completed project by the City,the payment to the City of all damage loss and expense which may occur to the City by reason of defective materials used,or by reason of defective or improper ' workmanship done, in the furnishing of materials, labor, and equipment in the performance of the said contract. All provisions of the bond shall be complete and in full accordance with statutory requirements. The bond ' . shall be executed with the property sureties through a company licensed and,qualified to operate in the state and approved by the City. Bond shall be signed by an agent resident in the state and date of bond shall be the date of execution of the contract. If at any time during the continuance of.the contract the surety on the Contractor's bond becomes Sirresponsible,the City shall have the right to require additional and sufficient sureties which the Contractor shall furnish to the satisfaction of the City within ten(10)days after notice to do so. In default thereof,the contract may be suspended, all payments or money due the Contractor withheld, and the contract completed as hereinafter provided. GP-6 INSURANCE ' GP-6.1- GENERAL: The Contractor shall secure, pay for and maintain during the life of the Contract, insurance of such types 1 and amounts as necessary to protect himself, and the City, against all hazards enumerated herein. All policies shall be in the amounts,form and companies satisfactory to the City. The insuring company shall deliver to the City certificates of all insurance required, signed by an authorized representative and stating that all provisions of the following specified requirements are complied with. ' All certificates of insurance required herein shall state that ten(10)days written notice will be given to the City before the policy is canceled or changed. All certifications of insurance shall be delivered to the City ' prior to the time that any operations under this contract are started. All of said Contractor's certificates of insurance shall be written in an insurance company authorized to do business in the State of Missouri. ' GP-6.2 BODILY INJURY LIABILITY& PROPERTY DAMAGE LIABILITY INSURANCE •_ (1) Bodily Injury Liability insurance coverage providing limits for bodily injuries,including death,of not less 1 than$2,000,000 per person and $300,000 per occurrence. 1 (2) Property Damage Liability insurance coverage for limits of not less than $2,000,000 per one occurrence nor less than $2,000,000 aggregate.to limit for the policy year. • GP-6.3 CONTRACTOR'S PROTECTIVE BODILY INJURY LIABILITY & PROTECTIVE PROPERTY ' DAMAGE LIABILITY INSURANCE: (COVERING OPERATIONS OF SUBCONTRACTORS) (1) Contractors contingent policy providing limits of at least $300,000 per person and $2,000,000 per ' occurrence for bodily injury or death. (2) Property Damage Liability providing limits of at least $2,000,000 per occurrence and $2,000,000 aggregate. , GP-6.4 CONTRACTUAL LIABILITY Property Damage coverage with $2,000,000 aggregate limit. ' GP-6.5 OWNER'S PROTECTIVE LIABILITY AND PROPERTY DAMAGE INSURANCE , The Contractor shall purchase and maintain Owner's Protective Liability and Property Damage insurance issued in the name of the Owner and the Engineer as will protect both against any and all claims that might arise as a result of the operations of the Contractor or his subcontractors in fulfilling this contract. ' The minimum amount of such insurance shall be the same as required for Bodily Injury Liability and Property Damage Liability Insurance. This policy shall be filed with the Owner and a copy filed with the ' Engineer. GP-6.6 EXCLUSIONS The above requirements GP-6.2,6.3,6.5 for property damage liability shall contain no exclusion relative , to: • (1) Blasting or explosion. (Consult Technical Specifications Part I, for possible deletion of this , requirement on subject project.) (2) Injury or destruction of property below the surface of the ground, such as wires, conduits, pipes, ' mains, sewers, etc., caused by the Contractor's operations. (3) The collapse of,or structural injury to,any building or structure on or adjacent to the City's premises, or injury to or destruction of property resulting therefrom, caused by the removal of other buildings, structures, or supports, or by excavations below the surface of the ground. GP-6.7 AUTOMOBILE BODILY INJURY LIABILITY & AUTOMOBILE PROPERTY DAMAGE , LIABILITY INSURANCE Contractor shall carry in his name, additional assured clauses protecting City, Liability Insurance with Bodily Injury or Death Limits of not less than$300,000 per person and$2,000,000 per occurrence, and ' property damage limits of not less than $300,000 with hired car and non-owned vehicle coverage or separate policy carrying similar limits. The above is to cover the use of automobiles and trucks on and off the site of the project. ' GP-6.8 EMPLOYER'S LIABILITY AND WORKMEN'S COMPENSATION Employer's and Workmen's Compensation Insurance as will protect him against any and all claims ' resulting from injuries to and death of workmen engaged in work under this contract, and in addition the • Contractor shall carry occupational disease coverage with statutory limits, and Employer's Liability with a limit of$300,000 per person. The"All State"endorsement shall be included. In case any class of employees is not protected under the Workmen's Compensation Statute, the Contractor shall provide and cause such contractor to provide adequate employer's liability coverage as ' will protect him against any claims resulting from injuries to and death of workmen engaged in work under this contract. GP-6.9 INSTALLATION FLOATER INSURANCE ' This insurance shall insure and protect the Contractor and the City from all insurable risks of physical loss or damage to materials and equipment, not otherwise covered under Builder's Risk Insurance, when in warehouses or storage areas, during installation, during testing and until the work is accepted. It shall be of the"All Risks"type,with coverage designed for the circumstances which may occur in the particular work included in this contract. The coverage shall be for an amount not less than the value of the work at completion,less the value-of the material and equipment insured under Builder's Risk.lnsurance. The value shall include the aggregate value of the City-furnished equipment and materials to be erected or installed by the Contractor not otherwise insured under Builder's Risk Insurance. Installation Floater Insurance shall also provide for losses, if any,to be adjusted with and made payable ' to the Contractor and the City as their interests may appear. If the aggregate value of the City-furnished and Contractor-furnished equipment is less than$10,000 such equipment may be covered under Builder's Risk Insurance, and if so covered, this Installation Floater ' Insurance may be omitted. GP-6.10 CONTRACTOR'S RESPONSIBILITY FOR OTHER LOSSES For the considerations in this agreement heretofore stated, in addition to Contractor's other obligations, the Contractor assumes full responsibility for all loss or damage from any cause whatsoever to any tools owned by the mechanics, any tool machinery, equipment, or motor vehicles owned or rented by the ' Contractor's, his agents, sub-contractors, material men or his or their employees; to sheds or other • temporary structures, scaffolding and staging, protective fences, bridges and sidewalk hooks. The .Contractor shall also assume responsibility for all loss or damage caused by,arising out of or incident to ' larceny,theft, or any cause whatsoever(except as hereinbefore provided)to the structure on which the work of this contract and any modifications, alterations, enlargements thereto, is to be done, and to materials and labor connected or to be used as a part of the permanent materials,and supplies necessary to the work. GP-6.11 CONTRACTOR'S RESPONSIBILITY ON DAMAGES&CLAIMS INDEMNIFYING CITY ' The Contractor shall indemnify and save harmless the City and Engineer and their officers and agents, of and from all losses,damages,costs,expenses,judgments,or decrees whatever arising out of action or suit that may be brought against the City or Engineer or any officer or agent of either of them,for or on account of the failure,omission,or neglect of the Contractor to do and perform any of the covenants,acts, ' matters,or things by this contract undertaken to be done or performed,or for the injury,death or damage caused by the negligence or alleged negligence of the Contractor or his subcontractors or his or their agents, or in connection with any claim or claims based on the lawful demands of subcontractors, ' workmen,material men,or suppliers of machineryand parts thereof,equipment,power tools and supplies incurred in the fulfillment of this contract. GP-6.12 NOTIFICATION IN EVENT OF LIABILITY OR DAMAGE Upon the occurrence of any event, the liability for which is herein assumed, the Contractor agrees to forthwith notify the City, in writing such happening,which notice shall forthwith give the details as to the ' happening,the cause as far as can be ascertained, the estimate of loss or damage done, the names of witnesses, if any, and stating the amount of any claim. • 1 1 - GP-7 ASSIGNMENT OF CONTRACT ' The Contractor shall not assign or transfer this contract nor sublet it as a whole, without the written consent of the City and of the Surety on the Contractor's bond. Such consent of Surety, together with ' copy of assignment, shall be filed with the City. No assignment, transfer or subletting, even though consented to, shall relieve the Contractor of his liabilities under this contract. Should any assignee fail to perform the work undertaken by him in a satisfactory manner, the City may at his option annul and ' terminate Assignee's contract. GP-8 SUBCONTRACTS, PRINCIPAL MATERIALS & EQUIPMENT Prior to the award of the contract, the Contractor shall submit for approval of the City a list of subcontractors and the sources of the principal items of materials and equipment which he proposes to use in the construction of the project. The Contractor agrees that he is as fully responsible to the City for the acts and omissions of his subcontractors and of person either directly or indirectly employed by them as he is for the acts and ' omissions or persons directly employed by him. Any notices to the Contractor shall be considered as notice to any affected subcontractors. Nothing contained in the Contract Documents shall create any contractual relation between any ' subcontractor and the City. No officer, agent or employee of the City, including the Engineer, shall have any power or authority whatsoever to bind the City or incur any obligation in its behalf to any subcontractor, material supplier or , other person in any manner whatsoever. GP-9 OTHER CONTRACTS ' The City reserves the right to let other contracts in connection with this work. The Contractor shall afford • other contractors reasonable opportunity for the introduction and storage of their materials and the execution of their work, and shall properly connect and coordinate his work with theirs. , If any part of the Contractor's work depends for proper execution or results on the work of any other contractor,the Contractor shall inspect and promptly report to the Engineer any defect in such work that ' renders it unsuitable for such proper execution and results. His failure so to inspect and report all constitute an acceptance of the other contractor's work as fit and proper for the reception of his work,except as to defects which may develop in the other contractor's work ' after the execution of his work. Wherever work being done by the City's forces or by other contractors is contiguous to work covered by , this Contract,the respective rights of the various interests involved shall be established by the Engineer, in order to secure the completion of the various portions of the work in general harmony. GP-10 LEGAL RESTRICTIONS, PERMITS AND REGULATIONS ' The Contractor shall procure at his own expense all necessary licenses and permits of a temporary nature and shall give due and adequate notice to those in control of all properties which may be affected by his , operations. Rights-of-way and easements for permanent structures or permanent changes in existing facilities shall be provided by the City unless otherwise specified. The Contractor shall give all notices and comply with all laws, ordinances, rules and regulations bearing on the conduct of the work as drawn or specified. ' GP-11 ROYALTIES AND PATENTS • It is agreed that all royalties for patents or patent claims, infringement whether such patents are for processes or devices, that might be involved in the construction or use of the work, shall be included in ' the contract amount and the Contractor shall satisfy all demands that may be made at any time for such oil and shall be liable for any damages or claims for patent infringements,and the Contractor shall at his own expense, defend any and all suits or proceedings that may be instituted at any time against the City for infringement or alleged infringement of any patent or patents involved in the work,.and in case of an award of damages,the said Contractor shall pay such award;final payment to the Contractor by the City will not be made while any such suits or claims remain unsettled. ' GP-12 SCOPE AND INTENT OF SPECIFICATIONS AND PLANS ' GP-12.1 GENERAL These Specifications and.Project Plans are intended to supplement, but not necessarily duplicate each other, and together constitute one complete set of Specifications and Plans so that any work exhibited in the one and not in the other, shall be executed just as if it has been set forth in both, in order that the ' work shall be completed according to the complete design of the Engineer. Should anything be omitted from the Specifications and Plans which is necessaryto a clear understanding ' of the work,or should it appear various instructions are in conflict,then the Contractor shall secure written instructions from the Engineer before proceeding with the construction affected by such omissions or discrepancies. It is understood and agreed that the work shall be performed and completed according ' to the true spirit, meaning and intent of the contract, specifications and plans. GP-12.2 FIGURED DIMENSIONS TO GOVERN ' Dimensions and elevations shown on the plans shall be accurately followed even though they differ from scaled measurements. No work shown on the plans,the dimensions of which are not-indicated shall be executed until the required dimensions have been obtained from the Engineer. 1 GP-12.3 CONTRACTOR TO CHECK PLANS AND SCHEDULES • The Contractor shall check all dimensions,elevations and quantities shown on the plans,and schedules ' given to him by the Engineer,and shall notify the Engineer of any discrepancy between the plans and the conditions on the ground,or any error or omission in plans,or in the layout as given by stakes, points,or instructions,which he may discover in the course of the work. The Contractor will not be allowed to take ' advantage of any error or omission in the plans or contract documents,as full instructions will be furnished by the Engineer should such error or omission be discovered, and the Contractor shall carry out such instructions as if originally specified. ' The apparent silence of the Plans and Specifications as to any detail or the apparent omission from them of a detailed description concerning any point, shall be regarded as meaning that only the best general practices, as accepted by the particular trades or industries involved, shall be used. ' GP-12.4 STANDARD SPECIFICATIONS Reference to standard specifications of any technical society,organization or association,or to codes of ' local or state authorities, shall mean the latest standard, code, specification, or tentative specification adopted and published at the date of taking bids, unless specifically stated otherwise. GP-13 CONSTRUCTION REPRESENTATIVE AT PROJECT ' The City may appoint or employ such "Construction Representative" as the City may deem proper, to observe the work performed under this Contract, to the end that said work is performed, in substantial ' accordance with the plans and specifications therefor. • The Project Representative assumes no direction of employees of the Contractor or Subcontractors and ' no supervision of the construction activities or responsibility for their safety. The sold duty of the Project Representative during the construction is to the City to endeavor to protect against defects and deficiencies in the work. The Contractor shall regard and obey the directions and instructions of the Construction Representative ' so appointed, when the same are consistent with the obligations of this contract and the specifications • therefor, provided, however, that should the Contractor object to any order given by the Construction Representative, the Contractor may make written appeal to the Engineer for his decision. ' The Construction Representative and other properly authorized representatives of the City shall be free at all times to perform their duties, an intimidation or attempted intimidation of any one of them by the Contractor or by any of his employees shall be sufficient reason, if the City so decides, to annul the contract. Such construction representation shall not relieve the Contractor from any obligation to perform said work , strictly in accordance with the plans and specifications or any modifications thereof as herein provided, and work not so constructed shall be removed and made good by the Contractor at his own expense,and free of all expense to the City, whenever so ordered by the Engineer,without reference to any previous , oversight in observation of work. Any defective material or workmanship may be rejected by the Engineer at any time before the final acceptance of the work, even though the same may have been previously overlooked and estimated for payment. The Construction Representative shall have no authority to permit any deviation from the plans and , specifications except on written order from the Engineer,and the Contractor will be liable for any deviation except on such written order. ' All condemned work shall be promptly taken out and replaced by satisfactory work,and all condemned materials shall be promptly removed from the vicinity of the work. Should the Contractor fail or refuse to comply with instructions in this respect the City may,upon certification by the Engineer,withhold payment ' or proceed to terminate contracts as herein provided. Reexamination of questioned work may be ordered by the Engineer,and if so ordered the work must be uncovered by the Contractor. If such work be done in accordance with the Contract Documents,the City ' shall pay the cost of reexamination and replacement. If such work be found not in accordance with the • Contract Documents,the Contractor shall pay such cost,unless he shall show that defect in the work was caused by another contractor of the City and in that event the City shall pay such cost. , The Contractor shall furnish samples of testing purposes of any material required by the Engineer, and shall furnish any information required concerning the nature or source of any material which he proposes to use. ' GP-14 LINES AND GRADES The Department of Community Development will set construction stakes establishing lines,scopes,and , continuous profile grade in road work, and center-line and bench marks for culvert work, and appurtenances as may be deemed necessary, and will furnish the Contractor, with all necessary ' information relating to lines, slopes, and grades, to lay out the work correctly. The Contractor shall maintain these lines, grades, and bench marks and use them to lay out the work he is to perform under this contract. The Contractor shall notify the Department of Community Development not less than 48 hours before ' stakes are required. No claims shall be made because of delays if the contractors fail to give such notice. The Contractor shall carefully preserve stakes and bench marks. If such stakes and bench mark become ' damaged,lost,displaced,or removed by the Contractor,they shall be reset at his expense and deducted from the payment for the work. Any work done without being properly located and established by base lines,offset stakes,bench marks, , or other basic reference points checked bythe Construction Representative may be ordered removed and replaced at the Contractor's expense. • 1 ' GP-15 CONTRACTOR'S RESPONSIBILITY FOR MATERIALS • The Contractor shall be responsible for the condition of all materials furnished by him, and he shall ' replace at his own cost and expense any and all such material found to be defective in design or manufacture,or which has been damaged after delivery. This includes the furnishing of all materials and labor required for replacement of any installed materials which is found to be defective at any time prior to the expiration of one year from the date of final payment. ' The manufacturer of pipe for use on this project shall certify in writing to the City that all materials furnished for use in this project do conform to these specifications. Whenever standard tests are conducted, he shall forward a copy of the test results to the City. ' GP-16 WATER All water required for and in connection with the work to be performed shall be provided by the Contractor. ' at his sole cost and-expense. "GP-17 POWER All power for lighting, operation of the Contractor's plant or equipment or for any other use by the Contractor, shall be provided by the Contractor at his sole cost and expense. ' GP-18 SUPERINTENDENCE AND WORKMANSHIP The Contractor shall keep on his work, during its progress, a competent superintendent and any necessary assistants. The superintendent shall represent the Contractor in his absence and all directions given to him shall be as binding as if given to the Contractor. The Contractor shall provide proper tools and equipment and the services of all workmen, mechanics, tradesmen,and other employees necessary in the construction and execution of the work contemplated ' and outlined.herein. The employees of the Contractor shall be competent and willing to perform satisfactorily the work required of them. Any employee who is disorderly, intemperate or incompetent • or who neglects or refuses to perform his work in a satisfactorily manner, shall be promptly discharged. It is called particularly to the Contractor's attention that only first class workmanship will be acceptable. ' GP-19 MAINTENANCE OF TRAFFIC Whenever any street is closed,the Police Department, Fire Department, and Ambulance Services shall be notified prior to the closing. When a portion of the project is closed to through traffic, the Contractor shall provide.proper barricades and shall mark a detour route around the section of the project if applicable. The route of all detours shall be approved by the Director of Community Development. All ' detour signing shall conform to the latest edition of the"Manual on Uniform Traffic Control Devices". Throughout the.project,wherever homes are served directly from a street or portion of a street which is to be reconstructed under this project,the Contractor shall make every effort to provide access to each home every night. This work shall be subsidiary to the construction and no direct payment will be made for it. GP-20 BARRICADES AND LIGHTS ' All streets,roads, highways,and other public thoroughfares which are closed to traffic shall be protected by means of effective barricades on which shall be placed acceptable warning signs. Barricades shall be located at the nearest intersecting public highway or street on each side of the blocked section. All open trenches and other excavations shall be provided with suitable barriers, signs, and lights to the extent that adequate protection is provided to the public. Obstructions, such as material piles and equipment, shall be provided with similar warning signs and lights. All barricades and obstructions shall be illuminated b means of warning lights at night. All lights used Ile Y 9 9 9 9 for this purpose shall be kept burning from sunset to sunrise. Materials stored upon or alongside public ' streets and highways shall be so placed,and the work at all times shall be so conducted,as to cause the minimum obstruction and inconvenience to the traveling public.. All barricades, signs, lights and other protective devices shall be installed and maintained in conformity , with applicable statutory requirements, and in conformance with the Manual of Uniform Traffic Control ' Devices. All necessary barricades, signs, lights and other protective devices will be furnished, installed and maintained by the Contractor. This work shall be subsidiary to the construction and no direct payment will be made for it. GP-21 EXISTING UNDERGROUND INSTALLATIONS AND STRUCTURES Pipe lines and other existing underground installations and structures in the vicinity of the work to be done hereunder are indicated on the plans according to the best information available to the City. The City , does not guarantee the accuracy of such information. The Contractor shall make every effort to locate all underground pipe lines, conduits and structures by contacting owners of underground utilities and by prospecting in advance of the excavation. Any delays to the Contractor caused by pipe lines or other underground structures or obstructions not , shown by the plans, or found in locations different than those indicated, shall not constitute a claim.for extra work, additional payment or damages. No payment will be made to the Contractor for locating and protecting utilities and cooperating with their owners,and any damages caused to the utilities by the Contractor's negligence shall be repaired entirely at the Contractor's expense. , Utilities, other than sanitary sewers and water mains, which, in the opinion of the Engineer, must be moved will be moved by the utility company at no cost to the Contractor. Sanitary sewers which must be ' moved shall be re-laid by the Contractor and paid for at the prices bid. Only sewers which must be moved because of direct conflict with the storm sewer conduit will be paid for in this manner. Sewers damaged by excavation but not in direct conflict with the storm sewer will be repaired at the Contractor's expense. GP-22 PROTECTION OF WORK AND PROPERTY , The Contractor shall be accountable for any damages resulting from his operations. He shall be fully • responsible for the protection of all persons including members of the public,employees of the City and employees of other contractors or subcontractors and all public and private property including structures, sewers and utilities above and below ground, along, beneath, above, across or near the site or sites of the work, or other persons or property which are in any manner affected by the prosecution of the work. , The Contractor shall furnish and maintain all necessary safety equipment such as barriers,signs,warning lights and guards as required to provide adequate protection or persons and property. The Contractor shall give reasonable notice to the owner or owners of public or private property and ' utilities when such property is liable to injury or damage through the performance of the work, and shall make all necessary arrangements with such owner or owners relative to the removal and replacement or protection of such property or utilities. , In an emergency affecting the safety of life or of the work or of adjoining property,the Contractor,without special instruction or authorization,is hereby permitted to act at his discretion to prevent such threatened , loss or injury,and he shall so act. Any compensation,claimed by the Contractor on account of emergency work,shall be determined by agreement or arbitration. The Contractor agrees to hold the City harmless from any and all loss or damages arising out of , jurisdictional labor disputes or other labor troubles of any kind that may occur during the construction or performance of this contract. GP-23 GUARANTEE OF MATERIALS AND WORKMANSHIP ' The Contractor hereby guarantees the work in connection with this contract against faulty materials or • poor workmanship during the period of one (1)year after the date of completion of the contract. , GP-24 NO WAIVER OF RIGHTS • Neither observation of work by the City or any of their officials, employees, or agents, nor any order by ' the City for payment of money, or any payment for, or acceptance of, the whole or any part of the work by the City, nor any extension of time, nor any possession taken by the City or its employees, shall operate as a waiver of any provision of this contract, or of any power herein reserved to the City, or any right to damages herein provided, nor shall any waiver of any breach in this contract be held to be a waiver of any other or subsequent breach. GP-25 USE OF COMPLETED PORTIONS If desired by the City,portions of the work may be placed in service when completed or partially completed and the Contractor shall give proper access to the work for this purpose;but such use and operation shall ' not constitute an acceptance of the work, and the Contractor shall be liable for defects due to faulty construction until the entire work under this Contract is finally accepted and for the guarantee period thereafter. 1 GP-26 ADDITIONAL, OMITTED, OR CHANGED WORK The Owner,without invalidating the Contract,may order additional work to be done in connection with the ' Contract or may alter or deduct from the work,the Contract sum.to be adjusted accordingly. All such work shall be executed to the same standards of workmanship and performance as though therein included. The Engineer shall have authority to-make minor changes in the work, not involving cost, and.not. ' inconsistent with the purposes of the work. Except for adjustments of estimated quantities for unit price work or materials to conform to actual pay quantities therefor as may be provided for in the Special Conditions, all changes and alterations in the ' terms or scope of the Contract shall be made under the authority of duly executed change orders issued • and signed by the Owner and accepted and signed by the Contractor. All work increasing the cost shall be done as authorized by the Owner and ordered in writing by the Engineer,which order shall state the ' location,character,amount,and method of compensation. No additional or changed work shall be made unless in pursuance of such written order by the Engineer, and no claim for an addition to the Contract sum shall be valid unless so ordered. If the modification or alteration increases the amount of work to be done,and the added work or any part thereof is of a type and character which can be properly and fairly classified under one or more unit price items of the Proposal, then such added work or part thereof shall be paid for according to the amount ' actually done and at the applicable unit price or prices therefor. Otherwise,.such work shall be paid for as "Extra Work"as hereinafter provided in this Article GP-26. If the modification or alteration decreases the amount of work to be done, such decrease shall not constitute the basis for a claim for damages or anticipated profits on work affected by such decrease. Where the value of omitted work is not covered by applicable unit prices, the Engineer shall determine on an equitable basis the amount of: ' 1. Credit due the Owner for Contract work not done as a result of an authorized change. 2. Allowance to the Contractor for any actual loss incurred in connection with the purchase,delivery and subsequent disposal of materials or equipment required for use on the work planned and which could not be used in any part of the work as actually built. ' 3. Any other adjustment of the Contract amount where the method to be used in making such adjustments is not clearly defined in the contract documents. • Statements for extra work shall be rendered by the Contractor not later than fifteen (15) days after the ' completion of each assignment of extra work and if found correct will be approved by the Engineer and submitted for payment with the next regular monthly estimate. The Owner reserves the right to contract with any person or firm other than the Contractor for any or all ' extra work. The Contractor's attention is especially called to the fact that he shall be entitled to no claim • for damages or anticipated profits on any portion of the work that may be omitted. Extra Work: (a) The term "Extra Work" shall be understood to mean and include all work that may be required to , accomplish any change or alteration in or addition to the work shown by the Plans or reasonably implied by the Specifications and not covered by the Contract proposal items and which is not otherwise provided under this Article GP-26. - (b) The Contractor shall perform all extra work under the direction of the Engineer when authorized by the Owner. The compensation to be paid the Contractor for performing extra work shall be determined by one or more of the following methods: , 1. Method A: By agreed unit price 2. Method B: By agreed lump sum , 3. Method C: If neither Method A or B can be agreed upon before the work is started,then the work shall be by force account as per Section 109, Measurement and Payment, of the Missouri ' Standard Specification for Highway Construction,as published by the Missouri State Highwayand Transportation Commission. GP-27 SUSPENSION OF WORK , The Owner may at any time suspend the work, or any part thereof by giving ten.(10) days notice to the Contractor in writing. The work shall be resumed by the Contractor within ten (10) days after the date , fixed in the written notice from the Owner to the Contractor to do so. • But if the work, or any part thereof, shall be stopped by the notice in writing aforesaid, and if the Owner does not give notice in writing to the Contractor to resume within a reasonable period of time, then the ' Contractor may abandon that portion of the work so suspended and he will be entitled to the estimates and payments for all work done on the portions abandoned, if any. GP-28 OWNER'S RIGHT TO DO WORK ' If the Contractor should neglect to prosecute the work properly or fail to perform any provision of this contract, the Owner, after ten (10) days written notice to the Contractor, may, without prejudice to any , other remedy he may have, make good such deficiencies and may deduct the cost thereof from the payment then or thereafter due the Contractor. GP-29 OWNER'S RIGHT TO TERMINATE CONTRACT , If the Contractor should be adjudged a bankrupt, or if he should make a general assignment for the benefit of his creditors,or if a receiver should be appointed on account of his insolvency,or if he should persistently or repeatedly refuse or should fail, except in cases for which extension of time is provided, to supply enough properly skilled workmen or proper materials, or if he should fail to make prompt payment to subcontractors or for material or labor, or persistently disregard laws, ordinances or the , instructions of the Engineer, or otherwise be guilty of a substantial violation of any provision of the Contract, then the Owner may, without prejudice to any other right or remedy and after giving the Contractor five(5)days written notice,terminate the employment of the Contractor and take possession of the premises and of all materials, tools, and appliances thereon and finish the work by whatever method he may deem expedient. In such case, no further payment will be made the Contractor until the work is finished. If the unpaid • balance of the contract price shall exceed the expense of finishing the work, including compensation for additional managerial and administrative services,such expenses shall be paid to the Contractor. If such expense shall exceed such unpaid balance, the Contractor shall pay the difference to the Owner. s, GP-30 CONTRACTOR'S RIGHT TO STOP WORK OR TERMINATE CONTRACT • If the work should be stopped under an order of any court, or other public authority,for a period of three months,through no act or fault of the Contractor or of anyone employed by him,then the Contractor may, upon five(5)days written notice to the Owner and the Engineer,stop work or terminate his contract and recover from the Owner payment for all work executed and any loss sustained upon any plant or materials ' and reasonable profit and damages. GP-31 LOSSES FROM NATURAL CAUSES ' All loss or damage arising out of the nature of the work to be done,of from the action of the elements, or from floods or overflows,or from ground water,or from any unusual obstruction of difficulty,or any other natural or existing circumstances either known or unforeseen, which may be encountered in the ' prosecution of the said work,shall be sustained and borne bythe Contractor at his own cost and expense. GP-32 SUNDAY, HOLIDAY AND NIGHT WORK ' No work shall be done between the hours of 6:00 p.m.and 7:00 a.m., nor on Sundays or legal holidays, without the written approval of the City. However, work necessary in case of emergencies or for the protection of equipment or finished work may be done without the City's approval. ' Night work may be established by the Contractor as a regular procedure with the written permission of the City; such permission however, may be revoked at any time by the City if the Contractor fails to maintain adequate equipment and supervision for the proper prosecution and control of the work at night. ' GP-33 UNFAVORABLE CONSTRUCTION CONDITIONS ' During unfavorable weather, wet ground, or other suitable construction conditions, the Contractor shall • confine his operations to work which will not be affected adversely thereby. No portion of the work shall be constructed under conditions which would affect adversely the quality or efficiency thereof, unless special means or precautions are taken bythe Contractor to perform the work in a proper and satisfactory ' manner. GP-34 MATERIALS AND EQUIPMENT ' Unless specifically provided otherwise in each case,all materials and equipment furnished for permanent installation in the work shall be new,unused,and undamaged when installed or otherwise incorporation in the work. No such material or equipment shall be used by the Contractor for any purpose other than ' that intended or specified, unless such use is specifically authorized by the Engineer in each case. GP-35 DEFENSE OF SUITS ' In case any action at law or suit in equity is brought against the City or any officer or agent of them for or on account of the failure,omission,or neglect of the Contractor to do and perform any of the covenants, acts, matters,or things by this contract undertaken to be done or performed,or for the injury or damage ' caused by the negligence or alleged negligence of the Contractor or his subcontractors or his or their agents, or in connection with any claim or claims based on the lawful demands of subcontractors, workmen, material men, or suppliers of machinery and parts thereof, equipment, power tools, and supplies incurred in the fulfillment of this contract,the Contractor shall indemnify and save harmless the City and their officers and agents, of and from all losses, damages, costs, expenses, judgments, or decrees whatever arising out of such action or suit that may be brought as aforesaid. ' GP-36 CHANGE ORDER Any changes or additions to the scope of work shall be through a written order from the Engineer to the • Contractor directing such changes in the work as made necessary or desirable by unforeseen conditions ' or events discovered or occurring during the progress of the work. GP-37 CONTRACT TIME t The time for the completion of the work is specified and it is an essential part of the contract. The • Contractor will not be entitled to any extension of contract time because of unsuitable weather condition ' unless suspension of the work for such conditions was authorized in writing by the Engineer. If the time for the completion of the work is based upon working days, this time will be specified in the , contract. A working day is defined as any day when, in the judgment of the Engineer, soil and weather conditions are such as would permit any then major operation of the project for six (6) hours or over unless other unavoidable conditions prevent the Contractor's operation. If conditions are such as to stop ' work in less than six (6) hours,the day will not be counted as a working day. No working days will be counted from December 15 to March 15, both dates inclusive. Saturdays, Sundays, and City holidays will not be counted as working days any time during the year. , GP-38 CONTRACT TIME EXTENSION The Engineer may make allowance for time lost due to causes which he deems justification for extension , of contract time. If the Contractor claims an extension of contract time on the grounds that he is unable to work due to causes beyond his control, he shall state his reasons in writing,furnish proof to establish his claim and state the approximate number of days he estimates he will be delayed. Notice of intention ' to claim an extension of contract time on the above grounds shall be filed with the Engineer at the time the cause or causes occur and the claim shall be filed in writing within 30 days after the claimed cause for the delay has ceased to exist. , GP-39 LIQUIDATED DAMAGES Time is an essential element of the contract and it is therefore important that the work be pressed ' vigorously to completion. Should the Contractor or in case of default the surety fail to complete the work • within the time specified in the contract, or within such extra time as may be allowed in the manner set out in the preceding sections, a deduction of an amount as set out in the contract will be made for each day and every calendar day that such contract remains uncompleted after the time allowed for the completion. The said amount set out in the proposal is hereby agreed upon, not as a penalty but as liquidated damages for loss to the City and the public, after the expiration of the time stipulated in the contract,and will be deducted from any money due the Contractor under the contract,and the Contractor , and his surety shall be liable for any and all liquidated damages. Permitting the Contractor to continue and finish the work or any part of it after the expiration of the specified time,or after any extension of the time, shall in no way operate as a waiver on the part of the City or any of its rights under the contract. GP-40 MEASUREMENT AND PAYMENT ' (a) BASIS FOR PAYMENT , Contractor will be paid for quantities actually constructed or performed as determined by field measurement (except as may be hereinafter provided) at the unit price bid for the items listed in the schedule of the Bid or for such extra work as may be authorized and approved by the Engineer. The cost , of incidental work not listed in the schedule of the Bid but necessary for the completion of the project shall be included in bid items. (b) DEDUCTIONS FOR UNCORRECTED WORK , If the Engineer deems it expedient not to correct work that has been damaged or that was not done in accordance with the Contract,an equitable deduction from the Contract price shall be made therefore. ' (c) LUMP SUM ITEMS • Payment for each lump sum item shall be at the lump sum bid for-,the item,complete in place, and shall ' include the costs of all labor, materials,tools, and equipment to construct the item as described herein and to the limits shown on the plans. 9 ' (d) PARTIAL PAYMENT Partial payment will be made on a monthly basis. The payment shall be based on the work that has been found generally acceptable under the contract by the Engineer or inspector. A retainer equal to 10%of the amount of work completed to date shall be withheld. ' (e) ACCEPTANCE AND FINAL PAYMENT Upon receipt of written notice that the work is ready for final inspection and acceptance,the Engineer will promptly make such inspection, and when he finds the work acceptable under the Contract and the Contract fully performed he will promptly issue a final certificate, over his own signature, stating that the work required by this contract has been completed and is acceptable by him under the terms and conditions thereof, and the entire balance found to be due the Contractor, including the retained ' percentage, shall be paid to the Contractor by the City of Jefferson within thirty(30) days after the date of said final certificate. (f) AFFIDAVIT OF COMPLIANCE ' Monies due to the Contractor will not be delivered to the Contractor without presentation to the Department of Community Development an Affidavit of Compliance with Prevailing Wage Law on ' prescribed form attached to the back of these contract documents. GP-41 RELEASE OF LIABILITY The acceptance by the Contractor of the last payment shall operate as.and shall be a release to the Owner and every officer and agent thereof,from all claims and liability to the Contractor for anything done or furnished for, or relating to the work, or for any act or neglect of the Owner or of any person relating ' to or affecting the work. GP-42 CERTIFICATIONS ' GP-42.1 All suppliers of materials such as drainage pipe or handrail and all suppliers of asphaltic concrete or portland cement concrete mixtures shall certify in writing that the product as supplied conforms fully with these specifications. Such certification shall be delivered in triplicate to the Department of Community Development at least 24 hours before the product is to be used on the project. GP-42.2 The City, at its option, may perform or have performed such tests as may be deemed necessary to further assure that only specified materials are incorporated into the work. GP-43 LOCAL PREFERENCE In making purchases or in letting contracts for the performance of any job or service,the purchasing agent shall give preference to all firms,corporations or individuals which maintain offices or places of business within the corporate limits of the City of Jefferson, when the.quality of the commodity or performance ' promised is equal or better and the price quoted is the same or less. GP-44 PREFERENCE FOR U.S. MANUFACTURED GOODS ' On purchases in excess of$5,000,the City shall select products manufactured,assembled or produced in the United States, if quantity,quality,and price are equal. Every contract for public works construction or maintenance in excess of$5,000 shall contain a provision requesting the contractor to use American products in the performance of the contract. GP-45 AWARD OF CONTRACT- REJECTION OF BIDS All bidders are required to submit with bid Minority Business Enterprise Eligibility Forms for all subcontractors and suppliers who the contractor intends to use on the project. Compliance with this 1 requirement and the Minority Business Enterprise Program shall be a consideration for award of this 1 contract. • The contract will be awarded to the lowest and best responsible bidder on the base bid proposal, ' complying with the conditions of the Advertisement for bids and Specifications, providing the bid is P � P 9 reasonable and it is in the interest of the City of Jefferson, Missouri to accept same. The bidder to whom an award is made will be notified at the earliest possible date. The City of Jefferson, however, reserves ' the right to reject any and all bids and to waive all informalities in bids received whenever such rejection or waiver is in their interest. GP-46 AFFIDAVIT OF COMPLIANCE WITH PUBLIC WORKS' CONTRACTS LAW Upon completion of project and prior to final payment,each contractor and subcontractor hereunder shall file with the City of Jefferson, Missouri, Department of Community Development,an affidavit stating that ' the contractor or subcontractor has fully complied with the provisions and requirements of Section 290.290,RSMo(1994 as amended),an act relating to public works contracts. The City of Jefferson shall not issue a final payment until such affidavit is filed. ' GP-47 MISSOURI LABORER REQUIREMENT Whenever there is a period of excessive unemployment in Missouri, which is defined as any month , immediately following two consecutive calendar months during which the level of unemployment in the State has exceeded five percent(5%)as measured by the U.S. Bureau of Labor Statistics in its monthly publication of employment and unemployment figures, only Missouri laborers or laborers from non- restrictive states may be hired bythe contractor or subcontractors to work on this Public Works'contract. An exception shall exist when Missouri laborers or laborers from non-restrictive states are not available or are incapable or performing the particular type of work involved, if so certified by the contractor or subcontractor hereunder and approved by the Director of Community Development of the City of , Jefferson, Missouri. Nor does this provision apply to regularly employed non-resident executive, supervisory or technical personnel or projects where federal aid funds are being utilized in the act and this provision would conflict with any federal statute, rule or regulation. , Laborers from non-restrictive states means persons who are residents of a state which has not enacted state laws restricting Missouri laborers from working on public works projects in that state,as determined by the Missouri Labor and Industrial Relations Commission. A Missouri laborer means any person who , has resided in Missouri for at least thirty(30)days and intends to become or remain a Missouri resident. GP-48 LIABILITY FOR COMPLIANCE WITH PUBLIC WORKS CONTRACTS LAW AND MISSOURI LABORER REQUIREMENT , In the event a contractor or subcontractor hereunder files with the City of Jefferson an.affidavit stating that the contractor or subcontractor has fully complied with the provisions and requirements of Section 290.290, RSMo (1994 as amended), when in fact the contractor or subcontractor has not complied, to the extent that any liability is assessed against the City of Jefferson,Missouri,or any additional expenses are incurred by the City of Jefferson, Missouri, any contractor making the false statement, or whose subcontractor makes a false statement, shall hold harmless and indemnify the City for any liability assessed against it or any additional expenses incurred. Any contractor who fails to comply with the requirements of hiring only Missouri laborers or laborers from , non-restrictive states,absent statutory exceptions,whenever there is a period of excessive unemployment in Missouri,agrees to hold harmless and indemnifythe City of Jefferson,Missouri,for any liability that may be assessed against it or any additional expenses incurred by the City of Jefferson, Missouri, because of the contractor or subcontractor's failure to comply. • END OF GENERAL PROVISIONS ' SPECIAL PROVISIONS ' • FORWARD: The provisions of this section take precedence over any other provisions in these specifications. ' SP-1 - PARTIAL ACCEPTANCE OF BID The City reserves the right to accept any part or the entire bid for the project. SP-2 PRE-CONSTRUCTION CONFERENCE Prior to starting work, a pre-construction conference will be held to discuss the project, its ' scheduling and its coordination-with the work of others. It is expected that this conference will be attended by representatives of the Owner, the Engineer, the Contractor and his Subcontractors, and the Utilities, as well as representatives of any other affected agencies which the Owner may wish to invite. 1 The work schedule specified in Section IB-23 of the Information for Bidders will be ' submitted at the conference. SP-3 PREVAILING WAGE LAW Bidders are hereby advised that compliance with the Prevailing Wage Law, Section 290.210 through 290.340 inclusive of the Revised Statutes of Missouri, is a requirement of this contract. (Reference Section I13-20) Section 290.265 requires that a clearly legible statement of all prevailing hourly wage • rates should be kept posted in a prominent and easily accessible place at the site by ' each contractor and subcontractor engaged in public works projects, and that such notice shall remain posted during the full time. SP-4 PROOF OF INSURANCE All certificates of insurance provided for this project shall be insured directly from the company affording coverage. Certification from a local agent in not acceptable without the necessary paperwork-empowering and authorizing the agent to sign the surety's name. ' In addition, when an aggregate amount is included, a statement of the amount of that aggregate available to date shall also be attached. ' SP-5 TECHNICAL SPECIFICATIONS AND DETAILS The Technical Specifications for this project shall consist of the 2004 version of the Missouri Standard Specifications for Highway Construction except as modified or contradicted by the City's Contract, Technical Specifications, General Provisions, Sanitary sewer Specifications, Special Provisions, Detail Plans, and any special or ' specific Specifications as included in the contract documents. . All construction details included with the plans contained in the City of Jefferson Standard Drawings Revised Edition 9/2007 and attached hereto shall be used in constructing this project. ' The City's Technical Specifications for use on this project shall be the "CITY OF JEFFERSON TECHNICAL STREET SPECIFICATIONS, REVISED OCTOBER, 2000". ' These specifications can be found on the City's website at www.ieffcitymo.orQ and are available upon request from the Department of Community Development. SP-6 PROTECTION OF ADJACENT PROPERTIES ' Surface water shall be diverted and otherwise prevented from entering or damaging ' adjacent property as a result of precipitation during construction. SP-7 ACCESS TO ADJACENT PROPERTIES ' Prior to the removal of the driveways to any dwellings or buildings, the Contractor shall notify the inhabitants of such structures that the use of the driveways or access will be ' temporarily affected. Notice shall be of sufficient length to allow the persons affected to remove vehicles and other items that may be inaccessible during construction activities. The contractor shall provide for vehicular access to all adjacent properties at the end of ' each working day. Pedestrian access shall be maintained at all times. Suitable access shall be provided ' across trenches, ditches or other barriers and obstacles to pedestrian traffic. Appropriate devices shall be used to warn the public of the dangers that may be present. SP-8 UTILITIES t The Contractor shall expose all utility crossings to establish location and depths prior to • construction. The necessary adjustment of utility services such as water, gas, telephone, ' electric and sanitary sewer, including meters, valves, manholes and other appurtenances not otherwise specified in the plans shall be subsidiary to the work. SP-9 ROCK REMOVAL ' No explosives shall be used on this project. Rock shall be removed by mechanical , chipping,jack-hammering or other methods approved by the Engineer. SP-10 STREET CLOSURE, PROJECT PHASING, AND TRAFFIC CONTROL The contractor may close Locust Street during its reconstruction. He shall provide access ' to adjoining properties to the greatest extent practical. In closing a street the contractor shall meet the notification of closure specified in GP- 19 as well as notifying adjacent ' landowners and provide road closed signage as shown in these plans. Dunklin Street is to remain open to traffic for the duration of the project. The contractor shall follow the traffic control plan set forth in these plans and shall meet the requirements of the , MUTCD. On all streets open to traffic the contractor shall provide the necessary traffic control ' personnel, such as flagmen, and any signing, warning devices and signs necessary to maintain traffic flow. All work shall be in accordance with the Manual on Uniform Traffic • Control Devices. Signs, cones, and barricades shall be placed both to protect workers ' and equipment and to protect the public by marking open trenches and other potential • dangers. ' All Type III barricades shall have a minimum of two MoDOT Type C LED lights. ' SP-11 SEQUENCING AND EROSION CONTROL The contractor shall sequence the project in a manner acceptable to the engineer that will limit the potential of sediment being transported from the site. SP-12 CONSTRUCTION STAKING ' The construction staking for this project will be performed by the City of Jefferson. Any restaking required due to the destruction of the original stakes can be provided to the contractor at the City Standard hourly rate. The contractor shall provide two working days ' notice of any staking he wishes to have performed. SP-13 DETECTABLE WARNING PANELS ' The proposed panels shall be MASCO CASTinTACT warning panels as manufactured by Masons Supply Company, (503-234-4321), or Detectable Warning Plates as ' Manufactured by Neenah Foundry Company, (800-558-5075), or approved equal. The Contractor shall follow the manufactures recommendations for the installation of the, panels. The panels shall match the slope of the ramp and shall be placed such that no ' vertical displacement occurs between the panel and the surrounding concrete. The panels are to be Salem Red in color(CASTinTACT)or natural unpainted iron ' (Neenah), and may be any may be made up of 2'x2', 2'x2.5', or 2'x3' panels. SP-14 PROJECT COORDINATION ' While this project is being constructed, site work on the property to the west(Lincoln University)will also be occurring, including grading and parking lot construction. The ' contractor shall perform and coordinate his work in a manner which does not inhibit the work being perused on that site. The final grade of the slopes to the western side of the street shall be constructed so as to match the curb that will be constructed for the parking lots on the Lincoln University property. The contractor shall work with the University's contractor to establish these grades. ' Inlet A shown on the plans, as well as the pipe between inlets A and B, will be constructed by the University's contractor. If possible the City's contractor shall ' coordinate his work to allow the pipe going to inlet A to be installed and inlet B to be constructed in the normal fashion. If the timing of the project will not allow this, the contractor shall block out a section of the back wall of the inlet so that the pipe may be ' installed at a later time. • There is a potable water valve and metering vault located near station 14+15. This vault will be moved by the University's contractor. The City's contractor shall ensure.that his schedule is communicated so that the movement of this vault does not interfere with the construction schedule. • SP-15 TOPSOIL IN AREAS TO BE SEEDED ' The top six(6) inches of all areas of the project to be vegetated shall be free of rocks, , stones and clods prior to seeding. This may require the contractor to utilize a mechanical rock rake, hand picking of stones, and/or placement of six(6) inches of clean topsoil in those areas to be vegetated. No direct payment will be made for this requirement. All areas to be vegetated shall be inspected prior to seeding, and any deficiency shall be corrected prior to the seed application: SP-16 SEEDING ' The contractor shall be responsible for the seeding of all disturbed areas to the east of Locust Street. Lincoln University will be responsible for the landscaping of the western side. ' This does not relieve the contractor from the topsoil and finish grading requirements on the western side of the street. The grass seed for the project shall be a mix of 80% Millennium Fescue, 10%Pizzazz Rye, ' and 10% Brooklawn Bluegrass, or approved alternative mix, applied at a rate of 350 Ibs/acre. Fertilizer shall be applied as specified in TS-9.3 or at a rate determined by a soil ' analysis. The area shall be covered with wheat straw at a minimum rate of 2000 Ibs/acre. The straw is to be secured to the ground by means of mechanical crimping or by the application of FINN Hydro Stick, or approved equal at a rate of 30 Ibs/acre. SP-17 3" ROLLED STONE BASE , i Payment for 3" Rolled Stone Base shall be made by square yard measured from back of , curb to back of curb, plus one (1)foot. Any additional thickness necessary under the curb and gutter section, that might be needed if the curb and gutter section is placed separately, shall be subsidiary to this item. No additional payment will be made. , SP-18 USE OF PRECAST STRUCTURES Precast stormwater inlets will not be allowed for this project. ' SP-19 CONTRACT DAYS— NOTICE TO PROCEED This is a calendar day contract containing 51 days. Days will be counted sequentially from the notice to proceed including weekends and holidays. If the contract is approved by the City Council as scheduled on June 2, 2008 the contractor can expect to receive ' the Notice to Proceed on June 9, 2008. SP-20 ALTERNATE A ' Alternate A provides for the construction of 6"thick concrete pavement in place of the asphalt pavement contained in the base bid. The first two bid items provide for a reduction of the asphalt pavement and the third provides for the concrete pavement. SP-21 SILT FENCE •. . 1 The contractor shall make use of the silt fence bid item to prevent sediment for being • transported from the site. The area most susceptible to erosion is the embankment to the ' west of the street. The contractor shall coordinate his work with the Lincoln University contractor and landscapers to minimize the time in which the slope remains unvegetated. The silt fence shall be utilized at the toe of the slope along the sidewalk edge to prevent ' sediment from being carried off the slope, or as directed by the engineer. SP-21 MEASUREMENT AND PAYMENT ' Item No. 1 - Mobilization This item shall consist of all the preparatory work and operations; including; but not limited to, those necessary for the movement of personnel, equipment, ' supplies, and incidentals to the project site, and for all other work and operations that must be performed or cost incurred prior to the beginning of work. The work provided herein will not be measured for payment, but will be considered a lump ' sum unit and will be paid at the lump sum bid price. Item No. 2 - Construction Signage and Traffic Control ' This item shall include all labor, material, equipment, and services necessary to provide the signage shown on the traffic control plan, and all barrels, cones, flaggers, and other apparatus needed to meet the requirements of the MUTCD. ' The work provided herein will not be measured for payment, but will be considered a lump sum unit and will be paid at the lump sum bid price. Item No. 3 -Silt Fence ' This item shall include all labor, material, equipment, and services necessary to install, maintain, and remove the silt fence as described in these provisions and detailed in the City of Jefferson standard drawings. The work provided herein will ' be measured by the linear foot along the fence. Payment will be made by the linear foot at the unit price. ' Item No. 4- Removals This item shall include all labor, material, equipment, and services necessary to remove the improvements on the site. The requirements for these removals are contained in the Technical Street Specifications TS-1.2 to TS-1.2.4. Excepted ' from this item are the removals associated with the removal necessary for the proposed curb and gutter and the sidewalk as it will be paid under those bid items. The work provided herein will not be measured for payment, but will be ' considered a lump sum unit and will be paid at the lump sum bid price. Item No. 5 - Earthwork ' This item shall include all labor, material, equipment, and services necessary to grade the site to the elevations shown on the plans. This work consists of but is not limited to, hauling, placement, compaction, sub grade preparation, and finish ' grading. It shall also include the necessary placement and grading of topsoil materials in areas that are to be vegetated. The work provided herein will not be measured for payment, but will be considered a lump sum unit and will be paid at ' the lump sum bid price. • Item No. 6 - Rock Excavation This item shall include all labor, material, equipment, and services necessary for the mechanical removal of rock. Rock is defined as being sandstone, limestone, chert, granite, sillstone;quartzite, slate, shale, occurring in its natural undisturbed • state, hard and unweathered or similar material in masses more than 1 1/2 yard in , volume, in ledges six(6) inches or more in thickness. The work provided herein will be measured by the cubic yard, and will be paid in a like fashion at-the unit price. ' Item No. 7—4'x 3'Type A Inlet This item shall include all labor, material, equipment, and services necessary for , the construction of a 4' x 3' Type"A" Inlet in accordance with the City of Jefferson Standard Drawings. The work provided herein will be measured per each inlet constructed, and will be paid in a like fashion at the unit price. Item No. 8—6' x 3' Type A Inlet , This item shall include all labor, material, equipment, and services necessary for the construction of a 6' x 3' Type "A" Inlet in accordance with the City of Jefferson ' Standard Drawings. The work provided herein will be measured per each inlet constructed, and will be paid in a like fashion at the unit price. Item No. 9—4' x 4'Type C Inlet ' This item shall include all labor, material, equipment, and services necessary for the construction of a 4' x 4' Type "C" Inlet in accordance with the City of Jefferson ' Standard Drawings and all necessary work to connect to the existing stormwater pipes at that location. The work provided herein will be measured per each inlet constructed, and will be paid in a like fashion at the unit price. Item No. 10—4' x 4' Junction Box- This item shall include all labor, material, equipment, and services necessary for the construction of a 4' x 4'junction box in accordance with the City of Jefferson ' Standard Drawings. The work provided herein will be measured per each junction box constructed, and will be paid in a like fashion at the unit price. . Item No. 11 - 15" Dia. RCP Class III ' This item shall include all labor, material, equipment, and services necessary for the installation of 15" Dia. RCP as shown on the Plans, and as specified in the City of Jefferson Standard Specifications and Standard Details. This shall include ' but is not limited to, trenching, bedding, haunching, backfilling with granular material, and surface repair. This item does not include any rock excavation, as it will be paid under a separate item. The work provided herein will be measured by ' the linear foot of installed pipe, and will be paid in a like fashion at the unit price. Item No. 12 - 18" Dia. RCP Class III , This item shall include all labor, material, equipment, and services necessary for the installation of 18" Dia. RCP as shown on the Plans, and as specified in the City of Jefferson Standard Specifications and Standard Details. This shall include , but is not limited to, trenching, bedding, haunching, backfilling with granular material, and surface repair. This item does not include any rock excavation, as it will be paid under a separate item. The work provided herein will be measured by the linear foot of installed pipe, and will be paid in a like fashion at the unit price. ' Item No. 13—Flowable Fill for Pipe Abandonment • i This item shall include all labor, material, equipment, and services necessary for • the abandonment of all remaining stormwater pipes not used in the new system ' by the complete filling with flowable fill. This item shall include but is not limited to, creating necessary access points to enable the complete filling of the pipe with flowable fill which shall be sand, grout,or engineer approved equal, sealing, ' capping/plugging, and surface repair. The work provided herein will be measured by the cubic yard of fill injected, and will be-paid in a like fashion at the unit price. Item No. 14—Temporary Surfacing ' This item shall include all labor, material, equipment, and services necessary for the placement and maintenance of stone-for-the-purpose of maintaining-vehicular access to the adjoining properties. The work provided herein will be measured by ' the.ton of material provided, and will be paid in a like fashion at the unit price. Item No. 15-Sub Grade Stabilization ' This item shall include all labor, material, equipment, and services necessary to identify and stabilize unsuitable soil encountered within the project limits. In a case where unsuitable material in found, the contractor, under the direction of the ' engineer shall furnish and place stone (the size of which will be determined by the engineer based on the conditions)as required to provide a stable sub-grade. Where possible, a portion of the stone shall be mixed with existing soil to create a stable sub grade. This item shall also include the removal of the unsuitable ' material and its disposal off-site. The work provided herein will be measured by the ton of stone provided based on tickets submitted to the City at the time the work is undertaken, with payment being made by the ton at the bid price. Item No. 16 - 3"Thick Rolled Stone Base • This item shall include all labor, material, equipment, and services necessary for ' the placement and compaction of a 3" lift of stone base as shown in the standard cross sections. The work provided herein will be measured by the square yard, and will be paid in a like fashion at the unit price. ' Item No. 17 -Type A Curb and Gutter This item shall include all labor, material, equipment, and services necessary for the construction of standard type A curb and gutter in accordance with the City of ' Jefferson Standard Details and specifications. The work provided herein will be measured by the linear foot at the flow line of the gutter. Payment will be made by the linear foot at the bid price. ' Item No. 18 -6" Thick PCC Residential Drive Approach _ This item shall include all labor, material, equipment, and services necessary for ' the construction of residential drive approaches as shown on the Plans and detailed in the City of Jefferson Standard Details and specifications. The work provided herein will be measured by the square yard, and will be paid in a like ' fashion at the unit price. Item No. 19-6 1 Thick PCC Residential Drive ' This item shall include all labor, material, equipment, and services necessary for the construction of 6"thick PCC driveways, as shown on the Plans and detailed • in the City of Jefferson Standard Details and specifications. The work provided herein will be measured by the square yard, and will be paid in a like fashion at r� the unit p rice. ' •Item No. 20 -8"Thick PCC Street/Commercial Drive Approach , This item shall include all labor, material, equipment, and services necessary for the construction of street and commercial drive approaches as shown on the Plans and detailed in the City of Jefferson Standard Details and specifications. ' The work provided herein will be measured by the square yard, and will be paid in a like fashion at the unit price. Item No. 21 -7" Thick PCC Street Pavement(Dunklin Street) ' This item shall include all labor, material, equipment, and services necessary for the construction of a 7"thick PCC pavement section. The pavement shall be placed as shown on the plans and shall conform to City of Jefferson Technical , Specifications. This item shall include all dowels, expansion,joints, and joint sealer as required. The work provided herein will be measured by the square yard, and will be paid in a like fashion at the unit price. ' Item No. 22—6 'h" Thick AC Base This item shall include all labor, material, equipment, and services necessary for ' the placement of the asphalt base. The pavement shall be placed as shown on the plans and shall conform to City of Jefferson Technical Specifications. The AC base shall be placed in lifts of no greater than 4". The work provided herein will ' be measured by the square yard, and will be paid in a like fashion at the unit price. Item No. 23— 1 VAC Surface BP-1 ' This item shall include all labor, material, equipment, and services necessary for ' the placement of the asphalt surface. The pavement shall be placed as shown on the plans and shall conform to City of Jefferson Technical Specifications. The ' work provided herein will be measured by the square yard, and will be paid in a like fashion at the unit price. Item No. 24 -4" Thick PCC Sidewalk ' This item shall include all labor, material, equipment, and services necessary for the construction of 4"thick portland cement concrete sidewalks as shown on the ' plans. The work shall include all sub-grade preparation and compaction, the sawing and placement of all joints, and all required expansion as specified in the City of Jefferson Standard Drawings Revised Edition 1/2006 or shown on the plans. The work provided herein will be measured by the square yard of , constructed sidewalk, with payment by the square yard at the bid price. Item No. 25 - 6" Thick PCC Sidewalk Ramps ' This item shall include all labor, material, equipment, and services necessary for the construction of 6" thick portland cement concrete sidewalk ramps as shown in the City of Jefferson Standard Details. The work shall include the sawing and ' placement of all joints and placement of expansion as specified or shown on the plans. The work provided herein will be measured by the square yard, with payment by the square yard at the bid price. ' Item No. 26 - Detectable Warning Panels • This item shall include all labor, material, equipment, and services necessary for r 1 ' the installation of the detectable warning panels as shown on the plans, and as • specified in these provisions. The work provided herein will be measured by the ' square foot, and will be paid in a like fashion at the unit price. Item No. 27 -Adjust Manhole This item shall include all labor, material, equipment; and services necessary for '. the adjustment of an existing manhole. The adjustment shall follow all specifications of TS-14.1.2. and brought to the proposed grade. The work provided herein will be measured per each structure adjusted, and will be paid in a like fashion at the bid price. Item No. 28—Seeding and Mulching ' This item shall include all labor, material, equipment, and services necessary for the seeding of the areas to be vegetated as described in these specifications. The work provided herein will be measured by the acre, and will be paid in a like fashion at the unit price. ALTERNATE A ' Item No. 30-6 1/2" Thick AC Base This item will reduce the unit price of base bid item number 22. ' Item No. 30— 1 1/2"Thick AC Surface BP-1 This item will reduce the unit price of base bid item number 23. Item No. 32 -6" PCC Pavement • This item shall include all labor, material, equipment, and services necessary for the construction of a 6"thick PCC pavement section. The pavement shall be ' placed as shown on the plans and shall conform to City of Jefferson Technical Specifications. This item shall include all dowels, expansion,joints, and joint sealer as required. The work provided herein will be measured by the square ' yard, and will be paid in a like fashion at the unit price. o-0 ' ADDENDUM NO. 1 . PROJECT NO.32095 ' LOCUST STREET ROADWAY IMPROVEMENTS MAY 2,2008 The bidder will acknowledge receipt of this Addendum and his acceptance of its conditions by signing this Addendum and including it with his bid. ' BIDDER: ' BY: TITTLE: ' 1. The pre-bid minutes by there inclusion herein are made part of the contract. ' CITY OF JEFFERSON,MISSOURI PATRICK E. SULLIVAN,P.E. DIRCTOR OF COMMUNITY DEVELOPMENT 1 c►�� Of a P ��; i John Landwehr City of Jefferson a Mayor ' • Department of Community Development Patrick E.Sullivan, P.E.; Director 320 East McCarty Street Phone: (573)634-6410 Jefferson City, Missouri 65101 -� 3 Fax: (573) 634-6562 i - May 2,2008. , Attendees and Plan Holders Locust St. Roadway Improvements, Project No.32095 ' Subject: Locust Street Roadway Improvements, Project No. 32095, Pre-Bid Minutes Dear Attendees and Plan Holders, A pre-bid conference was held in the Thomas Jefferson conference room of City Hall on Tuesday,April 1, 2008,for the above noted project. Those attending the meeting are as listed below: NAME REPRESENTING Kevin Harvey Muenks Brothers Construction Luke Hake Stockman Construction Bryant Gaines Sam Gaines Construction ' Jim Weber Lincoln University Gary Oldelehr City of Jefferson Len Bonnot City of Jefferson David Bange City of Jefferson The meeting proceeded with a general discussion of the planned project and an overview of the specifications. This letter summarizes the proceedings of that meeting and the questions received at the meeting. In addition, this memo contains,any questions received by telephone,or other means after the meeting and prior to the closure of the questions period. Below are the items that were specifically discussed. GENERAL COMMENTS: Bid Opening: Tuesday, May 6,2008 at 1:30 p.m. Contract Time: 51 calendar days ' Liquidated Damages: $500.00 a day. No questions will be allowed after 12:00 PM, Thursday, May 1,at 12:00 noon. ' Kill J:-....:..ieersonp.IiV —Citywof _— ....... _..___ _. ' FACITY-PROJECTS132095-Locust St.Improvements with Lincoln Univ\Correspondence\Pre Bid notes.doc ' 2.. ' This project will be constructed while construction is ongoing at the site of the new Lincoln University Dorm. Close • coordination the University's contractor will be necessary to ensure that the work on both sites may proceed unimpeded. PLAN REVIEW: Attention was drawn to several items in the plans. • The traffic control plan is shown on page three of the plans.The contractor may close Locust Street for the duration of the project. Dunklin Street is to remain open. Coordination will need to be made with Lincoln University to minimize the impact the street closure has on truck traffic accessing the new dorm site. ' . The water pit labeled as note one on the plans is scheduled to be relocated prior to the approval of this contract.The pit will be located immediately behind the sidewalk as opposed to the location.shown on the plans. The Contractor will be required to compact granular fill in the existing water pit vault. ' • The curbs shown on the Lincoln University Parking lots will be constructed by the University's contractor and their location on these plans are approximations good to within five feet. The schedule that we received from the University indicates that these curbs will be constructed prior the notice to proceed for this contract. ' • The contractor will be responsible for the construction on the approach into the University parking lot. The University's contractor will construct the remainder of the drive. There is a good deal of utility relocation that will need to take place for this project, most notably the relocation of the ' power and telecommunication poles along the western side of the present road. The poles cannot be relocated until the grade along the western edge of the street is cut.The contractor should begin his work in this area to facilitate the relocation process. ' • The proposed stormwater system conflicts with the estimated location of the several water lines. These lines will be relocated by others. ' SPECIFICATIONS AND CONTRACT DOCUMENT REVIEW: . . This contract is a Standard City of Jefferson Construction Contract. • Prevailing wage is required.Wage Order 14 has been included. ' . This is a calendar day contract containing 51 days. If the project is approved as scheduled, the Contractor will receive notice to proceed on June 9,2008. • Special Provisions ' o SP-14—Be aware of the need to coordinate work with the University's contractor o SP-16-The contractor is not required to seed the area to the western side of the street. QUESTION/ANSWER: (Received at the pre bid meeting and those received by telephone, or other means prior to ' 12:00 PM Thursday, May 1,2008) QUESTION: Does the University want the excess material from the site? ' ANSWER: The University will accept soil, no concrete,or other construction debris. The soil may be placed to the rear of the radio station off of Dunklin Street. ' QUESTION: Is there a lay down area for this project? ANSWER: There are several lots to the east of the project which are vacant as well as a lot containing an electric substation. The City has no owner ship of these lots. The contractor shall deal directly with the property ' owners if such a site is desired. ' City of , .. J...... ef a rs o n COMMUNfTY DEVELOPMENT "building a better community" FACITY-PROJECTS132095-Locust St.Improvements with Lincoln Univ\CorrespondenceTre Bid notes.doc 1 1 3 QUESTION: Where are the new utility poles going to be placed? ' ANSWER: The utility has indicated to us that the poles are going to be located immediately behind the curb on the west side of the street. A pole for the project has already been set and it is approximately one foot behind the proposed curb. It is our understanding that there will be five such poles along the west side of the street. ' QUESTION: When will the grading be completed for the parking lots, and how much grading will be completed for their construction? ' ANSWER: The schedule that we received for the University indicates that the parking lot curbs will be installed prior to the beginning of the street work. The University has indicated only that material which must be removed to construct the lots will be moved.The remainder will need to be moved under this contract: QUESTION: Will the contractor be responsible for the construction of the invert in inlet °B" if the pipe from inlet "A" is installed latter? ANSWER: Upon consultation with the University at a minimum a pipe stub will be available so that the inlet can be ' constructed without interruption,thus the invert is to be poured. QUESTION: Note four on the plans indicates the adjustment or relocation of a stormwater pipe, what will happen to this pipe? ANSWER: The pipe is to remain in place and the grade changed as indicated on the cross sections. The grading will partially uncover the existing boxes;however they will not be adjusted under this contract. QUESTION: Is rock anticipated in the area of the cut on the-western side of the street? ANSWER: Reports indicate that some rock was encountered in the construction of the inlets marked with note four on ' the plans.Two test pits were dug on the lower end of the project, namely at stations 18+94 and 19+38 at the back of the proposed westerly curb,to the approximate finished grade without encountering solid rock. S' 1 �R David Bange, P.E. Engineering Division Director ' City of, oil III e f e r s o n " COMMUNITY DEVELOPMENT 1U W "building a better community". ' FACITY-PROJECTS\32095-Locust St.Improvements with Lincoln Univ\Correspondence\Pre Bid notes.doc FINANCE DEPARTMENT i - PURCHASING DIVISION SUBJECT: Bid 2391 - Project No. 32095, Locust Street Improvements Community Development, Engineering, Opened May 6, 2008 BIDS RECEIVED: Stockman Construction Corp, Jefferson City, MO $ 173,578.00 Sam Gaines Construction, Inc.,New Bloomfield, MO $ 200,733.00 Concrete Engineering, LLC, Jefferson City, MO $ 220,498.00 Lehman Construction, LLC, California, MO $ 226,432.00 Don Schnieders Excavating Co., Inc.,Jefferson City,MO $ 230,963.10 Case Excavating, LLC, Jefferson City,MO $ 233,082.80 Keith Contracting,LLC, Columbia,MO $ 291,570.40 FISCAL NOTE: 3503-9900-7350-4107 • Major Road Improvements 2007-08 Budget $ 725,017.00 Expended 1,402.50 Encumbered 1,800.00 Bid No. 2391 $ 173.578.00 Balance $ 548,236.50 PAST PERFORMANCE: . This vendor has been awarded projects in the past and has completed work as specified and bid. RECOMMENDATION: Staff recommends award of the bid to Stockman Construction Corporation of Jefferson City, Missouri in the amount of$173,578.00. ATTACHMENTS - SUPPORTING DOCUMENTATION Signatur QJ Purchasin Agent Dire tor, Comm ity Development Page 1 CITY OF JEFFERSON Date:May 6,'08 BID TABULATION Bid No.2391 LOCUST STREET IMPROVEMENTS PROJECT NO.32095 ENGINEER'S ESTIMATE Stockman Construction Sam Gaines Construction Concrete Engineering LLC APPROX. UNIT UNIT UNIT UNIT ITEM NO. DESCRIPTION UNIT QUANTITY PRICE AMOUNT PRICE AMOUNT PRICE AMOUNT PRICE AMOUNT 1 Mobilization LS 1 $2,500.00 $2,500.00 $4.300.00 $4,300.00 $2,000.00 $2,000.00 $4,200.00 $4,200.00 2 Construction Signage and Traffic Control LS 1 $2,500.00 $2.500.00 $3,300.00 $3,300.00 $4,000.00 $4,000.00 $2,000.00 $2,000.00 3 Silt Fence LF 475 $3.50 $1,662.50 $2.20 $1,045.00 $5.00 $2,375.00 $2.00 $950.00 4 Removals LS 1 $8,000.00 $8,000.00 $10,000.00. $10,000.00 $17,824.00 $17,824.00 $14,500.00 $14,500.00 5 Earthwork LS 1 $10,000.00 $10,000.00 $15,500.00 $15,500.00 $10.000.00 $10,000.00 $27,000.00 $27,000.00 6 Rock Excavation CY 10 $150.00 $1,500.00 $90.00 $900.00 $175.00 $1,750.00 $150.00 $1,500.00 7 4'x 3'Type A Inlet EA 1 $2,600.00 $2,600.00 $2,000.00. .$2,000.00 $2,500.00 $2,500.00 $2,200.00 $2,200.00 8 6'x 3'Type A Inlet EA 1 $2,800.00 $2,800.00 $2,500.00 $2,500.00 13,000.00 $3,000.00 $2,300.00 $2,300.00 9 4'x 4'Type C Inlet EA 1 $3,400.00 $3,400.00 $2,900.00 $2,900.00 $3,000.00 $3,000.00 $2,600.00 $2.600.00 10 4'x 4'Junction Box EA 1 $2,200.00 $2,200.00 $2,100.00 $2,100.00 $2,500.00 $2,500.00 $2,000.00 $2,000.00 11 15"Dia.RCP Class III LF 63 $45.00 $2,835.00 $40.00 $2,520.00 $50.00 $3,150.00 $58.00 $3,654.00 12 18"Dia.RCP Class III LF 39 $50.00 $1,950.00 $46.00. $1,794.00 $60.00 $2,340.00 $90.00 $3,510.00 13 Fowable Fill for Pipe Abandonment CY 2 $350.00 $700.00 $250.00 $500.00 $200.00 $400.00 $200.00 $400.00 14 Temporary Surfacing TON 50 $20.00 $1,000.00 $21.00. $1,050.00 $15.00 $750.00 $16.00 $800.00 15 Sub Grade Stabilization TON 600 $22.00 $13,200.00 $21.00 $12,600.00 $30.00 $18,000.00 $22.00 $13.200.00 16 3"Thick Rolled Stone Base SY 2360 $4.00 $9,440.00 $4.50 $10,620.00 $3.75 $8,850.00 $5.00 $11,800.00 17 Type A Curb and Gutter LF 1120 $18.00 $20,160.00 $13.30 $14,896.00 $28.00 $31,360.00 $22.00 $24,640.00 18 6"Thick PCC Residential Drive Approach SY 20 $45.00 $900.00 $52.50 $1.050.00 $60.00 $1,200.00 $60.00 $1,200.00 19 6*Thick Residential Drive SY 19 $40.00 $760.00 $55.50 $1,054.50 $60.00 $1,140.00 $60.00 $1,140.00 20 8"Thick PCC Street/Commercial Approach SY 96 $48.00 $4,608.00 $47.50 $4,560.00 $55.00 $5,280.00 $62.00 $5,952.00 21 7"Thick PCC Street Pavement(Dunklin St.) SY 118 $45.00 $5,310.00 $50.00 $5,900.00 $55.00 $6,490.00 $60.00 $7,080.00 22 61/2"Thick AC Base SY 1847 $18.00 $33,246.00 $22.21 $41,021.87 $21.15 $39,064.05 $22.00 $40,634.00 23 1 1/2"AC Surface BP-1 SY 1847 $4.50 $8,311.50 $5.21 $9,622.87 $4.96 $9,161.12 $5.00 $9,235.00 24 4"Thick PCC Sidewalk SY 393 $35.00 $13,755.00 $32.20 $12,654.60 $45.00 $17,685.00 $36.00 $14,148.00 25 6"Thick PCC Sidewalk Ramps SY 34 $42.00 $1,428.00 $66.60 $2,264.40 $55.00 $1,870.00 $58.00 $1,972.00 26 Detectable Warning Panels SF 44 $50.00 $2,200.00 $50.00 $2,200.00 $50.00 $2,200.00 $40.00 $1,760.00 27 Adjust Sanitary Sewer Manhole EA 2 $500.00 $1,000.00 $500.00' $1,000.00 $500.00 $1,000.00 $500.00 $1,000.00 28 Seeding AC 0.1 $6,000.00 $600.00 $17,300.00 $1,730.00 $2,000.00 $200.00 $25,000.00 $2,500.00 TOTAL BASE BID $158,566.00 $171,583.24 $199,089.17 $203,875.00 %OVER/UNDER ENGINEER'S EST. 8.2%1 25.6%1 28.6% ALTERNATE A-CONCRETE PAVEMENT 30 6 1/2"Thick AC Base SY -1847 $18.00 $33,246.00 $22.21 ($41,021.87) $21.15 ($39,064.05) $22.00 ($40.634.00) 31 1 1/2"AC Surface BP-1 SY -1847 I $4.50 -$8,311.50 $5.21 ($9,622.87) $4.96 ($9,161.12) $5.00 ($9,235.00) 32 6"Thick PCC Pavement SY 1847 $32.00 $59,104.0011 $28.50 $52,639.50 $27.00 $49,869.00 $36.00 $66,492.00 TOTAL ALTERNATE A $117,546.50H $1,994.76 $1,643.83 $15,623.00 Altemate A-Accepted $17,546.50 $1,994.76 $1,643.83 $16,623.00 TOTAL CONTRACT WITH ACCEPTED ALTERNATES $176,112.50 $173,578.00 $200,733.00 $220,498.00 %OVER/UNDER ENGINEER'S EST. -1.5% 12.3% 20.1% , Page 2 CITY OF JEFFERSON Date:May 6,'08 BID TABULATION Bid No.2391 LOCUST STREET IMPROVEMENTS PROJECT NO.32095 Lehman Construction Don Schnieders Excavating Case Excavating LLC Keith Contracting APPROX. ITEM NO. DESCRIPTION UNIT QUANTffY UNIT PRICE AMOUNT UNIT PRICE AMOUNT UNIT PRICE AMOUNT UNIT PRICE AMOUNT i Mobilization LS 1 $10,000.00 $10,000.00 $4,000.00 $4,000.00 $4,100.00 $4,100.00 $13,000.00 $13,000.00. 2 Construction Signage and Traffic Control LS 1 $4,400.00 $4,400.00 $4,200.00. $4,200.00 $3,150.00 $3,150.00 $3,100.00 $3,100.00 3 Silt Fence LF 475 $3.00 $1,425.00 $2.00 $950.00 $1.60 $760.00 $2.00 $950.00 4 Removals LS 1 $9,280.00 $9,280.00 $18,970.00 $18,970.00 $13,500.00 $13,500.00 $17,555.00 $17,555.00 5 Earthwork LS 1 $17,500.00 $17,500.00 $26,500.00 $26,500.00 $24,750.00 $24,750.00 $22,750.00 $22,750.00 6 Rock Excavation CY 10 $175.00 $1,750.00 $250.00 $2,500.00 $100.10 $1,001.00 $170.00 $1,700.00 7 4'x 3'Type A Inlet EA 1 $2,890.00 $2,890.00 $2,000.00 $2,000.00 $2,385.00 $2,385.00 $3,050.00 $3,050.00 8 6'x 3'Type A Inlet EA 1 $3,685.00 $3,685.00 $2,500.00 $2,500.00 $2,632.50 $2,632.50 $3,215.00 $3,215.00 9 4'x 4'Type C Inlet EA 1 $3,888.00 $3,888.00 $2,400.00 $2,400.00 $2,497.50 $2,497.50 $3,590.00 $3,590.00 10 4'x 4'Junction Box EA 1 $2,590.00 $2,590.00 $2,000.00 $2,000.00 $2,036.30 $2,036.30 $2,865.00 $2,865.00 11 15"Dia.RCP Class III LF 63 $75.00 $4,725.00 $63.00 $3,969.00 $56.30 $3,546.90 $73.50 $4,630.50 12 18"Dia.RCP Class III LF 39 $88.00 $3,432.00 $65.00 $2,535.00 $86.70 $3.381.30 $81.50 $3,178.50 13 Fowable Fill for Pipe Abandonment CY 2 $375.00 $750.00 $320.00 $640.00 $506.30 $1,012.60 $245.00 $490.00 14 Temporary Surfacing TON 50 $14.50 $725.00 $20.00 $1,000.00 $33.80 $1,690.00 $22.50 $1,125.00 15 Sub Grade Stabilization TON 600 $22.50 $13,500.00 $20.00 $12,000.00 $33.80 $20,280.00 $21.50 $12,900.00 16 3"Thick Rolled Stone Base SY -2360 $4.80 $11,328.00 $5.25 $12,390.00 $5.60 $13,216.00 $6.35 $14,986.00 17 Type A Curb and Gutter LF 1120 $23.00 $25,760.00 $25.90 $29,008.00 $15.90 $17,808.00 $21.00 $23,520.00 18 6"Thick PCC Residential Drive Approach SY 20 $80.00 $1,600.00 $67.80 $1,356.00 $83.80 $1,676.00 $74.00 $1,480.00 19 6"Thick Residential Drive SY 19 $100.00 $1,900.00 $67.80 $1,288.20 $90.60 $1,721.40 $74.00 $1,406.00 20 8"Thick PCC Street/Commercial Approach SY 96 $70.00 $6,720.00 $75.00 $7,200.00 $133.00 $12,768.00 $74.00 $7,104.00 21 7"Thick PCC Street Pavement(Dunklin St.) SY 118 $69.00 $8,142.00 $71.55 $8,442.90 $120.10 $14,171.80 $68.00 $8.024.00 22 6 1/2"Thick AC Base SY 1847 $21.50 $39,710.50 $23.25 $42,942.75 $23.80 $43,958.60 $23.75 $43,866.25 23 1 1/2"AC Surface BP-1 SY 1847 $5.00 $9,235.00 $5.50 $10,158.50 $5.60 $10,343.20 $5.55 $10.250.85 24 4"Thick PCC Sidewalk SY 393 $46.50 $18,274.50 $33.00 $12,969.00 $39.50 $15,523.50 $42.00 $16,506.00 25 6"Thick PCC Sidewalk Ramps SY 34 $80.00 $2,720.00 $75.00 $2,550.00 $54.00 $1,836.00 $135.00 $4,590.00 26 Detectable Warning Panels SF 44 $160.00 $7,040.00 $50.00 $2,200.00 $56.30 $2,477.20 $19.10 $840.40 27 Adjust Sanitary Sewer Manhole EA 2 $590.00 $1,180.00 $1,000.00 $2,000.00 $719.30 $1,438.60 $165.00 $330.00 28 Seeding AC 0.1 $12,000.00 $1,200.00 $7,500.00 $750.00 $25,875.00 $2,587.50 $4,770.00 $477.00 TOTAL BASE BID $215,350.00 $219,419.35 $226,248.90 $227,479.50 %OVERIUNDER ENGINEER'S EST. 35.8% 38.4% 42.7% 43.5% ALTERNATE A-CONCRETE PAVEMENT 30 61/2"Thick AC Base SY -1847 $22.50 ($41,557.50) $23.25 ($42,942.75) $23.80 ($43,958.60) $23.75 ($43,866.25) 31 1 1/2"AC Surface BP-1 SY -1847 $5.50 ($10,158.50) $5.50 ($10.158.50) $5.60 ($10,343.20) $5.55 ($10,250.85) 32 6"Thick PCC Pavement SY 1847 $34.00 $62,798.00 $35.00 $64,645.00 $33.10 $61,135.70 $64.00 $118,208.00 TOTAL ALTERNATE A $11,082.00 $11,543.75 $6,833.90 $64,090.90 Alternate A-Accepted $11,082.00 $11,543.75 $6,833.90 $64,090.90 TOTAL CONTRACT WITH ACCEPTED ALTERNATES $226,432.00 $230,963.10 $233,082.80 $291,570.40 %OVERIUNDER ENGINEER'S EST. 22.2% 23.7% 24.4% 39.6%